Sol_140L6224R0005_Amd_0002.pdf

(x)

140L6224R0005 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

LYA

CHEYENNE WY 82009

5353 YELLOWSTONE RD.

BLM WY-STATE OFC BUS MGMT BR(WY951)

07/08/20240002

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

07/08/2024

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

BLM-WY Rawlins Vault Pumping- This is a new contract for base year plus four option years for vault pumping at the Rawlins Field Office Recreation Sites. See attached statement of work, wage determinations, map, and bid schedule.

1. Revising 52.212-2 Evaluation clause to incorporate the evaluation factors to ensure responsive quotes received.

52-212-2 Evaluation - Commercial Products and Commercial Services. (NOV 2021)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Antoinette Nelson

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140L6224R0005/0002 evaluate offers

Best Value with Tradeoffs using the following factors: Technical Approach and Price Evaluation.

Technical Approach:

(a) Technical Approach. Respondent shall describe a realistic plan, to include the means

(labor, equipment, and materials) and methods

(plan of work), and logical sequencing of activities (including interdependencies of activities) necessary to successfully complete the work within the required performance period.

The plan shall list the specific equipment availability, crew(s) (size and composition) proposed to work concurrently, any other available resources, and daily production rate required.

(b) Schedule and Resource Management.

Respondent shall submit a schedule identifying the milestones and critical path to successfully completing this work in addition to a list of available equipment and crew(s) (to include the size and composition of the crew) that will be used to perform this work. Respondent shall also address how it intends to meet the contract completion date if there are project delays.

(c) Quality and Safety Management. Respondent shall provide a narrative on the methods it intends for providing the contractor quality control and safety management required on this contract. The narrative shall include how the

Respondent will manage decision making on quality issues when there are schedule and/or cost impacts to those decisions, manage subcontractor quality control (if subcontracting is contemplated), identify safety goals, identify any potential high risks on this project and how you intend to mitigate the potential risks, and proposed staffing for quality control personnel and safety manager.

Price:

Respondent shall submit completed Standard Form

(SF) 1449 and Price Schedule.

1. Quality Control Plan (40 points)

2. Past Performance (20 points)

3. Contingency Plan (20 points)

4. Price Evaluation (20 points) Technical and past performance, when combined, are approximately more (Contracting Officer state, in accordance with FAR 15.304, the relative importance of all other evaluation

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140L6224R0005/0002 factors, when combined, when compared to price.)

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party.

Before the offer's specified expiration time, the

Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

Period of Performance: 08/02/2024 to 10/31/2024

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110