B09_Amendment_0002_140L4324R0006_COsigned030724_0002.pdf

(x)

140L4324R0006 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

LHA

PORTLAND OR 97204

1220 SW 3rd Avenue, 12th Floor

BLM OR-ST OFC PROC MGMT BR(OR952)

02/12/20240002

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

02/12/2024

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this amendment is to:

Change the requirement for Relevant Experience in section L.2.1.1 from 2 projects to 1 project; and, to correct a typo in the solicitation # that appears on page 42 (section L.2.2.4,). To effect these changes, the solicitation is amended as follows:

1.Remove and replace the solicitation pages 41 and 42 of 93 with the attached pages 41 and 42.

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Anita Macauley

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

GAOA WEAVER CREEK 2 CULVERT REPLACEMENT SOLICITATION NO. 140L4324R0006

BLM ROSEBURG DISTRICT Page 41 of 93

SECTION L � INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

L.1.0 GENERAL. This is a Request for Proposal (RFP). An award notice will be posted on the Contract Opportunities website located at www.sam.gov upon award. The award notice will include the awardee�s name and address and total award amount.

L.1.1 Electronic Response. Electronic quotation will not be accepted through: www.fedconnect.net. The quotation may be electronically submitted via email to jmenguit@blmgov and amacauley@blm.gov by

3/13/24, 2 PM PT.

L.1.2 Requests for Information. Questions regarding this solicitation must be submitted in writing to jmenguit@blmgov and amacauley@blm.gov by 2/26/24, 2 PM PT.

L.2.0 PROPOSAL INSTRUCTIONS. The proposal shall be submitted in two individual and separate parts consisting of (1) a technical proposal and (2) a price proposal.

L.2.1 FORMAT AND CONTENT OF TECHNICAL PROPOSAL. There are one (1) non-price/cost evaluation factors. The technical proposal shall be organized by evaluation factor and sequenced in the order the in paragraph L.2.0 and shall not contain any price information. The offeror shall address the following factors in sufficient narrative and qualitative detail to be evaluated.

L.2.1.1 Evaluation Factor 1, Relevant Experience. The Respondent shall demonstrate their specialized and relevant experience in the removal and installation of major culverts including; construction and maintenance of diversion during construction; construction of stream simulation materials; construction of aggregate subbase; and rip rap armoring of culvert embankment. Projects shall include at least two (2) one (1) project similar in scope and magnitude of this contract that were completed within six (6) years of the solicitation closing date. Experience information shall include:

a. Customer/contracting agency

b. Contract number

c. Contract/Project title with location

d. Identify whether experience was as a Prime

e. Award date

f. Initial award amount

g. Award amount at contract completion

h. Contract completion date

i. Actual completion date

j. Description of project (include photos if possible)

k. Describe relevant experience and any unique conditions and/or challenges

L.2.2 FORMAT AND CONTENT OF PRICE PROPOSAL

L.2.2.1 Submit the completed Standard Form 1442 and all acknowledged amendments, if any.

L.2.2.2 Evaluation Factor, Price. The Respondent shall remit a completed price schedule (Section B). The Respondent shall enter unit price and extended total for each item listed in Section B. The price shall include all necessary supervision, management, labor, transportation, equipment, materials, any other direct incidental costs, overhead and profit, unless the cost is identified as a separately priced contract line item.

L.2.2.3 The Respondent shall complete and submit all applicable Representations, Certifications and Other Statements of Offerors. In accordance with FAR 4.1201, representations and certifications shall be submitted to the System for Award Management (www.sam.gov) and updated at least annually to ensure they are kept current, accurate, and complete.

GAOA WEAVER CREEK 2 CULVERT REPLACEMENT SOLICITATION NO. 140L4324R0006

BLM ROSEBURG DISTRICT Page 42 of 93

L.2.2.4 The Offeror shall submit an executed Bid Guarantee in accordance with clause 52.228-1. When a Bid Guarantee is covered by an individual surety, the Offeror shall mail Standard Form 28 Affidavit of Individual Surety in original, wet signature form to:

Bureau of Land Management Oregon State Office ATTN: Branch of Procurement Management [Solicitation no. 140L4323R0004 140L4324R0006] P.O. Box 2965 Portland, OR 97208

Where authorized, bonds covered by United States bonds or notes, certified cashier�s checks, bank drafts or money orders, mail to the following address:

Bureau of Land Management Oregon State Office ATTN: CBS Lead [Solicitation no. 140L4323R0004 140L4324R0006] P.O. Box 2965 Portland, OR 97208

L.2.2.5 If the Offeror identifies an �equal� item in lieu of a brand name item specified, the Offeror shall furnish the required information pursuant to provision 52.211-6 Brand Name or Equal with the proposal, in order to be considered for award. The Government is not responsible for locating or obtaining any information not identified in the proposal.

The following provisions are incorporated by reference:

Provision Title Date

52.204-7 SYSTEM FOR AWARD MANAGEMENT OCT 2018

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE APR 1991

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY APR 1991

52.215-1 INSTRUCTIONS TO OFFERORS � COMPETITIVE ACQUISITION NOV 2021

The following provisions are provided in full text:

52.216-1 � TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed-price type of contract resulting from this solicitation.

(End of provision)

52.222-5 � CONSTRUCTION WAGE RATE REQUIREMENTS�SECONDARY SITE OF THE WORK (MAY

2014)

(a)

(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)