Sol_140F0619R0014.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040434661

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BOULEVARD

LAKEWOOD CO 80228-1807

F06

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BLVD.

LAKEWOOD, CO 80228-1807

Ryan Cope 303-236-4349

18-034 x 04/18/2019

140F0619R0014

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

REPLACE FISHING PIER AT TEWAUKON NATIONAL WILDLIFE REFUGE

NAICS 237990 - OTHER HEAVY AND CIVIL ENGINEERING CONSTRUCTION

PROJECT MAGNITUDE: BETWEEN $100,000 AND $250,000

SET-ASIDE: TOTAL SMALL BUSINESS

ATTACHMENTS:

1. SPECIFICATIONS, SEPTEMBER 2018, 53 PAGES

2. DRAWINGS, AUGUST 2018, 4 PAGES

3. PROJECT SUBMITTAL LIST, 1 PAGE

5. WAGE DETERMINATION - ND190007, 5 PAGES

WORK UNDER THIS CONTRACT:

The contractor shall furnish all material, equipment, and labor to construct and install a grated rolling fishing pier on Lake Tewaukon at the Tewaukon National

Wildlife Refuge in North Dakota. The contractor will be required to remove the existing rolling pier and transport the pier approximately 100 feet away or far

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 60 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR 52.211-10

05/17/2019

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BOULEVARD

LAKEWOOD CO 80228-1807

F06

Ryan Cope

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 38

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140F0619R0014 enough not to become damaged during construction.

The new rolling fishing pier shall contain a metal walkway, handrail system, gangway connecting to the existing concrete pad, wheel system, floating system, and appurtenances in accordance with the attached specifications and drawings.

LOCATION AND INSPECTION OF THE SITE:

The project location is at the Tewaukon National

Wildlife Refuge. The address is 9754 143 1/2

Avenue SE, Cayuga, ND 58013. Prospective bidders must contact the On-site Inspector, Kent

Sundseth, at 701-724-3598 ext. 2 or kent_sundseth@fws.gov to arrange for a site visit. Failure of the contractor to ascertain the nature, location, and conditions which affect the work will not relieve the contractor from the responsibility for successfully performing the work without additional expense to the

Government. All questions regarding the subject requirement shall be submitted no later than 1500

MT on May 2, 2019 in writing via email to the

Contracting Officer at ryan_cope@fws.gov. Please include the solicitation number, company name, address, telephone number, and contact name on any email correspondence.

PROSPECTIVE OFFERORS MUST BE REGISTERED WITH THE

SYSTEM OF AWARD MANAGEMENT AT:

http://www.sam.gov/portal/public/SAM

Legacy Doc #: FWS

Delivery: 60 Days After Notice to Proceed

Delivery Location Code: 0008350176

FWS TEWAUKON NWR

9754 143-1/2 AVENUE SE

CAYUGA ND 58013-9764 US

Period of Performance: 06/03/2019 to 08/02/2019

00010 REPLACE FISHING PIER AT TEWAUKON NATIONAL

WILDLIFE REFUGE

The contractor shall furnish all material, equipment, and labor to construct and install a grated rolling fishing pier on Lake Tewaukon at

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 38

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140F0619R0014 the Tewaukon National Wildlife Refuge in North

Dakota. The contractor will be required to remove the existing rolling pier and transport the pier approximately 100 feet away or far enough not to become damaged during construction. The new rolling fishing pier shall contain a metal walkway, handrail system, gangway connecting to the existing concrete pad, wheel system, floating system, and appurtenances in accordance with the attached specifications and drawings.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Solicitation # 140F0619R0014

Document Title

REPLACE FISHING PIER AT TEWAUKON NATIONAL WILDLIFE REFUGE

TABLE OF CONTENTS

A - Solicitation/Contract Form

B - Bid Schedule

C - Description/Specifications

E - Inspection and Acceptance

F - Deliveries or Performance

G - Contract Administration Data

H - Special Contract Requirements

I - Contract Clauses

J - List of Documents, Exhibits and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

L - Instructions, Conditions, and Notices to Bidders

M - Evaluation Factors for Award

Document Title

A - Solicitation/Contract Form Pages 1-3, (See SF 1442)

52.211-12 Liquidated Damages – Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $227.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.225-9 Buy American - Construction Materials. (MAY 2014)

(a) Definitions. As used in this clause-

Commercially available off-the-shelf (COTS) item-

(1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Document Title

Domestic construction material means-

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if-

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which no availability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a) (2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b) (2) and (b) (3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b) (2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b) (3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

Document Title

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute or Balance of Payments Program.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of Measure Quantity Price (dollars)*

Item 1:

Foreign construction material

Domestic construction material Item 2:

Foreign construction material Domestic construction material

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

52.225-10 Notice of Buy American Requirement - Construction Materials. (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the

Document Title requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b) (2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or (ii) May be accepted if revised during negotiations.

(End of provision)

1452.204-70 Release of Claims. (JUL 1996)

1452.215-70 Examination of Records by the Department of the Interior. (APR 1984)

1452.215-71 Use and Disclosure of Proposal Information-Department of the Interior. (APR 1984)

1452.236-70 Prohibition Against Use of Lead-based Paint. (JUL 1996)

1452.228-70 Liability Insurance. (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$300,000 each person* $1,000,000 each occurrence* $150,000 property damage*

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

Document Title

REPLACE FISHING PIER AT TEWAUKON NATIONAL WILDLIFE REFUGE

B – Bid Schedule

A. GENERAL CONDITIONS:

QTY UNIT UNIT COST TOTAL COST

Division 1: General Requirements

1. Mobilization/Demobilization, Bonding, 1 LS __________ __________ Overhead & Profit

Division 1 Total: __________ Division 35: Rolling Fishing Pier

1. Walkway including all items outlined in the specifications and drawings, support system, hinges, and all appurtenances to complete the work. 432 SF __________ __________

2. Gangway including all items outlined in the specifications and drawings, support system, hinges, and all appurtenances to complete the work. 1 LS __________ __________

3. Floating material including all items outlined in The specifications and drawings, support system, EPS, and all appurtenances to complete the work. 1 LS __________ __________

4. Wheel system including all items outlined in the specifications and drawings, support system, and all appurtenances to complete the work. 1 LS __________ ___________

5. Handrail and guardrail including all items outlined in the specifications and drawings, support system, and all appurtenances to complete the work. 1 LS __________ __________

6. Handrail 40 CPVC through bunkhouse wall including all items outlined in the specifications and drawings and all appurtenances to complete the work. 120 LF __________ __________

Division 35 Total: __________

Total All Divisions: _________________

Document Title

C- Description/Specifications

SEE ATTACHED SPECIFICATIONS AND DRAWINGS

E - Inspection and Acceptance

52.246-12 -- Inspection of Construction. (Aug. 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not --

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may --

Document Title

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of Clause)

F - Deliveries or Performance

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 60 Calendar days. The time stated for completion shall include final cleanup of the premises.

G - Contract Administration Data

DOI ELECTRONIC INVOICING Electronic Invoicing and Payment

Requirements – Invoice Processing Platform (IPP). (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP). "Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause. Additionally, prior to submission in IPP, provide a draft invoice for review by the Contracting Officers Representative and the Contracting Officer. IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP Invoice; SUBMIT A PAPER COPY OF YOUR INVOICE; LINE ITEMS MUST MATCH THE

CONTRACT.

https://www.ipp.gov/

Document Title

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131. If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Template)

Contracting Officer (CO) responsible for this contract:

Ryan Cope U.S. Fish and Wildlife Service Contracting and General Services PO Box 25486, MS 60181 Denver, CO 80225-0007 Telephone #: 303-236-4349 E-mail: ryan_cope@fws.gov

Engineering Project Manager is:

Michael Wandersee U.S. Fish and Wildlife Service Division of Engineering 134 Union Blvd.

Lakewood, CO 80228 Telephone #: 303-236-4479 E-mail: michael_wandersee@fws.gov

On-site Inspector:

Kent Sundseth U.S. Fish and Wildlife Service Tewaukon National Wildlife Refuge 9754 143 ½ Avenue SE Cayuga, ND 58013 Telephone #: 701-724-3598x 111 E-mail: kent_sundseth@fws.gov

Only a duly authorized Contracting Officer may change or modify the terms of this contract. All such actions must be formalized by a proper contractual document executed by the Contracting Officer.

All correspondence and submittals pertaining to the contract MUST be addressed to the Contracting Officer mailto:ippgroup@bos.frb.org mailto:ryan_cope@fws.gov mailto:michael_wandersee@fws.gov

Document Title

H - Special Contract Requirements

1452.201-70 AUTHORITIES AND DELEGATIONS. (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor.

Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.

The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph

(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

I - Contract Clauses

52.204-7 System for Award Management. (OCT 2018)

(a) Definitions. As used in this provision—

“Electronic Funds Transfer (EFT) indicator” means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the

Document Title same entity.

“Registered in the System for Award Management (SAM)” means that—

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM;

(2) The offeror has completed the Core, Assertions, and Representations and Certification, and Points of contact sections of the registration in the SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process.

(4) The Government has marked the record “Active”.

“Unique entity identifier” means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)

(1) An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror’s name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

http://www.sam.gov/

Document Title

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) Processing time should be taken into consideration when registering. Offerors who are not registered in SAM should consider applying for registration immediately upon receipt of this solicitation. See https://www.sam.gov for information on registration.

(End of Provision)

Alternate I (Oct 2018). As prescribed in 4.1105(a) (2), substitute the following paragraph (b) (1) for paragraph

(b) (1) of the basic provision:

(b)

(1) An Offeror is required to be registered in SAM as soon as possible. If registration is not possible when submitting an offer or quotation, the awardee shall be registered in SAM in accordance with the requirements of clause 52.204-13, System for Award Management Maintenance.

52.204-13 System for Award Management Maintenance. (OCT 2018)

(a) Definition. As used in this clause--

“Electronic Funds Transfer (EFT) indicator” means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

“Registered in the System for Award Management (SAM)” means that—

(1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM;

(2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required https://www.sam.gov/ http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/04.htm#P629_77532

Document Title to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record “Active”.

“System for Award Management (SAM)” means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes—

(1) Data collected from prospective Federal awardees required for the conduct of business with the Government;

(2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12; and

(3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits.

“Unique entity identifier” means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b) If the solicitation for this contract contained the provision 52.204-7 with its Alternate I, and the Contractor was unable to register prior to award, the Contractor shall be registered in SAM within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first.

(c) The Contractor shall maintain registration in SAM during contract performance and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement. The Contractor is responsible for the currency, accuracy and completeness of the data within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in SAM after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in SAM to ensure it is current, accurate and complete.

Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(d)

(1)

(i) If a Contractor has legally changed its business name or ``doing business as'' name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to--

(A) Change the name in the SAM;

(B) Comply with the requirements of subpart 42.12 of the FAR; and

Document Title

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (d)(1)(i) of this clause, or fails to perform the agreement at paragraph (d)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims). Assignees shall be separately registered in SAM. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the EFT clause of this contract.

(3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished.

(e) Contractors may obtain additional information on registration and annual confirmation requirements at https://www.sam.gov.

52.215-1 Instructions to Offerors - Competitive Acquisition. (JAN 2017)

52.216-1 Type of Contract. (APR 1984)

The Government contemplates award of a FIRM FIXED PRICE contract resulting from this solicitation.

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (Feb 1999)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade

0.7% 6.9%

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the https://www.sam.gov/

Document Title

Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor’s compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled “Affirmative Action Compliance Requirements for Construction,’’ and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.

The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer’s identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is Cayuga, Sargent County, North Dakota.

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (MAY 2014)

(a)

(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222- 6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)

(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

(End of Provision) http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/52_220.htm#P63_8740 http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/fardfars/far/52_220.htm#P63_8740

Document Title

52.223-1 Biobased Product Certification. (MAY 2012)

52.223-4 Recovered Material Certification. (MAY 2008)

52.233-2 Service of Protest. (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Ryan Cope, 134 Union Blvd Lakewood CO 80228.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

DOI AGENCY PROTESTS Agency Protests

(a) Interested parties may request an independent review at a level above the Contracting Officer of protests filed directly with the agency. This review is available as an alternative to consideration of the protest by the Contracting Officer or as an appeal of the Contracting Officer's response to the protest. An interested party may:

(1) Protest to the Contracting Officer;

(2) Protest directly to the Bureau Procurement Chief without first protesting to the Contracting Officer; or

(3) Appeal a contracting officer’s decision to the Bureau Procurement Chief.

(b) Requests for Bureau Procurement Chief review should be addressed to:

Kristin Young, Bureau Procurement Chief U.S. Fish and Wildlife Service 911 N.E. 11th Avenue East Federal Complex Portland, OR 97232-4181

(c) Requesting independent agency review will not extend the Government Accountability Offices (GAO) timeliness requirements. Any subsequent protest to the GAO must be filed within ten days of knowledge of initial adverse agency action (see 4 CFR 21.2(a) (3).)

(End of Clause)

52.222-55 Minimum Wages Under Executive Order 13658. (DEC 2015)

(a) Definitions. As used in this clause– “United States” means the 50 states and the District of Columbia.

“Worker” –

(1) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 13658, and—

(i) Whose wages under such contract are governed by the Fair Labor Standards Act (29 U.S.C.

chapter 8), the Service Contract Labor Standards statute (41 U.S.C. chapter 67), or the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV);

(ii) Other than individuals employed in a bona fide executive, administrative, or professional http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/

Document Title

(iii) capacity, as those terms are defined in 29 CFR part 541; and

(iv) Regardless of the contractual relationship alleged to exist between the individual and the employer.

(2) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).

(3) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor’s Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.

(b) Executive Order Minimum wage rate.

(1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $10.10 per hour beginning January 1, 2015.

(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2016, and annually thereafter, to meet the applicable annual E.O. minimum wage.