1305M324B0001 SF1447 Amendment 3 (5.13.2024).pdf

SOLICITATION/CONTRACT 1. This Contract is a Rated Order under the Defense Priorities and

5. SOLICITATION TYPE2. CONTRACT NUMBER 4. SOLICITATION NUMBER

PAGE OF PAGES

7. ISSUED BY CODE 8. THIS ACQUISITION IS

BIDDER/OFFEROR TO COMPLETE

RATING

Allocations System (DPAS) - Code of Federal Regulations - at 15 CFR 700

3. AWARD/

EFFECTIVE DATE ISSUE DATE

6. SOLICITATION

UNRESTRICTED OR SET ASIDE:

SMALL BUSINESS

SIZE STANDARD:

9. (AGENCY USE)

NO COLLECT CALLS

10. ITEMS TO BE PURCHASED (BRIEF DESCRIPTION)

SUPPLIES SERVICES

11. IF OFFER IS ACCEPTED BY THE GOVERNMENT WITHIN

CALENDAR DAYS (60 CALENDAR DAYS UNLESS OFFEROR INSERTS A DIFFERENT

PERIOD) FROM THE DATE SET FORTH IN BLOCK 9 ABOVE, THE CONTRACTOR

AGREES TO HOLD ITS OFFERED PRICES FIRM FOR THE ITEMS SOLICITED

HEREIN AND TO ACCEPT ANY RESULTING CONTRACT SUBJECT TO THE TERMS

AND CONDITIONS STATED HEREIN.

CODE 12. ADMINISTERED BY

13. CONTRACTOR FACILITY 14. PAYMENT WILL BE MADE BY CODE CODE

OFFEROR CODE

TELEPHONE NUMBER UNIQUE

ENTITY

CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK:

15. PROMPT PAYMENT DISCOUNT 16. AUTHORITY FOR USING OTHER

THAN FULL AND OPEN COMPETITION

UNDER THE UNITED STATES CODE AT

10 U.S.C. 3204(a) 41 U.S.C. 253

NEGOTIATED SEALED BIDS

1 50

04/15/2024

WAD-NMFS-Boulder

325 BROADWAY, SOU6

BOULDER CO 80305

WAD-NMFS-Boulder

325 BROADWAY, SOU6

BOULDER CO 80305

WAD-NMFS-B

100.00

237990

% FOR:X

x x

WAD-NMFS-B

Construction Srvcs: Fish River & Weeks Bay Marsh Restoration

$45

1305M324B0001

SYSTEM (NAICS):

HISTORICALLY

UNDERUTILIZED

BUSINESS ZONE

X

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS

8(A)

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOSB PROGRAM

ECONOMICALLY DISADVANTAGED WOMEN-OWNED

(HUBZone) SMALL BUSINESS

SMALL BUSINESS (EDWOSB)

NORTH AMERICAN INDUSTRY CLASSIFICATION

FOR PROPOSALFOR BID

(IFB) INVITATION (RFP) REQUEST

BLOCKS 11, 13, 15, 21, 22, & 27

17.

ITEM NUMBER

18.

SCHEDULE OF SUPPLIES/SERVICES

19.

QUANTITY

20.

UNIT

21.

UNIT PRICE

22.

AMOUNT

27. SIGNATURE OF OFFEROR/CONTACTOR 28. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

NAME AND TITLE OF SIGNER (TYPE OR PRINT) DATE SIGNED NAME OF CONTRACTING OFFICER DATE SIGNED

25. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET

FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY CONTINUATION SHEETS

SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

26. AWARD OF CONTRACT: YOUR OFFER ON SOLICITATION

NUMBER SHOWN IN BLOCK 4 INCLUDING ANY ADDITIONS

OR CHANGES WHICH ARE SET FORTH HEREIN, IS

ACCEPTED AS TO ITEMS:

23. ACCOUNTING AND APPROPRIATION DATA 24. TOTAL AWARD AMOUNT

(FOR GOVERNMENT USE ONLY)

GRACE PARKER

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION NOT USABLE

STANDARD FORM 1447 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214(d)

COPIES TO

TYPE OR PRINT NAME AND TITLE OF SIGNER

SIGNATURENAME AND ADDRESS OF FIRM (Include ZIP Code)

WE DO NOT, DESIRE TO BE RETAINED ON THE MAILING LIST FOR FUTURE PROCUREMENT OF THE TYPE OF ITEMS INVOLVEDWE DO

DO NOT REGULARLY MANUFACTURE OR SELL THE TYPE OF ITEMS INVOLVED

CANNOT MEET DELIVERY REQUIREMENT

OTHER (Specify)

UNABLE TO IDENTIFY THE ITEM(S)

CANNOT COMPLY WITH SPECIFICATIONS

PAGE

NO RESPONSE FOR REASONS CHECKED

50 2 OF

DATE AND LOCAL TIME

AFFIX

STAMP

HERE

TO:

FROM:

SOLICITATION NO.

WAD-NMFS-Boulder

325 BROADWAY, SOU6

BOULDER CO 80305

WAD-NMFS-B

1305M324B0001

STANDARD FORM 1447 (REV. 12/2022) BACK

1305M324B0001 BASE

Section II - Supplies or Services and Price/Costs Section III - Description/Specifications Section IV - Packaging and Marking Section V - Inspection and Acceptance Section VI - Deliveries or Performance Section VII - Contract Administration Section IX - Contract Clauses Section X - List of Attachments Section XI - Representations, Certifications, and Other Statements of Bidders

Representations, Certifications, and Other Statements of Bidders Section XII - Instructions, Conditions, and Notices Section XIII - Basis of Award

Section II - Supplies or Services and Price/Costs

CLIN List

Item Number Description Quantity Unit Unit Price Amount

CONSTRUCTION SERVICES: Fish River and Weeks Bay Marsh Restoration

PERIOD OF PERFORMANCE: 180 calendar days after issuance of Notice to Proceed

(NTP)

Award Type: Firm-fixed-price Requisition No: 143013-24-0022

Section III - Description/Specifications

The Specifications for the Fish River and Weeks Bay Marsh Restoration project are provided in the following four (4) attachments:

B.1 General Conditions B.2 Technical Provisions B.3 Environmental Protection Provisions B.4 Drawings

General Information: The Government intends to award a single Firm-Fixed-Price contract from this solicitation. This procurement is 100% set-aside for HUBZone small business concerns in accordance with FAR 19.1305. In accordance with the Gulf Coast Ecosystem Restoration Council-Interagency Agreement, which will govern performance under the resultant contract, to be eligible for award, the bidder must be a firm residing, headquartered or principally engaged as a business in the State of Alabama, or a Gulf Coast state. Gulf Coast State means any of the States of Alabama, Florida, Louisiana, Mississippi, and Texas.

In accordance with FAR 36.204: the estimated price is between $1.1M to 2M.

Instructions to Bidders: To be eligible for award, bidders must submit the following:

1. Completed Section I of the SF1447 with blocks 13 and 27 filled in. Note that pricing information need not be submitted in Section I (e.g., blocks 18 through 22) - pricing information shall be submitted via Attachment A - Bid Schedule.

2. Completed Attachment A- Bid Schedule.

3. Verification that the firm will perform services representing at least twenty percent (20%) of the total labor costs under the contract with its own employees.

4. Verification that the bidder is a firm residing, headquartered or principally engaged as a business in the State of Alabama, or a Gulf Coast state.

5. List of proposed equipment that will be used on the project. The awardee will be required to perform with the same or technically equivalent equipment post-award.

6. Completed Bond Forms: Attachment D SF24-23a Bid Bond Form, Attachment E - SF25-23a Performance Bond Form, and attachment F, SF25A-23a Payment Bond Form.

7. Completed solicitation Section XI.

Failure to complete and return all required submissions from this solicitation could render the bid non-responsive.

Electronic Submission of Bids: For this IFB Solicitation, NOAA is requesting all electronic bids be submitted via email with the Solicitation Number 1305M324B0001 in the subject line to the Contracting Officer and Contract Specialist: Contracting Officer – Grace Parker, Grace.Parker@noaa.gov; Contract Specialist – Nick Brown, Nicholas.G.Brown@noaa.gov.

The Contracting Officer and Contract Specialist will begin downloading bids one hour before the scheduled bid opening time. Bids are due by 10:00 AM Eastern on Monday, 20 May 2024, with the Bid Opening currently scheduled for Monday, 20 May 2024 at 11:00 AM Eastern.

Audio Teleconference Bid Opening Information: Bid Opening will be held on Monday, 20 May 2024 at

11:00 AM Eastern. The link and number are also provided below:

Google Meet: meet.google.com/hvg-homn-jgr Join by Phone: (US) +1 515-518-4522 PIN: 992 356 723#

Following the conclusion of the bid opening, the Bid Abstract will be uploaded to SAM website under this solicitation, within 24 hours.

Site Visit: The government will NOT be conducting a site visit for this procurement. The area where construction will take place is publicly accessible. Any interested parties may visit the site prior to the bid opening as they can access the site via highway 98 and/or the Fish river; for additional information, reference the map provided in drawing G-001 Cover Sheet of Attachment B.4 - Drawings. A NOAA/NMFS escort will not be provided and the Government is not liable for any contractor activity at the site.

Other Information: SALES TAX EXEMPTIONS: Bidders are reminded that certain states may exempt material purchased for, or use in, Government construction projects from the application of sales tax or use tax. The bidder is solely responsible for determining the applicability of and procedures for obtaining of such tax exemptions that may be available to the bidder for this project.

Questions: Any questions related to this solicitation must be submitted via email to the Contracting Officer and Contract Specialist identified below with the solicitation number 1305M324B0001 in the subject line: Contracting Officer – Grace Parker, Grace.Parker@noaa.gov; Contract Specialist – Nick Brown, Nicholas.G.Brown@noaa.gov All questions must be received by Thursday, April 25, 2024 to be addressed by the Government prior to the bid submission deadline. The Government is not obligated to answer any questions received after the deadline for receipt of questions.

mailto:Grace.Parker@noaa.gov mailto:Nicholas.G.Brown@noaa.gov

Section IV - Packaging and Marking

NOT APPLICABLE

Section V - Inspection and Acceptance

FAR 52.246-12 Inspection of Construction. (AUG 1996)

FAR 52.246-13 Inspection - Dismantling, Demolition, or Removal of Improvements. (AUG 1996)

CAR 1352.246-70 Place of acceptance. (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of acceptance will be:

in accordance with Attachment B.1 General Conditions, paragraph 2 entitled Construction Observation.

(End of clause)

CAR 1352.270-70 Period of performance. (APR 2010)

(a) The base period of performance of this contract is from [ ] through [ ]. If an option is exercised, the period of performance shall be extended through the end of that option period.

(b) The option periods that may be exercised are as follows:

[Enter the Period (Option I, Option II, Option III and Option IV), Start Date and End date]

Section VI - Deliveries or Performance

FAR 52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 140 calendar days after receipt of the Notice to Proceed, 180 days if all bid alternatives are exercised. The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

FAR 52.211-18 Variation in Estimated Quantity. (APR 1984)

FAR 52.236-15 Schedules for Construction Contracts. (APR 1984)

FAR 52.242-14 Suspension of Work. (APR 1984)

NOAA Acquisition Manual 1330-52.215-70 SCHEDULE OF DELIVERABLES (SEPT 2005)

The following is a schedule of all deliverables, including administrative deliverables, required during the period of performance of this contract:

Reference attachments B.1. General Conditions (Section 33), B.2 Technical Provisions (Section 28) and B.3 Environmental Protection Provisions (Section 15)

(End of solicitation and contract language)

Section VII - Contract Administration

CAR 1352.201-70 Contracting Officer's Authority. (MAR 2010)

CAR 1352.201-72 Contracting Officer's Representative (COR). (APR 2010)

(a) TO BE DESIGNATED BY SEPARATE LETTER is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

TBD

Phone Number: [ ]

E-mail: [ ]

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

NOAA Acquisition Manual 1330-52.242-70 SUBMITTAL OF INVOICES (FEB 2011)

The contractor shall prepare and submit an invoice to the COR for approval [with a copy to the contracting officer for information]. All invoices shall be submitted by the 10th day of the subsequent month.

To constitute a proper invoice, the contractor’s invoice shall be prepared in accordance with, and contain all elements specified in the paragraph titled, “Contractor’s Invoice,” of the applicable prompt payment provision of the contract (e.g., FAR 52.232-25, Prompt Payment; FAR 52.232-26, Prompt Payment for Fixed-Price Architect Engineer Contracts; or FAR 52.232-27, Prompt Payment for Construction Contracts). For contracts and orders for commercial items and services, paragraph (g) of FAR 52.212-4, titled, “Invoices,” applies.

If the invoice does not comply with the applicable prompt payment provision of the contract, the COR will return it to the contractor within seven days after the date the designated office received the invoice along with a statement as to the reasons why it is not a proper invoice.

Section IX - Contract Clauses

Clauses Incorporated by Reference Clause Number Clause Title

52.202-1 Definitions. (JUN 2020) 52.203-3 Gratuities. (APR 1984) 52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-6 Restrictions on Subcontractor Sales to the Government.

(JUN 2020)

52.203-7 Anti-Kickback Procedures. (JUN 2020)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity.

(MAY 2014)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (JUN 2020)

52.203-17 Contractor Employee Whistleblower Rights. (NOV 2023)

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. (JAN 2017)

52.204-9 Personal Identity Verification of Contractor Personnel.

(JAN 2011)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (JUN 2020)

52.204-13 System for Award Management Maintenance. (OCT 2018)

52.204-18 Commercial and Government Entity Code Maintenance.

(AUG 2020)

52.204-19 Incorporation by Reference of Representations and Certifications. (DEC 2014)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems. (NOV 2021)

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities. (DEC 2023)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021)

52.204-27 Prohibition on a ByteDance Covered Application. (JUN 2023)

52.204-30 Federal Acquisition Supply Chain Security Act Orders- Prohibition. (DEC 2023)

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (OCT 2018)

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015)

52.219-3 Notice of HUBZone Set-Aside or Sole Source Award. (OCT 2022)

Clause Number Clause Title 52.219-6 Notice of Total Small Business Set-Aside. (NOV 2020) 52.219-8 Utilization of Small Business Concerns. (FEB 2024) 52.219-14 Limitations on Subcontracting. (OCT 2022)

52.219-28 Post-Award Small Business Program Rerepresentation.

(FEB 2024)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation. (MAY 2018)

52.222-6 Construction Wage Rate Requirements. (AUG 2018) 52.222-7 Withholding of Funds. (MAY 2014) 52.222-8 Payrolls and Basic Records. (JUL 2021) 52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance With Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (MAY 2014) 52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations. (MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988) 52.222-15 Certification of Eligibility. (MAY 2014) 52.222-21 Prohibition of segregated facilities. (APR 2015) 52.222-26 Equal Opportunity. (SEP 2016)

52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015)

52.222-35 Equal Opportunity for Veterans. (JUN 2020)

52.222-36 Equal Opportunity for Workers with Disabilities. (JUN 2020)

52.222-37 Employment Reports on Veterans. (JUN 2020)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (DEC 2010)

52.222-50 Combating Trafficking in Persons. (NOV 2021) 52.222-54 Employment Eligibility Verification. (MAY 2022)

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (JAN 2022)

52.222-62 Paid Sick Leave Under Executive Order 13706. (JAN 2022)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts. (SEP 2013)

52.223-5 Pollution Prevention and Right-to-Know Information.

(MAY 2011)

52.223-6 Drug-Free Workplace. (MAY 2001) 52.223-10 Waste Reduction Program. (MAY 2011)

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts. (AUG 2018)

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving. (JUN 2020)

52.225-9 Buy American - Construction Materials. (OCT 2022) 52.225-13 Restrictions on Certain Foreign Purchases. (FEB 2021) 52.227-1 Authorization and Consent. (JUN 2020)

Clause Number Clause Title

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. (JUN 2020)

52.227-4 Patent Indemnity--Construction Contracts. (DEC 2007) 52.228-2 Additional Bond Security. (OCT 1997)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.228-11 Individual Surety-Pledge of Assets. (FEB 2021)

52.228-12 Prospective Subcontractor Requests for Bonds. (DEC 2022)

52.228-14 Irrevocable Letter of Credit. (NOV 2014)

52.228-15 Performance and Payment Bonds - Construction. (JUN 2020)

52.229-3 Federal, State, and Local Taxes. (FEB 2013)

52.232-5 Payments Under Fixed-Price Construction Contracts.

(MAY 2014)

52.232-17 Interest. (MAY 2014) 52.232-23 Assignment of Claims. (MAY 2014) 52.232-27 Prompt Payment for Construction Contracts. (JAN 2017)

52.232-33 Payment by Electronic Funds Transfer - System for Award Management. (OCT 2018)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (MAR 2023)

52.233-1 Disputes. (MAY 2014) 52.233-3 Protest After Award. (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004) 52.236-2 Differing Site Conditions. (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work.

(APR 1984)

52.236-5 Material and Workmanship. (APR 1984) 52.236-6 Superintendence by the Contractor. (APR 1984) 52.236-7 Permits and Responsibilities. (NOV 1991) 52.236-8 Other Contracts. (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (APR 1984)

52.236-10 Operations and Storage Areas. (APR 1984) 52.236-11 Use and Possession Prior to Completion. (APR 1984) 52.236-12 Cleaning Up. (APR 1984) 52.236-13 Accident Prevention. (NOV 1991) 52.236-16 Quantity Surveys. (APR 1984) - Alternate I (APR 1984) 52.236-17 Layout of Work. (APR 1984) 52.236-21 Specifications and Drawings for Construction. (FEB 1997) 52.236-26 Preconstruction Conference. (FEB 1995) 52.242-13 Bankruptcy. (JUL 1995) 52.243-4 Changes. (JUN 2007)

52.244-6 Subcontracts for Commercial Products and Commercial Services. (FEB 2024)

Clause Number Clause Title 52.248-3 Value Engineering - Construction. (OCT 2020)

52.249-2 Termination for Convenience of the Government (Fixed- Price). (APR 2012) - Alternate I (SEP 1996)

52.249-10 Default (Fixed-Price Construction). (APR 1984) 52.253-1 Computer Generated Forms. (JAN 1991) 1352.208-70 Restrictions on printing and duplicating. (APR 2010) 1352.209-72 Restrictions against disclosure. (APR 2010) 1352.209-73 Compliance with the laws. (APR 2010) 1352.209-74 Organizational conflict of interest. (APR 2010)

FAR 52.236-1 Performance of Work by the Contractor. (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least Twenty (20) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

FAR 52.236-4 Physical Data. (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by The physical conditions of the borrow and fill areas, as indicated on the Plans, are based on bathymetric and topographic surveys and sediment sampling data acquired in March 2019. The final geotechnical report was provided to NOAA by Fugro USA Land, Inc, and Moffatt and Nichol, in May of 2019.

(b) Weather conditions N/A.

(c) Transportation facilities N/A.

(d) N/A.

(End of clause)

FAR 52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): Federal Acquisition Regulations (FAR) Clauses: https://www.acquisition.gov/browse/index/far

Department of Commerce Acquisition Regulations (CAR) Clauses: https://www.acquisition.gov/car

(End of clause)

FAR 52.252-6 Authorized Deviations in Clauses. (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the date of the clause.

(b) The use in this solicitation or contract of any Department of Commerce Acquisition Regulation (48 CFR 13) clause with an authorized deviation is indicated by the addition of (DEVIATION) after the name of the regulation.

(End of clause)

NOAA Acquisition Manual 1330-52.203-71 NOTICE OF POST-GOVERNMENT EMPLOYMENT

RESTRICTIONS (OCT 2015)

By submission of an offer in response to a NOAA solicitation or acceptance of a contract, the contractor acknowledges the restriction on current NOAA employees regarding contact with offerors regarding prospective employment and the corresponding obligations for contractors who engage them. The contractor further acknowledges that it has provided notice to former NOAA employees who will provide service to NOAA under the contract of post-Government employment restrictions that apply to them. Such restrictions include, but are not limited to, those set forth in:

(a) 41 U.S.C. § 2103 regarding contacts between a Federal employee working on a procurement and an offeror about prospective employment;

(b) 18 U.S.C. § 207 regarding the restrictions on former Federal employees having contact with a Federal agency on behalf of another person or entity concerning a specific party matter with which the former employee was involved as a Federal employee or for which the former Federal employee had official responsibility;

(c) 18 U.S.C. § 207 regarding the restrictions on former senior employees and senior political employees from having contact with his former Federal agency on behalf of another person or entity concerning any official matter; and

(d) 41 U.S.C. § 2104 regarding the restrictions on a former Federal employee involved in an acquisition over $10,000,000 from accepting compensation from a contractor.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.208-70 SUBCONTRACTING WITH ABILITYONE NONPROFIT

ORGANIZATIONS (DECEMBER 2022)

NOAA recognizes and appreciates the value and talent that people with disabilities bring to our workplaces. The Committee for Purchase From People Who Are Blind or Severely Disabled (AbilityOne

Program) is one of the United States’ largest sources of employment for people who are blind or have significant disabilities, employing more than 40,000 individuals, including approximately 2,500 veterans.

Approximately 450 nonprofit organizations employ these individuals who provide quality products and services to the Federal Government totaling nearly $4 billion each year. Contracting with AbilityOne nonprofit organizations provides veterans and individuals who are blind or have significant disabilities more opportunities to work, lead independent lives, serve in their communities, and contribute to the strength of our Nation’s economy.

This contract action is identified as including opportunities for subcontracting. The statutory obligation for Government agencies to satisfy their requirements for supplies or services available from the AbilityOne Program also applies when contractors purchase the supplies or services for Government use. For this contract action (contracting officer select one):

[] A subcontracting plan is required. The contractor shall include AbilityOne as a separate goal on the subcontracting plan. This line must be reported in the Electronic Subcontracting Reporting System (eSRS) under Large Business. AbilityOne will give Other Than Small Business credit on subcontracting plans.

X A subcontracting plan is not required. The contractor should consider subcontracting with AbilityOne nonprofit organizations to the maximum extent practicable and allowable consistent with other statutory and regulatory requirements applicable to the acquisition.

To engage with an AbilityOne Contractor (Non-Profit Agency) for subcontracting opportunities, the prime contractor should include the following information in an email to primecontractor@abilityone.org:

a) Solicitation number

b) Copy of the performance work statement or scope of work

c) Identification of work that will be set aside for AbilityOne

d) Estimated annual value of work for AbilityOne

e) Prime contractor point of contact email address, phone number, name, and title

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.222-70 NOAA SEXUAL ASSAULT AND SEXUAL HARASSMENT

PREVENTION AND RESPONSE POLICY (MAY 2018)

In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA.

(a) Definitions.

Contractor Employees - The term “contractor employees,” as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members.

Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim.

Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true:

● Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment;

● Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual;

● The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment.

The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient’s sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures.

(b) Requirements.

1. It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment.

2. The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor.

3. If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the COR, subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6.07, Reporting from Remote Locations.

4. Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants’ needs are addressed.

5. The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor’s written policy (where applicable).

6. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within business days 30 business days of contract award or the date a contractor employee is assigned to perform under the contract, as applicable.

Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion.

Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance.

7. The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA’s Workplace Violence Program Manager. A link to the website including the required elements of the training is provided at https://www.noaa.gov/organization/acquisition-grants/noaa-workplace-harassment-training-for-contractors-and-financial. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed.

8. The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training.

9. NOAA’s Workplace Violence Program Manager, COR, or CO may periodically review the contractor’s training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor.

10. Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106.

11. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees.

(c) Sexual Assault/Sexual Harassment (SASH) Helpline.

For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee.

All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including:

● Phone: 1-866-288-6558

● Website & Online Chat: https://www.noaasashhelpline.org/

● Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores)

● Text: (202) 335-0265

(d) Confidentiality.

Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. “Confidentiality” means that the information shall only be shared with others who have a need to know the information to conduct their official duties.

(e) Remedies.

In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in:

1. Requiring the contractor to remove a contractor employee or employees from the performance of the contract;

2. Requiring the contractor to terminate a subcontract;

3. Suspension of contract payments until the Contractor has taken appropriate remedial action;

4. Termination of the contract for default or cause, in accordance with the termination clause of this contract;

5. Suspension or debarment; or

6. Other appropriate action.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.232-71 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (FEB 2023)

The Contractor must submit payment requests electronically through the U.S. Department of the Treasury's Invoice Processing Platform System (IPP). The Contractor must use the IPP website to register, access, and submit payment requests. The IPP website address is https://www.ipp.gov.

"Payment request" means any request for contract financing payment or invoice payment to the Contractor. To be considered proper, invoices must be prepared in accordance with, and contain all elements specified in, the contract payment clause (e.g., FAR 52.212-4(g), FAR 52.232-25(a)(3), FAR 52.232-26(a)(2), FAR 52.232-27(a)(2)).

The Contractor must include the following documents as attachments to payment requests submitted through the IPP: [].

If the Contractor is unable to comply with the requirement to submit payment requests through the IPP due to a threat to national security; a matter of unusual or compelling urgency; or because the political, financial, or communications infrastructure of a foreign country does not support access to the IPP, the Contractor must request an exception in writing. Contact the Contracting Officer for more information about requesting an exception.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.237-71 NOAA GOVERNMENT-CONTRACTOR RELATIONS - NON-

PERSONAL SERVICES CONTRACT (SEPT 2017)

(a) The Government and the contractor understand and agree that the services to be delivered under this contract by the contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the contractor’s personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations.

(b) Contractor personnel under this contract shall not:

1. Be placed in a position where they are under relatively continuous supervision and control of a Government employee.

2. Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other contractors performing under other NOAA contracts.

(c) The services to be performed under this contract do not require the contractor or the contractor’s personnel to exercise personal judgment and discretion on behalf of the Government. Rather, the contractor’s personnel will act and exercise personal judgment and discretion on behalf of the contractor.

(d) Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract.

(e) Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies:

1. The contractor shall notify the contracting officer in writing within 5 business days from the date of any situation or occurrence where the contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance.

2. The contracting officer will review the information provided by the contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the contractor. The contracting officer’s response will provide a decision on whether the contracting officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the issue.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.243-70 REQUESTS FOR EQUITABLE ADJUSTMENT (OCT 2017)

(a) The amount of any request for equitable adjustment to contract terms shall accurately reflect the contract adjustment for which the contractor believes the Government is liable. The request shall include only costs for performing the change. All indirect costs included in the request shall be properly allocable to the change in accordance with applicable acquisition regulations.

(b) Any request for equitable adjustment to contract terms that exceeds the simplified acquisition threshold shall bear, at the time of submission, the following certificate executed by an individual authorized to certify the request on behalf of the contractor:

I certify that the request is made in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief.

(Official’s Name)

(Title)

(c) The certification in paragraph (b) of this solicitation and contract language requires full disclosure of all relevant facts, including:

1. Certified cost or pricing data, if required, in accordance with subsection 15.403-4 of the Federal Acquisition Regulation (FAR); and

2. Data other than certified cost or pricing data, in accordance with subsection 15.403-3 of the FAR, including actual cost data and data to support any estimated costs, even if certified cost or pricing data are not required.

(d) The certification requirement in paragraph (b) of this solicitation and contract language does not apply to:

1. Requests for routine contract payments; for example, requests for payment for accepted supplies and services, routine vouchers under a cost-reimbursement type contract, or progress payment invoices; or

2. Final adjustments under an incentive provision of the contract.

(End of solicitation and contract language)

NOAA Acquisition Manual 1330-52.270-304 NOAA ACQUISITION AND GRANTS OFFICE OMBUDSMAN

(OCT 2022)

(a) The NOAAAGO Ombudsman is available to organizations to promote responsible and meaningful exchanges of information. Generally, the purpose of these exchanges will be to:

1. Allow contractors to better prepare for and propose on business opportunities.

2. Advise as to technologies and solutions within the marketplace that the Government may not be aware of, or is not fully benefiting.

3. Identify constraints in transparency.

(b) The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her. Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA.

(c) Before consulting with the AGO Ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations with the respective contracting officer for resolution.

However, direct access to the AGO Ombudsman may be sought when an interested party questions the objectivity or equity of a contracting officer’s decision, or when there is a bona fide reason to believe that reasonable, responsible, and objective consideration will not be received from an assigned contracting officer.

(d) There are several constraints to the scope of the AGO Ombudsman’s authority, for instance:

1. Consulting with the AGO Ombudsman does not alter or postpone the timelines of any formal process (e.g., protests, claims, debriefings, employee employer actions, activities involving A76 competition performance decisions, judicial or congressional hearings, or proposal, amendment, modification or deliverable due dates).

2. The AGO Ombudsman cannot participate in the evaluation of proposals, source selection processes, or the adjudication of protests or formal contract disputes.

3. The AGO Ombudsman is not authorized to generate or alter laws, judicial decisions, rules, policies, or formal guidance.

4. The AGO Ombudsman is not authorized to develop or alter opportunity announcements, solicitations, contracts, or their terms or conditions.

5. The AGO Ombudsman cannot overrule the authorized decisions or determinations of the contracting officer.

6. The AGO Ombudsman has no authority to render a decision that binds AGO, NOAA, the Department of Commerce, or the U.S. Government.

7. The AGO Ombudsman is not NOAA’s agent relative to the service of magistrate or judicial process and cannot be used to extend service of process to another party (whether federal, public, or a private entity).

(e) After review and analysis of a filed concern or recommendation, the AGO Ombudsman may refer the interested party to another more suitable Federal official for consideration. Moreover, concerns, disagreements, and/or recommendations that cannot be resolved by the AGO Ombudsman will need to be pursued through more formal venues.

(f) The AGO Ombudsman is not to be contacted to request copies of forms and/or documents under the purview of a contracting officer. Such documents include Requests for Information, solicitations, amendments, contracts, modifications, or conference materials.

(g) Questions regarding items (a) through (f) within this language shall be directed to ago.ombudsman@noaa.gov.

Section X - List of Attachments

Attachment Number Title

A Bid Schedule B.1 General Conditions B.2 Technical Provisions B.3 Environmental Protection Provisions B.4 Drawings C Davis-Bacon AL20230104 D SF24-23a Bid Bond Form E SF25-23a Performance Bond Form F SF25A-23a Payment Bond Form

Section XI - Representations, Certifications, and Other Statements of Bidders

Representations, Certifications, and Other Statements of Bidders

FAR 52.219-1 Small Business Program Representations. (FEB 2024)

(a) Definitions. As used in this provision-

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business (SDVOSB) concern means a small business concern-

(1)(i) Not less than 51 percent of which is owned and controlled by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran or;

(2) A small business concern eligible under the SDVOSB Program in accordance with 13 CFR part 128 (see subpart 19.14).

(3) Service-disabled veteran, as used in this definition, means a veteran as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16), and who is registered in the Beneficiary Identification and Records Locator Subsystem, or successor system that is maintained by the Department of Veterans Affairs' Veterans Benefits Administration, as a service-disabled veteran.

Service-disabled veteran-owned small business (SDVOSB) concern eligible under the SDVOSB Program means an SDVOSB concern that-

(1) Effective January 1, 2024, is designated in the System for Award Management (SAM) as certified by the Small Business Administration (SBA) in accordance with 13 CFR 128.300; or

(2) Has represented that it is an SDVOSB concern in SAM and submitted a complete application for certification to SBA on or before December 31, 2023.

Service-disabled veteran-owned small business (SDVOSB) Program means a program that authorizes contracting officers to limit competition, including award on a sole-source basis, to SDVOSB concerns eligible under the SDVOSB Program.

Small business concern-(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (b) of this provision.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

Small disadvantaged business concern, consistent with 13 CFR 124.1001, means a small business concern under the size standard applicable to the acquisition, that-

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-

(i) One or more socially disadvantaged…