127EAY23Q0005.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

7EAY

ALBUQUERQUE NM 87102-3498

333 BROADWAY BLVD SE

USDA-FS CSA SOUTHWEST 1

91W8 CODE 16. ADMINISTERED BYCODE

X

X

X

562910

SIZE STANDARD:

100.00 % FOR:SET ASIDE:UNRESTRICTED OR7EAY

RFPIFB

10. THIS ACQUISITION ISCODE

RFQ

14. METHOD OF SOLICITATION

13b. RATING

NAICS:

SMALL BUSINESS

01/04/2023 1300 PT

12/19/2022

530-560-5619TROY BOUDRO

(No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBERa. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

127EAY23Q0005

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 24 1084437OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

TELEPHONE NO.

17a. CONTRACTOR/

YREKA CA 96097

1711 S MAIN STREET

KLAMATH NATIONAL FOREST

USDA FOREST SERVICE

15. DELIVER TO

ALBUQUERQUE NM 87102-3498

333 BROADWAY BLVD SE

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

11.

SEE SCHEDULEX

12. DISCOUNT TERMS

THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

8(A)

USDA-FS CSA SOUTHWEST 1

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

Klamath National Forest Siskiyou County ATB Retardant Pumping, Disposal, Cleaning, and Inspection Delivery: 03/31/2022 Period of Performance: 01/09/2023 to 03/31/2023

0001 Klamath National Forest Siskiyou County Air Tanker Base Retardant System Pumping and Inspection

Continued ...

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

X

XX

DATED . YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

OFFER

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT:

REF.

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 2/2012) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

24 2 of

TABLE OF CONTENTS

SECTION II - CONTRACT CLAUSES

SECTION III – STATEMENT OF WORK

SECTION IV – CONTRACT DOCUMENTS, EXHIBITS, OR ATTACHMENTS

SECTION V - SOLICITATION PROVISIONS

52.212-1 Instructions to Offerors

52.212-2 Evaluation

(3) The following factors shall be used to evaluate quotes:

52.237-1 Site Visit

CONTRACTOR TO COMPLETE AND RETURN WITH OFFER/QUOTE

SECTION II - CONTRACT CLAUSES

52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR) Clauses: https://www.acquisition.gov/browse/index/far (FAR clauses begin with 52) Department of Agriculture Acquisition Regulation (AGAR) Clauses:

https://www.acquisition.gov/agar (AGAR clauses begin with 452) Deviations to clauses may be viewed at: Policies & Regulations | USDA

52.204-9 Personal Identity Verification of Contractor Personnel (JAN 2011)

52.204-13 System for Award Management Maintenance (OCT 2018)

52.204-18 Commercial and Government Entity Code Maintenance (AUG 2020)

52.212-4 Contract Terms and Conditions – Commercial Products and Commercial Services

(NOV 2021) (DEVIATION 2017-1)

52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders– Commercial Products and Commercial Services (OCT 2022) (DEVIATION 2017-1, DEVIATION APR 2020, and DEVIATION JUL 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/agar https://www.usda.gov/da/ocp/ppd/policies-regulations

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Nov 2021) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(5) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and

108-78 (19 U.S.C. 3805note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] ☐ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (June 2020), with Alternate I

(Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 2402).

☐ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

☐ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of

2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

☐ (4) 52.203-17, Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights (Jun 2020) (DEVIATION 2017-1)

☒ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note).

☐ (6) [Reserved].

☐ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

☐ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct

2016) (Pub. L. 111-117, section 743 of Div. C).

☒ (9) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors

Debarred, Suspended, or Proposed for Debarment. (Nov 2021) (31 U.S.C. 6101note).

☐ (10) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct

2018) (41 U.S.C. 2313).

☐ (11) [Reserved].

☐ (12) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15

U.S.C.657a).

☐ (13) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns

(Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C.

657a).

☐ (14) [Reserved] ☒ (15) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C.644).

☐ (ii) Alternate I (Mar 2020) of 52.219-6.

☐ (16) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

☐ (ii) Alternate I (Mar 2020) of 52.219-7.

☐ (17) 52.219-8, Utilization of Small Business Concerns (Oct 2022) (15 U.S.C. 637(d)(2) and (3)).

☐ (18) (i) 52.219-9, Small Business Subcontracting Plan (Oct 2022) (15 U.S.C. 637(d)(4)).

☐ (ii) Alternate I (Nov 2016) of 52.219-9.

☐ (iii) Alternate II (Nov 2016) of 52.219-9.

☐ (iv) Alternate III (Jun 2020) of 52.219-9.

☐ (v) Alternate IV (Sep 2021) of 52.219-9.

☐ (19) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

☐ (ii) Alternate I (MAR 2020) of 52.219-13

☐ (20) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C.637s) [Contracting Officer check as appropriate.]

☐ By the end of the base term of the contract and then by the end of each subsequent option period; or ☐ By the end of the performance period for each order issued under the contract.

☐ (21) 52.219-16, Liquidated Damages-Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

☐ (22) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Oct 2022)

(15 U.S.C. 657f).

☐ (23) (i) 52.219-28, Post Award Small Business Program Rerepresentation (Oct 2022) (15 U.S.C.

632(a)(2)).

☐ (ii) Alternate I (MAR 2020) of 52.219-28.

☐ (24) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

☐ (25) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C.

637(m)).

☐ (26) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C.

644(r)).

☐ (27) 52.219-33, Nonmanufacturer Rule (Sep 2021) (15 U.S.C. 637(a)(17)).

☒ (28) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

☒ (29) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2022) (DEVIATION

JUL 2020) (E.O.13126).

☒ (30) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

☒ (31) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

☐ (ii) Alternate I (Feb 1999) of 52.222-26.

☐ (32) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

☐ (ii) Alternate I (Jul 2014) of 52.222-35.

☒ (33) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C.793).

☐ (ii) Alternate I (Jul 2014) of 52.222-36.

☐ (34) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

☐ (35) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec

2010) (E.O. 13496).

☒ (36) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O.

13627).

☐ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter78 and E.O. 13627).

☐ (37) 52.222-54, Employment Eligibility Verification (May 2022). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

☐ (38) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☐ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☒ (39) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

☐ (40) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).

☐ (41) (i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

☐ (ii) Alternate I (Oct 2015) of 52.223-13.

☐ (42) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

☐ (ii) Alternate I (Jun 2014) of 52.223-14.

☐ (43) 52.223-15, Energy Efficiency in Energy-Consuming Products (May 2020) (42 U.S.C. 8259b).

☐ (44) (i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015)

(E.O.s 13423 and 13514).

☐ (ii) Alternate I (Jun 2014) of 52.223-16.

☒ (45) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Jun 2020) (E.O. 13513).

☐ (46) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

☐ (47) 52.223-21, Foams (Jun 2016) (E.O. 13693).

☐ (48) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

☐ (ii) Alternate I (Jan 2017) of 52.224-3.

☐ (49)(i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

☐(ii) Alternate I (Oct 2022) of 52.225-1 ☐ (50) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (Oct 2022)

(DEVIATION JUL 2020) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Pub. L. 103- 182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

☐ (iii) (ii) Alternate II (Jan 2021) (DEVIATION JUL 2020) of 52.225-3.

☐ (iv) (iii) Alternate III (Jan 2021) (DEVIATION JUL 2020) of 52.225-3.

☐ (v) (iv) Alternate IV (Oct 2022) of 52.225-3.

☐ (51) 52.225-5, Trade Agreements (Oct 2019) (DEVIATION JUL 2020) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

☐ (52) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

☐ (53) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008;

10 U.S.C. 2302 Note).

☐ (54) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

☐ (55) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42

U.S.C. 5150).

☐ (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

☐ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial

Services (Nov 2021) (41 U.S.C.4505, 10 U.S.C.2307(f)).

☐ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov

2021) (41 U.S.C.4505, 10 U.S.C.2307(f)).

☒ (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2018)

(31 U.S.C. 3332).

☐ (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management

(Jul 2013) (31 U.S.C.3332).

☐ (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C.3332).

☒ (62) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Nov 2021)

(DEVIATION APR 2020) (31 U.S.C.3332).

☐ (63) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

☐ (64) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

☐ (65) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46

U.S.C. 55305 and 10 U.S.C. 2631).

☐ (ii) Alternate I (Apr 2003) of 52.247-64.

☐ (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

Contracting Officer check as appropriate.] ☒ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

☒ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41

U.S.C. chapter 67).

In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor (29 CFR Part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C.5341 or 5 332.

This Statement is for Information Only: It is not a Wage Determination http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

Employee Class Monetary Wage/Fringe Benefits

☐ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment

(Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

☐ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment

(May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

☐ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

☐ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

☒ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

☒ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

☐ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C.

1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Nov 2021) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(v) 52.219-8, Utilization of Small Business Concerns (Oct 2022) (15 U.S.C.637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vii) 52.222-26, Equal Opportunity (Sep 2015) (E.O.11246).

(viii) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C.4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C.793).

(x) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C.4212).

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec

2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

(xiii) (A) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and

E.O 13627).

(B) Alternate I (Mar 2015) of 52.222-50(22 U.S.C. chapter 78 and E.O 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to

Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xvi) 52.222-54, Employment Eligibility Verification (May 2022) (E.O. 12989).

(xvii) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan

2022).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

(xix) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States

(Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008;

10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C.2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.217-8 Option to Extend Services (Nov 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 15 days of the end of the period of performance.

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (SEP 2013)

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts (AUG 2018)

52.228-5 Insurance – Work on a Government Installation (JAN 1997)

52.237-2 Protection of Government Buildings, Equipment, and Vegetation (APR 1984)

52.242-17 Government Delay of Work (APR 1984)

52.252-6 Authorized Deviations in Clauses (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR 4) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

452.204-70 Modification for Contract Closeout (DEVIATION JUL 2022)

Upon contract closeout for contracts utilizing Simplified Acquisition Procedures (SAP) according to

FAR 13:

(a) If unobligated funds in the amount of $1000 or less remain on the contract, the Contracting Officer (CO) shall issue a unilateral modification for deobligation. The contractor will receive a copy of the modification but will not be required to provide a signature. The CO shall immediately proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(b) If unobligated funds of more than $1000 remain on the contract, the CO shall issue a bilateral modification for deobligation. The contractor will receive a copy of the modification and will be required to provide a signature. (The CO may also request a Release of Claims be completed by the contractor, although not required for contract and orders using SAP procedures.) If the bilateral modification and Release of Claims are not returned to the CO within 60 days, the CO shall release the modification as unilateral and proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

452.215-73 Post Award Conference (NOV 1996)

A post award conference with the successful offeror may be required. If required, it will be scheduled by the Contracting Officer Representative at a mutually accepted place and time prior to starting work.

452.236-74 Control of Erosion, Sedimentation, and Pollution (NOV 1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

452.237-74 Key Personnel (FEB 1988)

(a) The Contractor shall assign to this contract the following key personnel: ________________.

(b) During the first ninety (90) days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 90-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. The contract will be modified to reflect any approved changes of key personnel.

SECTION III – STATEMENT OF WORK

Background: The Siskiyou County Airtanker Base is staffed on an as Call When Needed basis and equipped with government owned retardant and water tanks, pump, retardant mix system plumbing, and manifold. A recent inspection focused on the tanker base’s retardant lot acceptance / quality assurance (LA/QA) issues (i.e. solid and coagulated formations in liquid concentrate storage tanks).

Two (2) 10,000 gallon tanks,used for liquid concentrate storage are plumbed with valves at each end to accommodate recirculation and/or mixing. A recirculation system has not been installed at Siskiyou County ATB.

Siskiyou County ATB retardant recirculation and mixing is accomplished by one variable speed pump set at 200 GPM. Retardant mixing operations require the introduction of water into the pump housing.

If the mix pump is used for recirculation, water is introduced into stored concentrate, creates contamination and activates formula gum(coagulation).

There is currently approxinately 10,000 gallons of retardant distrubted between the two tanks retardant (3000 Gal South Tank, 7,000 Gal North Tank) An SDS for the retardant stored in the tanks is included as an attachment to this SOW.

Scope Of Work To Be Performed: The work to be performed under this contract includes pumping the retardant tanks located at the Siskiyou County Air Tanker Base, disposing of the retardant, cleaning the tanks, inspecting the tanks for needed repairs. (Note: Needed repairs that are identifed during the inspection will be performed under a different contract. No repairs will be performed under this SOW.) If the tanks are in need of repair, provide documentation of areas in need of repair. The Contractor shall furnish all labor, equipment, transportation, permits, testing and incidentals necessary for the performance of the tasks specified in this Statement of Work.

The Siskiyou County Air Tanker Base is located at 4646 Airport Road, Montague, CA.

Copies of relevant reports and a site maps will be provided.

During field conditions, if site conditions warrant additional work as described in the accepted workplan, but is outside of the original scope of work, this work may be initiated if appproval is obtained from the Forest Service Contracting Officer.

Compliance with Regulations: The Contractor shall comply with all applicable Federal, State (California), interstate and local laws (Siskiyou County),environmental regulations, and requirements.

This includes compliance with the National Contingency Plan (NCP), the Resource Conservation and Recovery Act (RCRA), and the California Health and Safety Code; California Code of Regulations, Title 22, Division 4.5. The duty of the Contractor to comply with all current applicable laws, regulations and requirements takes precedence over any other duty or task described herein. Therefore, in the event that subsequent legislation or regulations conflict with prescribed procedures contained in this contract, said changes shall take precedence. Where changes to law, regulation or requirement necessitate a change to the contract, the parties agree to negotiate an equitable adjustment for it upon written notice from the Contractor. Unless said notice is received within 60 days of the effective date of the amendment to the statute or regulation, said regulation shall be deemed to be a no-cost change.

All work submitted and performed by the Contractor may be subject to the review and approval of EPA and/or the appropriate State (California) regulatory agency. Therefore, it is the responsibility of the Contractor to contact the appropriate regulatory agency(s) to determine their requirements for each individual project. The government will be responsible for submitting reports to regulatory agencies unless other arrangements are approved by the Contracting Officer’s Representative (COR). It is the Contractor’s responsibility to find out from the regulatory agency(s) which guidance materials are current and applicable.

The Contractor shall, without additional expense to the Forest Service, be responsible for obtaining any necessary licenses and permits, and for complying with any applicable Federal, State and local laws, codes, and regulations in connection with the execution of the work. This includes ensuring project related hazardous or toxic wastes are sent to licensed, permitted, and approved disposal sites. The Forest Service will obtain, as necessary, the required temporary EPA Identification Number for site cleanup activities.

All work, including the handling of hazardous materials or the disturbance or dismantling of structures containing hazardous materials shall comply with the applicable requirements of 29 CFR 1910 and 29 CFR 1926. Work involving the disturbance or dismantling of asbestos or asbestos containing materials; the demolition of structures containing asbestos; and/or the disposal and removal of asbestos, shall also comply with the requirements of 40 CFR 61. All work shall comply with applicable state and municipal safety and health requirements. Where there is a conflict between applicable regulations, the most stringent shall apply.

Hazardous Waste Manifest Documents: The Forest Service will obtain and supply the Contractor with an EPA Identification Number (if needed) to be used on all hazardous waste manifests required for the sites identified in this contract.

The contractor is authorized to sign uniform hazardous waste manifest forms (40 CFR Part 262) (“manifests”) and land ban notifications/certifications/demonstrations (40 CFR Part 268.7 and .8) (“land ban records”) for the hazardous wastes being addressed under this contract. The contractor shall sign the manifests and land ban records after writing or printing in the phrase “On behalf of the USDA Forest Service” in the signature block. The contractor shall not be considered a generator of hazardous wastes solely as a result of having signed the manifests or land ban records on behalf of the Forest Service. Nothing contained in this paragraph shall be construed to create an agency relationship between the contractor and the Forest Service except with respect to the authorization to sign the manifests and land ban records. This authorization only extends to the waste being addressed under this contract.

Site Access: The project site is located at the Siskiyou County Air Tanker Base. The project site’s physical address is 4646 Airport Road, Montague, California. A gate code is required to access the site. The gate code will be provided prior to the start of the work described in this SOW. The air tanker base is an active fire tanker base.

Fees: The Contractor shall, without expense to the Government, pay all Federal, State, County and Municipal fees applicable to the performance of the work.

Applicable Codes: The following codes and standards shall apply to the work in this statement of work:

• Applicable California state and local laws, regulations, codes and ordinances

Underground Utilities and Other Underground Improvements: Underground utilities and other underground improvements exist at the site. The Contractor shall call 811 for the free utility location service. If a utility or other underground improvement is damaged in the event that excavation is required to clean up spilled retardant, the Contractor shall notify the Contracting Officer and the owner of the utility immediately.

The Contractor shall take all reasonable precautions to protect the utilities or other underground improvements where the locations have been designated. If a utility or other underground improvement is damaged, the Contractor shall repair the damage to the satisifaction of the Contracting Officer or the owner at the Contractor's expense. All repairs necessary shall be made immediately unless directed otherwise in writing by the Contracting Officer.

Laboratory Qualifications and Requirements: The Contractor may be required to use laboratory facilities for analysis of unknown chemicals/materials and potentially contaminated soil, groundwater, or surface water. The analytical laboratory chosen by the Contractor(s) to perform analysis shall be a State of California Certified Laboratory; and certified to perform the required analytical method at the time the tests are conducted. For optional work performed outside of Region 5 and the State of California, the analytical services shall be performed in accordance with the state specific requirements in which the project is located.

Contractor Caused Spills and Releases: The Contractor is solely responsible for any and all spills or leaks and subsequent clean ups that may be required during the performance of this contract which occur as a result of or are contributed to by the actions of its agents, employees, or subcontractors. The Contractor agrees to clean up such spills or leaks to the satisfaction of the Forest Service and in a manner that complies with applicable Federal, state, and local laws and regulations. The cleanup shall be at no cost to the Forest Service. The Forest Service’s EPA/State ID number/s cannot be used for contractor caused spills and/or releases.

The contractor shall provide spill response materials including, but not limited to, containers, shovels and personal protective equipment. Spill response materials shall be available at all times in which hazardous materials and hazardous wastes are being handled or transported. Spill response materials shall be compatible with the type of material being handled or transported.

The contractor shall report all such spills or leaks, regardless of their quantity, to the Forest Service immediately upon discovery. A written follow-up report shall be submitted to the Forest Service no later than 24 hours after the initial telephonic report. The written report shall be in narrative form and as a minimum include the following:

• Description of the item spilled (including identity, quantity, manifest no., etc).

• Whether amount spilled is EPA/state reportable, and if so whether it was reported, and to whom.

• Exact time and location of spill including a description of the area involved.

• Containment procedures initiated.

• Summary of any communications contractor has with press, Federal, state and local regulatory agencies and officials, or Forest Service officials.

Upon completion of the clean-up activities for contractor caused spills and releases, the contractor shall submit a final clean-up certification report to the Forest Service. The report shall include a description of clean-up procedures employed at the site, the final disposition and disposal location of spill residue. Include also copies of all spill related cleanup and closure documentation and correspondence from the regulatory agencies.

Hazardous Material and Hazardous Waste Management: Material/Waste Management on National Forest Lands: The Contractor is responsible for seeing that all materials and wastes generated during the activities of this contract are managed in compliance with Federal, state and local environmental laws and regulations. This includes ensuring that all excavated contaminated soils are immediately placed into appropriate containers upon excavation and not stored directly on the ground.

In those instances where contaminated soil stockpiling is necessary, soils shall be placed on a liner for containment purposes.

The Contractor(s) is responsible for seeing that all containers of hazardous site characterization and remediation wastes generated under the activities of this contract are removed from National Forest lands within the applicable regulatory time frames.

Transporters: For all hazardous wastes transported under this contract, the Contractor shall present at time of offer, all applicable state waste hauler licenses and hauler numbers.

Only experienced, licensed, transporters shall be used to haul hazardous wastes under this contract. The Contractor shall also provide and affix appropriate placards to each vehicle prior to leaving Forest Service premises and ensure that all EPA, DOT and State transporter requirements are met.

The contractor will comply with, and ensure that all applicable subcontractors comply with, all requirements of 49 CFR 100-199, regarding waste transportation under this contract.

Complete compliance with these regulations shall include, but not be limited to, ensuring that emergency response information is carried on transport vehicles and maintained at facilities where hazardous materials are received, stored, or handled during transportation. Shipping papers will contain an emergency response telephone number supplied by the disposal contractor which is monitored 24 hours a day in order to provide immediate, detailed emergency information to personnel reacting to emergencies. Technical names will be included in the descriptions of materials reflected on shipping papers by "not otherwise specified" (n.o.s.) descriptions.

Off-Site Recycling and Treatment/Storage/Disposal Facilities: The Contractor shall identify each recycling and/or TSD facility, which may receive hazardous materials/wastes under this contract. Each TSD facility must have, as a minimum; EPA RCRA permitted or state approval as a treatment or disposal facility and is in good standing with the regulatory community. The Contractor agrees that no facility other than those initially accepted by the Government in the award process will be used. The Forest Service on a case-by-case basis may accept additional TSD facilities.

In an effort to reduce the Region’s future liability for the wastes it generates, ALL wastes and contaminated media managed under this contract shall be sent to only those treatment/ storage/disposal facilities that are in compliance with EPA’s “Off-Site Rule” (40 CFR

300.400 on the U.S. Environmental Protection Agency’s “Off-Site Rule” list. The Contractor shall provide confirmation that the proposed off-site facility is Off-Site Rule compliant prior to the initiation of any shipment.

Deliverables: The USDA Forest Service will generally return comments to the Contractor within three weeks of receipt of a document. The Contractor will be responsible for incorporating all comments or explaining why a comment was not incorporated into the final document.

Site Specific workplans and Final reports shall be submitted to the technical contact as indicated in the general Statement of Work for the Forest Service Region 5 Regional Environmental Services IDIQ Contract. Any deviation from the accepted workplan(s) must be explained in the final report. Site Specific work plans shall be submitted for Forest Service review and approval after award of the Contract. All workplans shall include a wet ink signature and seal by one or more of the following California Registered professionals who have a minimum of five years experience in the environmental field:

• Registered Geologist,

• Certified Engineering Geologist,

• Progessional Engineer,

• Certified Hydro Geologist.

A site specific health and safety plan must be developed and submitted prior to conducting any field work. The health and safety plan must be signed by the Contractor’s Health and Safety Manager. The health and safety plan must be updated throughout the project to reflect new site conditions.

The Contractor’s Project Work Plan shall include, but is not limited to, the following:

• A description of the work to be performed

• A description of how the work will be performed.

• Specific exclusions/ assumptions regarding the specific work to be performed.

• A listing of personnel, including subcontractor(s), working on the project.

• Qualifications and experience of personnel and subcontractors.

• List of equipment and supplies to be utilized.

• “Field Sampling and Analysis Plan” (as required for hazardous material/waste identification, identification of chemical residual and contamination, etc.).

• “Hazardous Material/Waste Management Plan”, which includes waste identification protocol, identification of the proposed treatment, storage and disposal facility for all hazardous and solid wastes generated under the contract. Documentation and certification of the facility’s ability to accept hazardous materials/wastes shall be provided as an attachment to the work plan.

• “Contingency Plan” for addressing emergency spills and releases.

• “Health & Safety Plan”.

• Project Work Schedule and Timeline.

Work under this activity may be subject to oversight and approval of Federal, State (California) and/or local regulatory agencies. The contractor shall be responsible for ensuring that site activities comply with applicable federal and state regulatory requirements. This may entail submitting draft project work plans and reports to the appropriate regulatory agency for review and approval, responding to agency comments and preparing revised work plans and reports. It is the Contractor’s responsibility for ensuring that project work plans and deliverables satisfy applicable regulatory agency requirements.

The Contractor will prepare responses to all review comments for the Government by either incorporating them into the final product or by explaining why the comment was not followed. All reports become the sole property of the Government, and may be used in part or in their entirety, at the Government's discretion. Only the Government can release the information provided in these reports to the public.

Upon completion of the project work under this activity, the Contractor shall provide a electronic copy Final Project Report. The Final Report shall include, but is not limited to:

• A report of the investigation and assessments results, which includes a detailed description and documentation of the site-specific operations performed. Including, but not limited to:

hazardous material identification, sampling and analytical data, and hazardous materials and contaminated media (soil, water) volumes and quantities. The report shall be signed by the registered geologist or professional engineer responsible for the work, as required by the State of California.

• Destination and method of reuse, recycling, or disposal of all waste/contaminated material, including rationale for the selected disposition of said material. The name, address and EPA or State Identification Number of the site shall be included in this section of the report.

• Method of packaging of material/waste to comply with the requirements of this contract and to comply with Federal and State requirements for transportation and disposal. This includes the method of transport and name, address, and EPA-Identification Number of all transporters.

• Itemized costs for handling, transport, and disposal.

• Copies of all signed manifests, land disposal restriction forms, waste profile sheets, laboratory test results, etc.

Use of Government Facilities: This section identifies the facilities and their limits of use that will be available to the contractor.

Utilities – Electricity is available at the site. Water is available .

Equipment Storage – Contractor may temporarily store equipment and vehicles at the project site at locations designated by the Contracting Officer Representative. However, the Government will not be responsible for any damage caused to the Contractor's property.

Sanitary Facilities - The Contractor may use the existing sanitary facilities provided reasonable care is exercised when using them.

Site Operations - In no case shall the Contractor or his work interfere with normal or emergency operations at the project site. (The Contractor shall not block access to the tanker base at any time).

SECTION IV – CONTRACT DOCUMENTS, EXHIBITS, OR ATTACHMENTS

Document Name Pages

1. Wage Determination 11

2. Project Pictures 8

3. Safety Data Sheet 5

SECTION V - SOLICITATION PROVISIONS

52.252-1 Solicitation Provisions Incorporated by Reference (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR) Provisions:

https://www.acquisition.gov/browse/index/far (FAR Provisions begin with 52) Department of Agriculture Acquisition Regulation (AGAR) Provisions:

https://www.acquisition.gov/agar (AGAR Provisions begin with 452) Deviations to provisions may be viewed at: Policies & Regulations | USDA

52.204-7 System for Award Management (OCT 2018)

52.204-16 Commercial and Government Entity Code Reporting (AUG 2020)

52.212-1 Instructions to Offerors – Commercial Products and…