B2_Amd_0001_AE_Civil_Structural_Northern_Central_Statessigned.pdf
PDF 239 KB Posted
- Attached to
- ARCHITECT-ENGINEER (A-E) CIVIL STRUCTURAL IDIQ FOR NORTHERN & CENTRAL STATES OF INTERIOR US
- Solicitation number
- 1240LN26R0001
- Issued by
-
Department of Agriculture Forest Service
About this file
This is an amendment to a federal solicitation issued by the USDA Forest Service Procurement Operations. The amendment modifies solicitation number 1240LN26R0001_0001 for an Architect-Engineer Civil Structural Indefinite Delivery/Indefinite Quantity (IDIQ) contract covering the Northern and Central States of the Interior United States. The sole change made by this amendment is the extension of the proposal submission deadline from August 26, 2026 to September 11, 2026 at 1:30 PM Central Daylight Time. All other terms and conditions of the original solicitation remain unchanged. The amendment was issued on August 18, 2026 and is signed by Crystal Amos, the designated Contracting Officer.
The document also includes the standard Federal Acquisition Regulation (FAR) clause 52.211-12 regarding Liquidated Damages for Construction, which establishes that contractors failing to complete work within the specified timeframe will incur liquidated damages of $160.00 per calendar day of delay until work completion or acceptance.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
United States Department of Agriculture Forest Service Procurement Operations
August 18, 2026
USDA Forest Service
Crystal Amos, Contracting Officer
Procurement Operations
Subject: Special Notice, 1240LN26R0001_0001, Architect-Engineer Civil Structural IDIQ
For Northern & Central States of the Interior US
The purpose of this amendment is to:
Change the submission date from 26 August 2026 to 11 September 2026, 1:30, PM, CDT
All other terms and conditions of this solicitation remain the same.
Sincerely, CRYSTAL AMOS
Contracting Officer
FAR 52.211-12 LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $160.00 for each calendar day of delay until the work is completed or accepted.
(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the
Termination clause.
(End of clause)
Caring for the Land and Serving People Printed on Recycled Paper
| 2026-08-18T14:05:00-0500 | |
| CRYSTAL AMOS |
File details come from the government source that posted it. Updated .