Sol 1107143_Section D-Specifications.pdf

1308 MAIN STREET

LITTLE ROCK, AR 72202

(501) 378-0059 Phone

(501) 378-0415 Fax www.stuckarch.com

Jefferson Laboratories of the FDA SSmmookkee LLaabb –– BBuuiillddiinngg 5533AA

Jefferson, Arkansas

Comm. No. 2-3778-12

July 26, 2012

100% FINAL Submittal http://www.stuckarch.com/

Stuck Associates Table of Contents Smoke Lab July 26, 2012 Page 1 of 2 Building 53A Comm. No. 2-3778-12 Jefferson Laboratories of the FDA

TECHNICAL SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00 Summary 01 30 01 Submittal Log 01 31 00 Project Management and Coordination 01 32 00 Construction Progress Documentation 01 40 00 Quality Requirements 01 50 00 Temporary Facilities and Controls 01 60 00 Product Requirements 01 73 00 Execution 01 77 00 Closeout Procedures 01 78 39 Project Record Documents

DIVISION 02 - SITE CONSTRUCTION

02 41 00 Selective Structure Demolition

DIVISION 03 - CONCRETE

DIVISION 04 - MASONRY

DIVISION 05 – METALS

DIVISION 06 - WOOD AND PLASTICS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 13 Penetration Firestopping 07 92 00 Joint Sealants

DIVISION 08 - DOORS AND WINDOWS

08 11 13 Hollow Metal Doors and Frames 08 71 00 Door Hardware

DIVISION 09 - FINISHES

09 22 16 Non-Structural Metal Framing 09 29 00 Gypsum Board 09 65 13 Resilient Base and Accessories 09 65 16 Resilient Sheet Flooring 09 91 23 Interior Painting 09 96 00 Vinyl Flake Wall Coating 09 96 10 Epoxy Coating for Ceilings

DIVISION 10 – SPECIALTIES

DIVISION 11 – EQUIPMENT

DIVISION 12 – FURNISHINGS

12 31 10 Metal Casework

DIVISION 13 – SPECIAL CONSTRUCTION

DIVISION 14 – CONVEYING EQUIPMENT

Stuck Associates Table of Contents Smoke Lab July 26, 2012 Page 2 of 2 Building 53A Comm. No. 2-3778-12 Jefferson Laboratories of the FDA

DIVISION 23 – MECHANICAL

23 00 10 Mechanical General 23 00 11 Demolition 23 00 15 Through-Penetration Firestop Systems 23 00 30 Electrical Requirements for Mechanical Equipment 23 00 60 Basic Piping 23 01 00 Valves 23 01 30 Piping Specialties 23 01 40 Mechanical Supporting Systems 23 01 60 Mechanical Systems Insulation 23 01 90 Identification 23 04 45 Compressed Air Piping 23 04 47 Process Vacuum Piping 23 06 20 Hydronic Piping 23 07 10 HVAC Sheet Metal 23 07 15 High Pressure Ductwork 23 08 32 Exhaust Fans 23 09 71 Automatic Temperature Controls 23 09 90 Testing, Adjusting, and Balancing

DIVISION 26 – ELECTRICAL

26 00 10 Electrical – General Provisions 26 05 10 Wires and Cables (600 Volt Maximum) 26 05 33 Raceways, Boxes, Fittings and Supports 26 18 00 Wiring Devices 26 19 00 Miscellaneous Equipment 26 51 00 Lighting System

END OF SECTION

Stuck Associates

01 10 00

SUMMARY

Smoke Lab Building 53A

SECTION 01 10 00 - SUMMARY

PART 1 - GENERAL

1.1 SUMMARY

A. Section Includes:

1. Project information.

2. Work covered by Contract Documents.

3. Work under separate contracts.

4. Access to site.

5. Coordination with occupants.

6. Work restrictions.

7. Specification and drawing conventions.

1.2 PROJECT INFORMATION

A. Project Identification: Smoking Lab Renovation, Building 53A, Jefferson Laboratories of the

FDA Architect's Comm. #2-3778-12

B. Owner: Jefferson Laboratories of the FDA

C. Architect: Stuck Associates

1.3 WORK COVERED BY CONTRACT DOCUMENTS

A. The Work of Project is defined by the Contract Documents and consists of the following:

1. Renovation of approximately 190 square feet of lab space. Spaces will be reworked and new finishes provided for new operations. Associates support spaces will require some renovation. Demolition, general construction (including partitions, ceilings, doors, lab casework), mechanical, plumbing, and electrical work will be required. Smoking machines and their components to be furnished and installed by Owner.

B. Type of Contract.

1. Project will be constructed under a single prime contract.

1.4 WORK UNDER SEPARATE CONTRACTS

A. Work: Owner will award separate contract(s) for the following construction operations at

Project site.

B. Owner will purchase and install bio-safety cabinet. connection to building air systems wil be provided under general contractor.

1.5 ACCESS TO SITE

A. General: Contractor shall have limited use of Project site for construction operations as indicated on Drawings by the Contract limits and as indicated by requirements of this Section.

B. Use of Site: Limit use of Project site to areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Driveways, Walkways and Entrances: Keep driveways and entrances serving premises clear and available to Owner, Owner's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

Comm. No.: 2-3778-12 1 of 3 Jefferson Laboratories of the FDA

01 10 00

SUMMARY

Smoke Lab Building 53A

a. Schedule deliveries to minimize use of driveways and entrances by construction operations.

b. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

C. Condition of Existing Building: Maintain portions of existing building affected by construction operations in a weathertight condition throughout construction period. Repair damage caused by construction operations.

1.6 COORDINATION WITH OCCUPANTS

A. Partial Owner Occupancy: Owner will occupy the premises during entire construction period, with the exception of areas under construction. Cooperate with Owner during construction operations to minimize conflicts and facilitate Owner usage. Perform the Work so as not to interfere with Owner's operations. Maintain existing exits unless otherwise indicated.

1. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from Owner and authorities having jurisdiction.

2. Provide not less than 72 hours' notice to Owner of activities that will affect Owner's operations.

1.7 WORK RESTRICTIONS

A. Work Restrictions, General: Comply with restrictions on construction operations.

B. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Owner or others unless permitted under the following conditions and then only after providing temporary utility services according to requirements indicated:

1. Notify Owner not less than two days in advance of proposed utility interruptions.

2. Obtain Owner's written permission before proceeding with utility interruptions.

C. Noise, Vibration, and Odors: Coordinate operations that may result in high levels of noise and vibration, odors, or other disruption to Owner occupancy with Owner.

1. Notify Owner not less than two days in advance of proposed disruptive operations.

2. Obtain Owner's written permission before proceeding with disruptive operations.

1.8 SPECIFICATION AND DRAWING CONVENTIONS

A. Specification Content: The Specifications use certain conventions for the style of language and the intended meaning of certain terms, words, and phrases when used in particular situations. These conventions are as follows:

1. Imperative mood and streamlined language are generally used in the Specifications.

The words "shall," "shall be," or "shall comply with," depending on the context, are implied where a colon (:) is used within a sentence or phrase.

2. Specification requirements are to be performed by Contractor unless specifically stated otherwise.

B. Division 01 General Requirements: Requirements of Sections in Division 01 apply to the Work of all Sections in the Specifications.

C. Drawing Coordination: Requirements for materials and products identified on Drawings are described in detail in the Specifications. One or more of the following are used on Drawings to identify materials and products:

Comm. No.: 2-3778-12 2 of 3 Jefferson Laboratories of the FDA

Comm. No.: 2-3778-12

01 10 00

SUMMARY

Smoke Lab Building 53A

1. Terminology: Materials and products are identified by the typical generic terms used in the individual Specifications Sections.

2. Abbreviations: Materials and products are identified by abbreviations published as part of the U.S. National CAD Standard and scheduled on Drawings.

3. Keynoting: Materials and products are identified by reference keynotes referencing Specification Section numbers found in this Project Manual.

PART 2 - PRODUCTS (Not Used) PART 3 - EXECUTION (Not Used)

Stuck Associates Section 01 30 01 Smoke Lab July 26, 2012 SUBMITTAL LOG Building 53A Comm. No. 2-3778-12 Page 1 of 2 Jefferson Laboratories of the FDA

SECTION 01 30 01

SUBMITTAL LOG

SPEC

NO.

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

01 32 00 CONSTRUCTION PROGRESS DOCUMENTATION

Schedule X

01 40 00 QUALITY REQUIREMENTS

Independent Agency Field Testing X Certificates X Inspection Log X

01 60 00 PRODUCT REQUIREMENTS

Comparable Product log X

01 77 00 CLOSEOUT PROCEDURES

Product Data X List of Incomplete Items X Project Warranties X

01 78 39 PROJECT RECORD DRAWINGS

Record Drawing X Record Specifications X Record Product Data X

07 84 13 FIRESTOPPING

Product Schedule X

07 92 00 JOINT SEALERS

Product Test Reports X

08 11 13 HOLLOW METAL DOORS AND FRAMES

Shop Drawings X

Schedule X

08 71 00 DOOR HARDWARE

Hardware Schedules X Product Data X Substitution Samples X Templates X

09 22 16 NON STRUCTURAL METAL FRAMING

09 29 00 GYPSUM BOARD

09 65 13 RESILIENT BASE & ACCESSORIES

Stuck Associates Section 01 30 01 Smoke Lab July 26, 2012 SUBMITTAL LOG Building 53A Comm. No. 2-3778-12 Page 2 of 2 Jefferson Laboratories of the FDA

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

09 65 16 RESILIENT SHEET FLOORING

Samples X

09 66 00 VINYL FLAKE WALL COATING

Samples X Maintenance Instructions X Installers Qualifications X

09 66 10 Epoxy Coatings for Ceilings

Samples X Maintenance Instructions X Installers Qualifications X

09 90 00 INTERIOR PAINTING

Samples X Product List X Installer Qualifications X Extra Materials X

12 31 10 METAL CASEWORK

Manufacturers Qualifications X

Comm. No.: 2-3778-12

01 30 01-23

SUBMITTAL LOG - DIVISION 23

Smoke Lab

DIVISION 23 - MECHANICAL

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

23 00 15 THROUGH-PENETRATION FIRESTOP SYSTEMS

Product Data X

Installation Instructions X

Shop Drawings X

Statement of Qualifications X

23 00 40 VARIABLE FREQUENCY DRIVES

Product Data X

Test Data X

Maintenance Data X

23 00 60 BASIC PIPING

Product Data X

Welders Certificates X

23 01 10 VALVES

Product Data X

23 01 30 PIPING SPECIALTIES

Product Data X

23 01 40 MECHANICAL SUPPORTING SYSTEMS

Shop Drawings X

Product Data X

Installation Instructions X

Start Up Logs X

23 01 60 MECHANICAL SYSTEMS INSULATION

Product Data X

23 01 90 IDENTIFICATION

Valve Schedule X

Comm. No.: 2-3778-12

01 30 01-23

SUBMITTAL LOG - DIVISION 23

Smoke Lab

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

23 04 45 COMPRESSED AIR PIPING

Product Data X

Tests X

23 04 47 PROCESS VACUUM PIPING

Product Data X

Tests X

23 06 15 STEAM PIPING

Product Data X

Tests X

23 06 20 HYDRONIC PIPING

Product Data X

Tests X

23 07 10 HVAC SHEET METAL

Product Data X

Duct Sealant Product Data X

Duct Leak Tests X

23 07 15 HIGH PRESSURE DUCTWORK

Product Data X

Duct Sealant Product Data X

Duct Leak Tests X

23 08 32 EXHAUST FANS

Product Data X

Tests X

Maintenance Data X

23 08 95 AIR TERMINAL DEVICES

Product Data X

23 09 71 AUTOMATIC TEMP CONTROLS

Comm. No.: 2-3778-12

01 30 01-23

SUBMITTAL LOG - DIVISION 23

Smoke Lab

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

23 09 90 TESTING, ADJUSTING & BALANCING

Instrument List X

Test List X

Certification X

Test and Balance Reports X

Comm. No.: 2-3778-12

01 30 01-26

SUBMITTAL LOG - DIVISION 26

Smoke Lab

DIVISION 26 - ELECTRICAL

SPEC. SECTION

TITLE DESCRIPTION OF SUBMITTAL

SUBMIT FOR

REVIEW

SUBMIT FOR

INFORMATION

26 05 10 WIRES AND CABLES (600 VOLT MAXIMUM)

Product Data X

Shop Drawings X

26 05 33 RACEWAYS, BOXES, FITTINGS AND SUPPORTS

Product Data X

26 18 00 WIRING DEVICES

Product Data X

Shop Drawings X

26 19 00 MISCELLANEOUS EQUIPMENT

Product Data X

Shop Drawings X

26 51 00 LIGHTING SYSTEM

01 31 00

PROJECT MANAGEMENT AND

Smoke Lab Building 53A

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Coordination drawings.

2. Requests for Information (RFIs).

3. Project meetings.

1.2 DEFINITIONS

A. RFI: Request from Owner, Architect, or Contractor seeking information required by or clarifications of the Contract Documents.

1.3 GENERAL COORDINATION PROCEDURES

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work.

Coordinate construction operations, included in different Sections, that depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

1. Prepare similar memoranda for Owner and separate contractors if coordination of their Work is required.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's construction schedule.

2. Preparation of the schedule of values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Preinstallation conferences.

7. Project closeout activities.

8. Startup and adjustment of systems.

1.4 COORDINATION DRAWINGS

A. Coordination Drawings, General: Prepare coordination drawings according to requirements in individual Sections, where installation is not completely shown on Shop Drawings, where

Comm. No.: 2-3778-12 COORDINATION

01 31 00

PROJECT MANAGEMENT AND

Smoke Lab Building 53A limited space availability necessitates coordination, or if coordination is required to facilitate integration of products and materials fabricated or installed by more than one entity.

1. Content: Project-specific information, drawn accurately to a scale large enough to indicate and resolve conflicts. Do not base coordination drawings on standard printed data. Include the following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on the Drawings. Specifically note dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to Architect indicating proposed resolution of such conflicts. Minor dimension changes and difficult installations will not be considered changes to the Contract.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI in the form specified.

1. Contracting Officer's Representative will return RFIs submitted to Contracting Officer's Representative by other entities controlled by Contractor with no response.

2. Coordinate and submit RFIs in a prompt manner so as to avoid delays in Contractor's work or work of subcontractors.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. Project name.

2. Project number.

3. Date.

4. Name of Contractor.

5. Name of Architect.

6. RFI number, numbered sequentially.

7. RFI subject.

8. Specification Section number and title and related paragraphs, as appropriate.

9. Drawing number and detail references, as appropriate.

10. Field dimensions and conditions, as appropriate.

11. Contractor's suggested resolution. If Contractor's solution(s) impacts the Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

12. Contractor's signature.

13. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

C. RFI Forms: AIA Document G716 Software-generated form with substantially the same content as indicated above, acceptable to Architect.

D. Contracting Officer's Representative Action: Contracting Officer's Representative will review each RFI, determine action required, and respond. Allow seven working days for Architect's response for each RFI. RFIs received by Contracting Officer's Representative after 1:00 p.m. will be considered as received the following working day.

Comm. No.: 2-3778-12 COORDINATION

01 31 00

PROJECT MANAGEMENT AND

Smoke Lab Building 53A

1. The following RFIs will be returned without action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for coordination information already indicated in the Contract Documents.

d. Requests for adjustments in the Contract Time or the Contract Sum.

e. Requests for interpretation of Architect's actions on submittals.

f. Incomplete RFIs or inaccurately prepared RFIs.

2. Contracting Officer's Representative action may include a request for additional information, in which case Contracting Officer's Representative time for response will date from time of receipt of additional information.

3. Contracting Officer's Representative action on RFIs that may result in a change to the Contract Time or the Contract Sum may be eligible for Contractor to submit Change Proposal according to Section 012600 "Contract Modification Procedures."

a. If Contractor believes the RFI response warrants change in the Contract Time or the Contract Sum, notify Contracting Officer's Representative in writing within 10 days of receipt of the RFI response.

E. RFI Log: Prepare, maintain, and submit a tabular log of RFIs organized by the RFI number.

Submit log weekly. Software log with not less than the following:

1. Project name.

2. Name and address of Contractor.

3. Name and address of Architect.

4. RFI number including RFIs that were dropped and not submitted.

5. RFI description.

6. Date the RFI was submitted.

7. Date Architect's response was received.

F. On receipt of Contracting Officer's Representative action, update the RFI log and immediately distribute the RFI response to affected parties. Review response and notify Contracting Officer's Representative within seven days if Contractor disagrees with response.

1. Identification of related Minor Change in the Work, Construction Change Directive, and Proposal Request, as appropriate.

1.6 PROJECT MEETINGS

A. General: Schedule and conduct meetings and conferences at Project site unless otherwise indicated.

1. Attendees: Inform participants and others involved, and individuals whose presence is required, of date and time of each meeting. Notify Owner of scheduled meeting dates and times.

2. Agenda: Prepare the meeting agenda. Distribute the agenda to all invited attendees.

3. Minutes: Entity responsible for conducting meeting will record significant discussions and agreements achieved. Distribute the meeting minutes to everyone concerned, including Owner within three days of the meeting.

Comm. No.: 2-3778-12 COORDINATION

Comm. No.: 2-3778-12

01 31 00

PROJECT MANAGEMENT AND

COORDINATION

Smoke Lab

B. Preconstruction Conference: Schedule and conduct a preconstruction conference before starting construction, at a time convenient to Owner and Architect, but no later than 15 days after execution of the Agreement.

1. Attendees: Authorized representatives of Owner ; Contractor and its superintendent; major subcontractors; suppliers; and other concerned parties shall attend the conference. Participants at the conference shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Minutes: Entity responsible for conducting meeting will record and distribute meeting minutes.

C. Progress Meetings: Conduct progress meetings at biweekly intervals.

1. Attendees: In addition to representatives of Owner , each contractor, subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting.

Review other items of significance that could affect progress. Include topics for discussion as appropriate to status of Project.

3. Minutes: Entity responsible for conducting the meeting will record and distribute the meeting minutes to each party present and to parties requiring information.

a. Schedule Updating: Revise Contractor's construction schedule after each progress meeting where revisions to the schedule have been made or recognized. Issue revised schedule concurrently with the report of each meeting.

PART 2 - PRODUCTS (Not Used)

01 32 00

CONSTRUCTION PROGRESS

Smoke Lab Building 53A

SECTION 01 32 00 - CONSTRUCTION PROGRESS DOCUMENTATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for documenting the progress of construction during performance of the Work, including the following:

1. Contractor's construction schedule.

1.2 COORDINATION

A. Coordinate Contractor's construction schedule with the schedule of values, submittal schedule, progress reports, payment requests, and other required schedules and reports.

1. Secure time commitments for performing critical elements of the Work from entities involved.

PART 2 - PRODUCTS

2.1 CONTRACTOR'S CONSTRUCTION SCHEDULE (GANTT CHART)

A. Gantt-Chart Schedule: Submit a comprehensive, fully developed, horizontal, Gantt-chart-type, Contractor's construction schedule within 30 days of date established for the Notice to Proceed.

B. Preparation: Indicate each significant construction activity separately. Identify first workday of each week with a continuous vertical line.

1. For construction activities that require three months or longer to complete, indicate an estimated completion percentage in 10 percent increments within time bar.

PART 3 - EXECUTION

3.1 CONTRACTOR'S CONSTRUCTION SCHEDULE

A. Contractor's Construction Schedule Updating: At monthly intervals, update schedule to reflect actual construction progress and activities. Issue schedule one week before each regularly scheduled progress meeting.

B. Distribution: Distribute copies of approved schedule to Owner, separate contractors, testing and inspecting agencies, and other parties identified by Contractor with a need-to-know schedule responsibility.

END OF SECTION

Comm. No.: 2-3778-12 DOCUMENTATION

01 40 00

QUALITY REQUIREMENTS

Smoke Lab Building 53A

SECTION 01 40 00 - QUALITY REQUIREMENTS

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for quality assurance and quality control.

B. Testing and inspecting services are required to verify compliance with requirements specified or indicated. These services do not relieve Contractor of responsibility for compliance with the Contract Document requirements.

1. Specified tests, inspections, and related actions do not limit Contractor's other quality-assurance and -control procedures that facilitate compliance with the Contract Document requirements.

2. Requirements for Contractor to provide quality-assurance and -control services required by Architect, Owner, or authorities having jurisdiction are not limited by provisions of this Section.

3. Specific test and inspection requirements are not specified in this Section.

1.2 DEFINITIONS

A. Quality-Assurance Services: Activities, actions, and procedures performed before and during execution of the Work to guard against defects and deficiencies and substantiate that proposed construction will comply with requirements.

B. Product Testing: Tests and inspections that are performed by an NRTL, an NVLAP, or a testing agency qualified to conduct product testing and acceptable to authorities having jurisdiction, to establish product performance and compliance with specified requirements.

C. Source Quality-Control Testing: Tests and inspections that are performed at the source, e.g., plant, mill, factory, or shop.

D. Field Quality-Control Testing: Tests and inspections that are performed on-site for installation of the Work and for completed Work.

E. Testing Agency: An entity engaged to perform specific tests, inspections, or both. Testing laboratory shall mean the same as testing agency.

F. Installer/Applicator/Erector: Contractor or another entity engaged by Contractor as an employee, Subcontractor, or Sub-subcontractor, to perform a particular construction operation, including installation, erection, application, and similar operations.

1. Use of trade-specific terminology in referring to a trade or entity does not require that certain construction activities be performed by accredited or unionized individuals, or that requirements specified apply exclusively to specific trade(s).

G. Experienced: When used with an entity or individual, "experienced" means having successfully completed a minimum of five previous projects similar in nature, size, and extent to this Project; being familiar with special requirements indicated; and having complied with requirements of authorities having jurisdiction.

1.3 CONFLICTING REQUIREMENTS

A. Referenced Standards: If compliance with two or more standards is specified and the standards establish different or conflicting requirements for minimum quantities or quality levels, comply with the most stringent requirement. Refer conflicting requirements that are different, but apparently equal, to Architect for a decision before proceeding.

B. Minimum Quantity or Quality Levels: The quantity or quality level shown or specified shall be the minimum provided or performed. The actual installation may comply exactly with the

Comm. No.: 2-3778-12 1 of 4 Jefferson Laboratories of the FDA

01 40 00

QUALITY REQUIREMENTS

Smoke Lab Building 53A minimum quantity or quality specified, or it may exceed the minimum within reasonable limits. To comply with these requirements, indicated numeric values are minimum or maximum, as appropriate, for the context of requirements. Refer uncertainties to Contracting Officer's Representative for a decision before proceeding.

1.4 REPORTS AND DOCUMENTS

A. Test and Inspection Reports: Prepare and submit certified written reports specified in other

Sections. Include the following:

1. Date of issue.

2. Project title and number.

3. Name, address, and telephone number of testing agency.

4. Dates and locations of samples and tests or inspections.

5. Names of individuals making tests and inspections.

6. Description of the Work and test and inspection method.

7. Identification of product and Specification Section.

8. Complete test or inspection data.

9. Test and inspection results and an interpretation of test results.

10. Name and signature of laboratory inspector.

11. Recommendations on retesting and reinspecting.

B. Manufacturer's Field Reports: Prepare written information documenting tests and inspections specified in other Sections. Include the following:

1. Name, address, and telephone number of representative making report.

2. Statement on condition of substrates and their acceptability for installation of product.

3. Summary of installation procedures being followed, whether they comply with requirements and, if not, what corrective action was taken.

4. Results of operational and other tests and a statement of whether observed performance complies with requirements.

5. Other required items indicated in individual Specification Sections.

C. Permits, Licenses, and Certificates: For Owner's records, submit copies of permits, licenses, certifications, inspection reports, releases, jurisdictional settlements, notices, receipts for fee payments, judgments, correspondence, records, and similar documents, established for compliance with standards and regulations bearing on performance of the Work.

1.5 QUALITY ASSURANCE

A. General: Qualifications paragraphs in this article establish the minimum qualification levels required; individual Specification Sections specify additional requirements.

B. Manufacturer Qualifications: A firm experienced in manufacturing products or systems similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capacity to produce required units.

C. Fabricator Qualifications: A firm experienced in producing products similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capacity to produce required units.

Comm. No.: 2-3778-12 2 of 4 Jefferson Laboratories of the FDA

01 40 00

QUALITY REQUIREMENTS

Smoke Lab Building 53A

D. Installer Qualifications: A firm or individual experienced in installing, erecting, or assembling work similar in material, design, and extent to that indicated for this Project, whose work has resulted in construction with a record of successful in-service performance.

E. Professional Engineer Qualifications: A professional engineer who is legally qualified to practice in jurisdiction where Project is located and who is experienced in providing engineering services of the kind indicated. Engineering services are defined as those performed for installations of the system, assembly, or product that are similar in material, design, and extent to those indicated for this Project.

F. Testing Agency Qualifications: An NRTL, an NVLAP, or an independent agency with the experience and capability to conduct testing and inspecting indicated, as documented according to ASTM E 329; and with additional qualifications specified in individual Sections;

and, where required by authorities having jurisdiction, that is acceptable to authorities.

1. NRTL: A nationally recognized testing laboratory according to 29 CFR 1910.7.

2. NVLAP: A testing agency accredited according to NIST's National Voluntary Laboratory Accreditation Program.

G. Manufacturer's Representative Qualifications: An authorized representative of manufacturer who is trained and approved by manufacturer to observe and inspect installation of manufacturer's products that are similar in material, design, and extent to those indicated for this Project.

1.6 QUALITY CONTROL

A. Contractor Responsibilities: Tests and inspections not explicitly assigned to Owner are

Contractor's responsibility. Perform additional quality-control activities required to verify that the Work complies with requirements, whether specified or not.

B. Manufacturer's Field Services: Where indicated, engage a manufacturer's representative to observe and inspect the Work. Manufacturer's representative's services include examination of substrates and conditions, verification of materials, inspection of completed portions of the Work, and submittal of written reports.

C. Retesting/Reinspecting: Regardless of whether original tests or inspections were Contractor's responsibility, provide quality-control services, including retesting and reinspecting, for construction that replaced Work that failed to comply with the Contract Documents.

D. Testing Agency Responsibilities: Cooperate with Contracting Officer's Representative and Contractor in performance of duties. Provide qualified personnel to perform required tests and inspections.

1. Notify Contracting Officer's Representative and Contractor promptly of irregularities or deficiencies observed in the Work during performance of its services.

E. Associated Services: Cooperate with agencies performing required tests, inspections, and similar quality-control services, and provide reasonable auxiliary services as requested.

Notify agency sufficiently in advance of operations to permit assignment of personnel.

Provide the following:

1. Access to the Work.

2. Incidental labor and facilities necessary to facilitate tests and inspections.

3. Adequate quantities of representative samples of materials that require testing and inspecting. Assist agency in obtaining samples.

4. Facilities for storage and field curing of test samples.

5. Delivery of samples to testing agencies.

Comm. No.: 2-3778-12 3 of 4 Jefferson Laboratories of the FDA

Comm. No.: 2-3778-12

01 40 00

QUALITY REQUIREMENTS

Smoke Lab

6. Preliminary design mix proposed for use for material mixes that require control by testing agency.

7. Security and protection for samples and for testing and inspecting equipment at Project site.

F. Coordination: Coordinate sequence of activities to accommodate required quality-assurance and -control services with a minimum of delay and to avoid necessity of removing and replacing construction to accommodate testing and inspecting.

1. Schedule times for tests, inspections, obtaining samples, and similar activities.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 TEST AND INSPECTION LOG

A. Test and Inspection Log: Prepare a record of tests and inspections. Include the following:

1. Date test or inspection was conducted.

2. Description of the Work tested or inspected.

3. Date test or inspection results were transmitted to Contracting Officer's Representative.

4. Identification of testing agency or special inspector conducting test or inspection.

B. Maintain log at Project site. Post changes and revisions as they occur. Provide access to test and inspection log for Contracting Officer's Representative reference during normal working hours.

3.2 REPAIR AND PROTECTION

A. General: On completion of testing, inspecting, sample taking, and similar services, repair damaged construction and restore substrates and finishes.

1. Provide materials and comply with installation requirements specified in other Specification Sections or matching existing substrates and finishes. Restore patched areas and extend restoration into adjoining areas with durable seams that are as invisible as possible. Comply with the Contract Document requirements for cutting and patching in Section 017300 "Execution."

B. Protect construction exposed by or for quality-control service activities.

C. Repair and protection are Contractor's responsibility, regardless of the assignment of responsibility for quality-control services.

01 50 00

TEMPORARY FACILITIES AND

Smoke Lab Building 53A

SECTION 01 50 00 - TEMPORARY FACILITIES AND CONTROLS

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes requirements for temporary utilities, support facilities, and security and protection facilities.

1.2 PROJECT CONDITIONS

A. Temporary Use of Permanent Facilities: Engage Installer of each permanent service to assume responsibility for operation, maintenance, and protection of each permanent service during its use as a construction facility before Owner's acceptance, regardless of previously assigned responsibilities.

PART 2 - PRODUCTS

PART 3 - EXECUTION

3.1 INSTALLATION, GENERAL

A. Locate facilities where they will serve Project adequately and result in minimum interference with performance of the Work. Relocate and modify facilities as required by progress of the Work.

B. Provide each facility ready for use when needed to avoid delay. Do not remove until facilities are no longer needed or are replaced by authorized use of completed permanent facilities.

3.2 TEMPORARY UTILITY INSTALLATION

A. Electric Power Service: Connect to Owner's existing electric power service. Maintain equipment in a condition acceptable to Owner.

B. Lighting: Provide temporary lighting with local switching that provides adequate illumination for construction operations, observations, inspections, and traffic conditions.

3.3 SUPPORT FACILITIES INSTALLATION

A. General: Comply with the following:

1. Maintain support facilities until Contracting Officer's Representative schedules Substantial Completion inspection. Remove before Substantial Completion.

Personnel remaining after Substantial Completion will be permitted to use permanent facilities, under conditions acceptable to Owner.

B. Waste Disposal Facilities: Provide waste-collection containers in sizes adequate to handle waste from construction operations. Comply with requirements of authorities having jurisdiction. Comply with progress cleaning requirements in Section 017300 "Execution."

3.4 OPERATION, TERMINATION, AND REMOVAL

A. Supervision: Enforce strict discipline in use of temporary facilities. To minimize waste and abuse, limit availability of temporary facilities to essential and intended uses.

B. Maintenance: Maintain facilities in good operating condition until removal.

1. Maintain operation of temporary enclosures, heating, cooling, humidity control, ventilation, and similar facilities on a 24-hour basis where required to achieve indicated results and to avoid possibility of damage.

C. Temporary Facility Changeover: Do not change over from using temporary security and protection facilities to permanent facilities until Substantial Completion.

Comm. No.: 2-3778-12 CONTROLS

Comm. No.: 2-3778-12

01 50 00

TEMPORARY FACILITIES AND

CONTROLS

Smoke Lab

D. Termination and Removal: Remove each temporary facility when need for its service has ended, when it has been replaced by authorized use of a permanent facility, or no later than Substantial Completion. Complete or, if necessary, restore permanent construction that may have been delayed because of interference with temporary facility. Repair damaged Work, clean exposed surfaces, and replace construction that cannot be satisfactorily repaired.

1. Materials and facilities that constitute temporary facilities are property of Contractor.

Owner reserves right to take possession of Project identification signs.

2. At Substantial Completion, repair, renovate, and clean permanent facilities used during construction period. Comply with final cleaning requirements specified in Section 017700 "Closeout Procedures."

01 60 00

PRODUCT REQUIREMENTS

Smoke Lab Building 53A

SECTION 01 60 00 - PRODUCT REQUIREMENTS

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for selection of products for use in Project; product delivery, storage, and handling; manufacturers' standard warranties on products; special warranties; and comparable products.

1.2 DEFINITIONS

A. Products: Items obtained for incorporating into the Work, whether purchased for Project or taken from previously purchased stock. The term "product" includes the terms "material," "equipment," "system," and terms of similar intent.

1. Named Products: Items identified by manufacturer's product name, including make or model number or other designation shown or listed in manufacturer's published product literature, that is current as of date of the Contract Documents.

2. New Products: Items that have not previously been incorporated into another project or facility. Products salvaged or recycled from other projects are not considered new products.

3. Comparable Product: Product that is demonstrated and approved through submittal process to have the indicated qualities related to type, function, dimension, in-service performance, physical properties, appearance, and other characteristics that equal or exceed those of specified product.

1.3 ACTION SUBMITTALS

A. Comparable Product Requests: Submit request for consideration of each comparable product. Identify product or fabrication or installation method to be replaced. Include Specification Section number and title and Drawing numbers and titles.

1. Contracting Officer's Representative Action: If necessary, Contracting Officer's Representative will request additional information or documentation for evaluation within one week of receipt of a comparable product request. Contracting Officer's Representative will notify Contractor of approval or rejection of proposed comparable product request within 15 days of receipt of request, or seven days of receipt of additional information or documentation, whichever is later.

1.4 PRODUCT DELIVERY, STORAGE, AND HANDLING

A. Deliver, store, and handle products using means and methods that will prevent damage, deterioration, and loss, including theft and vandalism. Comply with manufacturer's written instructions.

B. Delivery and Handling:

1. Schedule delivery to minimize long-term storage at Project site and to prevent overcrowding of construction spaces.

2. Coordinate delivery with installation time to ensure minimum holding time for items that are flammable, hazardous, easily damaged, or sensitive to deterioration, theft, and other losses.

3. Deliver products to Project site in an undamaged condition in manufacturer's original sealed container or other packaging system, complete with labels and instructions for handling, storing, unpacking, protecting, and installing.

4. Inspect products on delivery to determine compliance with the Contract Documents and to determine that products are undamaged and properly protected.

01 60 00

PRODUCT REQUIREMENTS

Smoke Lab Building 53A

C. Storage:

1. Store products to allow for inspection and measurement of quantity or counting of units.

2. Store materials in a manner that will not endanger Project structure.

3. Store products that are subject to damage by the elements, under cover in a weathertight enclosure above ground, with ventilation adequate to prevent condensation.

4. Protect foam plastic from exposure to sunlight, except to extent necessary for period of installation and concealment.

5. Comply with product manufacturer's written instructions for temperature, humidity, ventilation, and weather-protection requirements for storage.

6. Protect stored products from damage and liquids from freezing.

1.5 PRODUCT WARRANTIES

A. Warranties specified in other Sections shall be in addition to, and run concurrent with, other warranties required by the Contract Documents. Manufacturer's disclaimers and limitations on product warranties do not relieve Contractor of obligations under requirements of the Contract Documents.

1. Manufacturer's Warranty: Written warranty furnished by individual manufacturer for a particular product and specifically endorsed by manufacturer to Owner.

2. Special Warranty: Written warranty required by the Contract Documents to provide specific rights for Owner.

B. Special Warranties: Prepare a written document that contains appropriate terms and identification, ready for execution.

1. Manufacturer's Standard Form: Modified to include Project-specific information and properly executed.

2. Specified Form: When specified forms are included with the Specifications, prepare a written document using indicated form properly executed.

3. Refer to other Sections for specific content requirements and particular requirements for submitting special warranties.

C. Submittal Time: Comply with requirements in Section 017700 "Closeout Procedures."

PART 2 - PRODUCTS

2.1 PRODUCT SELECTION PROCEDURES

A. General Product Requirements: Provide products that comply with the Contract Documents, are undamaged and, unless otherwise indicated, are new at time of installation.

1. Provide products complete with accessories, trim, finish, fasteners, and other items needed for a complete installation and indicated use and effect.

2. Standard Products: If available, and unless custom products or nonstandard options are specified, provide standard products of types that have been produced and used successfully in similar situations on other projects.

3. Owner reserves the right to limit selection to products with warranties not in conflict with requirements of the Contract Documents.

4. Descriptive, performance, and reference standard requirements in the Specifications establish salient characteristics of products.

B. Product Selection Procedures:

Comm. No.: 2-3778-12

01 60 00

PRODUCT REQUIREMENTS

Smoke Lab

1. Manufacturer/Source: Where Specifications name a single manufacturer or source, provide a product by the named manufacturer or source that complies with requirements. Comparable products or substitutions for Contractor's convenience will not be considered.

C. Visual Matching Specification: Where Specifications require "match Architect's sample", provide a product that complies with requirements and matches Architect's sample.

Contracting Officer's Representativedecision will be final on whether a proposed product matches.

2.2 COMPARABLE PRODUCTS

A. Conditions for Consideration: Contracting Officer's Representative will consider

Contractor's request for comparable product when the following conditions are satisfied. If the following conditions are not satisfied, Contracting Officer's Representative may return requests without action, except to record noncompliance with these requirements:

1. Evidence that the proposed product does not require revisions to the Contract Documents, that it is consistent with the Contract Documents and will produce the indicated results, and that it is compatible with other portions of the Work.

2. Detailed comparison of significant qualities of proposed product with those named in the Specifications. Significant qualities include attributes such as performance, weight, size, durability, visual effect, and specific features and requirements indicated.

3. Evidence that proposed product provides specified warranty.

4. Samples, if requested.

01 73 00

EXECUTION

Smoke Lab Building 53A

SECTION 01 73 00 - EXECUTION

PART 1 - GENERAL

1.1 QUALITY ASSURANCE

A. Cutting and Patching: Comply with requirements for and limitations on cutting and patching of construction elements.

1. Operational Elements: Do not cut and patch operating elements and related components in a manner that results in reducing their capacity to perform as intended or that results in increased maintenance or decreased operational life or safety.

2. Other Construction Elements: Do not cut and patch other construction elements or components in a manner that could change their load-carrying capacity, that results in reducing their capacity to perform as intended, or that results in increased maintenance or decreased operational life or safety.

3. Visual Elements: Do not cut and patch construction in a manner that results in visual evidence of cutting and patching. Do not cut and patch exposed construction in a manner that would, in Architect's opinion, reduce the building's aesthetic qualities. Remove and replace construction that has been cut and patched in a visually unsatisfactory manner.

PART 2 - PRODUCTS

2.1 MATERIALS

A. General: Comply with requirements specified in other Sections.

B. In-Place Materials: Use materials for patching identical to in-place materials. For exposed surfaces, use materials that visually match in-place adjacent surfaces to the fullest extent possible.

1. If identical materials are unavailable or cannot be used, use materials that, when installed, will provide a match acceptable to Contracting Officer's Representative for the visual and functional performance of in-place materials.

PART 3 - EXECUTION

3.1 EXAMINATION

A. Existing Conditions: The existence and location of utilities and construction indicated as existing are not guaranteed. Before beginning sitework, investigate and verify the existence and location of underground utilities, mechanical and electrical systems, and other construction affecting the Work.

1. Before construction, verify the location and invert elevation at points of connection of sanitary sewer, storm sewer, and water-service piping; electrical services, and other utilities.

2. Furnish location data for work related to Project that must be performed by public utilities serving Project site.

B. Examination and Acceptance of Conditions: Before proceeding with each component of the Work, examine substrates, areas, and conditions, with Installer or Applicator present where indicated, for compliance with requirements for installation tolerances and other conditions affecting performance. Record observations.

1. Examine roughing-in for mechanical and electrical systems to verify actual locations of connections before equipment and fixture installation.

Comm. No.: 2-3778-12 1 of 2 Jefferson Laboratories of the FDA

Comm. No.: 2-3778-12

01 73 00

EXECUTION

Smoke Lab

2. Examine walls, floors, and roofs for suitable conditions where products and systems are to be installed.

3. Verify compatibility with and suitability of substrates, including compatibility with existing finishes or primers.

C. Proceed with installation only after unsatisfactory conditions have been corrected.

Proceeding with the Work indicates acceptance of surfaces and conditions.

3.2 PREPARATION

A. Field Measurements: Take field measurements as required to fit the Work properly.

Recheck measurements before installing each product. Where portions of the Work are indicated to fit to other construction, verify dimensions of other construction by field measurements before fabrication. Coordinate fabrication schedule with construction progress to avoid delaying the Work.

B. Space Requirements: Verify space requirements and dimensions of items shown diagrammatically on Drawings.

C. Review of Contract Documents and Field Conditions: Immediately on discovery of the need for clarification of the Contract Documents caused by differing field conditions outside the control of Contractor, submit a request for information to Contracting Officer's Representative according to requirements in Section 013100 "Project Management and Coordination."

01 77 00

CLOSEOUT PROCEDURES

Smoke Lab Building 53A

SECTION 01 77 00 - CLOSEOUT PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for contract closeout, including, but not limited to, the following:

1. Substantial Completion procedures.

2. Final completion…