03 Solicitation - W912PB26BA010.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Patrick.Ferguson Line

Patrick.Ferguson Line

Section A - Solicitation/Contract Form

Repair Transformer Station 9, Range 301, USAG Bavaria, Grafenwoehr Instrument Name:

Training Area

Product Service Code : Z2NZ

W912PB26BA010

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quanti ty

Unit Unit Price Amount

0001 Project# 42A-01014-1P, Repair Transformer Station 9 at Range 301, USAG Bavaria, Grafenwoehr Training Area in accordance with the Specification in Attachment I, dated 09 July 26, 60 pages, and Attachment II, Photos and Attachment III, Layout.

Product Service Code: Z2NZ

North American Industry Classification System (NAICS):

238990

Pricing Arrangement: Firm Fixed Price

1 Job

Section C - Description/Specifications/Statement of Work

See Attachment I for the specification.

*** END OF NARRATIVE ***

Requirements Project # 42A-01014-1P, Repair Transformer station 9 at Range 301, USAG Bavaria, Grafenwoehr Training Area

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Full Text

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.246-12 Inspection of Construction. 1996-08

Inspection of Construction (Aug 1996)

(a) Definition."Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements.

The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not-

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this- section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary.

The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may-

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor;

or

(2) Terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction.

However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

Overall Contract Inspection/Acceptance Locations

0001 Inspection and Acceptance Location

Both Destination Instructions: COR WILL CONDUCT INSPECTION AND ACCEPTANCE.

DoDAAC: W90S01 CountryCode: DEU

W6FM USAG BAVARIA

DPW ENGINEERING DIVISION BLDG 329, EAST CAMP NEU AMBERGER

STRASSE

GRAFENWOEHR 92655

GERMANY

Section F - Deliveries or Performance

1. Site Visit (Construction)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: See Name of Contract Specialist on page 1 hereof

Address: See Address of Regional Contracting Office on page 1 hereof

Telephone: See Telephone Number of Contract Specialist on page 1 hereof

2. Commencement, Prosecution, and Completion of Work

The Contractor shall be required to (a) commence work under this contract within 30 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 400 calendar days after the date the contractor receives the notice to proceed . The time stated for completion shall include final cleanup of the premises.

3. Performance of Work by the Contractor

The Contractor shall perform, on the site and with its own organization, work equivalent to at least ten (10) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction, and the Contracting Officer determines that the reduction would be to the advantage of the Government.

*** END OF NARRATIVE ***

0001 Delivery Schedule Delivery Period From 30 Sep 2026 to 28 Apr 2028

1 JobQuantity

Address and POC Service Performance Site DoDAAC: W90S01 CountryCode: DEU

W6FM USAG BAVARIA

DPW ENGINEERING DIVISION BLDG 329, EAST CAMP NEU AMBERGER

STRASSE GRAFENWOEHR 92655 GERMANY

Period of Performance From 30 Sep 2026 To 28 Apr 2028

Section G - Contract Administration Data

CONTRACTOR PAYMENT PROCEDURES

a. The contractor shall submit payment requests in accordance with DFARS 252.232-7003 Electronic Submission of Payment Requests.

b. Payment will be made by:

Defense Finance & Accounting Services (DFAS) ATTN: RO (GFEBS)

Kleber Kaserne, Gebaeude 3200

Mannheimer Strasse 218/219 67657 Kaiserslautern

Code: HQ0672

*** END OF NARRATIVE ***

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.232-7008 Assignment of Claims (Overseas).

1997-06

DFARS Clauses Incorporated by Full Text

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative.

1991-12

CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

(a) Definition. "Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports.

2018-12

ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (DEC

2018)

(a) Definitions. As used in this clause-

"Contract financing payment" means an authorized Government disbursement of monies to a contractor prior to acceptance of supplies or services by the Government.

(1) Contract financing payments include-

(i) Advance payments;

(ii) Performance-based payments;

(iii) Commercial advance and interim payments;

(iv) Progress payments based on cost under the clause at Federal Acquisition Regulation (FAR) 52.232-16, Progress Payments;

(v) Progress payments based on a percentage or stage of completion (see FAR 32.102(e)), except those made under the clause at FAR 52.232-5, Payments Under Fixed-Price Construction Contracts, or the clause at FAR 52.232-10, Payments Under Fixed-Price Architect- Engineer Contracts; and

(vi) Interim payments under a cost reimbursement contract, except for a cost reimbursement contract for services when Alternate I of the clause at FAR 52.232-25, Prompt Payment, is used.

(2) Contract financing payments do not include-

(i) Invoice payments;

(ii) Payments for partial deliveries; or

(iii) Lease and rental payments.

"Electronic form" means any automated system that transmits information electronically from the initiating system to affected systems.

"Invoice payment" means a Government disbursement of monies to a contractor under a contract or other authorization for supplies or services accepted by the Government.

(1) Invoice payments include-

(i) Payments for partial deliveries that have been accepted by the Government;

(ii) Final cost or fee payments where amounts owed have been settled between the Government and the contractor;

(iii) For purposes of subpart 32.9 only, all payments made under the clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and the clause at 52.232-10, Payments Under Fixed-Price Architect-Engineer Contracts; and

(iv) Interim payments under a cost-reimbursement contract for services when Alternate I of the clause at 52.232-25, Prompt Payment, is used.

(2) Invoice payments do not include contract financing payments.

"Payment request" means any request for contract financing payment or invoice payment submitted by the Contractor under this contract or task or delivery order.

"Receiving report" means the data prepared in the manner and to the extent required by Appendix F, Material Inspection and Receiving Report, of the Defense Federal Acquisition Regulation Supplement.

(b) Except as provided in paragraph (d) of this clause, the Contractor shall submit payment requests and receiving reports in electronic form using Wide Area WorkFlow (WAWF). The Contractor shall prepare and furnish to the Government a receiving report at the time of each delivery of supplies or services under this contract or task or delivery order. .

(c) Submit payment requests and receiving reports to WAWF in one of the following electronic formats:

(1) Electronic Data Interchange.

(2) Secure File Transfer Protocol.

(3) Direct input through the WAWF website.

(d) The Contractor may submit a payment request and receiving report using methods other than WAWF only when-

(1) The Contractor has requested permission in writing to do so, and the Contracting Officer has provided instructions for a temporary alternative method of submission of payment requests and receiving reports in the contract administration data section of this contract or task or delivery order;

(2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System);

(3) DoD makes payment on a contract or task or delivery order for rendered health care services using the TRICARE Encounter Data System; or

(4) The Governmentwide commercial purchase card is used as the method of payment, in which case submission of only the receiving report in WAWF is required.

(e) Information regarding WAWF is available at https://wawf.eb.mil/.

(f) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payment requests.

252.232-7006 Wide Area WorkFlow Payment Instructions.

2023-01

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process Electronic invoicing.

vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF WAWF training.

Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web WAWF methods of document submission.

entry, Electronic Data Interchange, or File Transfer Protocol.

(f) The Contractor shall use the following information when WAWF payment instructions.

submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following Document type.

document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Construction and Facilities Management Invoice

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

N/A

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Document routing.

Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC

HQ0672

Issue By DoDAAC

W912PB

Admin DoDAAC

W912PB

Inspect By DoDAAC W90S01

Ship To Code W90S01

Ship From Code N/A

Mark For Code N/A

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC) W90S01

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC N/A

Other DoDAAC(s) N/A

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the Receiving report.

requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Mr. Kraus Tel: 09641-70-526-4165 email: Michael.j.kraus.ln@army.mil

Mr. Arlt Tel: 09641-70-599-4037 email: Robert.arlt.ln@army.mil

Mr. Arnold Tel: 09641-70-526-4170 email: Manfred.Arnold.ln@army.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

252.236-7000 Modification Proposals--Price Breakdown.

1991-12

W912PB26BA010

mailto:Michael.j.kraus.ln@army.mil mailto:Robert.arlt.ln@army.mil mailto:Manfred.Arnold.ln@army.mil

MODIFICATION PROPOSALS--PRICE BREAKDOWN (DEC 1991)

(a) The Contractor shall furnish a price breakdown, itemized as required and within the time specified by the Contracting Officer, with any proposal for a contract modification.

(b) The price breakdown-

(1) Must include sufficient detail to permit an analysis of profit, and of all costs for-

(i) Material;

(ii) Labor;

(iii) Equipment;

(iv) Subcontracts; and

(v) Overhead; and

(2) Must cover all work involved in the modification, whether the work was deleted, added, or changed.

(c) The Contractor shall provide similar price breakdowns to support any amounts claimed for subcontracts.

(d) The Contractor's proposal shall include a justification for any time extension proposed.

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.202-1 Definitions. 2020-06

52.203-3 Gratuities. 1984-04

52.203-5 Covenant Against Contingent Fees.

2014-05

52.203-7 Anti-Kickback Procedures. 2020-06

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity.

2014-05

52.203-12 Limitation on Payments to Influence Certain Federal Transactions.

2020-06

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel.

2011-01

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (Deviation 2026-O0038)

2026-02

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation 2026- O0038)

2026-02

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation 2026-O0038)

2026-02

52.214-29 Order of Precedence-Sealed Bidding.

1986-01

52.222-50 Combating Trafficking in Persons. (Deviation 2026-O0038)

2026-02

52.225-14 Inconsistency between English Version and Translation of Contract.

2000-02

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.228-3 Workers' Compensation Insurance (Defense Base Act).

2014-07

52.228-4 Workers' Compensation and War- Hazard Insurance Overseas.

1984-04

52.229-6 Taxes-Foreign Fixed-Price Contracts.

2026-02

52.232-8 Discounts for Prompt Payment. 2002-02

52.232-17 Interest. 2014-05

52.232-33 Payment by Electronic Funds 2018-10

Transfer-System for Award Management.

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.232-90 Fast Payment Procedure.

(Deviation 2026-O0038)

2026-02

52.233-1 Disputes. (Deviation 2026- O0038)

2026-02

52.233-3 Protest after Award. (Deviation 2026-O0038)

2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation 2026- O0038)

2026-02

52.236-8 Other Contracts. (Deviation 2026- O0038)

2026-02

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (Deviation 2026-O0038)

2026-02

52.236-10 Operations and Storage Areas.

(Deviation 2026-O0038)

2026-02

52.236-11 Use and Possession Prior to Completion. (Deviation 2026- O0038)

2026-02

52.236-12 Cleaning Up. (Deviation 2026- O0038)

2026-02

52.236-13 Accident Prevention. (Alternate I) 2026-02 Alternate I 1991-11

52.236-17 Layout of Work. (Deviation 2026- O0038)

2026-02

52.236-21 Specifications and Drawings for Construction. (Deviation 2026- O0038)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation 2026- O0038)

2026-02

52.242-13 Bankruptcy. 1995-07

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation 2026-O0038)

2026-04

52.246-26 Reporting Nonconforming Items. 2024-08

52.253-1 Computer Generated Forms.

(Deviation 2026-O0038)

2026-02

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense- Contract-Related Felonies.

2023-01

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. (DEVIATION 2024-

O0013 REVISION 1)

2024-05 Deviation 2024- O0013

2024-05

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.222-7002 Compliance with Local Labor Laws (Overseas).

1997-06

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium.

2023-01

252.225-7005 Identification of Expenditures in the United States .

2005-06

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.225-7041 Correspondence in English. 1997-06

252.225-7048 Export-Controlled Items. 2013-06

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime.

2023-01

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.229-7002 Customs Exemptions (Germany). 1997-06

252.229-7014 Full Exemption from Two- Percent Excise Tax on Certain Foreign Procurements.

2022-10

252.232-7010 Levies on Contract Payments. 2006-12

252.243-7001 Pricing of Contract Modifications. 1991-12

252.243-7002 Requests for Equitable Adjustment.

2022-12

252.244-7001 Contractor Purchasing System Administration. (Alternate I)

2025-01 Alternate I 2025-01

252.244-7999 Subcontracts for Commercial Products or Commercial Services. (DEVIATION 2026- O0015)

2026-02 Deviation 2026- O0015

2026-01

252.246-7002 Warranty of Construction ( Germany ).

1997-06

252.246-7007 Contractor Counterfeit Electronic Part Detection and Avoidance System.

2023-01

252.246-7008 Sources of Electronic Parts. 2023-01

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.203-6 Restrictions on Subcontractor Sales to the Government.

2020-06

Restrictions on Subcontractor Sales to the Government (Jun 2020)

(a) Except as provided in (b) of this clause, the Contractor shall not enter into any agreement with an actual or prospective subcontractor, nor otherwise act in any manner, which has or may have the effect of restricting sales by such subcontractors directly to the Government of any item or process (including computer software) made or furnished by the subcontractor under this contract or under any follow-on production contract.

(b) The prohibition in (a) of this clause does not preclude the Contractor from asserting rights that are otherwise authorized by law or regulation.

(c) The Contractor agrees to incorporate the substance of this clause, including this paragraph (c), in all subcontracts under this contract which exceed the simplified acquisition threshold, as defined in Federal Acquisition Regulation 2.101 on the date of subcontract award.

52.204-13 System for Award Management- Maintenance. (Deviation 2026- O0038)

System for Award Management-Maintenance (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Commercial and Government Entity code means-

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location (referred to as "CAGE code"); or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency to entities located outside the United States and its outlying areas that the DLA CAGE Branch records and maintains in the CAGE master file (referred to as "NCAGE code").

Unique Entity Identifier (UEI) means an identifier used to identify a specific commercial, nonprofit, or Government entity.

(b) Active registration.

(1) The Contractor shall maintain an active Federal Government contracts registration in the System for Award Management (SAM) at https://www.sam.gov during contract performance and through final payment under this contract. To maintain an active registration in SAM, the Contractor shall review at least annually its registration in SAM and validate that the information is current, accurate, and complete.

(2) The Contractor is responsible for the currency, accuracy, and completeness of the information provided within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete information. Updating SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(c) Novation and change-of-name agreements.

(1) If the Contractor has legally changed its business name or "doing business as" name (whichever is shown on the contract), or has transferred the assets used to perform the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in part 42 of the Federal Acquisition Regulation (FAR), the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to -

(i) Change the legal business name in SAM;

(ii) Comply with the requirements of FAR part 42; and

(iii) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with its written notification sufficient documentation to support the legally changed name.

(2) If the Contractor fails to comply with the requirements of paragraph (c)(1) of this clause, or fails to perform the agreement at paragraph (c)(1)(iii) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(d) Assignees.

(1) The Contractor shall not change the legal business name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR part 32). Assignees shall be separately registered in SAM.

(2) Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be incorrect information within the meaning of the "Suspension of Payment" paragraph of the EFT clause of this contract.

(e) Unique entity identifier (UEI). The Contractor shall ensure that its UEI is maintained throughout the life of the contract.

(f) Commercial and Government Entity (CAGE) code. The Contractor shall ensure that the CAGE code is maintained throughout the life of the contract. To update a CAGE code, the Contractor shall initiate the change by updating its SAM registration.

(g) Communicating changes. The Contractor shall communicate any change to its UEI or CAGE code to the Contracting Officer within 30 days after the change, so a modification can be issued to update the UEI or CAGE code on this contract. A change in the UEI does not necessarily require a novation.

52.204-19 Incorporation by Reference of Representations and Certifications.

2014-12

Incorporation by Reference of Representations and Certifications (Dec 2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

52.211-12 Liquidated Damages- Construction.

2000-09

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for _EURO 92.40 each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.229-12 Tax on Certain Foreign Procurements. (Deviation 2026-

Tax on Certain Foreign Procurements (Feb 2026) (Deviation 2026-O0038)

(a) Definitions. As used in this clause-

Foreign person means any person other than a United States person.

United States person, as defined in 26 U.S.C. 7701(a)(30), means-

(1) A citizen or resident of the United States;

(2) A domestic partnership;

(3) A domestic corporation;

(4) Any estate (other than a foreign estate, within the meaning of 26 U.S.C. 7701(a)(31)); and

(5) Any trust if-

(i) A court within the United States is able to exercise primary supervision over the administration of the trust; and

(ii) One or more United States persons have the authority to control all substantial decisions of the trust.

(b) This clause applies only to foreign persons. It implements 26 U.S.C. 5000C and its implementing regulations at 26 CFR 1.5000C-1 through 1.5000C-7.

(c)

(1) If the Contractor is a foreign person and has only a partial or no exemption to the withholding, the Contractor shall include the Department of the Treasury IRS Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, with each voucher or invoice submitted under this contract throughout the period in which this status is applicable. The excise tax withholding is applied at the payment level, not at the contract level.

The Contractor should revise each IRS Form W-14 submission to reflect the exemption (if any) that applies to that particular invoice, such as a different exemption applying. In the absence of a completed IRS Form W-14 accompanying a payment request, the default withholding percentage is 2 percent for the section 5000C withholding for that payment request. Information about IRS Form W-14 and its separate instructions is available via the internet at www.irs.gov /w14.

(2) If the Contractor-

(i) Is a foreign person; and

(ii) Has indicated in its offer in the provision 52.229-11, Tax on Certain Foreign Procurements- Notice and Representation, that it is fully exempt from the withholding; and

(iii) Certified the full exemption on the IRS Form W-14, and if that full exemption no longer applies due to a change in circumstances during the performance of the contract that causes the Contractor to become subject to the withholding for the 2 percent excise tax; then the Contractor shall-

(A) Notify the Contracting Officer within 30 days of a change in circumstances that causes the Contractor to be subject to the excise tax withholding under 26 U.S.C. 5000C; and

(B) Comply with paragraph (c)(1) of this clause.

(d) The Government will withhold a full 2 percent of each payment unless the Contractor claims an exemption. If the Contractor enters a ratio in Line 12 of the IRS Form W-14, the result of Line 11 divided by Line 10, the Government will withhold from each payment an amount equal to 2 percent multiplied by the contract ratio. If the Contractor marks box 9 of the IRS Form W-14 (rather than completes Lines 10 through 12), the Contractor must identify and enter the specific exempt and nonexempt amounts in Line 15 of the IRS Form W-14; the Government will then withhold 2 percent only from the nonexempt amount. See the IRS Form W-14 and its instructions.

(e) Exemptions from the withholding under this clause are described at 26 CFR 1.5000C-1(d)(5) through (7). Any exemption claimed and self-certified on the IRS Form W-14 is subject to audit by the IRS. Any disputes regarding the imposition and collection of the 26 U.S.C. 5000C tax are adjudicated by the IRS as the 26 U.S.C. 5000C tax is a tax matter, not a contract issue.

(f) Taxes imposed under 26 U.S.C. 5000C may not be-

(1) Included in the contract price; nor

(2) Reimbursed.

(g) A taxpayer may, for a fee, seek advice from the IRS as to the proper tax treatment of a transaction. This is called a private letter ruling. Also, the IRS may publish a revenue ruling, which is an official interpretation by the IRS of the Internal Revenue Code, related statutes, tax treaties, and regulations. A revenue ruling is the conclusion of the IRS on how the law is applied to a specific set of facts. For questions relating to the interpretation of the IRS regulations go to https://www.irs.gov/help/tax-law-questions.

52.232-5 Payments under Fixed-Price Construction Contracts.

2014-05

Payments under Fixed-Price Construction Contracts (May 2014)

(a) Payment of price. The Government shall pay the Contractor the contract price as provided in this contract.

(b) Progress payments. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

(1) The Contractor's request for progress payments shall include the following substantiation:

(i) An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment requested.

(ii) A listing of the amount included for work performed by each subcontractor under the contract.

(iii) A listing of the total amount of each subcontract under the contract.

(iv) A listing of the amounts previously paid to each such subcontractor under the contract.

(v) Additional supporting data in a form and detail required by the Contracting Officer.

(2) In the preparation of estimates, the Contracting Officer may authorize material delivered on the site and preparatory work done to be taken into consideration. Material delivered to the Contractor at locations other than the site also may be taken into consideration if-

(i) Consideration is specifically authorized by this contract; and

(ii) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract.

(c) Contractor certification. Along with each request for progress payments, the Contractor shall furnish the following certification, or payment shall not be made: (However, if the Contractor elects to delete paragraph (c)(4) from the certification, the certification is still acceptable.)

I hereby certify, to the best of my knowledge and belief, that-

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of Chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract; and

(4) This certification is not to be construed as final acceptance of a subcontractor's performance.

____ (Name)

____ (Title)

____ (Date)

(d) Refund of unearned amounts. If the Contractor, after making a certified request for progress payments, discovers that a portion or all of such request constitutes a payment for performance by the Contractor that fails to conform to the specifications, terms, and conditions of this contract (hereinafter referred to as the "unearned amount"), the Contractor shall-

(1) Notify the Contracting Officer of such performance deficiency; and

(2) Be obligated to pay the Government an amount (computed by the Contracting Officer in the manner provided in paragraph (j) of this clause) equal to interest on the unearned amount from the 8th day after the date of receipt of the unearned amount until-

(i) The date the Contractor notifies the Contracting Officer that the performance deficiency has been corrected; or

(ii) The date the Contractor reduces the amount of any subsequent certified request for progress payments by an amount equal to the unearned amount.

(e) Retainage. If the Contracting Officer finds that satisfactory progress was achieved during any period for which a progress payment is to be made, the Contracting Officer shall authorize payment to be made in full. However, if satisfactory progress has not been made, the Contracting Officer may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved. When the work is substantially complete, the Contracting Officer may retain from previously withheld funds and future progress payments that amount the Contracting Officer considers adequate for protection of the Government and shall release to the Contractor all the remaining withheld funds. Also, on completion and acceptance of each separate building, public work, or other division of the contract, for which the price is stated separately in the contract, payment shall be made for the completed work without retention of a percentage.

(f) Title, liability, and reservation of rights. All material and work covered by progress payments made shall, at the time of payment, become the sole property of the Government, but this shall not be construed as-

(1) Relieving the Contractor from the sole responsibility for all material and work upon which payments have been made or the restoration of any damaged work; or

(2) Waiving the right of the Government to require the fulfillment of all of the terms of the contract.

(g) Reimbursement for bond premiums. In making these progress payments, the Government shall, upon request, reimburse the Contractor for the amount of premiums paid for performance and payment bonds (including coinsurance and reinsurance agreements, when applicable) after the Contractor has furnished evidence of full payment to the surety. The retainage provisions in paragraph (e) of this clause shall not apply to that portion of progress payments attributable to bond premiums.

(h) Final payment. The Government shall pay the amount due the Contractor under this contract after-

(1) Completion and acceptance of all work;

(2) Presentation of a properly executed voucher; and

(3) Presentation of release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of1940 ( 31 U.S.C.3727 and 41 U.S.C. 6305).

(i) Limitation because of undefinitized work. Notwithstanding any provision of this contract, progress payments shall not exceed 80 percent on work accomplished on undefinitized contract actions. A "contract action" is any action resulting in a contract, as defined in FAR subpart 2.1, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the Changes clause, or funding and other administrative changes.

(j) Interest computation on unearned amounts. In accordance with 31 U.S.C. 3903(c)(1), the amount payable under paragraph (d)(2) of this clause shall be-

(1) Computed at the rate of average bond equivalent rates of 91-day Treasury bills auctioned at the most recent auction of such bills prior to the date the Contractor receives the unearned amount; and

(2) Deducted from the next available payment to the Contractor.

52.232-27 Prompt Payment for Construction Contracts.

2017-01

Prompt Payment for Construction Contracts (Jan 2017)

Notwithstanding any other payment terms in this contract, the Government will make invoice payments under the terms and conditions specified in this clause. The Government considers payment as being made on the day a check is dated or the date of an electronic funds transfer.

Definitions of pertinent terms are set forth in sections 2.101, 32.001, and 32.902 of the Federal Acquisition Regulation. All days referred to in this clause are calendar days, unless otherwise specified. (However, see paragraph (a)(3) concerning payments due on Saturdays, Sundays, and legal holidays.)

(a) Invoice payments-

(1) Types of invoice payments. For purposes of this clause, there are several types of invoice payments that may occur under this contract, as follows:

(i) Progress payments, if provided for elsewhere in this contract, based on Contracting Officer approval of the estimated amount and value of work or services performed, including payments for reaching milestones in any project.

(A) The due date for making such payments is 14 days after the designated billing office receives a proper payment request. If the designated billing office fails to annotate the payment request with the actual date of receipt at the time of receipt, the payment due date is the 14th day after the date of the Contractor's payment request, provided the designated billing office receives a proper payment request and there is no disagreement over quantity, quality, or Contractor compliance with contract requirements.

(B) The due date for payment of any amounts retained by the Contracting Officer in accordance with the clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, is as specified in the contract or, if not specified, 30 days after approval by the Contracting Officer for release to the Contractor.

(ii) Final payments based on completion and acceptance of all work and presentation of release of all claims against the Government arising by virtue of the contract, and payments for partial deliveries that have been accepted by the Government (e.g., each separate building, public work, or other division of the contract for which the price is stated separately in the contract).

(A) The due date for making such payments is the later of the following two events:

(1) The 30th day after the designated billing office receives a proper invoice from the Contractor.

(2) The 30th day after Government acceptance of the work or services completed by the Contractor. For a final invoice when the payment amount is subject to contract settlement actions (e.g., release of claims), acceptance is deemed to occur on the effective date of the contract settlement.

(B) If the designated billing office fails to annotate the invoice with the date of actual receipt at the time of receipt, the invoice payment due date is the 30th day after the date of the Contractor's invoice, provided the designated billing office receives a proper invoice and there is no disagreement over quantity, quality, or Contractor compliance with contract requirements.

(2) Contractor's invoice. The Contractor shall prepare and submit invoices to the designated billing office specified in the contract. A proper invoice must include the items listed in paragraphs (a)(2)(i) through (a)(2)(xi) of this clause. If the invoice does not comply with these requirements, the designated billing office must return it within 7 days after receipt, with the reasons why it is not a proper invoice. When computing any interest penalty owed the Contractor, the Government will take into account if the Government notifies the Contractor of an improper invoice in an untimely manner.

(i) Name and address of the Contractor.

(ii) Invoice date and invoice number. (The Contractor should date invoices as close as possible to the date of mailing or transmission.)

(iii) Contract number or other authorization for work or services performed (including order number and line item number).

(iv) Description of work or services performed.

(v) Delivery and payment terms (e.g., discount…