FAR 42.1302 Suspension of work
Section Federal Acquisition Regulation
Facts
- Citation
- FAR 42.1302
- Type
- Section
- Text as of
- FAC 2026-01
- Official text
- acquisition.gov
Text from acquisition.gov. Federal Register history from the Federal Register's records of the rules that amended this section.
Text
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.
Quick answers
What is FAR 42.1302?
FAR 42.1302 is a section of the Federal Acquisition Regulation, titled "Suspension of work".
Are changes to FAR 42.1302 proposed?
No proposed rule from the last 3 years is waiting on a final rule.
On GovTribe
Follow the rules behind federal contracts
- Search Federal Register rules and proposed rules for the FAR, DFARS and agency supplements
- Solicitations, awards and government files in one search
- Ask GovTribe AI about the rules that apply to a contract