Courthouse Attic Remediation and Roof Repair

Walker County Government is requesting proposals for attic remediation and roof repair at the Walker County Courthouse, 103 S Duke Street, LaFayette, Georgia, with proposals due August 25, 2026 at 2:00 p.m. An on-site visit is scheduled for August 7, 2026 at 2:00 p.m., with assembly at the Courthouse Annex I lobby.

The scope encompasses asbestos abatement, mold remediation, structural and masonry repairs, TPO roof system replacement, roof drains and restoration, fourth-floor window and door replacement, and restoration of north and south stairwells and Office 318. Work must address moisture intrusion, structural deficiencies, and restoration of affected interior and exterior building components. All work must comply with applicable building codes, domestic preference provisions for U.S.-manufactured materials, and Georgia Security and Immigration Compliance Act requirements.

Walker County requires contractors to demonstrate a minimum of three years' construction experience and provide documentation of two similar projects completed within the past five years, three project references, and detailed project methodology. Contractors and subcontractors must provide E-Verify compliance affidavits and IRS Form W-9 documents. Performance and payment bonds equal to the contract award amount are required if the award exceeds $100,000. Insurance must include workers' compensation; public liability of at least $1,000,000 per occurrence; motor vehicle liability of at least $500,000 combined single limit; and professional liability of at least $1,000,000.

Work begins October 5, 2026 and must be completed by February 1, 2027, with liquidated damages assessed at $500 per day for delays beyond that date. Walker County retains 10% on all invoices until final completion and acceptance. Prices must remain firm for 60 days after bid opening. Written inquiries are due August 10, 2026 at 9:00 a.m. EDT, with responses published by August 12, 2026. Proposals must include one original and one copy in hard format plus one digital copy with pricing submitted on the provided proposal schedule form.