Levee Rehab - Prime Contractor
Closed Pre-Solicitation Posted
- Solicitation number
- W912DW26Q1BMH
- Agency
-
ENDIST Seattle
US Army Corps of Engineers, Department of Defense
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 237990 Other Heavy and Civil Engineering Construction
- Place of performance
- Washington, United States
Notice details come from SAM.gov. Updated .
About this opportunity
The Seattle District U.S. Army Corps of Engineers intends to solicit one or more firm fixed price construction contracts for levee maintenance and repair across five Washington State river basins (Nooksack, Skagit, Snoqualmie, Cedar, and Green), with a target completion date of October 1, 2026, and responses to this sources sought notice due by May 26, 2026.
This procurement is set aside for small business. The anticipated NAICS code is 237990 (Other Heavy and Civil Engineering Construction), with a size standard of $45 million in average annual receipts.
The work encompasses as many as 14 levees and includes all necessary oversight, materials, and equipment for repair. Repairs are required before the fall flood season. The Corps notes that if market research indicates the October 1 completion target may be unrealistic, respondents should provide specific information such as equipment lead times or other timeline concerns to inform acquisition strategy.
This is a sources sought notice for market research only; no solicitation is currently available and no award will result from responses. The Government will use responses to determine acquisition strategies, assess market capabilities, and identify potential sources. Respondents should include the sources sought notice number in email subject lines and provide company UEI and CAGE codes. The Corps encourages interested vendors to register on the Interested Vendors List.
Notice text
This Sources Sought Notice is being issued for market research purposes to determine the availability, capability, and interest of small business firms for a potential Government requirement. NO SOLICITATION IS AVAILABLE; requests for a solicitation will go unanswered. No award will be made from this notice. Responses will be used to determine potential acquisition strategies, understand current market capabilities, and to gain knowledge of potential sources.
The Seattle District USACE anticipates a potential opportunity for the maintenance and repair for as many as 14 levees across five Washington State river basins: Nooksack, Skagit, Snoqualmie, Cedar and Green. Repairs are necessary before the next fall flood season and the target completion date for all work is 1 October 2026. If market conditions indicate this estimate may be unrealistic, respondents are encouraged to provide specific information (such as known equipment lead times or other timeline concerns) for Government consideration when responding to this Sources Sought Notice.
This notice is for one or more firm fixed price construction contracts that will provide all necessary oversight, materials, and equipment for levee repair.
The North American Industrial Classification System (NAICS) code for the potential requirement is anticipated to be 237990 - Other Heavy and Civil Engineering Construction. The small business size standard for the NAICS, as established by the U.S. Small Business Administration, is $45,000,000. Size standards are the average annual receipts or the average employment of a firm. How to calculate average annual receipts and average employment of a firm can be found in 13 CFR § 121.104 and 13 CFR § 121.106, respectively.
Please include the Sources Sought Notice number in the e-mail subject line. Include your company’s UEI and CAGE code in your response.
We encourage you to add your name to the Interested Vendors List at this announcement.
Similar open opportunities
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity