7th Floor Clerk of the Court and Magistrate Chamber Expansion, San Diego, CA
Closed Pre-Solicitation Posted
Not the latest version. See the latest solicitation from .
- Solicitation number
- 47PK0123R0002
- Agency
-
Region 9
Public Buildings Service, General Services Administration
- Responses due
- Set-aside
- Total Small Business
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- San Diego, California 92101, United States
Notice details come from SAM.gov. Updated .
About this opportunity
This notice is seeking construction services for tenant improvements on the 7th floor of the James M. Carter and Judith N. Keep United States Courthouse located in San Diego, California. The General Services Administration will procure approximately 14,790 square feet of new magistrate chambers and Clerk of the Court office space. Work must be performed after hours without disruption and be completed within 365 calendar days of the notice to proceed. Proposals will be evaluated based on conforming to all requirements and being most advantageous to the government considering cost/price and other factors. The request for proposal will be available on March 22nd with proposals due approximately 40 days later.
This will be a total small business set-aside awarded using FAR 15.1 with a NAICS code of 236220 for contractors with average annual receipts less than $45 million over the past five years. The estimated value is between $1 million to $5 million to provide construction, mechanical, electrical, and low-voltage systems.
Notice text
The U.S. General Services Administration (GSA) has a requirement to provide construction services involving approximately 14,790 square feet on a partially occupied floor on the 7th Floor at the James M. Carter and Judith N. Keep United States Courthouse, 333 W. Broadway, San Diego, CA. The tenant improvement includes construction of four (4) new magistrate chambers and Clerk of the Court office space on the 7th Floor of the Courthouse.
This project will involve: mechanical, electrical, plumbing, elevator programming, fire and life safety, data, audio and visual, and security systems; the highest quality interior finishes; and premium quality millwork. The work must be performed after hours with no disruption to the existing building tenants and operations.
The completion time for this project is 365 calendar days from issuance of the Notice to Proceed to Substantial Completion. The estimated cost range is between $1 million and $5 million. The proposed contract is being solicited as a Total Small Business Set Aside, in accordance with FAR 19.502-2. The North American Industry Classification System (NAICS) code for this procurement is 236220 with average annual receipts of less than $45 million for the last five (5) years.
This project will be solicited utilizing FAR 15.1, Source Selection Processes and Techniques. Award will be made to the offeror whose proposal conforms to all requirements of the solicitation and is considered to be most advantageous to the Government, cost or price and other factors considered.
The Request for Proposal (RFP) will be available for download on Sam.gov on or about March 22, 2023. Proposals will be due approximately 40 calendar days after the RFP is issued.
Any questions regarding this notification should be directed via email to the Contracting Officer listed in this notice. Potential offerors will be responsible for downloading the solicitation and monitoring the website for amendments, if any, to the solicitation. Please continue to monitor this announcement to receive the most updated information.
Notice history
| Notice | Type | Posted |
|---|---|---|
| 7th Floor Clerk of the Court and Magistrate Chamber Expansion, San Diego, CA | Solicitation | |
| This notice | Pre-Solicitation | |
| Clerk of the Court and Magistrate Chamber Expansion, San Diego, CA | Pre-Solicitation |
Similar open opportunities
| Opportunity | Agency | Set-aside | Responses due |
|---|---|---|---|
| Office Security Enhancements, Reno, NV | — | Total Small Business | |
| General Contractor for the Seismic Retrofit Project at the Clemente Ruiz Nazario U.S. Courthouse, San Juan, Puerto Rico | — | No set-aside | |
| USBC Tenant Improvement Services, Reno, NV | — | Total Small Business | |
| DHS HSI Schwartz 2nd Floor Carpet Replacement | — | Total Small Business |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity