A07.23_RFQ_W913E517Q0005.pdf

PR W2R2 COLD RGNS RSCH ENG LAB

DPW - RICHARD ROBINSON

72 LYME ROAD

HANOVER NH 03755-1290

TEL: 603-646-4364 FAX:

W81EWF72338174

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W913E517Q0005 23-Aug-2017 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

ERDC CONTRACTING OFFICE

HANOVER OFFICE

72 LYME ROAD

HANOVER NH 03755-1290

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

06-Sep-2017(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

217-373-7309KIM D ROBERSON

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W913E517Q0005

Section A - Solicitation/Contract Form

POINTS OF CONTACT

CONTRACTOR POC: TBD

TECHNICAL POINT OF CONTACT: TBD

CONTRACTING POC: Kim Roberson – Contract Specialist

(217) 373-3478 Kim.D.Roberson@usace.army.mil

Ashley Jenkins – Contract Officer

(217) 373-7297 Ashley.M.Jenins@usace.army.mil

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

OVERHEAD DOORS

FFP

The Contractor shall provide the products/materials, labor, tools, and equipment necessary to install a total of three (3) overhead doors in two (2) buildings in accordance with the Purchase Description (PD) in section C.

FOB: Destination

MILSTRIP: W81EWF72338174

PURCHASE REQUEST NUMBER: W81EWF72338174

NET AMT

Section C - Descriptions and Specifications

PURCHASE DESCRIPTION

Furnish and Install Overhead Doors

GENERAL:

Contractor shall provide all labor, materials, tools, and equipment necessary to perform the services described herein. All work shall be done in accordance with this Scope of Work.

Contractors are responsible for verifying all dimensions, details, locations, and conditions.

All work shall be performed in accordance with the highest industry standards and all applicable provisions of the U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1 and OSHA 29 CFR1910 regulations. The EM 385-1- 1 and its changes are available at http://www.hq.usace.army.mil (at the HQ homepage, select Safety and Occupational Health and then select EM and Changes to EM).

The Contractor shall be responsible for complying with the current edition and all changes posted on the web as set forth in this document. A hard copy of this regulation is available on site at CRREL for review. All applicable State and Federal safety regulations relating to protection of eyes, other extremities, and hearing protection shall also be followed.

Machinery and equipment shall be operated in accordance with the manufacturer’s instructions and recommendations. Material Safety Data Sheets are required for any products or materials brought on to this facility for use under this award. If there are conflicting regulations or standards, the most stringent shall take precedence. Materials shall NOT be installed during adverse weather conditions that would detrimentally affect the final performance of those materials.

PRE-PERFORMANCE:

A pre-performance meeting shall be scheduled prior to commencement of work.

Contractor shall take note that Government employees are not permitted to receive materials for Contactor use under this award. The contractor shall provide a list of employees name and proposed work schedule to the Government prior to the agreed upon start work date.

Contractor shall be provided space at the worksite for storage of tools, equipment, and materials during non-working hours. Contractor assumes all liability for such stored items. At all times, either stored or in-use Contractor materials, etc. shall be stored/used in a manner as to minimize harm or hazard to personnel or property and shall never block emergency access/egress at any time.

The Government work site facilities are a “No Smoking” area. Contractor personnel shall be shown appropriate areas where smoke breaks may be taken Contractor employees have limited access to the Government facility and may move unescorted through the immediate job site, smoking areas and rest room facilities. Government furnished utilities provided for the completion of this project include – Electricity and Water.

GENERAL:

Install a total of three (3) overhead doors; 2 at Yellow Storage Building & 1 at FERF Building that are INOP and require complete replacement to improve facility condition and eliminate safety concerns.

PERFORMANCE:

The Contractor shall furnish all labor, supervision, tools, materials, equipment, and other items and services necessary to manufacture/furnish specified doors, remove old doors, and install new doors utilizing current opening where old doors are currently installed (3 Each).

1. Yellow Storage Building - Two (2) Thermacore type sectional door North & South that will have man doors on each for the Yellow Storage Building. Door sizes 12’ 2” wide by 12’ 1” high operation electric and jamb type steel. Doors will have no glass. Work to be performed at Yellow Storage Building at the Cold Regions Research and Engineering Laboratory, 72 Lyme Road, Hanover, NH.

2. FERF Building - One (1) Thermacore type sectional door North that will have no man doors for the FERF Building. Door size 98” wide by 10’ high operation electric and jamb type steel. Door will have two windows. Work to be performed at FERF Building at the Cold Regions Research and Engineering Laboratory, 72 Lyme Road, Hanover, NH.

POST-PERFORMANCE:

Government will do a final inspection of all new work and of the surrounding areas within 5 days of notification from the contractor that the work is complete.

SECURITY REQUIREMENTS:

A. Overview: All contractor personnel are required to follow all security regulations as directed by the CRREL Security Office, as written in this Statement of Work, and as otherwise specified at the post award orientation. General disruption by the contractor is limited to the immediate work site. The contractor is strictly responsible for the security of all products, materials, tools and equipment used during the duration of each job.

B. United States Citizenship: All contractor employees entering the CRREL site must be U.S. citizens.

C. Identification: All contractor employees must have a positive picture I.D. (such as a valid picture driver’s license) to enter the site and must be prepared to show it at any time. The Security Office may require each contractor employee to wear a badge issued by the Security Office and also to sign in and out when entering the leaving the work site. The contractor is responsible for all badges issued to his employees and shall ensure they are returned to the Security Office upon completion of the work, when leaving the site, or when otherwise directed.

D. Weapons: Weapons of any kind are prohibited on the CRREL site.

E. Access and General Protection/Security Policy and Procedures: The contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy.

In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

F. iWATCH Training: The contractor and all associated subcontractors shall brief all employees on the USACE iWATCH program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 45 calendar days of contract award and within 45 days of new employees commencing performance on the contract. The contractor shall provide certification of completion to the COR within 10 days of training completion. Training documents will be provided by the Security Office.

G. Personnel Security Screening: The contractor shall conduct a security screening on every employee prior to their performance under this contract. The security screening shall cover the most recent five (5) years or since age 18, whichever is shorter, providing it includes the most recent two (2) years of the applicant’s life. The security screening shall include, as a minimum, checks with former employers, former supervisors and personal references, along with a local record check with the police departments. The contractor shall furnish the Contracting Officer (KO) with a record of the results of each employee’s security screening prior to entry on duty.

H. Pre-Screen E-Verify Program: The contractor must pre-screen Candidates using the E-verify

Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

EMERGENCY INSTRUCTIONS

Fire:

Pull Alarm Leave the area Dial 9-911 and advise of exact location and type of fire Dial 4800 and report emergency

Medical Emergency:

Dial 9-911 and advise of the type of medical emergency and exact location Dial 4800 and report emergency

Ammonia Leak:

Leave the area Call 4800 Report any injured or missing persons to Security

Chemical Spill:

Leave the area Call 4800 Report any injured or missing persons to Security

Police:

Dial 9-911 and advise of the reason for police assistance Dial 4800 and report emergency

Emergency Evacuation:

If the fire alarm sounds or an evacuation command is given over the PA. Leave via the nearest safe exit and gather with the CREEL employees in the parking lots. Report any missing or injured persons to the Security Guard. Do not reenter the building until all clear is given by Security

Notification: In all cases, call 4800

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

252.246-7000 Material Inspection And Receiving Report MAR 2008

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 30-SEP-2017 1 PR W2R2 COLD RGNS RSCH ENG LAB

DPW - RICHARD ROBINSON

72 LYME ROAD

HANOVER NH 03755-1290

603-646-4364 FOB: Destination

W14GQK

52.242-17 Government Delay Of Work APR 1984 52.247-34 F.O.B. Destination NOV 1991

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

INVOICE ONLY (STAND-ALONE)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

GOVERNMENT

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC W916TX Issue By DoDAAC W913E5 Admin DoDAAC W913E5 Inspect By DoDAAC W913E5 Ship To Code W14GQK Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) NA Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC Contractor Discretion Other DoDAAC(s) Contractor Discretion

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

WAWF Acceptor: Lynn Long: Lynn.C.Long@usace.army.mil

Technical Point of Contact: TBD

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Contracting Officer: Ashley Jenki: Ashly.MJenkins@usace.army.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section I - Contract Clauses

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.237-2 Protection Of Government Buildings, Equipment, And Vegetation

APR 1984

52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic

(Dec 2016)

DEC 2016

252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016 252.225-7031 Secondary Arab Boycott Of Israel JUN 2005 252.225-7048 Export-Controlled Items JUN 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (JAN 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

____ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

____ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

___ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-

282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div.

C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub.

L. 111-117, section 743 of Div. C).

___ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

____ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (July 2013) (41 U.S.C. 2313).

____ (10) [Reserved]

____ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

____ (ii) Alternate I (NOV 2011) of 52.219-3.

____ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (ii) Alternate I (JAN 2011) of 52.219-4.

____ (13) [Reserved]

X (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

____ (ii) Alternate I (NOV 2011).

____ (iii) Alternate II (NOV 2011).

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

____ (ii) Alternate I (Oct 1995) of 52.219-7.

____ (iii) Alternate II (Mar 2004) of 52.219-7.

____ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

____ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (Nov 2016) of 52.219-9.

____ (iii) Alternate II (Nov 2016) of 52.219-9.

____ (iv) Alternate III (Nov 2016) of 52.219-9.

____ (v) Alternate IV (Nov 2016) of 52.219-9.

____ (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

____ (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

____ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C.

657f).

X (22) 52.219-28, Post Award Small Business Program Rerepresentation (July 2013) (15 U.S.C. 632(a)(2)).

____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

____(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

X (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

____ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

____ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014) (29 U.S.C. 793).

____ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

____ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

X (33)(i) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

____ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

____ (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016).

____ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693).

____ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693).

____ (40) (i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (41)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-14.

____ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

____ (43)(i) 52.223-16, Acquisition of EPEAT[supreg]-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

____ (ii) Alternate I (Jun 2014) of 52.223-16.

X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O.

13513).

____ (45) 52.223-20, Aerosols (June, 2016) (E.O. 13693).

____ (46) 52.223-21, Foams (June, 2016) (E.O. 13693).

____ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

____(49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L.

103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I (May 2014) of 52.225-3.

____ (iii) Alternate II (May 2014) of 52.225-3.

____ (iv) Alternate III (May 2014) of 52.225-3.

____ (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (51) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150

____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

____ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

____ (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X (57) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (July 2013) (31 U.S.C. 3332).

____ (58) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (July 2013) (31 U.S.C. 3332).

____ (59) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

____ (61) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

____ (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

____ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_____(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

_____ (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

_____ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____(8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (E.O. 13658).

_____ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

_____ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

_____ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) _____ (A) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O.

13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvi)52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658).

(xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016)).

(xix) (A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C.

2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C.

1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/vffara.htm http://farsite.hill.af.mil/vfdfara.htm

Section K - Representations, Certifications and Other Statements of Offerors

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of…