Amendment 0001_W912WJ20-Q-0106.pdf

W13G86015764230001

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to answ er technical questions and extend the closing date until 28 July 2020 at 5:00 p.m.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 24-Jul-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912WJ20Q0106

X 9B. DATED (SEE ITEM 11)

10-Jul-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

24-Jul-2020

CODE

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

W912WJ 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

Jessica.M.Kidd@usace.army.milEMAIL:978/318-8699TEL:

JESSICA M KIDD / ADDED BY UPASS

W912WJ20Q0106

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

QUESTIONS AND ANSWERS

1. QUESTION: I have a question about Clause 52.211-10 for Notice ID W912WJ20Q0106, 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 14 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and ( c) complete the entire work ready for use not later than 60 days from NTP. The time stated for completion shall include final cleanup of the premises.

This would normally not be a concern but with the COVID19 pandemic, can you please let me know what the penalties would be for violation?

1. ANSWER: This contract contains requirements for the timely execution of the work under normal circumstances. Contract Clause 52.249-10 Default (Construction) addresses circumstances where delays in proceeding with the work may be excusable. Please note that the contract also requires compliance with all applicable Federal, State and local laws and regulations, including any applicable State issued shut down orders. If, in the course of performing the contract, the contractor wishes to request a time ajustement for excusable delays, the contractor should submit a written request with specific information about the time impact the pandemic has had on operations relative to performance of the project.

2. QUESTION: My concern is if COVID19 delays our process internally or with our suppliers. We received notice from the Mill that lead time on the particular material could be 8 to 10 weeks.

It would seem that we will have an issue with Clause 52.211-10, we would need help with that if we are awarded. If this precludes me from submitting a proposal please let me know.

2. ANSWER: This contract contains requirements for the timely execution of the work under normal circumstances. Contract Clause 52.249-10 Default (Construction) addresses circumstances where delays in proceeding with the work may be excusable. Please note that the contract also requires compliance with all applicable Federal, State and local laws and regulations, including any applicable State issued shut down orders. If, in the course of performing the contract, the contractor wishes to request a time ajustement for excusable delays, the contractor should submit a written request with specific information about the time impact the pandemic has had on operations relative to performance of the project.

(End of Summary of Changes)