Amendment0001_W912WJ17Q0133.pdf

W912WJ17Q0133

W13G86718878860001

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This amendment has been issued to revise the subject solicitation; including FAR Clause 52.236-2 Alt I, FAR Clause 52.211-10, and Scope of Work. All other terms and conditions shall remain unchanged.

Quotes are now due on/before CLOSE OF BUSINESS (4:30 PM EST) ON 31-AUGUST-2017.

1. CONTRACT ID CODE PAGE OF PAGES

1 14

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 22-Aug-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912WJ17Q0133

X 9B. DATED (SEE ITEM 11)

17-Aug-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

22-Aug-2017

CODE

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

W912WJ 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

Sheila.M.Winston@usace.army.milEMAIL:978-318-8159TEL:

SHEILA M WINSTONVINCUILLA / CONTRACT SPECIALIST

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION A - SOLICITATION/CONTRACT FORM

The required response date/time has changed from 28-Aug-2017 05:00 PM to 31-Aug-2017 05:00 PM.

SECTION B - SUPPLIES OR SERVICES AND PRICES

The following have been modified:

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- THURSDAY, AUGUST 24, 2017 at 10:00 AM EST

(c) Participants will meet at--

LITTLEVILLE DAM

32 GOSS HILL ROAD

HUNTINGTON, MA 01050

POINT OF CONTACT: MATTHEW COLEMAN, PROJECT MANAGER

978-318-8846 PH, Matthew.S.Coleman@usace.army.mil

(End of provision)

SCOPE OF WORK

REPAIR HOLD-DOWN STRAPS

LITTLEVILLE LAKE DAM,

HUNTINGTON, MASSACHUSETTS

STATEMENT OF WORK

August 2017

A. General Description of the Work to be Performed

Littleville Dam is located on the Middle Branch of the Westfield River about one mile upstream of the confluence of the Middle Branch and the Westfield River and approximately two miles north of Huntington, Massachusetts. The dam serves as a dual purpose water supply and flood control project. The dam consists of an embankment, outlet works, and a spillway. The embankment is a rolled earth and rock fill structure 1,360 feet long, the top of which is 164 feet above the riverbed and has rock slope protection with an impervious core. The flood control outlet works consists of a 17.5 foot wide intake channel, two 4 foot x 8 foot sluice gates, and a 374 foot long horseshoe conduit which is 8 feet in diameter. The water supply outlet works consist of a wet well tower with four 36 inch diameter sluice gates at different elevations to allow discharge from various levels of the reservoir, an outlet conduit and a 48 inch diameter concrete water supply pipeline within a 9 foot wide by 800 feet long arch-shaped conduit under the dam. The ogee weir, chute spillway is located on the left abutment and has a crest length of 400 feet.

The purpose of this project is to replace broken retaining straps and associated hardware used to secure the RCP pipe in the water supply pipe conduit located as shown in the plan at the end of this statement of work. The straps are either loose, broken or exhibit anchor bolt failure. This project is in a permit required confined space.

Replace all broken retaining straps as indicated on the chart and drawings at the end of this Statement of Work, with new stainless steel components. Replacement straps should be fabricated to the appropriate length to ensure they are not pre-stressed during installation and anchor bolts can be properly installed.

The water line acts as an emergency fire supply for local schools and is under constant pressure. In order to safely enter the work area, a valve at the upstream end of the water line must be closed to relieve the pressure. For short entry durations (less than 4 hours) the Army Corps will close the valve. These short outages may be used to verify dimensions or to take field measurements. For longer durations (greater than 4 hours) the water must be drained from the pipe via a relief valve at the downstream end of the pipe. Because of this requirement, the actual work under this contract must be performed during Christmas school break, February school break, April school break and/or during the summer school break. Contractor shall give one week's notice before the line will be de-pressurized or drained. Note that confined space entry requirements must be adhered to for all entries into the work area.

B. General Project Requirements

1. Contractor’s Responsibility. The Contractor shall furnish all plant, labor, equipment and materials and carry out all operations as necessary to accomplish the work of this project as described in this document and on the contract drawings.

2. Commencement, Prosecution and Completion of Work. The Contractor shall commence work under this contract within 15 days after the date of receipt of the Notice to Proceed, shall prosecute the work diligently, employing ample personnel and sufficient equipment, and shall complete the entire work ready for use not later than 300 days after the date of receipt of the Notice to Proceed. The time included for completion shall include final cleanup of the project site. Additional restrictions concerning the prosecution and completion of work are as follows:

A. The Contractor shall attend a Preconstruction Conference prior to the start of on-site construction work (see paragraph entitled "Preconstruction Conference", below).

B. The on-site work is restricted to daylight hours; generally 0700 (7:00 AM) to 1730 (5:30 PM).

3. Superintendence by the Contractor. At all times during the performance of the contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent project superintendent who is satisfactory to the Contracting Officer and has the authority to act for the Contractor. The project superintendent shall maintain a physical presence at the site at all times and be responsible for all construction and related activities at the site, except as otherwise acceptable to the Contracting Officer.

Failure to comply with these requirements shall be deemed as cause for a non-compensatory stoppage and suspension of work until the deficiency is remedied.

4. Coordination and Direction during Construction. The Contractor shall not take or accept any direction or instructions issued by any person, employed by the Government or otherwise, other than the Contracting Officer that changes the terms and conditions of contract actions, the scope, or any change that impacts the cost, price, or schedule. Changes authorized by the Contracting Officer will be in the form of a written, official, signed modification to the contract action received by the Contractor before the Contractor will act upon those changes.

The Contractor will comply with the changes clause of this contract when the Contractor believes direction has been given from persons other than the Government Contracting Officer that equate to a change by notifying the Contracting Officer as directed by the clause. Any direction given by any Government employee or any other person outside their authority must be reported to the Contracting Officer.

The Contracting Officer Representative (COR) is limited to the authorities stated in the COR appointment letter. If a COR is appointed under this contract, they will be appointed by written letter from the Contracting Officer to the Contractor and COR specific to this contract only. COR appointment letters from previous contracts are not valid for this contract.

5. Traffic Regulation and Control. During construction the Contractor shall provide access as necessary to maintain traffic and to provide vehicle access to the project area. The Contractor shall maintain and protect traffic on all affected roads during the construction period, except as otherwise specifically directed by the Contracting Officer. The Contractor shall be responsible for the repair of any damage to the dam access roads and grounds adjacent to the project caused by construction operations.

6. Construction Site Plan. Prior to the start of work, the Contractor shall submit a site plan showing the locations and dimensions of temporary facilities including layouts and details, equipment and material storage areas. Indicate if the use of a supplemental or other staging area is desired. Show locations of safety and construction fences, site trailers, construction entrances, trash dumpsters, temporary sanitary facilities, and worker parking areas. The plan shall also show where temporary utility hook-ups are to be located, if required, and how grounding of equipment and trailers will be achieved, as appropriate.

7. Hours of Operation. Unless otherwise authorized in writing by the Contracting Officer, the project site will be available for construction activities between 7:00 a.m. and 5:30 p.m. Monday through Friday.

Normal work hours are from 7:00 a.m. through 5:30 p.m., Monday through Friday. The Contractor will not be permitted to work on Saturday, Sunday or legal holidays unless otherwise authorized by the Contracting Officer.

The exclusion of work on Saturday, Sunday and legal holidays has been considered in computing the performance time of this contract. The following legal holidays are observed:

January 1st

Third Monday in January Third Monday in February Last Monday of May July 4th

1st Monday of September 2nd Monday of October 11th of November

Fourth Thursday of November 25th of December

When one of the above designated legal holidays falls on a Sunday, the following Monday will be observed as a legal holiday. When a legal holiday falls on a Saturday, the preceding Friday is observed as a holiday.

Work outside the normal hours of operation requires Contracting Officer approval. The request to work outside the hours of operation shall be made in writing to the Contracting Officer 10 calendar days prior to such work to allow arrangements to be made by the Government. The request application shall include specific dates, hours, location, type of work to be performed, contract number and project title, and names of all individuals who will be working outside the hours of operations. During periods of darkness, the different parts of the work shall be lighted in a manner approved by the Contracting Officer.

8. Progress Schedule. The initial project schedule shall be in the form of a chart graphically indicating the sequence proposed to accomplish each work feature or operation. The chart shall be prepared to show the starting and completion dates of all work features on a linear horizontal time scale beginning with date of Notice to Proceed and indicating calendar days to completion. The Contractor shall indicate on the chart the important work features or operations that are critical to the timely overall completion of the project. Key dates for such important work features and portions of work features are milestone dates and shall be so indicated on the chart.

This schedule will be the medium through which the timeliness of the Contractor's construction effort is appraised. Anticipated adverse weather delay days shall be included in the schedule..

An updated schedule showing actual progress shall be submitted monthly or with each pay request. Changes to the base-line schedule shall be outlined in a narrative describing the reason for the change.

9. Rate of Progress. Should the Contractor fail to maintain a satisfactory rate of progress in accordance with the Contractor's approved progress schedule, the Contracting Officer may require that additional personnel and equipment be placed on the work and weekend and overtime work be performed, in order that the work be brought up to schedule and maintained.

10. Preconstruction Conference. The Contracting Officer will conduct a preconstruction conference after receipt of Notice to Proceed by the Contractor and prior to the start of on-site construction activities. The date, time, and place for this conference shall be mutually agreed upon by the Contractor and the Contracting Officer. It is mandatory that the Contractor's project site supervisory personnel assigned to this project attend the conference;

no personnel substitutions will be permitted. The purpose of the conference is to review contract requirements and to establish a working relationship between the Contractor's Staff and the U.S. Army Corps of Engineers personnel who will be closely associated with the project. During the conference, the Contracting Officer's Representative will inform the Contractor concerning job safety, project phasing, work hour restrictions, traffic control, quality control, labor relations, and environmental protection. The Preconstruction Conference will be arranged by the Contracting Officer.

11. Material Substitutions. This contract is based on the materials and methods as shown on the contract drawings and as described in this document. The Contractor shall not substitute materials or methods unless such substitution has been specifically approved in writing by the Contracting Officer.

12. Quality Control. The Contractor shall establish a quality control system to perform sufficient inspection of all items of work, including that of any subcontractors, to ensure conformance to this document with respect to materials, workmanship, construction, finish and functional performance. The system shall cover all construction operations, both onsite and offsite. The site project superintendent will be held responsible for the quality of work on the job and is subject to removal by the Contracting Officer for non-compliance with the quality requirements specified in the contract. The site project superintendent in this context shall be the highest level manager responsible for the overall construction activities at the site, including quality and production. The site project superintendent shall maintain a physical presence at the site at all times, except as otherwise acceptable to the Contracting Officer, and shall be responsible for all construction and construction related activities at the site. The CQC System Manager shall be a construction person with a minimum of three years in related work. This CQC System Manager shall be on the site at all times during construction and shall be employed by the prime Contractor.

The CQC System Manager shall be assigned as System Manager but may have other duties in addition to quality control. The site project superintendent, the CQC system manager and the SSHO can all be one person.

13. Quality Assurance. All items of work not addressed in the contract documents shall be completed in strict accordance with the manufacturers’ specifications.

The Government is not obligated to inspect the Contractor’s work, or to protect the Contractor from the consequences of its work. Government inspections are a general examination of the Contractor’s conduct and workmanship and are solely for the purpose of the Government.

Government-designated Quality Assurance Representatives (QARs) do not have the authority to accept work, nor is a Government inspection to be construed as conclusive.

Government agents including QARs and project engineers are not authorized to change the contract without the written approval of the Contracting Officer; this lack of authority extends to all situations in which the action of these agents could be construed as constituting a change.

The quality of workmanship is subject to audit by Government or Government-designated QARs at any time during the contract. The Contractor shall cooperate fully and provide all information necessary for this audit.

The Contractor shall submit all requests for changes in writing to the Contracting Officer. Do not proceed with changes without possession of written authorization of the Contracting Officer.

The Contractor shall not conceal any work unless the Contracting Officer has approved all items of work which are to be concealed. The Contractor shall notify the Contracting Officer of its intention to conceal work at least 24 hours in advance of concealment.

14. Utilities. Water and electricity required in the prosecution of the work shall be furnished by the Contractor at his own expense. The Government will not supply water and electricity.

15. Temporary Electrical Equipment and Connections. The Contractor, at his own expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines. All required temporary electrical equipment and lines shall be furnished, installed, connected, and maintained by the Contractor according to EM 385-1-1, Section 11.E, NFPA 241,and NFPA 70, Article 305-6(b), "Assured Equipment Grounding Conductor Program". All temporary equipment and lines shall be removed prior to final acceptance of the work. Materials and equipment need not be new, but must be in good repair and serviceable condition. Periodic inspections of systems and devices will be made by the Contractor at intervals not to exceed one week.

16. Environmental Protection. The Contractor shall minimize environmental pollution and damage that may occur as the result of construction operations. The environmental resources within the project boundaries and those affected outside the limits of permanent work shall be protected during the entire duration of this contract. Comply with all applicable environmental Federal, State, and local laws and regulations. Any delays resulting from failure to comply with environmental laws and regulations will be the Contractor's responsibility.

A. Environmental Protection Plan: Prior to commencing construction activities or delivery of materials and equipment to the site, the Contractor shall submit an Environmental Protection Plan for review and approval by the Contracting Officer. The purpose of the Environmental Protection Plan is to present a comprehensive overview of known or potential environmental issues which the Contractor must address during construction. Issues of concern shall be defined within the Environmental Protection Plan. The Contractor shall address each topic at a level of detail commensurate with the environmental issue and required construction task(s). The Environmental Protection Plan shall be current and maintained onsite by the Contractor.

B. The Contractor shall obtain all required environmental permits and comply with all stipulations and commitments required by Federal, State, Regional, and local environmental laws and regulations.

This action is the sole responsibility of the Contractor.

C. Erosion and Sediment Controls: The Contractor shall be responsible for providing erosion and sediment control measures in accordance with Federal, State, and local laws and regulations. The erosion and sediment controls selected and maintained by the Contractor shall be such that water quality standards are not violated as a result of the Contractor's construction activities. The area of bare soil exposed at any one time by construction operations should be kept to a minimum. The Contractor shall construct or install temporary and permanent erosion and sediment control best management practices (BMPs.

BMPs may include, but not be limited to, vegetation cover, slope stabilization, silt fences, sediment traps, and inlet and outfall protection. Any temporary measures shall be removed after the area has been stabilized.

D. Fuels and Lubricants: Storage, fueling and lubrication of equipment and motor vehicles shall be conducted in a manner that affords the maximum protection against spill and evaporation. Manage and store fuel, lubricants and oil in accordance with all Federal, State, Regional, and local laws and regulations. Used lubricants and used oil to be discarded shall be stored in marked corrosion-resistant containers and recycled or disposed in accordance with State, and local laws and regulations. Storage of fuel on the project site is not allowed. Fuel shall be brought to the project site each day that work is performed. Storage and usage of lubricants and daily fueling of machinery and equipment shall occur at least 50 feet from any drainage inlets, water bodies (rivers, streams, lakes), environmentally sensitive areas (wetlands, vernal pools).

17. Waste. The Contractor shall provide on-site containers for the collection of waste materials, debris, and rubbish. The Contractor shall clean the project site on a daily basis to prevent the accumulation of waste materials and rubbish resulting from construction activities. The Contractor shall transport all solid waste off of the project site and dispose of it in compliance with Federal, State and local requirements for solid waste disposal.

The Contractor shall prevent waste material from inadvertently falling into nearby wetlands and shall provide a barrier to prevent this in areas where a barrier does not already exist. Upon completion of the construction work, the project site shall be returned to its pre-work condition.

18. Contract Drawings. Contract drawings showing the work of this project are attached at the end of this document.

19. Damages. The Contractor shall exercise caution and follow sound construction practices in the conduct of the work to avoid construction-related damage to existing features to remain.

20. Sequence of Work. In general, the work shall be performed in the following sequence: existing conditions verification, preparation of submittals, material procurement, establish site safety, construct project features, and project close out.

21. Contractor's Receipt of Supplies. The Contractor shall be responsible for all arrangements for the receipt of materials and supplies at the job site. Government personnel are not permitted to receive or sign for items delivered to the site.

22. Storage Area. There is no physical storage area, however parking is available on the road adjacent to the work site area and the Contractor can access his vehicles from there for storage.

23. Restoration of Storage Area. Upon completion of the project remove barricades, temporary utilities, sanitation facilities, construction vehicles, materials and equipment, and any other temporary equipment, materials, or products from within and around the work areas and temporary storage areas. Clean and repair damage caused by installation or removal of temporary materials, equipment, or utilities. Areas used by the Contractor for the storage of equipment or material, or other use, shall be restored to the original or better condition, including pavement repair, or topsoil and seeding as necessary.

24. Contractor Use of Premises. Work shall be restricted to the areas shown on the contract drawings in addition to storage areas assigned to this Contractor. Access to the project site is currently available for construction traffic.

25. Protection and Security. Protection to Contractor personnel or their equipment cannot be provided at the worksite by the Government. The Contractor shall protect all its personnel, Government personnel, and the general public from injury. The Contractor shall conduct all its work so as to prevent injury or unsafe conditions during construction.

26. Damaged Property. Work shall proceed in a manner which will minimize disturbance or risk of damage to structures and surrounding lands. The Contractor shall repair such items damaged in the course of carrying out the work at no additional cost to the Government. All repairs shall match similar existing items in all aspects.

All replacements shall be in kind.

27. Contractor's Receipt of Supplies. The Contractor shall be responsible for all arrangements for the receipt of materials and supplies at the job site. Government personnel are not permitted to receive or sign for items delivered to the site.

28. Sanitary Facilities. In accordance with Section 2 of EM 385-1-1, provide, maintain, and make available to all workers provisions for sanitation. Maintain these provisions at all times without nuisance. Upon completion of the work, all sanitary provisions and facilities shall be removed from the premises by the Contractor, leaving the premises clean and free from nuisance.

In accordance with Section 2, Subpart 02.C of EM 385-1-1, provide, maintain, and make available to all workers an adequate supply of potable water for both drinking and personal cleansing. During hot weather, provide cool drinking water.

In accordance with Section 2, Subpart 02.E of EM 385-1-1, provide, maintain, and make available to all workers adequate minimum field-type portable toilets. Portable toilets shall be properly secluded from public observation in such a manner as required or approved by the Contracting Officer. Periodically empty wastes into a municipal, district, or station sanitary sewage system, or remove waste to a commercial facility. Include provisions for pest control and elimination of odors.

Any penalties and/or fines associated with improper discharge of wastewater shall be the responsibility of the Contractor. Government toilet facilities will not be provided.

29. Preparation of Record Drawings. Maintain at the jobsite one set of full-size contract drawings marked to show all deviations which have been made from the contract drawings, including buried or concealed construction and utility features revealed during the course of construction. Record the horizontal and vertical location of all buried utilities that differ from the contract drawings. These drawings shall be available for review by the Contracting Officer at all times. Upon completion of the work, submit the original marked set of prints to the Contracting Officer for approval. Requests for partial payments will not be approved if the marked prints are not current, and request for final payment will not be approved until the marked prints are submitted to and approved by the Contracting Officer.

The entries shall be made in the jobsite set of prints at the time field changes are made, pertinent information collected, or need for corrections established, as a continuing process during the life of the contract. As revised drawings are issued by the Contracting Officer, revised prints shall be introduced into the set to replace the superseded drawings and all applicable notations previously made on the superseded drawings transferred to the current prints. Carefully prepared sketches, not less than 8-1/2 inch by 11 inch, may be used to depict changes or added information in lieu of notations on the actual prints. Staple sketches to the prints affected by the change.

All plan views, sections, elevations, profiles, diagrams, details, or schedules affected by a change shall be marked up as required to reflect the change. All notations or changes made on the prints shall be in sufficient detail to clearly depict the change. Colored pens or pencils shall be used to make notations on the record prints as follows:

Red pen or pencil shall be employed to indicate added or corrected work or information.

Green pen or pencil shall be used to show the deleted or incorrectly depicted work or information.

Blue or black pen or pencil shall be used to show information not to be recorded on the drawings but included on the marked-up prints for explanatory or clarification purposes for the benefit of the Contracting Officer.

C. Safety

1. Accident Prevention Plan: The Contractor shall prepare an Accident Prevention Plan (APP) specific to the activities being performed. It shall include an Activity Hazard Analysis (AHA) as described in Paragraph "2" below. All work shall be conducted in accordance with the APP, the U.S. Army Corps of Engineers Safety and Health requirements Manual (EM 385-1-1, 2014 edition), and all applicable Federal, State, and local safety and health requirements. The APP shall detail how safety and health will be managed during the project. The APP shall address the requirements of applicable Federal, State and local safety and health laws, rules, and regulations.

The Contractor shall comply with Federal Acquisition Regulation Clause No. 52.236-13 for Accident Prevention, which is added by reference. Special attention shall focus on the requirements of EM 385-1-1, specifically Section 01.A.11 through 01.A.18, Figure 1-2 AHA, and Appendix A, (Minimum Basic Outline for Accident Prevention Plan). The APP shall be developed by a qualified person. The Contractor shall be responsible for documenting the qualified person’s credentials. Work shall not proceed until the APP has been reviewed by the Government Designated Authority (GDA) and deemed acceptable for use on the project.

The APP shall interface with the Contractor's overall safety and health program. Any portions of the Contractor's overall safety and health program referenced in the APP shall be included in the applicable APP element and made site-specific. The Government considers the Prime Contractor to be the "controlling authority" for safety and health of the subcontractors. Contractors are responsible for informing their subcontractors of the safety provisions under the terms of the contract, the penalties for noncompliance, and inspecting subcontractor operations to ensure that accident prevention responsibilities are being carried out.

The Contractor shall conduct a safety meeting at the project site on the first day of work, whenever a new activity or phase of work begins, or at least weekly during the progress of work. All safety meetings shall be documented.

A copy of a suggested weekly safety meeting form will be provided by the Contracting Officer’s Representative. Records of the safety briefings shall be submitted to the GDA weekly.

2. AHA: An AHA shall be submitted for each major phase of work. A major phase of work is defined as an operation involving a type of work presenting hazards not experienced in previous operations or where a new subcontractor or work crew is to perform the work. The analysis shall define all activities to be performed, identify the sequence of work, the specific hazards anticipated, and the control measures to be implemented to eliminate or reduce each hazard to an acceptable level. Work shall not proceed on a phase of work until the AHA has been accepted by the GDA. A preparatory meeting shall be conducted by the Contractor to discuss the AHA contents with all engaged in the activity. The preparatory meeting shall be conducted by the prime Contractor and shall include all subcontractors and Government on-site representatives. The AHA shall be continuously reviewed and revised to address changing site conditions or operations as appropriate.

3. Accident Reporting: All accidents and near misses shall be investigated by the Contractor. All work-related recordable injuries, illnesses and property damage accidents (excluding on-the- road vehicle accidents), in which the property damage exceeds $5,000.00, shall be verbally reported to the GDA within 24 hours of the incident.

Serious accidents as described in EM 385-

1-1, Section 01.D.02, shall be immediately reported to the GDA. ENG Form 3394 (available from the Contracting Officer’s Representative) shall be completed and submitted to the GDA within five working days of the incident.

The Contractor shall complete the “USACE Contractor Monthly Summary Record of Injuries/Illness and Work Hour Exposure” (for prime and its subcontractors), an EXCEL spreadsheet available from the Contracting Officer’s Representative, and forward the completed form to the GDA no later than close of business on the 10th calendar day of the following month. The method of transmission by the prime contractor to the GDA shall be electronically.

4. Site Safety and Health Officer (SSHO): The Contractor shall designate one individual as the SSHO.

Documentation of SSHO qualifications shall be submitted for approval prior to initiating work. The SSHO shall have:

A. A minimum of five years of experience in implementing safety and health programs at similar projects, along with a 30 hour OSHA training (or equivalent);

B. Working knowledge of construction safety procedures as well as Federal and state occupational safety and health regulations.

C. Documented experience overseeing Confined Space Entries, related safety equipment, and PPE applicable to this project.

The SSHO may have other duties in addition to site safety and health, but may not be the Contractor’s Site Superintendent.

5. Equipment: The Contractor shall submit to the Contracting Officer’s Representative a current written safety inspection for all heavy equipment proposed for use on this contract. The Contractor, upon award of the contract, will be required to make available for suitability and safety compliance inspection all equipment proposed for use to perform the work of this contract. Equipment shall be made available for inspection by the Government Representative five working days prior to the start of construction. Any additional equipment added during the prosecution of the work shall also be made available for inspection prior to its use on the project. The Contractor shall keep equipment available for inspection by the Contracting Officer’s Representative during the construction process.

Equipment not accepted by the Contracting Officer’s Representative should be repaired or replaced by the Contractor.

D. Submittals Required

Items for Submission. The Contractor shall submit the items identified below for approval to the Contracting Officer. Government acceptance, as defined in EM 385-1-1, is required for safety related submittals (identified below with an “S” after the submittal name). The Contractor shall submit electronic copies of each submittal item in PDF format. The Contractor will be informed at the Preconstruction Conference to send all submittals to either the project Resident Office or to the project Area Engineer Office, or other office, as applicable.

Preconstruction Submittals: The following submittals shall be made by the Contractor and review action completed by the Contracting Officer prior to the commencement of work at the site.

Initial Progress Schedule: In accordance with the contract clauses, the Contractor shall, within five days after receipt of Notice to Proceed (NTP), or as otherwise determined by the Contracting Officer, submit for approval a practicable Initial Project Schedule. When changes are authorized that result in contract time extensions, the Contractor shall submit a revised project schedule for approval by the Contracting Officer..

Accident Protection Plan (S): The Contractor shall prepare an Accident Prevention Plan (APP) specific to the activities being performed. It shall include an Activity Hazard Analysis (AHA) for each major phase of work

Site Specific Confined Space Entry Plan (S): Due to the confined space work environment, the Contractor will be required to submit a Confined Space Program with site specific Confined

Space Entry Procedures IAW Section 34 in the EM 385-1-1 (2014). These shall be developed and submitted to the GDA for review and acceptance as part of the APP prior to the start of work.

These documents shall be developed by a Confined Space Competent Person (CSCP), who meets the definition of CSCP listed in Appendix Q in the EM 385-1-1. The qualifications of the CSCP shall be included for review. The plan shall describe in detail the specific practices, equipment, permits, roles and responsibilities, training, and rescue procedures that will be in place to protect workers from confined space entry hazards.

SSHO Qualifications (S): Documentation of SSHO qualifications shall be submitted for approval.

Safety Inspection for all Heavy Equipment (S): The Contractor shall submit a current written safety inspection for all heavy equipment proposed for use on this contract

Construction Site Plan. Prior to the start of work, the Contractor shall submit a site plan showing the locations and dimensions of temporary facilities.

Work Plan: The Contractor shall submit a written Work Plan describing the methods and equipment required to accomplish the work and provide the required environmental and worker protection.

Environmental Protection Plan: The Contractor shall submit an Environmental Protection Plan for review and approval by the Contracting Officer.

Product Submittals: The Contractor shall submit documentation that the following proposed products meet or exceed the material specified in the contract drawings unless otherwise approved in writing by the Contracting Officer and to comply with the approved Project Schedule, as appropriate:

1. Stainless Steel Pipe Straps and associated hardware.

Other Submittals: The following submittals shall be made by the Contractor to allow sufficient time for review action to be taken by the Contracting Officer and to comply with the approved Project Schedule, as appropriate.

Accident Reports (S)

Monthly Summary Record of Injuries/Illness and Work Hour Exposure (S)

Periodic Schedule Updates: An updated schedule showing actual progress shall be submitted monthly or with each pay request.

Record Drawings: Record drawings showing all deviations which have been made from the contract drawings shall be submitted to the Contracting Officer for approval at the completion of work. See paragraph RECORD DRAWINGS for record keeping and submittal requirements.

Approved Submittals. The Contracting Officer's approval of submittals shall not be construed as a complete check, but will indicate only that the general method of construction, materials, detailing and other information are satisfactory. Approval will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor under the Contractor Quality Control (CQC) requirements of this contract is responsible for the satisfactory construction of all work. After submittals have been approved by the Contracting Officer, no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.

Disapproved Submittals. The Contractor shall make all corrections required by the Contracting Officer and promptly furnish a corrected submittal in the form and number of copies specified for the initial submittal. If the Contractor considers any correction indicated on the submittals to constitute a change to the contract, a notice shall be given promptly to the Contracting Officer.

E. Technical Requirements

All technical requirements for the work of this project are shown on the contract drawings.

G. Delivery, Handling and Storage

As appropriate, materials shall be delivered to the project site in the manufacturer’s original packaging with the brand and item identification reference clearly marked. Components shall be stored in a dry location that is adequately ventilated, free from dust, water, or other contaminants, and which is easily accessible for inspection and handling.

H. Material Warranties

Manufacturer’s standard performance guarantees or warranties that extend beyond a 1-year period shall be provided.

I. Coordination

Liaison with the U.S. Army Corps of Engineers, New England District, by the Contractor shall be maintained for the duration of the project by communication with the Contracting Officer’s Representative assigned to this project. All Contractor project related questions, comments, clarifications, etc. shall be directed to the Contracting Officer’s Representative for action.

J. References

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 241 (2009) Standard for Safeguarding Construction, Alteration, and Demolition Operations

NFPA 70 (2014; AMD 1 2013; Errata 1 2013; AMD 2 2013; Errata 2 2013; AMD 3 2014; Errata

3 2014) National Electrical Code

AMERICAN ASSOCIATION OF STATE HIGHWAY AND TRANSPORTATION OFFICIALS

MUTCD, Manual on Uniform Control Devices (2009)

U.S. ARMY CORPS OF ENGINEERS

Safety and Health Requirements Manual, U.S. Army Engineering Manual, EM-385-1-1, 2014.

DRAWINGS & ATTACHMENTS

DRAWINGS

THIS DRAWING IS FIO

STRAP

NUMBER

NEW NUTS, ANCHOR

RODS, AND SPRINGS

ON BOTH SIDES

NEW STRAP OTHER NOTES

11 YES YES N/A 1, 2, 3, 4

13 NO NO

PROVIDE NEW

NUT AND

WASHER ON

LEFT SIDE

1, 2

14 NO NO TIGHTEN LOOSE

NUTS 1, 2

15 YES REUSE N/A 1, 2, 3, 4

20 YES YES N/A 1, 2, 3, 4

21 YES YES N/A 1, 2, 3, 4

22 YES YES N/A 1, 2, 3, 4

23 YES REUSE N/A 1, 2, 3, 4

30 YES YES N/A 1, 2, 3, 4

41 YES YES N/A 1, 2, 3, 4

42 YES YES N/A 1, 2, 3, 4

51 YES REUSE N/A 1, 2, 3, 4

52 YES REUSE N/A 1, 2, 3, 4

54 YES YES N/A 1, 2, 3, 4

55 YES YES N/A 1, 2, 3, 4

57 YES YES N/A 1, 2, 3, 4

61 YES REUSE N/A 1, 2, 3, 4

65 YES REUSE N/A 1, 2, 3, 4

66 YES YES N/A 1, 2, 3, 4

70 YES YES N/A 1, 2, 3, 4

71 YES YES N/A 1, 2, 3, 4

79 YES YES N/A 1, 2, 3, 4

82 YES YES N/A 1, 2, 3, 4

85 YES REUSE N/A 1, 2, 3, 4

91 YES YES N/A 1, 2, 3, 4

96 YES REUSE N/A 1, 2, 3, 4

Note 1: Pipe straps are counted from the downstream bulkhead

Note 2: Contractor shall field verify all dimensions

Note 3: New strap shall be located as close as practible to the existing strap

Note 4: Old anchor rods shall be cut flush with concrete

SECTION I - CONTRACT CLAUSES

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within FIFTEEN (15) DAYS AFTER NOTICE TO PROCEED, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than THREE HUNDRED (300) CALENDAR DAYS AFTER NOTICE TO PROCEED. The time stated for completion shall include final cleanup of the premises.

(End of clause)

The following have been deleted:

52.222-55

SECTION L - INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

The following have been deleted:

252.209-7992 (Dev)

The following included by full text have been revised:

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/ http://farsite.hill.af.mil

(End of provision)

(End of Summary of Changes)