W912QR24Q0038.pdf

Patoka Lake Tow er Heating Unit Replacement.

This estimated contruction cost is betw een $25,000 and $50,000.

One firm-f ixed price construction purchase order w ill be aw arded on the low est total price quote.

NAICS code 238220, Size Determination $19,000.00.

This project is 100% set-aside for Small Business.

The solicitation w ill be available on the w eb only. Faxed, Telephoned, or mailed requests for this solicitation w ill not be honored. To dow nload the solicitation for this project, and to view other contracting opportunities, contractors are required to register as Sam.gov.

PLEASE NOTE: SAM is completely free of charge to registrants and users.

MARCIE BILLOTTO 502.315.6213

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

07-Mar-2024

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______14 calendar days and complete it w ithin ________30 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________21 Mar 2024 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

12:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 502.315.7494 TEL: FAX:

W912QR24Q0038 34

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912QR24Q0038

SPECIAL INSTRUCTIONS

Contractor shall provide Heating Unit removal, replacement, & repair for Patoka Lake Tower at Patoka Lake.

The contractor’s work and responsibility will include furnishing all labor, materials, supplies, tools and, equipment necessary to assure that all work is conducted in accordance with the contract requirements and all applicable Federal, State and Local laws and regulations. All work will be performed in strict compliance with the attached specifications and all other terms and conditions incorporated herein. Work will shall begin with in 14 calendar days of award and must conclude 30 calendar days after date of award.

Location:

United States Corps of Engineers Patoka Lake Tower 4512 N. Cuzco Road South Dubois, Indiana 47527-9661

This procurement is 100% set-aside for Small Business, NAICS 238220, Size Standard $19,000.00.

Method of Payment under this contract will be Electronic Funds Transfer (EFT) to a commercial bank account specified by the Contractor.

Note: The contract award will be based on lowest total price to the Government.

Quotes are due 21 March 2024, 12:00PM Eastern Time. Fax and mailed submittals will not be accepted.

Electronic submittals may be emailed to Marcie Billotto at marcie.billotto@usace.army.mil.

Offerors shall submit any questions regarding this solicitation in writing to marcie.billotto@usace.army.mil no later than 11:00 AM Eastern Time on 15 March 2024, in order to allow a written response prior to the quote due date. No remarks or written responses to questions by government personnel will change the terms or conditions of this RFQ.

The RFQ will only be changed by a formal written amendment.

All contractors must be registered in the System for Award Management (www.SAM.gov) prior to submission of proposal. All proposed contractors are highly encouraged to review FAR Clause 52.232-33 Payments by Electronic Funds Transfer – System for Award Management, which indicates “All payments by the Government under this contract shall be made by electronic funds transfer (EFT).” Those not currently registered can obtain registration by going to the website http://www.SAM.gov. The process can usually be completed from 24 to 48 hours after submission. Contractors will need to obtain a Unique Entity Identifier (formerly DUNS number) for processing their registration. If you do not already have a Unique Entity Identifier, one can be obtained from http://www.SAM.gov.

Please begin the registration process immediately in order to avoid delay of the contract award should your firm be selected.

ALERT: You must submit a notarized letter appointing the authorized Entity Administrator before your registration will be activated. This requirement now applies to both new and existing entities. Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required before the GSA Federal Service Desk (FSD) will activate the entity's registration.

Effective 29 June 2018, vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) within 30 days of activation or the vendor risks no longer being active in SAM.

Vendors can check whether an account is active by performing a query by their CAGE or Unique Entity Identifier.

The new registration process may now take several weeks, so vendors are highly encouraged to begin registering as soon as possible to avoid any possible delays in future contract awards. Remember, there is no cost to use SAM.

To find out additional information about the changes of the SAM registration process, contractors should visit the Frequently Asked Questions (FAQ) link located at the top of the SAM homepage (www.sam.gov).

Request for Quotes:

-Companies responding to this request for quotes should provide a good total dollar figure.

PRICE BREAKOUT SCHEDULE

Line Item Description Unit/Qty Unit Price Total

0001 6 ton geothermal heating and cooling unit

Job-1 $ $

The contractor will be responsible for all costs involving shipping, delivery, storage, any rentals or associated equipment to install above item and will be part of the contract offer price.

DEPARTMENT OF THE ARMY

U.S. Army Engineer District, Louisville.

Patoka Lake

4512 N. Cuzco Rd South Dubois, Indiana, 47527-9661

812-678-3761

FAX – 812-678-3762

POC Steven M Rector SOW for FY23 Patoka Lake Tower Heating Unit Replacement

TP-1.1 GENERAL:

a. Description. The contractor shall furnish all materials, supplies, tools, parts, equipment, transportation, labor, supervision, communication, and quality control to complete the work listed below, at the areas specified at Patoka Lake, located in Dubois County, Indiana.

b. Work. Shall be provided in accordance with all Terms, Conditions, General, Specific and Technical Provision, Exhibits Attachments, Drawings, etc. contained herein or incorporated by Reference. This includes all mandatory provisions of the Federal Acquisition Regulation (FAR), whether referenced or not, current at time of award.

c. Contractor Responsibility. Contractor’s work and responsibility shall include but are not limited to supply of equipment/materials, all planning, programming, administration, management, supervision, and inspection required to assure all equipment/materials are acquired and services are conducted in accordance with the contract and all applicable laws, regulations, or directives. The Contractor shall insure all work meets or exceeds specifications.

The prime Contractor shall be responsible for ensuring all subcontractors comply with the provisions of this contract.

At no time should the contractor do additional work without prior authorization of the Contracting Officer, and no work shall be performed that will cause the Contractor to exceed the contract price. Work performed without a binding contract document authorizing such work shall result in the Contractor not being paid for that work performed. During the contract, any additional work determined to be needed may be requested by the Park Manager to the Contracting Officer for a Contract Modification.

d. Performance Required. Special consideration of the Contractor is directed to the fact that the required accuracy, thoroughness, safety, and progress of this work are essential to the intended purpose. The contractor must be cognizant of the difficulties involved and of the contingencies which may arise, and must make certain that their personnel, equipment, transportation facilities and supply of materials are always adequate to ensure complete compliance with all provisions of these specifications. The work shall be done under professional supervision by competent employees. All contract services shall be in accordance with the submitted documents, and any additions, revisions or deletions must be approved by the Contracting Officer or his/her authorized representative.

e. Completion of Work. Completion of work shall include acceptable performance of all aspects of this contract.

f. Payment. Payment will be made by Electronic Funds Transfer (EFT), upon acceptance of the completed work and providing final invoice and labor records.

g. Conditions. N/A

h. Pre-Work Conference. Seven (7) days after the contractor receives the notice to proceed the contractor must attend a pre-work conference prior to beginning work. During which time the Contractors plan of work procedures, safety procedures, fencing area off for public safety, start-up date, and other items included in this contract will be briefly discussed.

i. Damages. The contractor shall be responsible for all damages to government or private property during this contract. The contractor shall, at their own expense, provide and maintain during the entire performance of this contract the following: Insurance Type – General Liability (Bodily Injury and Property Damage Combined) Minimum Amounts of Liability $100, 000.00 Each Occurrence, $100,000.00 Aggregate. The Contractor is required to provide a Certificate of Insurance to the Park Manager at the time of the Pre-work Conference.

j. Hours and Days of Work. Work may be conducted between the hours of 7:00 a.m. and 3:45 p.m. (Local time/EST), Monday through Friday. No work shall be performed outside of these times, or on Saturday or Sunday or on federal Holidays, unless approved by the Technical POC.

Federal Holidays When one of the designated holidays falls on a Sunday the following Monday is observed as a legal holiday. When a legal holiday falls on a Saturday, the preceding Friday is observed as a holiday.

Work that interferes with other ongoing functions at the project shall be scheduled around normal working hours to be approved by Project Manager. Work shall be scheduled around the above listed Federal holidays unless approved in advance.

Eleven Federal holidays observed are as follows:

New Year’s Day (January 1st) Martin Luther King Day (3rd Monday in January) President’s Day (3rd Monday in February) Memorial Day (Last Monday in May) Juneteenth (19th June) Independence Day (July 4th) Labor Day (1st Monday in September) Columbus Day (2nd Monday in October) Veterans Day (November 11th) Thanksgiving (4th Thursday in November) Christmas (December 25)

k. Contract Start and Completion Dates. Work under this contract must be completed within 30 days from receipt of Award.

l. Wage rates: Department of Labor wage rates apply to this work and are included. The contractor is required to provide payroll documents for all work performed under this contract.

m. Special Requirements.

1. The Contractor shall, always take care to protect and preserve all materials, supplies, and equipment of every description (including material and property which may be Government owned) and all work performed. All reasonable requests of the Contracting Officer or his/her authorized representative to enclose or specially protect such property shall be complied with. The Government is not responsible for providing storage areas or facilities for the storage of Contractor supplies, materials, and equipment. With prior approval, the Park Manager/Technical POC may provide a location for the Temporary storage of materials, tools, and equipment.

However, the Government assumes no liability for the loss, damage to, or destruction of Contractor equipment while it is stored on Government Property.

2. If so, determined by the Contracting Officer, material, equipment, supplies, and work performed are not adequately protected by the Contractor, such property may be protected by the Government and the cost thereof may be charged to the Contractor or deducted from any payment due to them.

3. The Contractor will notify the Lake Manager upon commencement of work activities, and difficulties, interruption, or suspension of work, and when the required work has been completed.

The Contractor shall update the Lake Manager no less than once weekly on status of work being done.

4. Equipment malfunctions/breakdowns or other situations adversely affecting the performance of contract work shall be promptly reported to the Park Manager. However, the reporting of such situations shall not be constructed as an excuse for not performing the specified work before the required completion date.

TP-1.2 CONTRACTOR SUBMITTAL.

Unless otherwise specified, the Contractor shall submit the following information to the Technical POC prior to the pre-work conference for this contract:

a. Safety Plans.

Unless otherwise specified, the Contractor will submit the following information to the TPOC prior to the prework conference for this contract

a. Quality Control Plan. A suggested outline for the Contractor's Quality Control Plan.

b. Contractor Quality Control Inspector. List of Quality Control Inspectors.

c. Contractor Representatives. List of names of Contractor Representatives.

d. Accident Prevention Plan (APP). A suggested outline for the Contractor’s Accident Prevention Plan Appendix A of EM 385-1-1 See Section C-1.9 for APP requirements. Exhibit D.

e. Emergency Contacts. A prioritized list, including phone numbers, of those persons (normally Contractor Representatives) to call in case of emergencies.

f. Operators. A list of names of qualified equipment/vehicle operators, including experience, training and qualification to operate specific equipment.

g. Certificate of Insurance.

h. Performance Bond. (where applicable)

i. Security Requirements.

TP-1.3 SAFETY.

a. General Safety. The Contractor shall comply with the safety standards contained in Corps of Engineers Manual, EM 385-1-1, “Safety and Health Requirements Manual”, current at the time of award, as well as all current provisions of the Occupational Safety and Health Act (OSHA).

b. Safety Manual Requirements. The Contractor and employees shall comply with the Corps of Engineer’s Safety and Health Requirements Manual, EM 385-1-1, current at the time of award, and any subsequent revisions. This manual will be available on the Internet at:

http://www.publications.usace.army.mil/. Near the top of the screen, place cursor on (USACE Publications), a drop-down menu appears, highlight Engineer Manuals, Click, new Screen appears / select EM 385-1-1. Contractor’s safety plan must be submitted in writing and can be turned in at the same time as the pre-work conference.

c. Personal Protective Apparel and Equipment. Protective apparel and equipment, as identified in the AHA, shall be provided to eliminate or minimize hazards to personnel. As a minimum, each employee shall wear a sleeved shirt, long trousers and safety-toe shoes or boots during all contract work. Hard hats, face shields, safety glasses with side-shields, or goggles, and hearing protection shall be worn by employees when required by safety manual. Fire extinguisher(s) and first aid kit(s) meeting the Safety Manual standards shall also be provided and easily accessible to all employees.

d. Contractor Requirements.

a. General. Performance of all services will assure complete safety to public visitors, Contractor employees, and all other persons in the area. The Contractor will comply with any pertinent requirements contained in the Corps of Engineers Safety Manual (EM 385-1-1), current at the time of award and any subsequent revisions to that document. Furthermore, the Contractor will comply with pertinent occupational safety and health standards for general industry (29 CFR Part 1910) as required by the Occupational Safety and Health Administration (OSHA). If the Contractor fails or refuses to promptly comply with safety and security requirements as specified herein, the TPOC or any other project employee may stop all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to any such work stoppage will be made subject to any claims for extension of time or for excess costs or damages sustained by the Contractor. Also, the Contractor will not be paid for work not performed as a result of the stop order.

b. The Contractor will comply with the Occupational Safety and Health Act (OSHA), the Corps of Engineers Manual, EM 385-1-1, https://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1- 1.pdf or latest version and as otherwise stated herein. Special attention will be given to the requirements for safety meetings.

The Contractor will inform the TPOC a minimum of 7 calendar days prior to a Contractor monthly safety meeting, to permit a government representative to attend.

c. Accident Prevention Plan (APP). The Contractor will prepare an Accident Prevention Plan to assure that requirements of the safety program are provided as specified. This plan must be accepted by the Contracting Officer prior to commencement of any work. One copy of the Accident Prevention Plan will be provided to the Contracting Officer and the TPOC one week prior to the pre-work conference. The Accident Prevention Plan must be in the outline and form prescribed in Appendix A of EM 385-1-1.

d. Activity Hazard Analysis (AHA). The Contractor will use Activity Hazard Analyses (AHA’s) as one of many tools to insure safe performance of work. It is the Contractor’s responsibility to prepare the AHA. Sample AHA’s may be available at the project office for review and use by the Contractor to assist in the development of site-specific Activity Hazard Analyses prior to the Contractor performing the job. The Contractor is encouraged to revise or add to these sample AHA’s as necessary to address changing conditions. Prior to performing jobs with inherent hazards, the Contractor will review, at a “Toolbox” safety meeting, the approved AHA’s with those employees who will perform that work each time the work is ordered. The Government may request advanced notification of the time and date of the above AHA “Toolbox” safety meeting for Contractor employees so that the Government may attend such reviews.

The Government will require the Contractor to prepare an AHA for any jobs for which an adequate AHA does not already exist. A copy of this AHA will be submitted to the TPOC and must be accepted before the Contractor starts the job. This copy of the AHA will become the property of the Government. Guidance is included, which will be used by the Contractor as a guide for the preparation of required AHA's.

A copy of the approved AHA’s will be always available to workers at each associated job site and a copy will be provided to the Government.

e. Public Safety. The Contractor will ensure that reasonable precautions are taken to always protect the public where work is being performed. The Contractor will immediately report to the TPOC any potential hazards found by his employees on the project. The Accident Prevention Plan will include procedures to be taken to provide for public safety. Additionally, the Contractor will not allow any persons, except employees, into work areas that are not otherwise open to the public; nor will the Contractor transport in Contractor work vehicles any persons, except employees, during times the Contractor is on the project performing work under a contract.

f. Personal Protective Apparel and Equipment. Protective apparel and equipment, as identified in the AHA, will be provided to eliminate or minimize hazards to personnel. As a minimum, each employee will wear a short-sleeved shirt, long trousers, and appropriate footwear during all contract work. Face shields, spectacles with side-shields, or goggles, and hearing protection will be worn by employees when required by safety manual. Fire extinguisher(s) and first aid kit(s) meeting the Safety Manual standards will also be provided and easily accessible to all employees.

g. Contractor Employees Certified in First Aid & CPR. The Contractor will schedule employees, so the appropriate numbers of certified personnel are on duty to administer First Aid and CPR as required by the Safety Manual.

Copies of their certification will be provided in accordance with regulations. Two people per crew will be trained in First Aid and CPR. Individuals working alone will be trained in First Aid.

h. Hazard Communication Program. The Contractor will be responsible for implementing a hazard communication program for Contractor employees, as required by the Safety Manual. The Contractor will provide Material Safety Data Sheets (MSDS) and/or Safety Data Sheets (SDS) for review by the TPOC prior to use of any hazardous substance on the project and provide a plan for the proper handling, transportation, storage and usage of hazardous substances on the project.

TP-1.4 ACCIDENT REPORTING.

The Contractor shall maintain accurate accident records and report accidents as prescribed by the Technical POC. Accidents shall be reported within 24 hours of occurrence and all serious accidents (those resulting in death or injury requiring medical attention or lost time) shall be reported immediately.

TP-1.5 DAMAGE REPORTS.

In all instances where Government property, equipment, natural features, landscape, or trees are damaged by contract employees, an immediate notification shall be made to the Technical POC. A full report of the incident and extent of such damage shall be submitted to the Technical POC within two working days of occurrence, excluding weekends and holidays.

TP-1.6 CONTRACT EMPLOYEES.

All contract employees shall always conduct themselves in a proper and courteous manner.

Contract employees shall comply with all provisions of Title 36, Chapter III, Part 327, CFR and obey all posted signs and regulations in the performance of the work under this contract. Being under the influence of or consuming alcoholic beverages or controlled substances by the Contractor or employees while on duty is prohibited.

TP- 2.1 SPECIAL REQUIREMENTS:

a. All contractors must be registered in the System for Award Management (www.SAM.gov) prior to award of a contract. All proposed contractors are highly encouraged to review FAR Clause 52.232-33 Payments by Electronic Funds Transfer – System for Award Management, which indicates “All payments by the Government under this contract shall be made by electronic funds transfer (EFT).” Those not currently registered can obtain registration by going to the website http://www.SAM.gov. The process can usually be completed from 24 to 48 hours after submission.

Contractors will need to obtain a Unique Entity Identifier (formerly DUNS number) for processing their registration. If you do not already have a Unique Entity Identifier, one can be obtained from http://www.SAM.gov. Refer to www.SAM.gov for information formerly found in CCR, EPLS, ORCA and FedReg.

Please begin the registration process immediately to avoid delay of the contract award should your firm be selected.

ALERT: You must submit a notarized letter appointing the authorized Entity Administrator before your registration will be activated. This requirement now applies to both new and existing entities.

Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required before the GSA Federal Service Desk (FSD) will activate the entity's registration.

Effective 29 June 2018, vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) with 30 days of activation or the vendor risks no longer being active in SAM.

PLEASE NOTE: SAM is completely free of charge for both registrants and users.

TP- 2.2 SECURITY SECTION:

1.General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor (“Contractor”) and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of

Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as “RAMs”), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

3. Physical security and access control requirements: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as “NCIC-III”) and Terrorist Screening Database (commonly referred to as “TSDB”). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed.

Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

6. Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or see something, Say Something): All contract personal shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

14. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/ eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

SUPPLEMENTAL SECURITY REQUIREMENTS

All Contractors and subcontractor employee(s) working on this contract who require access to any Louisville District Lake Projects and Lock and Dam Projects shall receive authorization to be on site at these facilities based upon a favorable background investigation in accordance with “Homeland Security Presidential Directive 12: Policy for a Common Identification Standard for Federal Employees and Contractors” (HSPD 12). The Louisville District Security Management Office shall submit contractor(s) personal information to complete the basic background investigation in order to make a recommendation to the Contracting Office of an employee’s suitability for work on Government property. The Procuring Contracting Officer (PCO) has the right to deny any contractor or subcontractor employee from working on the contract based upon the results of the background investigation provided by the Louisville District Security Office. The Government, Contractor, and subcontractors shall not permit any employee(s) access to drawings, blueprints, records, photos, sites, or projects until the Louisville District Security Management Office has completed an Operations Security (OPSEC) review of such items and determined they can be released.

FOR ALL LOUISVILLE DISTRICT CONTRACTS:

Contractors shall submit a complete investigation packet for each contractor and subcontractor employee to the Louisville District Security Management office within 10 working days after award of any contract, or prior to the individual being permitted access to Louisville District facilities.

The Contractor must also provide the following: (1) Name of the Contract Specialist with whom he/she is working,

(2) Project Name, (3) Contract Number (4) Task Order Number when applicable, and (5) US Citizens Security Access Form or Pre-Bid/Site Visit Form; each employee working on site must have a background investigation form submitted directly to the Louisville District Security Office.

The Contractor must provide a full legal name, complete SSN#, Date of Birth, Place of Birth (City and State) and Driver’s license number if available. It is the Contractor’s responsibility to ensure the above information is accurate and legible, otherwise delays may occur.

Contractors shall have background checks completed for their employees annually in the case of Contracts with an initial period of performance (POP) greater than 1 year and those Contracts with Options or Modifications Which Extend the POP beyond 1 year. For instance, if the employee was cleared in May of 2022, they shall be cleared again in May of 2023. It is the Contractor’s responsibility to ensure that each employee’s security is up to date. Failure to comply may lead to possible removal from the project/jobsite.

The Contractor must ensure if new employees are brought in to work on an existing Contract with the U.S.

Army Corps of Engineers (USACE), they must process the employee through the Louisville District USACE Security Office for background purposes.

FOR CONTRACTORS REQUIRING DOD COMMON ACCESS CARDS (CAC)

The documents listed below are required: SF 85, Questionnaire for Non-Sensitive Positions (see http://www.opm.gov/forms/ to print form). Fingerprints are captured electronically at the closest Army Recruiting Station to the contractor’s home of record or at the USACE, Louisville District Security Office.

Contractor shall report any changes in personnel, or at any time conditions change at least 5 working days prior to individual(s) need to have access to the site. The Contractor shall provide the same information as listed above for all new employees.

Following submission of paperwork, the Louisville District Security Office will conduct an initial criminal check based upon the information provided. If there are no issues, the Louisville District Security Office will make recommendations to the PCO or their Designated Representative. The Louisville District Security Office cannot give approval due to unfavorable report(s). The Louisville District Security Office shall coordinate with Office of Counsel and will jointly make recommendations to the PCO and/or the Designated Representative should a background investigation come back with derogatory information. The PCO will make the determination whether to allow the Contractor personnel to work on the site based on Security and Office of Counsel recommendations, and the PCO will advise the Contractor of the decision.

FOREIGN NATIONALS

The Contractor shall provide the package listed above, as well as additional materials noted below for all Foreign Nationals. The Contractor is to expect additional time in the approval process for all Foreign Nationals due to the level of review and elevation of the review to Headquarters staff to complete. All Foreign Nationals must comply with the following paragraph:

In accordance with Engineering Regulation 380-1-18, “Technology Transfer, Disclosure of Information and Contacts with Foreign Representatives” dated 1 August 1996, Section 4, all foreign nationals who work on Corps of Engineers’ contracts shall be approved by the Headquarters US Army Corps of Engineers (HQ USACE) Foreign Disclosure Officer before beginning work on this contract; this regulation includes subcontractor employees. The Contractor shall submit to the Security Management Office, the names of all foreign nationals proposed for performance under this contract, along with documentation to verify legal admittance into the United States. Such documentation shall include at least one of the following: a U.S.

passport, Certificate of U.S. Citizenship (INS Form N-560 or N-561), Certificate of Naturalization (INS Form N-550 or N-570), Alien Registration Card with photograph (INS Form I-151 or I-551), Employment Authorization Card (INS Form I-688A), etc.

In order to assure forms are properly completed, and to minimize time delays, the Contractor is encouraged to work closely with the Louisville District Security Office. The Government will return for correction incomplete forms, illegible forms, etc. which will delay the contractor / subcontractor from beginning work.

Security requirements are subject to change in accordance with HSPD-12, Office of Personnel Management, regulation, or policy changes, etc. The Government shall add any changes to security requirements by modification to the contract.

The Contractor shall contact the Louisville District Security Office by phone, letter, or email at the following numbers/addresses:

CELRL-SC

600 Martin Luther King Jr. Pl

Louisville, KY 40202

Charles R. Tanner, phone (502) 315-6929; email Charles.R.Tanner@usace.army.mil James R. Milner, phone

(502) 315-6916; email James.R.Milner@usace.army.mil Jason Almodovar, phone (502) 315-6754; email Jason.Almodovar@usace.army.mil

TP-3.1 GENERAL SPECIFICATIONS

The contractor shall furnish all materials and perform all the labor necessary to remove existing oil heating furnace in control tower and install 6 ton Geothermal heating and cooling unit for US Army

Corps of Engineers at Patoka Lake, IN. The existing heating unit is located inside the tower building and the new geothermal unit will occupy the same footprint and utilize the existing electrical panel located next to the unit. Loop lines will exit the building via a floor level 12” x 12” opening on west wall with 1 ¼” copper supply and return lines down to the water. Then transition to 1 ¼ “ PE SDR 11 pipe and install the lake loop to set on the bottom of the lake. The condensate will be stubbed out the same 12” x 12” opening. There will be a supply air plenum on top of the unit. Reconnect the power from the electrical panel that is next to the unit. The loop lines will include 20% methanol. You will remove and dispose of the old furnace and cap off the fuel lines.

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-22 Alternative Line Item Proposal JAN 2017

CLAUSES INCORPORATED BY FULL TEXT

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/ https://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

REPS & CERTS

REPRESENTATIONS AND CERTIFICATIONS

COMPANY NAME AND ADDRESS: _________________________________________

PHONE NUMBER: _________________________________________

EMAIL ADDRESS: _________________________________________

BUSINESS SIZE (select one or more as applicable):

Large Business ____ Small Business ____ HUBZone ____ 8(a) ____ Women-Owned Small Business ____ Economically Disadvantaged Women-Owned Small Business ____ Service-Disabled Veteran-Owned ____

CURRENTLY REGISTERED WITH SYSTEM FOR AWARD MANAGEMENT (SAM): YES ____ NO ____

(Note: See FAR 52.204-7)

TAX IDENTIFICATION NUMBER (TIN): ____________

UNIQUE ENTITY IDENTIFIER: ____________

(Note: See FAR 52.204-7. The Unique Entity Identifier is a 12 character alphanumeric code.)

CAGE CODE: ________

(Note: See FAR 52.204-7)

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

SEP 2022

252.225-7055 Representation Regarding Business Operations with the Maduro Regime

MAY 2022

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region - Representation

JUN 2023

252.225-7973 (Dev) Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems - Representation (DEVIATION 2020- O0015)

MAY 2020

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220.

(2) The small business size standard is $19,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic…