Amendment0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The Government hereby adds pictures for the dew atering basin at Rough River Lake, Kentucky.

1. CONTRACT ID CODE PAGE OF PAGES

1 12

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912QR23Q0010

X 9B. DATED (SEE ITEM 11)

13-Dec-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

14-Dec-2022

CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

Looking out of conduit

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 1449 - CONTINUATION SHEET

The following have been added by full text:

SITE PICTURES

W912QR23Q0010

Location for Pump

Tailwater Work Area

Stilling Basin Dewatering 14957 Falls of Rough Road

Falls of Rough, Kentucky, 40119-9801

Performance Work Statement

TP-1.1 GENERAL.

a. Description. The contractor shall furnish tools, supplies, equipment, labor, supervision, communication, and quality control necessary to pump water out of the stilling basin as part of the dewatering activities and maintain a 1day dewatered condition at specified levels for fish removal and conduit inspection at Rough River Lake stilling basin located in the Rough River Lake Tail Waters in Grayson County KY. Due to unpredictable water levels and weather conditions, the period of performance will be sixteen (16) months form the date of award.

b. Work shall be provided in accordance with all Terms, Conditions, General, Specific and Technical Provisions, etc. contained herein or incorporated by Reference. This includes all mandatory provisions of the Federal Acquisition Regulation (FAR), whether referenced or not, current at time of award.

c. Contractor Responsibility. Contractor’s work and responsibility shall include but are not limited to supply of equipment/materials, all planning, programming, administration, management, supervision, and inspection required to assure all equipment/materials are acquired and services are conducted in accordance with the contract and all applicable laws, regulations, or directives. The Contractor shall insure all work meets or exceeds specifications. The prime Contractor shall be responsible for ensuring all subcontractors comply with the provisions of this contract.

d. Performance Required. Special consideration of the Contractor is directed to the fact that the required accuracy, thoroughness, safety, and progress of this work are essential to the intended purpose. The contractor must be cognizant of the difficulties involved and of the contingencies which may arise, and must make certain that their personnel, equipment, transportation facilities and supply of materials are adequate at all times to ensure complete compliance with all provisions of these specifications. The work shall be done under professional supervision by competent employees. All contract services shall be in accordance with the submitted documents, and any additions, revisions or deletions must be approved by the Contracting Officer or his/her authorized representative.

e. Completion of Work. Completion of work shall include acceptable performance of all aspects of this contract.

f. Conditions.

1. Pre-Work Conference. The contractor will be required to attend a pre-work conference at least one week prior to beginning work, during which time the Contractor shall supply the COR with an Accident Prevention Plan (APP) and Activity Hazard Analysis (AHA), IAW EM385-1-1 covering the contractor’s plan of work procedures, safety procedures, security, schedule, and equipment. This manual will be available on the Internet at:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf The Contractor shall supply material submittals as listed in Paragraph 1.2 that will be used for this project, which must be approved by the COR prior to start of work.

2. Damages. The responsibility for damage to any part of the permanent work shall be as set forth in CONTRACT CLAUSE: PERMITS AND RESPONSIBILITIES. However, if in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood or earthquake, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor will make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or lump sum prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or lump sum prices applicable to any part of such work, an equitable adjustment pursuant to CONTRACT CLAUSE:

The following have been modified:

PERFORMANCE WORK STATEMENT

CHANGES, will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or lump sum prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

3. Hours and Days of Work. Generally, work will be conducted between the hours of 5:00 a.m. and 3:00 p.m. CST, Monday through Friday. Daily work schedule will be given from Technical POC to Contractor POC. No work shall be performed outside of these times, or on federal Holidays, unless approved by the Technical POC.

Holiday Work. The Eleven Federal holidays observed are:

New Year's Day (January 1st) Martin Luther King Day (3rd Monday in January) President's Day (3rd Monday in February) Memorial Day (Last Monday in May) Juneteenth (June 19th) Independence Day (July 4th) Labor Day (1st Monday in September) Columbus Day (2nd Monday in October) Veterans Day (November 11th) Thanksgiving Day (4th Thursday in November) Christmas Day (December 25th)

When one of the above designated holidays falls on a Sunday, the following Monday is observed as a legal holiday.

When a legal holiday falls on a Saturday, the preceding Friday is observed as a holiday. Work will be scheduled around the above listed Federal holidays except as specified herein or as approved by the TPOC.

4. Payment Procedure/Additional Work. At no time should the contractor do additional work without prior authorization of the Contracting Officer, and no work shall be performed that will cause the Contractor to exceed the contract price. Work performed without a binding contract document authorizing such work shall result in the Contractor not being paid for that work performed. During the course of the contract, any additional work determined to be needed may be requested by the Park Manager to the Contracting Officer for a Contract Modification.

5. Contract Start and Completion Dates. Work must commence on specified days. Receipt of notice to proceed will be given 24 hours prior to scheduled day of dewatering. All services will be completed as scheduled, unless weather or circumstances beyond the control of either party occur requiring a delay in the work. Government reserves the right to delay or stop work as needed to accommodate higher priorities, time allowed for completion will be adjusted accordingly. Additional time may be granted for inclement weather, but only in accordance with a., below.

a. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the contract clause entitled "Default: Fixed Price Construction". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

1. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

2. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

3. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORKDAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

[6] [4] [6] [6] [6] [5] [6] [4] [4] [4] [4] [5]

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated listed above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)".

6. Wage Rates: Department of Labor wage rates apply to this work and are included. The contractor is required to provide payroll documents for all work performed under this contract.

7. The Contractor shall, take care to protect and preserve all materials, supplies, and equipment of every description (including material and property which may be Government owned) and all work performed. All reasonable requests of the Technical POC or his/her authorized representative to enclose or specially protect such property shall be complied with. If so determined by the Technical POC, material, equipment, supplies, and work performed are not adequately protected by the Contractor, such property may be protected by the Government and the cost thereof may be charged to the Contractor or deducted from any payment due to them.

8. The Contractor will notify the Technical POC or his/her authorized representative, upon commencement of work activities, and difficulties, interruption, or suspension of work. The Contractor shall update the Technical POC, or their authorized representative, no less than once daily at beginning, and throughout dewatering on status of work being done. Work will commence when the funds are allocated, and work orders have been received from the Technical POC or his/her authorized representative.

9. SITE VISIT: The Performance Work Statement only contains or reference. Each interested contractor should visit the job site and assume responsibility for quantities, materials, equipment, and work conditions used to calculate a quote.

Site visits will be by appointment only. The site visit will start from the Rough River Lake project office. Those planning to attend shall advise the POC ahead of time. The POC’s contact information is as follows:

Bryan Duvall, Maintenance Leader, or Blake Sullivan, Maintenance Mechanic Rough River Lake 14957 Falls of Rough RD Falls of Rough, KY 40119 270-257-2061

TP-1.2 CONTRACTOR SUBMITTAL. Unless otherwise specified, the Contractor shall submit the following information to the Technical POC prior to the pre-work conference for this contract:

a. Safety Plans. The Contractor shall submit, for acceptance by the Technical POC, an accident prevention plan and Activity Hazard Analysis (AHA) in accordance with the requirements of the Corps of Engineer’s Safety and Health Requirements Manual, EM385-1-1, hereinafter referred to as the Safety Manual, current at the time of award.

b. Certification of Employees Qualified to Administer First Aid and CPR. The Contractor shall submit proof to the Technical POC that the appropriate number of employees, as required in the Safety Manual, are certified to administer First Aid and CPR

TP-1.3 SAFETY.

a. General Safety. The Contractor shall comply with the safety standards contained in Corps of Engineers Manual, EM 385-1-1, “Safety and Health Requirements Manual”, current at the time of award, as well as all current provisions of the Occupational Safety and Health Act (OSHA). Per Par. 01.A.17 of EM 385-1-1, the SSHO is only required to have the minimum listed requirements.

b. Safety Manual Requirements. The Contractor and employees shall comply with all pertinent sections of the Corps of Engineer’s Safety and Health Requirements Manual, EM 385-1-1, current at the time of award, and any subsequent revisions. The Contractor’s safety plan must be submitted in writing prior to onsite work and can be turned in at the same time as the pre-work conference.

c. Personal Protective Apparel and Equipment. Protective apparel and equipment, as identified in the AHA, shall be provided to eliminate or minimize hazards to personnel. As a minimum, each employee shall wear a sleeved shirt, long trousers and safety-toe shoes or boots during all contract work. Hard hats, face shields, safety glasses with side-shields, or goggles, and hearing protection shall be worn by employees when required by the safety manual. Fire extinguisher(s) and first aid kit(s) meeting the Safety Manual standards shall also be provided and easily accessible to all employees.

d. Contractor Employees Certified in First Aid & CPR. The Contractor shall schedule employees, so the appropriate numbers of certified personnel are on duty to administer First Aid and CPR as required by the Safety Manual. Copies of their certification shall be provided before work begins under this contract.

TP-1.4 ACCIDENT REPORTING. The Contractor shall maintain accurate accident records and report accidents as prescribed by the Technical POC. Accidents shall be reported within 24 hours of occurrence, and all serious accidents (those resulting in death or injury requiring medical attention or lost time) shall be reported immediately.

TP-1.5 DAMAGE REPORTS. In all instances where Government property, equipment, natural features, landscape, or trees are damaged by contract employees, an immediate notification shall be made to the Technical POC. A full report of the incident and extent of such damage shall be submitted to the Technical POC within two working days of occurrence, excluding weekends and holidays.

TP-1.6 CONTRACT EMPLOYEES. All contract employees shall conduct themselves in a proper and courteous manner at all times. Contract employees shall comply with all provisions of Title 36, Chapter III, Part 327, CFR and obey all posted signs and regulations in the performance of the work under this contract. Being under the influence of or consuming alcoholic beverages or controlled substances by the Contractor or employees while on duty is prohibited.

TP-2.1 SPECIAL REQUIREMENTS:

Security:

a. General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor (“Contractor”) and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as “RAMs”), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

b. Physical security and access control requirements: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as “NCIC-III”) and Terrorist Screening Database (commonly referred to as “TSDB”). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

c. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E- Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

d. Supplemental Security Requirements:

1. All Contractors and subcontractor employee(s) working on this contract who require access to any Louisville District Lake Projects and Lock and Dam Projects shall receive authorization to be on site at these facilities based upon a favorable background investigation in accordance with “Homeland Security Presidential Directive 12: Policy for a Common Identification Standard for Federal Employees and Contractors” (HSPD 12). The Louisville District Security Management Office shall submit contractor(s) personal information to complete the basic background investigation in order to make a recommendation to the Contracting Office of an employee’s suitability for work on Government property. The Procuring Contracting Officer (PCO) has the right to deny any contractor or subcontractor employee from working on the contract based upon the results of the background investigation provided by the Louisville District Security Office. The Government, Contractor, and subcontractors shall not permit any employee(s) access to drawings, blueprints, records, photos, sites, or projects until the Louisville District

Security Management Office has completed an Operations Security (OPSEC) review of such items and determined they can be released.

2. Contractors shall submit a complete investigation packet for each contractor and subcontractor employee to the Louisville District Security Management office within 10 working days after award of any contract, or prior to the individual being permitted access to Louisville District facilities.

3. The Contractor must also provide the following:

(1) Name of the Contract Specialist with whom he/she is working,

(2) Project Name

(3) Contract Number

(4) Task Order Number when applicable, and

(5) US Citizens Security Access Form or Pre-Bid/Site Visit Form; each employee working on site must have a background investigation form submitted directly to the Louisville District Security Office.

4. The Contractor must provide a full legal name, complete SSN#, Date of Birth, Place of Birth (City and State) and Driver’s license number if available. It is the Contractor’s responsibility to ensure the above information is accurate and legible, otherwise delays may occur.

5. Contractors shall have background checks completed for their employees annually in the case of Contracts with an initial period of performance (POP) greater than 1 year and those Contracts with Options or Modifications Which Extend the POP beyond 1 year. For instance, if the employee was cleared in May of 2022, they shall be cleared again in May of 2023. It is the Contractor’s responsibility to ensure that each employee’s security is up to date.

Failure to comply may lead to possible removal from the project/jobsite.

6. The Contractor must ensure if new employees are brought in to work on an existing Contract with the U.S. Army Corps of Engineers (USACE), they must process the employee through the Louisville District USACE Security Office for background purposes.

7. Foreign Nationals:

The Contractor shall provide the package listed above, as well as additional materials noted below for all Foreign Nationals. The Contractor is to expect additional time in the approval process for all Foreign Nationals due to the level of review and elevation of the review to Headquarters staff to complete. All Foreign Nationals must comply with the following paragraph:

In accordance with Engineering Regulation 380-1-18, “Technology Transfer, Disclosure of Information and Contacts with Foreign Representatives” dated 1 August 1996, Section 4, all foreign nationals who work on Corps of Engineers’ contracts shall be approved by the Headquarters US Army Corps of Engineers (HQ USACE) Foreign Disclosure Officer before beginning work on this contract; this regulation includes subcontractor employees. The Contractor shall submit to the Security Management Office, the names of all foreign nationals proposed for performance under this contract, along with documentation to verify legal admittance into the United States. Such documentation shall include at least one of the following: a U.S. passport, Certificate of U.S. Citizenship (INS Form N-560 or N-561), Certificate of Naturalization (INS Form N-550 or N-570), Alien Registration Card with photograph (INS Form I-151 or I-551), Employment Authorization Card (INS Form I-688A), etc.

8. Security Office Contact: In order to assure forms are properly completed, and to minimize time delays, the Contractor is encouraged to work closely with the Louisville District Security Office. The Government will return for correction incomplete forms, illegible forms, etc. which will delay the contractor / subcontractor from beginning work.

Security requirements are subject to change in accordance with HSPD-12, Office of Personnel Management, regulation or policy changes, etc. The Government shall add any changes to security requirements by modification to the contract.

The Contractor shall contact the Louisville District Security Office by phone, letter, or email at the following numbers/addresses:

CELRL-SC

600 Martin Luther King Jr. Pl Louisville, KY 40202

Charles R. Tanner, phone (502) 315-6929; email Charles.R.Tanner@usace.army.mil James R. Milner, phone (502) 315-6916; email James.R.Milner@usace.army.mil Jason Almodovar, phone (502) 315-6754; email Jason.Almodovar@usace.army.mil

TP-3.1 GENERAL SPECIFICATIONS:

General. Unless otherwise specified, the contractor shall furnish tools, supplies, materials, equipment, labor, supervision, communication, and quality control to dewater and maintain specified water level for fish removal, and conduit inspection. Contractor must be able to setup and perform dewatering operations within a 24-hour notice. All work is to be performed by specifications listed below.

Work to be performed. The work to be performed is as follows:

Mobilization and operations:

1. Upon notification contractor will be responsible to provide adequate amounts of pumps to remove water from stilling basin, to specified water level. Stilling basin needs to be pumped out within a 4-hour window from 5am to 11am CST. Once specified level is reached contractor shall continue pumping to maintain water level as indicated below.

a. Water level will be at a depth of 6 inches in stilling basin to allow for removal of fish from stilling basin and inspection of conduit.

b. After inspection is completed and all personnel and equipment removed from stilling basin contractor will stop pumping and demobilize.

2. Option 0001 may be requested by the government in the event that the dewatering of the stilling basin is halted due to weather or conditions within the conduit. In this case the contractor may be asked to maintain 1 additional calendar day of dewatered conditions at a specified levels outlined in item 1 above.

3. Option 0002: If the contractor is asked to remove his equipment as a result of weather or any other conditions this option will be exercised to provide for the additional mobilization and demobilization.

Government furnished items and training:

1. US Army Corps of Engineers maintenance staff will be responsible for closing of gates and performing lockout/tag out procedures to eliminate flow through service and bypass gates. All contract personnel shall attend a mandatory AHA/Safety meeting provided by Project Safety Officer. Maintenance personnel will also provide sand in pumping area and stilling basin sill to decrease the risk of slipping on slick surfaces.

END OF SPECIFICATIONS

(End of Summary of Changes)