W912QR20Q0138_15SEPT20.pdf

Project Office Roof and Gutter Replacement for JT Myers Lock & Dam.

Estimated Construction Cost is between $25,000 and $100,000.

Award will be based on the lowest price.

NAICS Code: 238160 - Roofing Contractors. Size Standard is $16.5 Million.

The solicitation w ill be available on the web only. To download the solicitation for this project, go to https://Beta.Sam.gov.

This project is a set-aside 100% for a Small Business.

Block 12A Below: In lieu of Performance and Payment bonds, per FAR 52.228-13 Alternate Payment Protections (2000), Payment Bonds or Irrevocable Letter of Credit is required. A Performance Bond is not required.

Central Contractor Registration and ORCA are now available through the System for Award Management (SAM), available at www.sam.gov.

Offerors must comply with the requirements of 52.204-7, 52.232-33, and any other CCR/ORCA requirements in this solicitation through SAM.

PLEASE NOTE: SAM is completely free of charge for both registrants and users.

AMY M PHILLIPS 502.315.6666

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

15-Sep-2020

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________25 Sep 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than ___9_0___ calendar days for Government acceptance after the date offers are due w ill not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

11. The Contractor shall begin performance within ___1_0___ calendar days and complete it within ___1_2_0___ calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _5_2_._2_1_1-_1_0_________________ .)

12B. CALENDAR DAYS

12:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

502.315.6195 OR 6193FAX:TEL: 502.315.6172 TEL: FAX:

W912QR20Q0138 58

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912QR20Q0138

Section 00 10 00 - Solicitation

SPECIAL INSTRUCTIONS

The contractor shall furnish all materials, supplies, tools, parts, equipment, transportation, labor, supervision, communication, and quality control to complete the work listed below, at the areas specified at JT Myers Lock and Dam, located in Posey County, IN.

LOCATION:

DEPARTMENT OF THE ARMY

U.S. Army Corps of Engineers JT Myers Lock and Dam 16501 Raben RD Mt. Vernon, IN 47620

This procurement is 100% set-aside for Small Business, NAICS 238160, Roofing Contractors (Size Standard:

$16.5M).

One award will be made from this Solicitation. The contract award will be based on Lowest Price to the Government.

Method of Payment under this contract will be Electronic Funds Transfer (EFT) to a commercial bank account specified by the contractor.

Note: In addition to the completed price breakout schedule/price quote, the Offeror must complete their Representation and Certifications located in the solicitation.

Quotes are due on 25 September 2020 at 1:00PM Eastern Time. You may submit your quote via email to amy.m.phillips@usace.army.mil.

SITE VISITS ARE HIGHLY ENCOURAGED. To have a full understanding of the Scope of Work (SOW) a site visit is highly encouraged. Please contact the technical point of contact (TPOC) if you require information about the location of the sites and/or if you would like to schedule a site visit. Additionally, all areas listed in the SOW are open for access without an appointment.

The TPOCs’ information are as follows:

Dallas Jackson or Patrick Buttry JT Myers Lock and Dam Mt. Vernon, IN 42451 Phone: 812-838-5836 Fax: 812-838-6191 Email: Dallas.W.Jackson@usace.army.mil Email: Patrick.E.Buttry@usace.army.mil

For contractual questions, please contact Amy M. Phillips at (502) 315-6666 or by e-mail at Amy.m.phillips@usace.army.mil.

All contractors must be registered in the System for Award Management (www.SAM.gov) prior to award of a contract. All proposed contractors are highly encouraged to review FAR Clause 52.232-33 Payments by Electronic Funds Transfer – System for Award Management, which indicates “All payments by the Government under this contract shall be made by electronic funds transfer (EFT).” Those not currently registered can obtain registration by going to the website http://www.SAM.gov. The process can usually be completed from 24 to 48 hours after submission. Contractors will need to obtain a Unique Entity Identifier (formerly DUNS number) for processing their registration. If you do not already have a Unique Entity Identifier, one can be obtained from http://www.SAM.gov.

Refer to www.SAM.gov for information formerly found in CCR, EPLS, ORCA and FedReg.

Please begin the registration process immediately in order to avoid delay of the contract award should your firm be selected.

ALERT: You must submit a notarized letter appointing the authorized Entity Administrator before your registration will be activated. This requirement now applies to both new and existing entities. Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required before the GSA Federal Service Desk (FSD) will activate the entity's registration.

Effective 29 June 2018, vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) within 30 days of activation or the vendor risks no longer being active in SAM.

Vendors can check whether an account is active by performing a query by their CAGE or Unique Entity Identifier (known as DUNS). The new registration process may now take several weeks, so vendors are highly encouraged to begin registering as soon as possible to avoid any possible delays in future contract awards. Remember, there is no cost to use SAM.

To find out additional information about the changes of the SAM registration process, contractors should visit the Frequently Asked Questions (FAQ) link located at the top of the SAM homepage (www.sam.gov).

Note: Page numbering in this document may not be accurate.

PRICE BREAKOUT SCHEDULE

Item # Description Unit Price

Unit of

Issue Qty TOTAL

Project Office Roof JT Myers Lock and Dam Remove/Replace Roof Shingles and all identified material within SOW.

EA

Guttering by specifications of SOW

EA

TOTAL CONTRACT PRICE: $ ___________

Section 00 20 00 - Instructions for Procurement

SCOPE OF WORK

Scope of Work Project Office Roof Replacement

U.S. Army Corps of Engineers JT Myers Lock and Dam

16501 Raben RD Mt. Vernon, IN 47620

TP-1.1 GENERAL:

a. Description. The contractor shall furnish all materials, supplies, tools, parts, equipment, transportation, labor, supervision, communication, and quality control to complete the work listed below, at the areas specified at JT Myers Lock and Dam, located in Posey County, IN

b. Work shall be provided in accordance with all Terms, Conditions, General, Specific and Technical Provision, Exhibits, Attachments, Drawings, etc. contained herein or incorporated by Reference. All distances and measurements given are approximate. Each interested contractor is urged to visit the job site to assess quantities, critical dimensions, and work conditions. All work will be done according to standard industry practices. Access to the work area is controlled and appointments to look at the site shall be coordinated with the Technical Representative. This includes all mandatory provisions of the Federal Acquisition Regulation (FAR), whether referenced or not, current at time of award.

c. Contractor Responsibility. Contractor’s work and responsibility shall include, but are not limited to supply of equipment/materials, all planning, programming, administration, management, supervision, and inspection required to assure all equipment/materials are acquired and work is conducted in accordance with the contract and all applicable laws, regulations, or directives. The Contractor shall ensure all work meets or exceeds specifications. The prime Contractor shall be responsible for ensuring all subcontractors comply with the provisions of this contract.

d. Performance Required. Special consideration of the Contractor is directed to the fact that required accuracy, thoroughness, safety, and progress of this work are essential to the intended purpose. The contractor must be cognizant of the difficulties involved and of the contingencies which may arise, and must make certain that their personnel, equipment, transportation facilities and supply of materials are adequate at all times to ensure complete compliance with all provisions of these specifications. The work shall be done under professional supervision by competent employees. All contract work shall be in accordance with the submitted documents, and any additions, revisions or deletions must be approved by the Contracting Officer or his/her authorized representative.

e. Completion of Work. Completion of work shall include acceptable performance of all aspects of this contract.

f. Conditions.

1. Pre-Work Conference: The contractor will be required to attend a pre-work conference, scheduled at least one week prior to beginning work, where the Contractors plan of work, safety plan, security plan, start-up date, and other items included in this contract will be briefly discussed. The contractor will also be required to supply the necessary proof of liability insurance (copy of insurance forms) at that time.

In addition, a copy of the Safety Data Sheet will be given to the government at this time and reviewed to ensure contractor compliance. This area is a secure area and the contractor will need to supply the government with a list of contractor personnel that will be working on-site.

2. Damages. The contractor shall be responsible for all damages to government or private property during the course of this contract. The contractor shall have appropriate insurance to cover liability and damages.

3. Hours and Days of Work. Work may be conducted between the hours of 6:30 a.m. and 7:00 p.m.

Central Time, Monday through Friday (only during daylight hours). No work shall be performed outside of these times, on Saturdays or Sundays, or on federal Holidays, unless approved by the Technical Representative, or as otherwise noted below.

Date Holiday Wednesday, January 1 New Year’s Day

Monday, January 20 Birthday of Martin Luther King, Jr.

Monday, February 17 Washington’s Birthday

Monday, May 25 Memorial Day

Friday, July 3 (observed) Independence Day

Monday, September 7 Labor Day

Monday, October 12 Columbus Day

Wednesday, November 11 Veterans Day

Thursday, November 26 Thanksgiving Day

Friday, December 25 Christmas Day

4. Payment Procedure/Additional Work. At no time should the contractor do additional work without prior authorization of the Contracting Officer, and no work shall be performed that will cause the Contractor to exceed the contract price. Work performed without a binding contract document authorizing such work shall result in the Contractor not being paid for that work performed. During the course of the contract, any additional work determined to be needed may be requested by the Technical Representative to the Contracting Officer for a Contract Modification.

5. Contract Start and Completion Dates. Work under this contract shall begin within 10 calendar days of Notice to Proceed (NTP) being issued and must be completed within 120 calendar days of Notice to Proceed. Additional time may be granted for inclement weather, when coordinated with and approved by the Technical Representative. This includes delay of work that may occur during excessive rainfall or wet periods.

6. Wage Rates: Department of Labor wage rates apply to this work and are included. The contractor is required to provide payroll documents for all work performed under this contract.

7. The Contractor shall, at all times prior to delivery, take care to protect and preserve all materials, supplies, and equipment of every description (including material and property which may be Government owned) and all work performed. All reasonable requests of the Contracting Officer or his/her authorized representative to enclose or specially protect such property shall be complied with. If so determined by the Contracting Officer, material, equipment, supplies, and work performed are not adequately protected by the Contractor, such property may be protected by the Government and the cost thereof may be charged to the Contractor or deducted from any payment due.

8. The Contractor will notify the Technical Representative or his/her authorized representative, upon commencement of work activities, and difficulties, interruption, or suspension of work, and when the required work has been completed. The Contractor shall update the Technical Representative, or their authorized representative, no less than once weekly on status of work being done. Work will commence when the funds are allocated, and work orders have been received from the Contracting Officer or his/her authorized representative.

TP-1.2 CONTRACTOR SUBMITTAL. Unless otherwise specified, the Contractor shall submit the following information to the Technical Representative prior to the pre-work conference for this contract:

a. Safety Plans. The Contractor shall submit, for acceptance by the Technical Representative, an accident prevention plan and Activity Hazard Analysis (AHA) in accordance with the requirements of the Corps of Engineer’s Safety and Health Requirements Manual, EM385-1-1, hereinafter referred to as the Safety Manual, current at the time of award.

b. Certification of Employees Qualified to Administer First Aid and CPR. The Contractor shall submit proof the appropriate number of employees, as required in the Safety Manual, are certified to administer First Aid and CPR.

TP-1.3 SAFETY.

a. General Safety. The Contractor shall comply with the safety standards contained in Corps of Engineers Manual, EM 385-1-1, “Safety and Health Requirements Manual”, current at the time of award, as well as all current provisions of the Occupational Safety and Health Act (OSHA).

b. Safety Manual Requirements. The Contractor and employees shall comply with all pertinent sections of the Corps of Engineer’s Safety and Health Requirements Manual, EM 385-1-1, current at the time of award, and any subsequent revisions. This manual will be available on the Internet at:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf The Contractor’s safety plan must be submitted in writing and can be turned in at the same time as the pre-work conference.

c. Personal Protective Apparel and Equipment. Protective apparel and equipment, as identified in the AHA, shall be provided to eliminate or minimize hazards to personnel. As a minimum, each employee shall wear a sleeved shirt, long trousers and safety-toe shoes or boots during all contract work. Hard hats, face shields, safety glasses with side-shields, or goggles, and hearing protection shall be worn by employees when required by safety manual. Fire extinguisher(s) and first aid kit(s) meeting the Safety Manual standards shall also be provided and easily accessible to all employees.

d. Contractor Employees Certified in First Aid & CPR. The Contractor shall schedule employees, so the appropriate numbers of certified personnel are on duty to administer First Aid and CPR as required by the Safety Manual. Copies of their certification shall be provided before work begins under this contract.

TP-1.4 ACCIDENT REPORTING. The Contractor shall maintain accurate accident records and report accidents as prescribed by the Technical Representative. Accidents shall be reported within 24 hours of occurrence, and all serious accidents (those resulting in death or injury requiring medical attention or lost time) shall be reported immediately.

TP-1.5 DAMAGE REPORTS. In all instances where Government property, equipment, natural features, landscape, or trees are damaged by contract employees, an immediate notification shall be made to the Technical Representative. A full report of the incident and extent of such damage shall be submitted to the Technical Representative within two working days of occurrence, excluding weekends and holidays.

TP-1.6 CONTRACT EMPLOYEES. All contract employees shall conduct themselves in a proper and courteous manner at all times. Contract employees shall comply with all provisions of Title 36, Chapter III, Part 327, CFR and obey all posted signs and regulations in the performance of the work under this contract. Being under the influence of or consuming alcoholic beverages or controlled substances by the Contractor or employees while on duty is prohibited.

TP- 2.1 SPECIAL REQUIREMENTS:

a. Security

1. Access and General Protection/Security Policy and Procedures. All contractor and all associated sub-contractors’ employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative).

The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

2. Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something).

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the Technical Representative, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the Technical Representative NLT 5 calendar days after the completion of the training.

3. Pre-screen candidates using E-Verify Program. The Contractor must pre-screen Candidates using the E- Verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-Verify system. An initial list of verified/eligible Candidates must be provided to the Technical Representative no later than 3 business days after the initial contract award." *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

b. Payment: Payment will be made by Electronic Funds Transfer (EFT), upon acceptance of the completed work and providing final invoice and labor records.

c. Qualifications: The contractor shall have at least five (5) years’ experience in the requirements for this Scope of Work preceding the date of the solicitation.

TP-3.1 GENERAL SPECIFICATIONS:

a. Project Office Roof Replacement

Please Note: All distances and measurements given are approximate. Each bidding contractor is urged to visit the job site to assess quantities, critical dimensions, and work conditions. All work will be done according to standard industry practices.

All inquiries and correspondence concerning this job shall be directed to the following. Any reference to Technical POC or TPOC will apply to following as well.

TPOCs:

Dallas Jackson or Patrick Buttry JT Myers Lock and Dam Mt. Vernon, IN 42451 Phone: 812-838-5836 Fax: 812-838-6191 Email: Dallas.W.Jackson@usace.army.mil Email: Patrick.E.Buttry@usace.army.mil

Contractor shall furnish all materials, supplies, tools, equipment, transportation and labor in order to complete this Scope of Work. All materials and workmanship will be manufactured and accomplished according to industry standards and specifications.

Line Item 1 (Base Bid), Project Office:

1. Remove approximately 5700 Square Feet of existing roof shingles, Underlayment (Felt), and replace with new roof shingles and breather-type underlayment. Gutters shall be newly installed. All removed materials, including small debris such as nails and pieces of black paper, will be disposed of in a sanitary landfill, designated for that type of material. Landfill receipts will need to be retained and provided to Project Personnel. The area around the office will be kept clean of loose debris on a regular basis (at least daily). The installation of the new roof shingles will follow the removal of the old roof in order to minimize possible damage from rain and moisture. Any gaps or holes in the roof must be fully secured and protected at the end of each workday.

In addition to shingles and underlayment the following items shall be minimum standard for materials used for new roofing.

a. Ice and water protection for valleys, flashings, and eves approximately 574 ft

b. Drip Edge for rakes and eves approximately 334 ft

c. Starter strip for rakes and eves approximately 334 ft

d. Step flashing approximately 120 ft

e. Apron flashing approximately 194 ft

f. Pipe Jack and split boot times 1

g. Ridge vent approximately 158 ft

h. Ridge cap approximately 158 ft

2. Approximately 252 linear feet of aluminum 6” gutters, that closely match the color of the roof shingles, will be added to the building TPOC will choose color of gutters prior to installation. Downspouts will be placed at the direction of the TPOC.

[All roof shingles will be impact rated for extreme weather, minimum of a class A fire rating, and minimum wind warranty of 130 MPH.

All Shingles shall meet or exceed the following testing methods.

ASTM D3018 Type I ASTMD3161 Class F ASTMD3462 Yes ASTM D7158 Class H TAS 100-95 Yes UL 790 Class A UL 2218 Class 4

The roof will be installed according to manufacturer’s specifications and according to standard industry practices. All shingles shall be constructed of Fiberglass Asphalt. All roofing specs and manufacturer’s warranties will be provided with the bid sheet. The exact color of the roofing will be determined by the TPOC. Contractor shall provide 1-year warranty of installation and construction practices. All warranties after that will be that of the manufacturer.

Pictures for Reference

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-22 Alternative Line Item Proposal JAN 2017 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

CLAUSES INCORPORATED BY FULL TEXT

52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-29 (AUG 1998)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service, Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision.

Additional copies will be issued for a fee.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

4.8% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Mount Vernon, in Posey County, Indiana.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Dallas Jackson or Patrick Buttry JT Myers Lock and Dam Mt. Vernon, IN 42451 Phone: 812-838-5836 Fax: 812-838-6191 Email: Dallas.W.Jackson@usace.army.mil Email: Patrick.E.Buttry@usace.army.mil

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

The full text of FAR clauses and provisions can be found at:

https://www.acquisition.gov/

The full text of DFARS clauses and provisions can be found at:

https://www.acq.osd.mil/dpap/dars/dfarspgi/current/index.html

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

Section 00 45 00 - Representations and Certifications

REPS & CERTS

REPRESENTATIONS & CERTIFICATIONS

COMPANY NAME AND ADDRESS: __________________________________________

PHONE NUMBER _____________________ FAX NUMBER _____________________

EMAIL ADDRESS ________________________________________________________

BUSINESS SIZE (select one)

Large Business _____ Small Business_____ HUBZone Business_____ 8A _____

Woman-Owned ____ Service-Disabled Veteran-Owned ____

Contractor is registered with SAM: _____ YES _____ NO

(See FAR 52.204-7)

TAX ID # ______________________

INDICATE Unique Entity Identifier (previously DUNS NUMBER) ___________________ (This is 9 digit numeric code)

CAGE NO. _________ (Note: See Unique Entity Identifier (FAR 52.204-7)

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160.

(2) The small business size standard is $16,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAY 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this…