RPA_Amendment_0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

0001 3Mar14

U.S. Army Engineer District, Los Angeles District ATTN: Contracting Division 915 Wilshire Boulevard, Suite 930 Los Angeles, CA 90017

W912PL-14-R-0008

25Feb14

Remotely Piloted Aircraft (RPA) Mission Complex located in the northeast corner of Creech

AFB, NV.

The purpose of this amendment is to replace the following in their entirety:

* Section 00 10 00 - Pricing Schedule

* Section 00 45 00 - Representations & Certifications

* Section 00 21 00 - Instructions to Proposers

* Section 31 00 00 - Earthwork

Add: * Table of Contents and Section 00 22 16 - Proposal Evaluation and Contract Award

W912PL-14-R-0008

AMEND 0001

PROJECT TABLE OF CONTENTS

DIVISION 00 – PROCUREMENT AND CONTRACTING REQUIREMENTS

Standard Form Solicitation, Offer, and Award

Section 00 10 00 Pricing Schedule Wage Rates General Decision Number: NV140022 Section 00 21 00 Instructions to Proposers Section 00 21 16 Instructions to Proposers Section 00 22 16 Proposal Evaluation and Contract Award Section 00 45 00 Representations & Certifications Section 00 72 00 General Conditions (Contract Clauses) Section 00 73 00 Supplementary Conditions (Special Contract Requirements)

SECTION 00 10 00 -1

SECTION 00 10 00 – PRICING SCHEDULE

THE CONTRACTOR SHALL COMPLETE THE ENTIRE WORK READY FOR USE NOT LATER THAN

365 CALENDAR DAYS AFTER THE CONTRACTOR RECEIVES THE NOTICE TO PROCEED.

CONTRACTOR SHALL FURNISH ALL PLANT, LABOR, MATERIAL, EQUIPMENT, ETC. NECESSARY

TO PERFORM ALL WORK IN STRICT ACCORDANCE WITH THE TERMS AND CONDITIONS SET

FORTH IN THE CONTRACT TO INCLUDE ALL ATTACHMENTS THERETO.

Item Estimated Unit No. Description Quantity Unit Price Amount

BASE BID

0001 Construct Perimeter Fence including lights, Power, communications, entry control points and gates.

1 L.S. **** $

0002 Construct Area Circulation Fence at Bldg 1052.

Construct Area Circulation Fence at Bldg 1055.

L.S.

Construct Area Circulation Fence at Bldg Complex1005.

L.S.

0005 Construct Area Circulation Fence at Bldg 1000.

0006 Construct Area Circulation Fence at Bldg 1130.

0007 Valley Electric Association Service Fee See Note A below.

1 L.S. **** $_______________

0008 Underground Utility Crossings not shown in RFP.

25 EA. $_______ $

TOTAL AMOUNT BASE ITEMS (CLINs 0001-0008): $

SECTION 00 10 00 -2

NOTES:

NOTE A. This is a fee charged by Valley Electric Association to provide electric distribution of this project which is to be paid by the Contractor directly to Valley Electric Association.

1. EVALUATION: The Government intends to issue a contract resulting from the Request for Proposal (RFP) to the responsible Offeror whose proposal represents the lowest priced technically acceptable proposal meeting or exceeding the acceptability standards for non-cost factors by using the procedure as described in Sections 00 21 16 and 00 22 16. The award decision will be based on a comparative assessment in proposals against all source selection criteria in the solicitation.

2. Award of the Base will be made to one offeror. Offerors must submit a price on all items, in the Pricing Schedule to be eligible for award.

3. ARITHMETIC DISCREPANCIES:

(a) For the purpose of initial evaluation of bids, the following will be utilized in the resolving arithmetic discrepancies found on the face of bidding schedule as submitted by the offeror:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price shall govern, and in a discrepancy between the sum of extended prices and the stated total for the base or optional items, the sum of the extended prices will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

(b) For the purposes of bid evaluation, the government will proceed on the assumption that the offeror intends his bid to be evaluated on basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

(c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low. (EFARS 52.214-5000)

4. The lump sum, “L.S.” line items above are not “estimated quantity” line items and therefore are not subject to the Variation in Quantity contract clause.

5. PROGRESS PAYMENT REQUESTS made by the Contractor pursuant to the provisions of Contract Clause, PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS, shall be submitted on ENG FORM 93 to the administration office as designated in Section 00100. ENG FORM 93 shall be submitted to that office on the 20th day of each month in appropriate form and certified. Photocopies of the form shall be furnished on that same date to the Corps of Engineers offices designated at the Pre-Construction Conference.

6. MANDATORY WORK STOPPAGES

(a) A mandatory work stoppage occurs whenever the Contractor is restricted from working a full workday and is unable to reallocate work forces to other locations. All costs associated with five (5) mandatory work stoppages must be included in the bid price. No additional compensation or extension to the Contract performance period will be given as a result of five (5) mandatory work stoppages.

SECTION 00 10 00 -3

(1) In the event that the Contractor's work force is required to evacuate any part of the working area during working hours established by the Contractor for this contract, the Government will then make an adjustment under the clause entitled, FAR 52.242-14 SUSPENSION OF WORK, see Section 00700. The Government's liability will be considered to be limited to reimbursement for loss of time of Contractor's employees and equipment which otherwise would have been employed on the job. The completion time for any part of the work will not be extended if the total number of working hours of work stoppage does not exceed 0.08 times the number of calendar days in the period between the date of notice to proceed and the specified completion date.

In the event the Contractor is required to evacuate the area in excess of the time specified above, the completion times will be adjusted.

(b) The Contractor may be required, without advance notice, to move work to a different location. The Contractor shall be prepared to increase or decrease work forces with appropriate trades to perform work in the relocated work areas at no additional cost to the Government.

(c) The Contractor shall notify the Contracting Officer when a mandatory work stoppage occurs for recording purposes. Otherwise, the work stoppage will not be credited to the Contractor.

7. If a modification to a bid based on unit prices is submitted, which provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment to each unit price in the bid schedule must be stated.

If it is not stated, the offeror agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the bid schedule.

8. Principal Contracting Officer. The Contracting Officer who signs this contract will be the Principal Contracting Officer for this contract. However, any Contracting Officer assigned to the Los Angeles District, contracting within his authority, may take formal action on this contract when the Principal Contracting Officer is unavailable and the action needs to be taken.

9. Amounts and prices shall be indicated in either words or figures, NOT BOTH.

10. The offeror shall furnish all plant, labor, material, equipment, etc., necessary to perform all work in strict accordance with the terms and conditions set forth in the contract including all attachments thereto complete and ready for use.

11. Some quantities are ESTIMATED, the offerors prices MUST BE FIRM.

12. Offeror is cautioned to check his Price Schedule carefully prior to submission. If the Price Schedule contains unit prices, they should be round off to the second decimal point only NOT EXTENDED FURTHER.

13. The Offeror shall distribute his indirect costs (overhead, profit, bond, etc.,) over all items in the Price Schedule.

The Government will review submitted Price Schedule for any unbalancing of the items. Any submitted Price Schedule determined to be unbalanced may cause the offeror to be ineligible for contract award.

14. The Contract Clause 52.232-27, “Prompt Payment for Construction Contracts” requires that the name and address of the contractor official, to whom payment is to be sent, be the same as that in the contract or in a proper Notice of Assignment.

15. Payment of Electronic Funds Transfer (EFT) is the mandatory method of payment. The Contractors attention is directed to Contract Clause No. 52.232-33 "Mandatory Information for Electronic Funds Transfer" located in Section 00 73 00.

16. PLEASE NOTE: The Contractor agrees to attend any Post Award conference convened by the contracting activity or contract administration in accordance with Federal Acquisition Regulation subpart 42.5.0

SECTION 00 10 00 -4

17. CONTRACTOR PERFORMANCE EVALUATIONS. In accordance with the provisions of Subpart 36.201(Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $650,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Construction Contractor Appraisal Support System (CCASS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 30 days. Accessing and using CCASS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.navy.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CCASS and PKI certification is the sole responsibility of the Contractor.

18. PLEASE NOTE: PROSPECTIVE OFFERORS SHOULD SUBMIT CONTRACTING AND TECHNICAL

INQUIRIES AND QUESTIONS RELATING TO PROPOSAL PROCEDURES ARE TO BE SUBMITTED VIA

OFFEROR INQUIRY IN PROJNET AT WWW.PROJNET.ORG.PROJNET REFER TO SECTION 00100

CLAUSE ENTITLED, “INQUIRIES”

19. PLEASE NOTE: ALL PROSPECTIVE OFFERORS MUST BE REGISTERED IN SYSTEM FOR AWARD

MANAGEMENT (SAM) https://www.sam.gov/portal/public/SAM/

20. At the time this solicitation was issued, the FY2014 Military Construction Act has not yet been signed into law by the President of the United States. This MILCON project is included or provided for in the financial plan for fiscal year 2014. Funds for this prospective Air Force military construction project are not yet available. This project is considered a high priority project in that there is a high probability that the requirement will not be cancelled.

21. Funds are not presently available for this acquisition. No contract award will be made until appropriated funds are made available.

http://www.cpars.navy.mil/ http://www.projnet.org.projnet/ https://www.sam.gov/portal/public/SAM/

SECTION 00 10 00 -5

CERTIFICATE OF CORPORATE PRINCIPAL

1) IF THE OFFEROR IS A JOINT VENTURE, COMPLETE THE FOLLOWING:

(Company Name) (Signature) (Title)

(Company Name) (Signature) (Title)

2) IF THE OFFEROR IS PARTNERSHIP, LIST FULL NAME OF ALL PARTNERS:

(Company Name) (Signature) (Title)

3) IF THE OFFEROR IS A CORPORATION, THE FOLLOWING CERTIFICATION SHOULD BE

COMPLETED:

CERTIFICATION AS TO CORPORATE PRINCIPAL

I, , certify that I am the Secretary of the corporation named as principal in the within contract; that , who signed the said contract on behalf of the principal, was the of the corporation; that I know his signature and that his signature is genuine; and that said contract was duly signed, sealed and attested for in behalf of said corporation by authority of its governing body.

SECTION 00 10 00 -6

CORPORATE PRINCIPAL

CORPORATE SEAL

SECRETARY

SECTION 00 10 00 -7

(4) IF THE OFFEROR IS A LIMITED LIABILITY COMPANY, LIST FULL NAME OF ALL MANAGERS

BELOW. SIGNATURES BY ALL MANAGERS HERE SIGNIFY THAT THAT THE INDIVIDUAL WHO

SIGNED THE OFFER IN BLOCK 20B HAS THE AUTHORITY TO BIND THE LIMITED LIABILITY

COMPANY.

Name Signature

SECTION 00 10 00 -8

AMEND0001

SECTION 004500 - REPRESENTATIONS & CERTIFICATIONS

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JULY 2013)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY

2013)

252.209-7002 DISCLOSURE OF OWNERSHIP OR CONTROL BY A FOREIGN GOVERNMENT

(JUN 2010)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JULY 2013)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238990. 237990

(2) The small business size standard is $14.0 million. $33.5 million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation. This provision applies to solicitations using funds appropriated in fiscal years 2008, 2009, 2010, or 2012.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xvi) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225- 1.

(xvii) 52.225-4, Buy American Act--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,494, the provision with its Alternate II applies.

(D) If the acquisition value is $77,494 or more but is less than $100,000, the provision with its Alternate III applies.

(xviii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xix) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xx) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran--Representation and Certifications. This provision applies to all solicitations.

(xxi) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

(i) 52.219-22, Small Disadvantaged Business Status.

(A) Basic.

(B) Alternate I.

(ii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iii) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

(iv) 52.222-52, Exemption from Application of the Service Contract Act to Contracts for Certain Services–Certification.

(v) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA–Designated Products (Alternate I only).

(vi) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website accessed through https://www.acquisition.gov.

After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

https://www.acquisition.gov/

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2013)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7001, Disclosure of Ownership or Control by the Government of a Terrorist Country. Applies to all solicitations expected to result in contracts of $150,000 or more.

(ii) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(iii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vi) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7022, Trade Agreements Certificate--Inclusion of Iraqi End Products.

____ (v) 252.225-7031, Secondary Arab Boycott of Israel.

____ (vi) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

____ (vii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

252.209-7002 DISCLOSURE OF OWNERSHIP OR CONTROL BY A FOREIGN GOVERNMENT (JUN

2010)

(a) Definitions. As used in this provision--

(1) “Effectively owned or controlled” means that a foreign government or any entity controlled by a foreign government has the power, either directly or indirectly, whether exercised or exercisable, to control the election, appointment, or tenure of the Offeror’s officers or a majority of the Offeror’s board of directors by any means, e.g., ownership, contract, or operation of law (or equivalent power for unincorporated organizations).

(2) “Entity controlled by a foreign government”—

(i) Means—

(A) Any domestic or foreign organization or corporation that is effectively owned or controlled by a foreign government;

or

(B) Any individual acting on behalf of a foreign government.

(ii) Does not include an organization or corporation that is owned, but is not controlled, either directly or indirectly, by a foreign government if the ownership of that organization or corporation by that foreign government was effective before October 23, 1992.

(3) “Foreign government” includes the state and the government of any country (other than the United States and its outlying areas) as well as any political subdivision, agency, or instrumentality thereof.

(4) “Proscribed information” means—

(i) Top Secret information;

(ii) Communications security (COMSEC) material, excluding controlled cryptographic items when unkeyed or utilized with unclassified keys;

(iii) Restricted Data as defined in the U.S. Atomic Energy Act of 1954, as amended;

(iv) Special Access Program (SAP) information; or

(v) Sensitive Compartmented Information (SCI).

(b) Prohibition on award. No contract under a national security program may be awarded to an entity controlled by a foreign government if that entity requires access to proscribed information to perform the contract, unless the Secretary of Defense or a designee has waived application of 10 U.S.C. 2536(a).

(c) Disclosure. The Offeror shall disclose any interest a foreign government has in the Offeror when that interest constitutes control by a foreign government as defined in this provision. If the Offeror is a subsidiary, it shall also disclose any reportable interest a foreign government has in any entity that owns or controls the subsidiary, including reportable interest concerning the Offeror’s immediate parent, intermediate parents, and the ultimate parent. Use separate paper as needed, and provide the information in the following format:

Offeror’s Point of Contact for Questions about Disclosure (Name and Phone Number with Country Code, City Code and Area Code, as applicable)

Name and Address of Offeror

Name and Address of Entity Controlled by a Foreign Government

Description of Interest, Ownership Percentage, and Identification of Foreign Government

SECTION 002100 - INSTRUCTIONS TO PROPOSERS

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4010 INQUIRIES

52.0000-4001 DIRECTIONS FOR SUBMITING OFFERORS

52.204-7 SYSTEM FOR AWARD MANAGEMENT (JULY 2013)

52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-

29 (AUG 1998)

52.211-6 BRAND NAME OR EQUAL (AUG 1999)

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY

PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

52.211-5000 VARIATIONS IN ESTIMATED QUANTITIES — SUBDIVIDED ITEMS (MAR 1995) .. 9

52.215-1 INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)

52.215-20 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER

THAN CERTIFIED COST OR PRICING DATA (OCT 2010)

52.222-5 DAVIS-BACON ACT--SECONDARY SITE OF THE WORK (JUL 2005)

52.222-18 CERTIFICATION REGARDING KNOWLEDGE OF CHILD LABOR FOR LISTED

END PRODUCTS (FEBRUARY 2001)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.225-12 NOTICE OF BUY AMERICAN ACT REQUIREMENT-- CONSTRUCTION

MATERIALS UNDER TRADE AGREEMENTS (FEB 2009)

52.228-1 BID GUARANTEE (SEP 1996)

52.228-4507 BID GUARANTEE FORM AND AMOUNT

52.233-2 SERVICE OF PROTEST (SEP 2006)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD

OFFICIALS (NOV 2011)

SECURITY CONTRACT LANGUAGE FOR ALL CORPS OF ENGINEERS' UNCLASSIFIED

CONTRACTS

52.0000-4010 INQUIRIES

Any prospective offeror desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders/offerors before submission of their bids/offers. Oral explanations or instructions given before award of a contract are not binding. Any information given to a prospective offeror concerning a solicitation will be furnished promptly to all other prospective offerors as an amendment to the solicitation, if that information is necessary in submitting offers or if lack of it would be prejudicial to other prospective bidders/offerors.

1. All inquiries relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at www.projnet.org/projnet.

A. To submit and review bid inquiry items, bidders will need to be a current registered user, or self register into the ProjNet system.

To access the Bid Inquiry system, go to the ProjNet web page and fill in:

- Managing Agency - USACE

- Email address

- Key Access (this is the Bidder Inquiry Key - see below for key)

- Click on “Sign In”

- You will be prompted for the answer to your secret question on the next screen

If this is your first time accessing ProjNet, you will be directed to a screen titled “User account not found. Please create one using the form below”. Fill in the requested information (name, company, city, phone #, etc)

For additional guidance, see the attached 1-page pdf file for accessing the Bid Inquiry system.

B. From this page, you may view all bidder inquiries or add an inquiry. Please Note: Offerors shall only submit one question per inquiry. All inquiries containing multiple questions may be rejected.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by the technical team.

D. The Solicitation Number is: W912PL-14-R-0008 The Bidder Inquiry Key is: NEED BIDDER’S KEY FROM SPK - LAURA TF42W5-6PU5TP

2. The Bidder Inquiry System will be unavailable for new inquiries 5 business days prior to bid/proposal submission in order to ensure adequate time allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specifications in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The ProjNet call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

5. Responses on the Bidder Inquiry System do not revise, change, amend or supersede the provisions of the solicitation. Changes to the solicitation must be by written amendment thereto. Any Bidder Inquiry System response that can be interpreted to be in conflict with the solicitation or amendment, shall be subordinate to the conflicting provision, term, and/or note, wherever it appears in the solicitation, until revised or altered by a written amendment to the solicitation.

http://www.projnet.org/projnet

Additionally, offerors may not anticipate a change to the solicitation until the change, revision, correction, or alteration of the solicitation is actually made, in writing and published as an amendment to the solicitation.

52.0000-4001 DIRECTIONS FOR SUBMITING OFFERORS

(a) Envelopes containing offers, cost and technical, etc., must be sealed, marked and addressed follows:

Envelopes containing bids must be sealed, marked and addressed as follows:

MARK ENVELOPES:

RFP No. W912PL-14-R-0008 Proposal Due Date: See Block 13 of SF 1442

ADDRESS ENVELOPES TO:

Department of the Army U. S. Army Engineer District, Los Angeles ATTN: Contracting Division C/O: Christina M. Chavez

915 Wilshire Blvd., Suite 1440 Los Angeles, CA 90017

EXPRESS MAIL ENVELOPES:

Department of the Army U.S. Army Engineer District, Los Angeles ATTN: Contracting Division C/O: Christina M. Chavez

(b) Hand carried proposals may be deposited prior to the time and date set for receipt of proposals as follows:

Department of the Army U.S. Army Engineer District, Los Angeles ATTN: Contracting Division C/O: Christina M. Chavez

915 Wilshire Blvd., Suite 1101

SPECIAL INSTRUCTIONS PERTAINING TO HAND-CARRIED OFFERS:

Due to security precautions, all Corps of Engineers visitors/couriers are now required to check in at the Security Office, Suite 1101, 915 Wilshire Blvd, Los Angeles, CA. Offerors are no longer permitted to hand-carry their offers directly to Contacting Division without an authorized escort. Offers may NOT be left unattended at the Security Office, Suite 1101.

Offerors who desire to hand-deliver their offers prior to the scheduled time/date set for receipt of offerors must notify the Contracting Division to arrange for receipt of their offer by Contracting Division personnel. Normally the contact will be the Contract Specialist designated above. In the event the Contract Specialist cannot be reached, please call the main Contracting Division telephone number, 213-452-3231 or the following alternative telephone numbers -3233, -3245, -3234, or -3235, in order to request assistance.

20 minutes prior to the scheduled receipt of offer time/date, the Contract Specialist will be in the Security Office (PAO) Suite 1101, to accept offers. For negotiated procurements, there is no public proposal opening.

In order to expedite visitor processing, offerors are encouraged to complete the information requested on the Notice of Visitor(s) Form (attached). The completed form can be faxed to the Contract Specialist at (213) 452-3716, prior to the date for receipt of offers. In addition, no more than 2 visitors per firm will be permitted within the building. No exceptions will be made. The offeror is responsible for compliance with the security requirements and shall ensure that any company representative, courier or delivery personnel are aware of these special procedures pertaining to hand carried offers.

NOTICE OF VISITOR(S)

1. Date(s) of Visit (Inclusive)

2. Arrival Time

3. Name of Visitor(s) (Last, First)

4. Agency/Company of Visitor

5. Name of Person Being Visited (Include Div, Br, Sec)

Christina Chavez

6. Suite Number

7. Telephone Number

213-452-3246

8. Contact Person (if other than Person Being Visited)

Ryan Rivas

8. Telephone Number

213-452-3310

10. Other Comments or Instructions

- All visitors must report to the Public Affairs Office, Suite 980

- Visitors must use the Visitor Tag provided.

- Visitors must be escorted to Corps of Engineers floors

- Parking validation is only available for Engineering Division, Construction-Operations, and Information Management field personnel.

- Delivery personnel will be validated for 30 minutes only.

CESPL Form 820

23 APR 2006

52.204-7 SYSTEM FOR AWARD MANAGEMENT (JULY 2013)

(a) Definitions. As used in this provision--

Data Universal Numbering System (DUNS) number means the 9-digit number assigned by Dun and Bradstreet, Inc.

(D&B) to identify unique business entities.

Data Universal Numbering System +4 (DUNS+4) number means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional System for Award Management records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at Subpart 32.11) for the same parent concern.

Registered in the System for Award Management SAM database means that--

(1) The offeror has entered all mandatory information, including the DUNS number or the DUNS+4 number, the Contractor and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see Subpart 4.14) into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS +4” followed by the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number--

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and Zip Code.

(iv) Company Mailing Address, City, State and Zip Code (if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

(End of clause)

52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-29

(AUG 1998)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service, Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision.

Additional copies will be issued for a fee.

52.211-2 AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM DESCRIPTIONS

LISTED IN THE ACQUISITION STREAMLINING AND STANDARDIZATION INFORMATION

SYSTEM (ASSIST) (JAN 2006)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (http://assist.daps.dla.mil);

(2) Quick Search (http://assist.daps.dla.mil/quicksearch);

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(1) Using the ASSIST Shopping Wizard (http://assist.daps.dla.mil/wizard);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

52.211-6 BRAND NAME OR EQUAL (AUG 1999)

(a) If an item in this solicitation is identified as “brand name or equal,” the purchase description reflects the characteristics and level of quality that will satisfy the Government's needs. The salient physical, functional, or performance characteristics that “equal” products must meet are specified in the solicitation.

(b) To be considered for award, offers of “equal” products, including “equal” products of the brand name manufacturer, must--

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by--

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate “equal”…