Am01_Spec.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

0001 Dec 13, 2009

USACE, Los Angeles District Contracting Division, West Region Branch P.O. Box 532711 Los Angeles, CA 90053-2325

W912PL-10-B-0001

Dec 2, 2009

RECOVERY-SAN DIEGO RIVER AND MISSION BAY, CA MAINTENANCE DREDGING, SAN DIEGO COUNTY, CA

Amendment issued to revise the following:

1) Provide the "Bidders Key" for ProjNet inquiries (Section 00100, 52.0000-4010 Inquiries):

ONUYSR-6NM5LT

See attached continuation sheet for other revisions.

RECOVERY Project Number 015750 W912PL-10-B-0001 San Diego River and Mission Bay, CA Maintenance Dredging

SF30 Continuation – Amendment 1

Specification:

1. Replace Table of Contents

2. Replace Section 00010 BIDDING SCHEDULE.

3. Replace Section 00800 SPECIAL CONTRACT REQUIREMENTS.

4. Replace Section 01 00 00 GENERAL REQUIREMENTS.

5. Replace Section 01 22 00 MEASUREMENT AND PAYMENT.

6. Replace Submittal Register at end of Section 01 33 00

7. Replace Section 01 35 26 GOVERNMENTAL SAFETY

REQUIREMENTS.

8. Replace Section 01 45 04 CONTRACTOR QUALITY CONTROL.

9. Replace Section 01 57 20 ENVIRONMENTAL PROTECTION

10. Replace Section 35 20 23 DREDGING.

Appendices:

1. Add Appendix C – Pre-Dredge Eelgrass and Caulerpa Surveys – Aug 09

Plans:

1. Replace sheet 3 of 11

2. Replace sheet 7 of 11 .

3. Replace sheet 9 of 11 .

4. Replace sheet 10 of 11 .

SF-30 Continuation Amendment 1

RECOVERY PROJECT NUMBER 015750 W912PL-10-B-0001

SAN DIEGO RIVER AND MISSION BAY, CA

MAINTENANCE DREDGING

PROJECT TABLE OF CONTENTS

DIVISION 0 - BIDDING REQUIREMENTS, CONTRACT FORMS AND CONTRACT CONDITIONS

SF1442 SOLICITATION, OFFER and AWARD (SF 1442)

00010 BIDDERS NOTES/BID SCHEDULE

00100 INSTRUCTIONS TO BIDDERS

00600 REPRERSENTATIONS AND CERTIFICATIONS

00700 CONTRACT CLAUSES

00800 SPECIAL CONTRACT REQUIREMENTS

00850 WAGE RATES

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 GENERAL REQUIREMENTS

01 22 00 MEASUREMENT AND PAYMENT

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 02 QUALITY CONTROL SYSTEM (QCS)

01 45 04 CONTRACTOR QUALITY CONTROL

01 57 20 ENVIRONMENTAL PROTECTION

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 23 DREDGING

APPENDICES

Appendix A Vibracore Logs and Particle Size Analysis

Appendix B City of San Diego Sewer Line Information

Appendix C Pre-Dredge Eelgrass and Caulerpa Surveys – August 2009

-- End of Project Table of Contents --

Amendment 1

Recovery-Project #015750, San Diego River & W912PL-10-B-0001 Mission Bay, Mission Bay Maintenance Dredging, San Diego County, California

SECTION 00010

BID SCHEDULE

The Offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirements stated in Item 13D of the SF-1442. Failure to insert any number means the offeror accepts the minimum in Item 13 D of the SF-1442.)

BASE BID

Item Estimated Estimated No. Description Quantity Unit Unit Price Amount

1. Mobilization and Demobilization 1 Job Lump Sum $____________

2. Dredge Approach Channel & Entrance Channel 350,000 cubic yards $________ $____________ (Station 5+00 to 69+00)

3. Dredge Mariner’s Basin 40,000 cubic yards $________ $____________ (Station 106+00 to 125+00)

TOTAL ESTIMATED BASE BID $_____________

OPTION ITEMS

4. Dredge Main Channel East 35,000 cubic yards $________ $___________ (Station 69+00 to 90+75)

5. Dredge Main Channel West (Station 69+00 to 90+75)

5A. First 25,000 cubic yards 25,000 cubic yards $________ $___________

5B. Over 25,000 cubic yards 40,000 cubic yards $________ $___________

TOTAL ESTIMATED AMOUNT, BASE BID PLUS OPTION ITEMS $________________

SECTION 00010-1

252.236-7008 CONTRACT PRICES--BIDDING SCHEDULES (DEC 1991)

(a) The Government's payment for the items listed in the Bidding Schedule shall constitute full compensation to the Contractor for-

(1) Furnishing all plant, labor, equipment, appliances, and materials; and

(2) Performing all operations required to complete the work in conformity with the drawings and specifications.

(b) The Contractor shall include in the prices for the items listed in the Bidding Schedule all costs for work in the specifications, whether or not specifically listed in the Bidding Schedule.

(End of provision)

1. All extensions of the unit prices shown will be subject to verification by the Government. In case of variation between the unit price and the extension, the unit price will be considered to be the bid.

2. If a modification to a bid based on unit prices is submitted which provides for a lump sum adjustment to the total estimated amount, the application of the lump sum adjustment to each unit price in the Price Schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the Price Schedule.

3. Prices must be submitted on all individual items of the Price Schedule, otherwise the bid will be considered non-responsive and will be rejected.

4. For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the Price Schedule as submitted by the bidder:

a. Obviously misplaced decimal points will be corrected;

b. In case of discrepancy between the unit price and the extended price, the unit price will govern;

c. Apparent errors in extensions of unit prices will be corrected;

d. Apparent errors in addition of lump sum and extended prices will be corrected.

5. For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends the bid to be evaluated on the basis of unit prices the totals arrived at by the resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

6. The lump sum "LS" line items in the Price Schedule are not "Estimated Quantity" line items and are not subject to the "Variation in Estimated Quantity" contract clause.

7. Principal Contracting Officer. The Contracting Officer who signs this contract will be the Principal Contracting Officer for this contract.

However, any Contracting Officer assigned to the Los Angeles District, contracting within his authority, may take formal action on this contract when the Principal Contracting Officer is unavailable and the action needs to be taken.

SECTION 00010-2

SECTION 00010-3

8. Amounts and prices shall be indicated in either words or figures, NOT

BOTH.

9. The bidder shall distribute his indirect costs (overhead, profit, bond, etc.,) over all items in the Price Schedule.

10. Some quantities are ESTIMATED, the bidders prices MUST BE FIRM.

11. Bidder is cautioned to check his Price Schedule carefully prior to submission. If the Price Schedule contains unit prices, they should be rounded off to the second decimal point only, NOT EXTENDED FURTHER.

12. The Government contemplates award on one contract to the responsive, responsible bidder who submits the low bid for the total of all the items in the Price Schedule.

-- End of Section --

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

Section 00800 - Special Contract Requirements

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.217-4001 EXERCISE OF OPTION LINE ITEMS

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

52.211-5001 VARIATION IN ESTIMATED QUANTITIES, SUBDIVIDED ITEMS (MAR1995) ……..3

52.231-5000 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

MAR 1995)—EFARS

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-16 QUANTITY SURVEYS (APR 1984)

52.236-17 – LAY0UT OF WORK (APR 1984)

52.0236-4201 CONTRACTOR PERFORMANCE EVALUATIONS

52.236-5000 PLANT AND MATERIAL REMOVAL AFTER CONTRACT TERMINATION (MAR

1995)--EFARS

52.249-5000 BASIS FOR SETTLEMENT OF PROPOSALS

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

252.236-7002 OBSTRUCTION OF NAVIGABLE WATERWAYS. (DEC 1991)

252.236-7004 PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC 1991)

00800-1 Amendment 1

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

Section 00800 - Special Contract Requirements

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) provide payment and performance bonds within 10 calendar days after award of the contract,

(b) commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed,

(c) prosecute the work diligently, and

(d) complete the entire Base Bid work and Option Items (if awarded) ready for use no later than November 30th, 2010. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.217-4001 EXERCISE OF OPTION LINE ITEMS

The Government may exercise the options in the Contract Schedule. The Government will exercise the options not later than October 5th, 2010. Exercise of the options shall be by the Contracting Officer depositing in the U.S. Mail a Standard Form (SF) 30 "Modification of Contract" citing this section as the authority for exercising the options. Options shall be considered to have been exercised at the time the Government deposits the SF 30 to the Contractor in the mail.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,059.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

00800-2 Amendment 1

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

52.211-5001 VARIATIONS IN ESTIMATED QUANTITIES, SUBDIVIDED ITEMS (MAR 1995)—

EFARS

This variation in estimated quantities clause is applicable only to Items Nos._5A and 5B.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for Item No. 5A is less than 85% of the quantity of the first sub-item listed under such item, the contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause FAR 52.212-11, Variation in Estimated Quantities.

(c) If the actual quantity of work performed under Item No. 5A exceeds 115% or is less than 85% of the total estimated quantity of the sub-item under that item and/or if the quantity of the work performed under the second sub-item or any subsequent sub-item under Item No. 5B exceeds 115% or is less than 85% of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantities.

52.231-5000 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

MAR 1995)—EFARS

(a) This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VII. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-

36. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

00800-3 Amendment 1

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

San Diego County, California

(End of clause)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least thirty-five percent (35%) of the total amount of work to be performed under the contract. Please note: to be considered small for purposes of Government Procurement, a firm must perform at least 40% of the volume dredged with its own equipment or equipment owned by another small dredging concern. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys.

(b) Weather conditions, the contractor shall make his own investigations as to weather conditions at the site.

(c) Transportation facilities, the contractor shall make his own investigations as to transportation facilities.

52.236-16 QUANTITY SURVEYS (APR 1984)

(a) Quantity surveys shall be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

(b) The Government shall conduct the original and final surveys and make the computations based on them.

The Contractor shall conduct the surveys for any periods for which progress payments are requested and shall make the computations based on these surveys. All surveys conducted by the Contractor shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance.

(c) Promptly upon completing a survey, the Contractor shall furnish the originals of all field notes and all other records relating to the survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer.

52.236-17 – LAY0UT OF WORK (APR 1984)

The Contractor shall lay out its work from Government established base lines and bench marks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The

00800-4 Amendment 1

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

San Diego County, California

Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

(End of Clause)

52.0236-4201 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201(Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $100,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Construction Contractor Appraisal Support System (CCASS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 30 days. Accessing and using CCASS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site:

http://www.cpars.navy.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CCASS and PKI certification is the sole responsibility of the Contractor.

52.236-5000 PLANT AND MATERIAL REMOVAL AFTER CONTRACT TERMINATION (MAR

1995)--EFARS

Should this contract be terminated as provided in clause 52.232-5001 because of the failure of Congress to provide additional funds for its completion, the contractor may be permitted to remove plant and material on which payments for preparatory work have been made, subject to an equitable deduction from the amounts due the contractor to reimburse the United States for the unabsorbed value of such plant and material.

52.249-5000 BASIS FOR SETTLEMENT OF PROPOSALS

Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

(1) Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the contractor's accounting records to determine total actual equipment costs.

(2) If equipment costs have been allocated to a contract using predetermined rates , those charges will be adjusted to actual costs.

(3) Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

(4) Ownership costs (depreciation) will be determined using the contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

(5) License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.

(End of Clause)

00800-5 Amendment 1 http://www.cpars.navy.mil/

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

TITLE FILE NO. SHEET

INDEX TO CONTACT DRAWINGS, NOTES, AND LEGEND B-0511 2

252.236-7002 OBSTRUCTION OF NAVIGABLE WATERWAYS. (DEC 1991)

(a) The Contractor shall --

(1) Promptly recover and remove any material, plant, machinery, or appliance which the contractor loses, dumps, throws overboard, sinks, or misplaces, and which, in the opinion of the Contracting Officer, may be dangerous to or obstruct navigation;

(2) Give immediate notice, with description and locations of any such obstructions, to the Contracting Officer; and

(3) When required by the Contracting Officer, mark or buoy such obstructions until the same are removed.

00800-6 Amendment 1

Recovery – Project #015750, San Diego River & W912PL-10-B-0001

00800-7 Amendment 1

(b) The Contracting Officer may --

(1) Remove the obstructions by contract or otherwise should the Contractor refuse, neglect, or delay compliance with paragraph (a) of this clause; and

(2) Deduct the cost of removal from any monies due or to become due to the Contractor; or

(3) Recover the cost of removal under the Contractor's bond.

(c) The Contractor's liability for the removal of a vessel wrecked or sunk without fault or negligence is limited to that provided in sections 15, 19, and 20 of the River and Harbor Act of March 3, 1899 (33 U.S.C.

410 et. seq.).

252.236-7004 PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC 1991)

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) Seventy percent (70%) of the lump sum price upon completion of the contractor's mobilization at the work site.

(2) The remaining thirty percent (30%) upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a) (1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of --

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(3) The Contracting Officer's determination of the actual costs in paragraph (b)(1) of this clause is not subject to appeal.

This page was intentionally left blank for duplex printing.

Recovery-San Diego River & Mission Bay W912PL-10-B-0001

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 00 00

GENERAL REQUIREMENTS

05/09

PART 1 GENERAL

1.1 APPLICABLE PUBLICATIONS

1.2 SUBMITTALS

1.3 PROJECT SIGNS AND BULLETIN BOARDS

1.3.1 General

1.3.2 Construction Signs

1.3.2.1 Execution

1.3.2.2 American Recovery and Reinvestment Act (ARRA)

1.3.3 Special Notification Signs

1.3.4 Bulletin Board at the Contractor's office

1.3.5 Maintenance and Disposal

1.4 GOVERNMENT FIELD OFFICE

1.5 PUBLIC UTILITIES

1.5.1 General

1.5.2 Utilities To be Relocated or Protected

1.5.3 Relocation or Removal

1.5.4 Coordination

1.5.5 Utilities Not Shown

1.5.6 Electric Current

1.5.7 Underground Services Alert

1.6 NOTICES

1.6.1 City of San Diego

1.6.2 Traffic Routing

1.6.3 Existing Bench Marks and R/W Markers

1.6.4 United States Coast Guard

1.7 POINTS OF CONTACT

1.8 AIDS TO NAVIGATION

1.9 MARINE CONSTRUCTION AIDS

1.10 RESTRICTIONS

1.10.1 No Dredging Allowed from March 1st to Sept 15th

1.10.2 Construction Vehicles

1.10.3 Obstruction of Channel

1.10.4 Booster Unit

1.10.5 Discharge Pipeline

1.10.6 Beach Access Ramp

1.10.7 Local Restrictions

1.11 MARINE PLANT

1.12 PUBLIC SAFETY

1.13 GENERAL SAFETY REQUIREMENTS

1.13.1 General

1.13.2 Job Hazards Analysis

1.14 SIGNAL LIGHTS

1.15 RADIO COMMUNICATION

1.16 OVERSIZE LOADS

1.17 REPAIR OF STREETS, ACCESS ROADS, AND WORK AREAS

SECTION 01 00 00 Page 1 Amendment 1

1.18 INSPECTIONS

1.19 NAVIGATION

1.20 WORK AREAS AND EASEMENTS

1.21 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.22 NON CONTRACT WORK

1.23 COORDINATION WITH OTHER CONSTRUCTION

1.24 Corps of Engineers Reserve Fleet (CERF) Implementation

PART 2 MATERIALS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section Table of Contents --

SECTION 01 00 00 Page 2 Amendment 1

SECTION 01 00 00

GENERAL REQUIREMENTS

05/09

PART 1 GENERAL

1.1 APPLICABLE PUBLICATIONS

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by basic designation only.

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

CFR 29 Part 1926 Safety and Health Regulations for Construction

CFR 33 Part 80 Colregs Demarcation Lines

CFR 33 Part 156 Oil and Hazardous Material Transfer Operations

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2008) Safety and Health Requirements Manual

ER 415-1-15 Construction Time Extensions for Weather

EP 310-1-6a (2006) Sign Standards Manual

STATE OF CALIFORNIA DEPARTMENT OF OCCUPATIONAL AND HEALTH (CAL

OSHA)

Title 8 Regulations California Occupational Safety and Health Regulations

1.2 SUBMITTALS

Government approval is required for all submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Work and Storage Areas Plan G

Site Safety Health Plan/Accident Prevention Plan (APP) G

Job Hazards Safety Analysis G

SECTION 01 00 00 Page 3 Amendment 1

1.3 PROJECT SIGNS AND BULLETIN BOARDS

1.3.1 General

The Contractor shall construct and erect a project sign and hard hat sign and a bulletin board at respective locations designated by the Contracting Officer. The signs shall conform to the requirements of the EP 310-1-6a, attached at the end of this section. Signs shall be erected as soon as possible and within 5 days after commencement of work under this contract.

1.3.2 Construction Signs

1.3.2.1 Execution.

The following signs shall be erected:

Project Sign at location designated by the Contracting Officer.

Warning Signs facing approaching traffic on all haul roads crossing under overhead power transmission lines.

Two (2) hard hat signs at locations directed.

Three (3) beach placement signs at locations directed.

Project and hard hat signs shall be constructed as detailed in EP 310-1-6a, and illustrations, provided at the end of this section. Project signs shall display the American Recovery and Reinvestment Act (ARRA) emblem in accordance with guidelines attached to the end of this Section. Decals for hard hat signs will be furnished by the Contracting Officer.

All exposed surfaces and edges of plywood shall be given one coat of linseed oil and be wiped prior to applying primer. All exposed surfaces of signs and supports shall be given one coat of primer and 2 finish coats of white paint. Except as otherwise indicated, lettering on all signs shall be black and sized as indicated.

1.3.2.2 American Recovery and Reinvestment Act (ARRA)

The Project Sign shall display the American Recovery and Reinvestment Act (ARRA) emblem in accordance with guidelines attached to the end of this Section.

1.3.3 Special Notification Signs

Special notification signs may be required to be posted in the vicinity of the Mission Beach nourishment area to notify beach users and pedestrians of beach fill construction activities. The number of signs, wording of signs and location of signs shall be coordinated in advance with the City of San Diego and approved by the Contracting Officer Representative. This coordination to take place during the pre-construction meeting. The number of special notification signs shall not exceed five (5).

1.3.4 Bulletin Board at the Contractor's office

A weatherproof bulletin board, approximately 3 feet wide and 2.5 feet high, with hinged glass door shall be provided adjacent to or mounted on the

SECTION 01 00 00 Page 4 Amendment 1

Contractor's project office. If adjacent to the office, the bulletin board shall be securely mounted on no less than 2 posts. Bulletin board and posts shall be painted or have other approved factory finish. The bulletin board shall be easily accessible at all times and shall contain wage rates, equal opportunity notice, and such other items required to be posted.

1.3.5 Maintenance and Disposal

The Contractor shall maintain the signs in good condition throughout the life of the project. Signs shall remain the property of the Contractor and upon completion of the project they shall be removed from the site.

1.4 GOVERNMENT FIELD OFFICE

The Contractor shall provide as a minimum, an office space in the Contractor's project trailer/office for the Contracting Officer's Representative. The space shall not be less than 10 feet wide by 15 feet long, and shall contain the following:

* suitable desk and minimum 2 chairs

* 1 telephone

* independent service for telephone and modem

* 1 file cabinet, minimum 3 drawer, legal, lockable

* access to a copy machine

* access to a FAX machine

* electric light and power

* heater and air conditioning

* toilet facilities

A mail slot in the door or a lockable mail box mounted on the surface of the door shall be provided. At completion of the project, the office shall remain the property of the Contractor and shall be removed from the site.

Utilities shall be connected and disconnected in accordance with local codes and to the satisfaction of the Contracting Officer.

1.5 PUBLIC UTILITIES

1.5.1 General

The approximate location of all pipelines, sewer lines, and other utilities known to exist within the limits of the work are indicated on the drawings. The sizes, locations, and names of owners of such utilities are given from available information, but their accuracy is not guaranteed.

Except as otherwise indicated on the drawings, all existing utilities will be left in place and the Contractor shall conduct his operations in such a manner that the utilities will be protected from damage at all times, or arrangements shall be made by the Contractor for their relocation at the Contractor's own expense. The Contractor shall be responsible for any damage to utilities known to exist and shall reimburse the owners for such damage caused by his operations.

See Appendix B for information related to the two (2) sewer lines crossing the Entrance Channel.

1.5.2 Utilities To be Relocated or Protected

The Contractor shall notify the Contracting Officer, in writing, 10 calendar days in advance prior to starting work on any utility to be relocated or protected. On each relocation, notification shall include

SECTION 01 00 00 Page 5 Amendment 1 dates on which the Contractor plans excavation, by-pass work, removal work and/or installation work, as applicable.

1.5.3 Relocation or Removal

Utilities to be relocated or removed not as part of this contract are designated "To be Relocated by Others" or "To be Removed by Others," respectively. Utilities shown on the plans and not so designated shall be left in place and will be subject to the provisions of the paragraph entitled "Protection of Existing Vegetation, Structures, Utilities, and Improvements" of Section 00700 CONTRACT CLAUSES. The Contractor without cost to the Government, may make arrangements with the owner for the temporary relocation and restoration of utilities not designated to be relocated, or for additional work in excess of the work needed to relocate utilities designated for relocation.

1.5.4 Coordination

The Contractor shall consult and cooperate with the owner of utilities that are to be relocated or removed by others to establish a mutual performance schedule and to enable coordination of such work with the construction work. These consultations shall be held as soon as possible after award of the contract or sufficiently in advance of anticipated interference with construction operations to provide required time for the removal or relocation of affected utilities.

1.5.5 Utilities Not Shown

If the Contractor encounters, within the construction limits of the entire project, utilities not shown on the plans and not visible as of the date of this contract and if such utilities will interfere with construction operations, he shall immediately notify the Contracting Officer in writing to enable a determination by the Contracting Officer as to the necessity for removal or relocation. If such utilities are left in place, removed or relocated, as directed by the Contracting Officer, the Contractor shall be entitled to an equitable adjustment for any additional work or delay.

1.5.6 Electric Current

All electric current required by the Contractor shall be furnished at his expense. All temporary lines shall be furnished, installed, connected, and maintained by the Contractor in a workmanlike manner satisfactory to the Contracting Officer Representative and shall be removed by the Contractor in a like manner at his expense prior to final acceptance of the construction.

1.5.7 Underground Services Alert

The Contractor shall contact Underground Services Alert South (USA) at 1-800-422-4133 at least 5 working days prior to performing any excavation or other work close to any underground pipeline, conduit, duct, wire or other structure.

1.6 NOTICES

Copies of letters or notifications made to utility companies, U.S. Coast Guard, Mission Bay representatives, City of San Diego or San Diego County representatives, etc. shall be provided to the Contracting Officer.

SECTION 01 00 00 Page 6 Amendment 1

1.6.1 City of San Diego

The Contractor shall notify the Contracting Officer and the City of San Diego at least 10 days in advance of commencement of operation. The following information shall be provided:

a. Size and type of construction equipment performing work in the project area, including any equipment to be working at staging or loading areas, or on the beach.

b. 24-hour telephone numbers of the project engineer, superintendent, and foreman.

c. Schedule for completion of project.

City of San Diego Kevin Jiampa tel (858)581-9979

1.6.2 Traffic Routing

The Contractor shall notify the Contracting Officer Representative 5 days in advance of the time work will be started in areas requiring the rerouting of traffic, traffic lane striping, or removal of street signs.

The foregoing shall apply to progressive modifications of traffic routing within an area in which work is in progress.

1.6.3 Existing Bench Marks and R/W Markers

The Contractor shall notify the Contracting Officer, in writing, 5 days in advance of the time he proposes to remove any bench mark or right-of-way marker.

1.6.4 United States Coast Guard

The Contractor shall notify the Commander Eleventh Coast Guard District, and the Coast Guard Sector San Diego not less than 14 calendar days prior to commencing work. The notifications shall be provided by e-mail with information attached as a WORD.doc or pdf file. The notification shall include as a minimum the following information:

a. Project description including the type of operation (i.e. jetty repair, dredging, diving, construction, etc).

b. Location of operation, including Latitude / Longitude (NAD 83).

c. Work start and completion dates and the expected duration of operations. The Coast Guard needs to be notified if these dates change.

d. Vessels involved in the operation (name, size and type).

e. VHF-FM radio frequencies monitored by vessels on scene.

f. Point of contact and 24 hour phone number.

g. Chart number for the area of operation (18765).

h. Potential hazards to navigation.

i. Recommend the following language be used in the LNM: "Mariners are

SECTION 01 00 00 Page 7 Amendment 1 urged to transit at their slowest safe speed to minimize wake, and proceed with caution after passing arrangements have been made."

Address:

Commander, 11th Coast Guard District (dpw) U.S. Coast Guard ATTN: Local Notice to Mariners Sector San Diego Coast Guard Island Building 50-2 Attn: LCDR Michael Dolan Alameda, CA 94501-5100 2710 North Harbor Drive Tel: (510) 437-2980 San Diego, CA 92101 e-mail: d11LNM@uscg.mil Phone # (619) 278-7261 Web:www.uscg.mil/d11/dp/LnmRequest.asp e-mail: Michael.B.Dolan@uscg.mil

1.7 POINTS OF CONTACT

The following is a list of points of contact:

Company or Agency Contact Telephone

U.S. Army Corps of Engineers Resident Engineer Greg Schulz (619)428-8791 Project Engineer Nichelle Smith (760)352-5344 Construction Representative Harlan Jefferson (760)385-5031

City of San Diego Harbor Patrol Lt. Greg Buchanan (619)221-8833 Park & Recreation Dept. Kevin Jiampa (619)961-5160 SDPD Mission Bay Harbor Unit Mark Heacox (858)354-6505 Mission Bay Lifeguard Unit Sgt.John Everhart (619)980-0938 San Diego Lifeguards Sgt. Rick Strobel (619)980-0231 Mission Bay Park Stacy McKenzie (619)235-1154

U.S. Coast Guard Local Notice to Mariners John Hinson, BM1 (510)437-2980 Aids-To-Navigation Operations Baxter Smoak, LT (510)437-5984 Assistant Operations Officer Jay Field, BMC (510)437-2969

U.S. Coast Guard Sector San Diego Waterways Management Division LCDR Mike Dolan (619)278-7261

1.8 AIDS TO NAVIGATION

The Contractor shall not remove, relocate, obstruct, willfully damage, make fast to, or interfere with any aids to navigation. The Contractor shall notify the Eleventh Coast Guard District in writing with a copy to the Contracting Officer not less than 30 calendar days in advance of the time he plans to operate any equipment adjacent to any aids to navigation which requires relocation or removal.

1.9 MARINE CONSTRUCTION AIDS

The Contractor shall coordinate with the Harbor Patrol prior to placing any buoy or other aid marker in the water. Buoys and other construction aid markers shall be equipped with the necessary lights, and the Contractor shall insure that all lights are in proper working order prior to installation. Buoys and construction aid markers shall be maintained throughout the length of the construction operation and shall not be

SECTION 01 00 00 Page 8 Amendment 1 colored, marked, or placed in a manner that will obstruct or be confused with other navigational aids. The Contractor's buoys and aid markers shall conform to U.S. Coast Guard regulations.

1.10 RESTRICTIONS

1.10.1 No Dredging Allowed from March 1st to Sept 15th

a. To avoid impacts to grunion and the least tern, no dredging shall occur between March 1st and September 15th.

1.10.2 Construction Vehicles

a. The Contractor shall secure any necessary permits for vehicular access to the project site, beach site, and staging area. All Contractor's vehicles granted such permit shall display said permit at all times.

b. The Contractor and his employees shall park all private vehicles within the designated storage or staging area.

1.10.3 Obstruction of Channel

The Government will not undertake to keep the harbor entrance or navigation channels free from vessels or other obstructions. The Contractor shall be required to conduct the work in such a manner as to obstruct navigation as little as possible, and in case the Contractor's plant so obstructs the channel as to make difficult or endanger the passage of vessels, said plant shall be promptly moved on the approach of any vessel to such an extent as may be necessary to afford a practicable passage. Upon the completion of the work, the Contractor shall promptly remove his plant, including ranges, temporary buoys, and piles and other marks placed by him under the contract. The Contractor's plant shall be equipped for bridge to bridge communication with other vessels and the Contractor shall monitor prescribed channels in compliance with Coast Guard regulations.

All underwater and above surface hazards to navigation associated with this work shall be marked with a white light of at least 40 candella.

1.10.4 Booster Unit

If a booster unit is required, it shall be mounted on rubber to reduce vibrations, the blower shall be vented toward the ocean, and all other necessary precautions taken to minimize the noise level. The booster unit shall be fully enclosed with a bamboo, grade-stake, or chain-link fencing not less than 6-foot in height. Location of the booster unit is subject to approval of the Contracting Officer.

1.10.5 Discharge Pipeline

At no time shall the pipeline be floating within the navigation channel such that it poses a navigation hazard.

1.10.6 Beach Access Ramp

The Contractor shall provide an access ramp over the discharge pipeline at every street entrance and lifeguard tower and pedestrian access point.

The Contractor shall provide access ramps over the discharge pipeline per direction of the Contracting Officer in coordination with the Mission Bay

SECTION 01 00 00 Page 9 Amendment 1

Lifeguard Unit.

1.10.7 Local Restrictions

The following restrictions apply to the construction operations conducted at Mission Bay Harbor:

a.. Truck traffic to and from the Contractor's staging area is limited to Monday thru Friday, 7:00 a.m. to 7:00 p.m.

b. The Contractor's mooring site shall be coordinated through Sgt.

John Everhart of the Mission Bay Lifeguard Unit.

c. All overland access (trucks arriving) to the project site shall be coordinated with the City of San Diego Park and Recreation Department.

1.11 MARINE PLANT

a. All marine plant and equipment which are required by federal regulations to be inspected by the United States Coast Guard, shall have valid certifications. No marine plant or equipment requiring Coast Guard inspection shall be put into use on the job without the required certification issued by the U.S. Coast Guard Officer in Charge of Marine Inspections.

b. All marine construction equipment shall monitor appropriate VHF marine safety radio channels.

c. Fuel transfer operations shall conform to U.S. Coast Guard design regulations, CFR 33 Part 156.

1.12 PUBLIC SAFETY

Attention is invited to the CONTRACT CLAUSE: PERMITS AND RESPONSIBILITIES. The Contractor shall provide temporary fencing, barricades, and/or guards, as required, to provide protection in the interest of public safety. Whenever the Contractor's operations create a condition hazardous to the public, he shall furnish at his own expense and without cost to the Government, such flagmen and guards as are necessary to give adequate warning to the public of any dangerous conditions to be encountered and he shall furnish, erect, or maintain such fences, barricades, lights, signs and other devices as are necessary to prevent accidents and avoid damage or injury to the public. Flagmen and guards, while on duty and assigned to give warning and safety devices shall conform to applicable city, county, and state requirements. Should the Contractor appear to be neglectful or negligent in furnishing adequate warning and protection measures, the Contracting Officer may direct attention to the existence of a hazard and the necessary warning and protective measures shall be furnished and installed by the Contractor without additional cost to the Government. Should the Contracting Officer point out the inadequacy of warning and protective measures, such action of the Contracting Officer shall not relieve the Contractor from any responsibility for public safety or abrogate his obligation to furnish and pay for those devices. The installation of any general illumination shall not relieve the Contractor of his responsibility for furnishing and maintaining any protective facility.

SECTION 01 00 00 Page 10 Amendment 1

The Contractor shall furnish flagmen, watchmen, or other security personnel to control traffic and protect pedestrians in the vicinity of construction operations at all times while work is in progress in the construction area, if needed or directed by the Contracting Officer.

1.13 GENERAL SAFETY REQUIREMENTS

1.13.1 General

The Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, (see CONTRACT CLAUSES: SECTION 00700, ACCIDENT PREVENTION), the Occupational Safety and Health Act (OSHA) Standards for Construction (Title 29, Code of Federal Regulations Parts 1926 as revised from time to…