SF30_W912PB19Q3149-0002.pdf

0011360271

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See Summary of Changes

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 28-Jun-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912PB19Q3149

X 9B. DATED (SEE ITEM 11)

19-Jun-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

28-Jun-2019

CODE

RCO BAVARIA

AMERIKANISCHE BESCHAFFUNGSSTELLE

GEB 542

92655 GRAFENWOEHR LAGER

GERMANY

W912PB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912PB19Q3149

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SOLICITATION INFORMATION AND INSTRUCTION

Regional Contracting Office POC Contract Specialist: SSG Jason Shettles Commercial Phone: +49-9641-83-8039

DSN: 314-475-8039

E-mail: jason.d.shettles.mil@mail.mil

Customer POC: to be added at time of award

Short Description of Requirement: Window Roller Blinds with Installation, Storck Barracks at USAG Ansbach

SUMMARY OF CHANGES

The purpose of this amendment is to address questions from potential quoters, resulting in the following changes (in red/bold text):

SECTION SF 1449 - CONTINUATION SHEET

The following have been modified:

REQUIREMENT SPECIFICATIONS

The Contractor shall provide and install 852 roller blinds in 17 buildings (eleven (11) of which are currently occupied by Soldiers) at Storck Barracks within United States Army Garrison - Ansbach. All buildings on Storck Barracks have three floors each that require the blinds.

All roller blinds shall be 100% black-out, controlled by plastic continuous loop, surface-mounted to wall or ceiling based on site condition unless noted otherwise, neutral grey in color on the inside, and backed by heat reflection backing.

Contractor shall paint and patch as necessary. The Contractor is responsible for painting and patching the walls around the roller blinds. If something is damaged during installation, the Contractor shall repair it.

The measurements below are only estimates and must be verified by the Contractor after contract award. The length (vertical dimension) of the roller blinds is the minimum length/height (Höhe) to cover the height of the window from top to bottom. The width (horizontal dimension) is the width (Breite) of the window plus approximately 4 cm overlap per side.

W912PB19Q3149

Opening

Width (m)

Length (m)

QTY

Door 1.00 2.45 42 Window 1.65 1.65 702 Window 2.55 1.65 42 Window 2.30 1.90 54 Window 3.60 1.65 12

Total 852

Entrance to the eleven (11) occupied buildings require coordination with the occupying units through the customer.

Occupied barracks building access requires a minimum of 1-month coordination (the Contractor should begin work in unoccupied buildings while coordination for access to occupied buildings takes place). The available hours to access rooms for installation are 0900-1700, Monday through Friday. It is possible to install on Saturdays in unoccupied barracks rooms from 1000-1700. No work shall be performed on Sundays, US Federal and training holidays, or German holidays. Requests for specific days to access rooms inside approved barracks buildings requires a minimum of 1-week coordination. The Contractor shall provide a schedule for building access for each building to the Customer POC who is the approving authority. The Government reserves the right to grant building access only on specific dates or temporarily suspend installation work if mission requires.

No unfinished installation shall be left in an occupied bedroom (BR) overnight unless approved by the customer.

Nine (9) of the 17 buildings each have six (6) 3-BR and six (6) 4-BR units. The other eight (8) buildings each have six (6) 2-BR, six (6) 3-BR, and six (6) 4-BR units. The windows of these eight (8) buildings have moldings that come to the edge of the window openings. If the molding interferes with the blinds, the contractor shall provide a solution that meets the requirement.

The Contractor shall not move furniture and/or other personal items from in front of and around window openings in occupied rooms. The Contractor shall contact the Customer POC if there are items that prevent the installation of blinds in any room.

OFFEROR’S ESTIMATED INSTALLATION SCHEDULE (*Offeror Insert # of Days):

Installation of all blinds SHOULD be completed within ________* calendar days upon receipt of the order, barring unforeseen delays related to Government-provided access to buildings/rooms. (This estimated completion date will be considered when stating the required delivery date in the purchase order.)

(End of Summary of Changes)