01_W912PB-17-B-8106.pdf

0010999350

Maintenance of Family Housing Quarters, USAG Bavaria, Grafenw oehr Military Community - Tow er Barracks

See Section J for Attachments

Instead of Block 11 below , see Special Provision in Section F, paragraph 2, Commencement of Work

X

REGINA RUECKSCHLOSS +49-9641-83-5107

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

10-May-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______ calendar days and complete it w ithin ________ calendar days after receiving aw ard, notice to proceed. This performance period is mandatory, negotiable. (See _________________________Section F

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________14 Jun 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______180 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

ECC RCO BAVARIA

AMERIKANISCHE BESCHAFFUNGSSTELLE

GEB 542

92655 GRAFENWOEHR LAGER

GERMANY

W912PB

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: SEE NAME OF POC TEL: FAX:

W912PB-17-B-8106 42

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912PB-17-B-8106

Section A - Solicitation/Contract Form

GENERAL INFORMATION

1. REQUIRED WORK

Maintenance of Family Housing Quarters, USAG Bavaria, Grafenwoehr Military Community - Tower Barracks in accordance with the Specification in Attachment I.

2. CONTRACT PERIOD: 15 November 2017 - 14 November 2022

The contract period is contingent upon award by 01 November 2017 unless waived in writing by the contracting parties. If award is made after that date and not waived, there will be a corresonding unilateral change in the contract period.

3. TYPE OF CONTRACT

a. The contract resulting from this Invitation for Bids (IFB) will be an Indefinite Delivery - Indefinite Quantity type contract with firm fixed price task orders.

b. The maximum contract value is Euro 8,500,000.00 for the entire contract period.

c. The guaranteed minimum is Euro 20,000.00.

4. PLACE OF PERFORMANCE

The Contractor shall perform renovation work in Government owned family quarters, "Bachelor Officers Quarters (BOQ)" and "Senior Enlisted Bachelor Officers Quarters (SEBOQ)" in Tower Barracks (Grafenwoehr), as well as in leased quarters in Altenstadt/WN, Erbendorf, Eschenbach, Gmuend, Grafenwoehr, Huetten, Kastl, Kemnath, Kulmain, Luhe, Mantel, Meerbodenreuth, Netzaberg, Neunkirchen (Weiden), Neustadt/WN, Kohlberg, Parkstein, Pressath, Rothenstadt, Schwarzenbach, Speichersdorf, Weiden, Weiherhammer and others within a radius of 40 kilometers from Tower Barracks.

5. NOTICE TO OFFERORS:

a. The stated quantities of each specification item are ESTIMATES only and may not reach those indicated. The estimated quantities will be used only for evaluation purposes. These quantitites shall not constitue a basis for a claim or price increase during the period of this contract. Payment will only be made for quantities actually ordered and delivered.

b. Contracting Officers assigned to RCO Bavaria and duly appointed Ordering Officers within the Housing Division Grafenwoehr are authorized to issue Task Orders under this contract.

c. Oral calls are authorized in accordance with Section G.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Maintenance of Family Housing Quarters

FFP

Maintenance of Family Housing Quarters, USAG Bavaria, Grafenwoehr Military Community - Tower Barracks.

Orders may be placed up to the stated maximum amount of the contract for Maintenance and Repair of Family Housing Quarters, USAG Bavaria, Grafenwoehr Military Community in accordance with the Specifications in Attachment I, the Price Schedules in Attachment II, and the Total of all Price Schedules in Attachment III.

Price Schedule:

Prices for the individual years must be inserted for each specification item in the price schedules in Attachment II. The specification items include all types of work that may be performed. The estimated quantities will be used ONLY for evaluation purposes

FOB: Destination

PURCHASE REQUEST NUMBER: 0010999350

NET AMT

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY FULL TEXT

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

Section F - Deliveries or Performance

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within two (2) working days after the issuance of a Task Order, (b) prosecute the work diligently, and (c) complete the entire work ready for use as per below stated rate of work. The time stated for completion shall include final cleanup of the premises.

RATE OF WORK:

Cleaning Work

Apartments up to 129 sqm 1 working day Apartments 130 through 470 sqm 2 working days Stairwells 1 working day

Repair and Painting Work

Apartments up to 300 sqm 1 working day Apartments 301 through 450 sqm 2 working days Apartments above 450 sqm 3 working days Stairwells 2 working days

Repair and Replace Floors Apartments up to 129 sqm 3 working day Apartments 130 through 470 sqm 4 working days Stairwells 3 working day

Remove Mold and other Repair Work Apartments up to 300 sqm 3 working day Apartments 301 through 500 sqm 6 working days Apartments 501 through 1200 sqm 12 working days Stairwells 3 working days

Exact performance dates will be established on each individual Task Order issued against this contract. The Contractor shall contact the Contracting Officer Representative (COR) respectively the Ordering Officer (OO) to either arrange an appointment for the pick up of the keys for vacant apartments or to receive the work schedule for apartments that are occupied during performance of the work. If the required material for the Task Order is not on hand and delivery date will exceed the above stated rate of work, the contractor shall immediately inform the COR of the expected delivery date.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of Euro 321.30 for each apartment and stairwell for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Section G - Contract Administration Data

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Payment Invoice

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Use code of Block # 14 on page 1 of each task order

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC use code of Block 15 on page 1 of the task order Issue By DoDAAC not applicable Admin DoDAAC W912PB Inspect By DoDAAC use code of Block 14 on page 1 of the task order Ship To Code use code of Block 14 on page 1 of the task order Ship From Code not applicable Mark For Code not applicable Service Approver (DoDAAC) not applicable Service Acceptor (DoDAAC) use code of Block 14 on page 1 of the task order Accept at Other DoDAAC not applicable LPO DoDAAC not applicable DCAA Auditor DoDAAC not applicable Other DoDAAC(s) not applicable

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Gerhard.Hartung.ln@mail.mil Gerhard Engelhardt.ln@mail.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Gerhard.Hartung, telephone 09641-83-7124 Gerhard Engelhardt, telephone 09641-83-5312

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

5152.232-4001 FOREIGN VENDORS REQUESTING PAYMENT VIA ELECTRONIC FUNDS TRANSFER

(June 2016)

Foreign vendors requesting payment via Electronic Funds Transfer (EFT) shall provide the following information on their invoice at time of invoice submission. Only one EFT instruction per invoice is authorized.

- Bank Name:

- Bank Identification Code (BIC):

- International Bank Account Number (IBAN):

ADDITIONAL INFO SECTION G

1. ORDERING PROCEDURES FOR TASK ORDERS

a.. Contracting Officers assigned to RCO Bavaria or duly appointed Ordering Officers within the Housing Division Grafenwoehr are authorized to issue Task Orders under this contract using a DD Form 1155. Each task order will include the following information:

(1) Date of the task order

(2) Contract number and task order number

(3) Item(s) and Quantities being ordered and description of work

(4) Total amount of the task order (both in Euro and US Dollars)

(5) Performance Period

(6) Place of Performance

(7) Accounting and appropriation data

(8) Disbursing Finance Office

(9) Any other pertinent data

b. All task orders issued hereunder are subject to the terms and conditions of the contract. The contract shall control in the event of conflict with any task orders.

c. Above authorities are authorized to place oral calls under this contract; such calls must be confirmed in writing.

d. In placing an oral call, the person authorized to place a call will provide the contractor with

(1) the contract number and task order number

(2) line item(s) and quantities being ordered and description of work

(3) total amount of the order

(4) performance period

(5) place of performance

(6) any other pertinent data

e. Task Orders may not exceed 12 months.

2. CONTRACTOR PAYMENT PROCEDURES

a. The contractor shall submit payment requests in accordance with DFAR 252.232-7003 Electronic Submission of Payment Requests (see Section I).

b. Payment will be made by the appropriate disbursing finance office as indicated on the task order.

Section H - Special Contract Requirements

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 40 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

5152.204-4005 CONVENTIONAL FORCES EUROPE (CFE) TREATY VERIFICATION INSPECTION

(June 2016)

Contractor-owned or controlled structures and containers located on U.S. Government installations are subject to short-notice inspections by CFE treaty inspection teams. The Government will endeavor to provide the Contractor as much notice as possible in the event of such inspections. The contractor shall provide access to such structures and containers at the request of the Government. The Contractor shall report such inspections to the Contracting Officer in writing within ten (10) calendar days of completion of the inspection. Contractor-owned or controlled structures and/or containers on U.S. installations may have to be inspected to comply with the CFE treaty even if Contractor personnel are unavailable to provide access. Any costs borne by the Contractor or any impact on contract performance as a result of the inspection will be a matter of negotiation between the Contractor and the Contracting Officer.

5152.225-4001 INSTALLATION CLEARANCE REQUIREMENTS (June 2016)

(a) Access to U.S. installations and controlled areas is limited to personnel who meet security criteria and are authorized by Host Nation law to work in that country. Failure to submit required information/data and obtain required documentation or clearances in accordance with AE Regulation 190-16, Installation Access Control, will be grounds for denying access to U.S. installations and controlled areas. The Contractor is responsible to ensure that any Subcontractor used in performance of this contract complies with these requirements and that all employees, of both the Contractor and any Subcontractor utilized by the contractor, are made aware of and comply with these requirements.

(b) The Contractor is responsible for being aware of and complying with the requirements associated with Installation Access Control. The Government is not liable for any costs associated with performance delays due solely to a firm’s failure to comply with Installation Access Control (IAC) processing requirements.

(c) The Contractor is responsible for returning installation passes to the issuing Installation Access Control Office (IACO) when the contract is completed or when a contractor employee no longer requires access.

(d) AE Regulation 190-16 (and AE Regulation190-16-G German translation) can be found on the following website:

http://www.eur.army.mil/aepubs/AE-Regulations.html

(e) Below is the responsible Organizational Sponsor & Installation Access Control Office for this contract:

Organizational Sponsor: Gerhard Hartung

Location: Grafenwoehr Tower Barracks Building No: 244 DSN Phone No: 475-7124 Commercial Phone No: 0049-9641-83-7124

Installation Access Control Offices:

Location: Grafenwoehr Tower Barracks Building No: 244, Room 134 DSN Phone No: 4 475-8414/8415 Commercial Phone No.: 0049-9641-83-8414/8415

(End of local clause)

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreeements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-3 Worker's Compensation Insurance (Defense Base Act) JUL 2014 52.228-4 Workers' Compensation and War-Hazard Insurance Overseas APR 1984 52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.236-2 Differing Site Conditions APR 1984 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.242-13 Bankruptcy JUL 1995 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items JAN 2017 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2016 252.225-7048 Export-Controlled Items JUN 2013 252.227-7022 Government Rights (Unlimited) MAR 1979 252.229-7000 Invoices Exclusive of Taxes or Duties JUN 1997 252.232-7008 Assignment of Claims (Overseas) JUN 1997 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.246-7002 Warranty of Construction (Germany) JUN 1997 252.246-7003 Notification of Potential Safety Issues JUN 2013 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.216-19 ORDER LIMITATIONS. (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than Euro 250.00, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor:

(1) Any order for a single item in excess of Euro 19,500.00;

(2) Any order for a combination of items in excess of Euro 19,500.00; or

(3) A series of orders from the same ordering office within one (1) day that together call for quantities exceeding the limitation in subparagraph (1) or (2) above.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) above.

(d) Notwithstanding paragraphs (b) and (c) above, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within five (5) days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after expiration of the final task order issued during the contract's ordering period..

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF CONTRACT

(FEB 2000)

In the event of inconsistency between any terms of this contract and any translation into another language, the English language meaning shall control.

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

Funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

52.232-37 MULTIPLE PAYMENT ARRANGEMENTS (MAY 1999)

This contract or agreement provides for payments to the Contractor through several alternative methods. The applicability of specific methods of payment and the designation of the payment office(s) are either stated--

(a) Elsewhere in this contract or agreement; or

(b) In individual orders placed under this contract or agreement.

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

United States law will apply to resolve any claim of breach of this contract.

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to

(1) conditions bearing upon transportation, disposal, handling, and storage of materials;

(2) the availability of labor, water, electric power, and roads;

(3) uncertainties of weather, river stages, tides, or similar physical conditions at the site;

(4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract.

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer's notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed.

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if—

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include—

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor’s right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

http://www.acquisition.gov

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

(a) "Definition. Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

252.216-7006 ORDERING (MAY 2011)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the contract schedule. Such orders may be issued from contract start through contract expiration.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c)(1) If issued electronically, the order is considered ``issued'' when a copy has been posted to the Electronic Document Access system, and notice has been sent to the Contractor.

(2) If mailed or transmitted by facsimile, a delivery order or task order is considered ``issued'' when the Government deposits the order in the mail or transmits by facsimile. Mailing includes transmittal by U.S. mail or private delivery services.

(3) Orders may be issued orally only if authorized in the schedule.

(End of Clause)

252.225-7041 CORRESPONDENCE IN ENGLISH (JUNE 1997)

The Contractor shall ensure that all contract correspondence that is addressed to the United States Government is submitted in English or with an English translation.

252.225-7043 ANTITERRORISM/FORCE PROTECTION POLICY FOR DEFENSE CONTRACTORS

OUTSIDE THE UNITED STATES (JUN 2015)

(a) Definition. United States, as used in this clause, means, the 50 States, the District of Columbia, and outlying areas.

(b) Except as provided in paragraph (c) of this clause, the Contractor and its subcontractors, if performing or traveling outside the United States under this contract, shall--

(1) Affiliate with the Overseas Security Advisory Council, if the Contractor or subcontractor is a U.S. entity;

(2) Ensure that Contractor and subcontractor personnel who are U.S. nationals and are in-country on a non-transitory basis, register with the U.S. Embassy, and that Contractor and subcontractor personnel who are third country nationals comply with any security related requirements of the Embassy of their nationality;

(3) Provide, to Contractor and subcontractor personnel, antiterrorism/force protection awareness information commensurate with that which the Department of Defense (DoD) provides to its military and civilian personnel and their families, to the extent such information can be made available prior to travel outside the United States; and

(4) Obtain and comply with the most current antiterrorism/force protection guidance for Contractor and subcontractor personnel.

(c) The requirements of this clause do not apply to any subcontractor that is--

(1) A foreign government;

(2) A representative of a foreign government; or

(3) A foreign corporation wholly owned by a foreign government.

(d) Information and guidance pertaining to DoD antiterrorism/force protection can be obtained from HQDA-AT;

telephone, DSN 222-9832 or commercial (703)692-9832.

252.225-7993 PROHIBITION ON PROVIDING FUNDS TO THE ENEMY (DEVIATION 2015-O0016) (SEP 2015)

(a) The Contractor shall—

(1) Exercise due diligence to ensure that none of the funds, including supplies and services, received under this contract are provided directly or indirectly (including through subcontracts) to a person or entity who is actively opposing United States or Coalition forces involved in a contingency operation in which members of the Armed Forces are actively engaged in hostilities;

(2) Check the list of prohibited/restricted sources in the System for Award Management at www.sam.gov —

(i) Prior to subcontract award; and

(ii) At least on a monthly basis; and

(3) Terminate or void in whole or in part any subcontract with a person or entity listed in SAM as a prohibited or restricted source pursuant to subtitle E of Title VIII of the NDAA for FY 2015, unless the Contracting Officer provides to the Contractor written approval of the Head of the Contracting Activity to continue the subcontract.

(b) The Head of the Contracting Activity has the authority to—

(1) Terminate this contract for default, in whole or in part, if the Head of the Contracting Activity determines in writing that the contractor failed to exercise due diligence as required by paragraph (a) of this clause; or

(2)(i) Void this contract, in whole or in part, if the Head of the Contracting Activity determines in writing that any funds received under this contract have been provided directly or indirectly to a person or entity who is actively opposing United States or Coalition forces involved in a contingency operation in which members of the Armed Forces are actively engaged in hostilities.

(ii) When voided in whole or in part, a contract is unenforceable as contrary to public policy, either in its entirety or with regard to a segregable task or effort under the contract, respectively.

(c) The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts, including subcontracts for commercial items, under this contract that have an estimated value over $50,000 and will be performed outside the United States and its outlying areas.

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS

(JUNE 2012)

(a) Definitions. As used in this clause–

(1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(4) Receiving report means the data required by the clause at 252.246-7000, Material Inspection and Receiving Report.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic…