A21_-_W912P819B0059_(incls_p&s).pdf

ED 19-010

IFB NO. W912P819B0059

US Army Corps of Engineers New Orleans District

Mississippi River Outlets Vicinity of Venice, LA

Baptiste Collette Bar Channel West Jetty Extension

Plaquemines Parish, Louisiana

Construction Solicitation and Specifications

23 August 2019

REPLY TO

ATTENTION OF

DEPARTMENT OF THE ARMY

NEW ORLEANS DISTRICT, CORPS OF ENGINEERS

7400 LEAKE AVENUE

NEW ORLEANS, LOUISIANA 70118-3651

Contracting Division Projects West Branch

ATTENTION BIDDERS

In preparing your bid -----

1. Have you signed the bid? Are all blank spaces filled in?

2. If signing on behalf of your company and not an offer thereof, have you attached evidence of your authority to sign the bid?

3. Have you acknowledged receipt of all amendments?

4. Have you checked your bid for possible errors? Arithmetically?

5. Have you furnished all information required by the invitation for bids or the specifications?

6. Are you submitting your bid on time? If mailed, will it reach the place of bid opening at the designated hour?

7. If required by the invitation, have you submitted a bid bond? Is it signed? Is it in the proper amount?

8. Have you identified on the face of the envelope containing your bid, the invitation number to which it pertains, and the date and hour of opening?

9. Note to bidders: Visitors will be checked at the gate when arriving at installation where bid opening will take place. The district has a new policy where all visitors must have a background search performed by district security and will not be allowed on the reservation if they are not cleared. To avoid possible delays, ensure your representative has no outstanding “problems” that can be discovered by the background check.

LMN FL 1078-1

AUGUST 90 (previous editions are obsolete) Proponent: CEMVN-CT-W

INQUIRIES REGARDING THIS SOLICITATION SHOULD BE MADE TO

THE FOLLOWING:

JENIFER BORDELON

EMAIL: JENIFER.M.BORDELON@USACE.ARMY.MIL

TELEPHONE: 504-862-2466

COLLECT CALLS NOT ACCEPTED

FOR THE MOST PROMPT RESPONSE, SEND ALL QUESTIONS VIA

EMAIL. ALL QUESTIONS MUST CONTAIN THE SOLICITATION

NUMBER IN THE SUBJECT LINE.

mailto:JENIFER.M.BORDELON@USACE.ARMY.MIL

DEPARTMENT OF THE ARMY

CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

7400 LEAKE AVE

NEW ORLEANS, LA 70118-3651

ED 19-010

SOLICITATION: W912P819B0059 23 August 2019

FOR: Mississippi River Outlets, Vicinity of Venice, Louisiana, Baptiste Collette Bar Channel, West Jetty Extension Plaquemines Parish, Louisiana (ED-19-010)

TO OPEN: BID OPENING DATE IS 23 SEPTEMBER 2019 AT 2:00 PM CDT.

(Questions are due not later than 5 September 2019 at 5:00 PM CDT.)

I. NOTE THE AFFIRMATIVE ACTION PROGRAM REQUIREMENT OF THE EQUAL OPPORTUNITY

CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING FROM THIS SOLICITATION.

II. NOTE THE CERTIFICATION OF NONSEGREGATED FACILITIES IN THIS SOLICITATION.

Bidders, offerors and applicants are cautioned to note the "Certification of Non-segregated Facilities" in the solicitation. Failure of a bidder or offeror to agree to the certification will render his bid or offer non-responsive to the terms of solicitations involving awards of contracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause.

III. Prospective contractors must register in the System for Award Management (SAM). See FAR Clause 52.204-7 for required information. The website for SAM is https://www.sam.gov. You will be required to provide your company’s Dun and Bradstreet (D&B) D-U-N-S number. If you do not already have a D&B D-U-N-S number, one can be requested at http://fedgov.dnb.com/webform. Contractors must complete, and submit with their bid, the provisions located in Section 00600. A bidder may also submit, in lieu of the completed Section 00600, a complete hard copy of their Online Representations and Certifications which is located within the System for Award Management (SAM). Prospective contractors with expired or inactive Representations and Certifications in SAM at time of award will be deemed unresponsive.

Bidders must provide full, accurate, and complete information as required by this solicitation and its attachments.

The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001. (FAR 52.214-4 APR 1984).

DESCRIPTION AND MAGNITUDE OF WORK: The work consists of extending the Baptiste Collette Bar Channel west jetty 1,325-ft by placing geotextile fabric on the sea floor followed by a crushed stone base, and an armor stone cap. The work shall start by tying into the end of the existing jetty and proceed northward. Optional work is included in the project which extends the west jetty an additional 675-ft.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time and for visitor background checks by MVN security when entering the installation at place of bid opening. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH

THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS

MANUAL", DATED NOVEMBER 2014.

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

W912P819B0059

USACE, CONTRACTING DIVISION

ATTN: CEMVN-CT, ROOM 172

7400 LEAKE AVE.

NEW ORLEANS LA 70118-3651

Mississippi River Outlets, Vicinity of Venice, Louisiana, Baptiste Collette Bar Channel, West Jetty Extension, Plaquemines Parish, Louisiana (ED 19-010)

DESCRIPTION OF WORK: The work consists of extending the Baptiste Collette Bar Channel west jetty 1,325-ft by placing geotextile fabric on the sea floor followed by a crushed stone base, and an armor stone cap. The work shall start by tying into the end of the existing jetty and proceed northward. Optional work is included in the project which extends the west jetty an additional 675-ft.

This procurement is UNRESTRICTED.

Magnitude of Construction: Between $5,000,000.00 and $10,000,000.00.

See Item 7

Jenifer Bordelon 504-862-2466

08/23/2019 local time 09/23/2019

2:00 PM

FAR 52.211-10

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

USACE, New Orleans Area Office 7400 Leake Avenue, Rm 186 New Orleans, LA 70118

USAED New Orleans C/O USACE FINANCE CENTER (UFC) Attn: CEFC-AO-P

5722 INTEGRITY DRIVE, MILLINGTON, TN 38054-5005

PTC-1 ED 19-010

PROJECT TABLE OF CONTENTS

Division 00 – PROCUREMENT AND CONTRACT REQUIREMENTS

Solicitation, Offer and Award (SF-1442) 00010 Bidding Schedule 00100 Instructions to Bidders 00600 Representations and Certifications 00700 Contract Clauses 00800 Special Contract Requirements

Division 01 - GENERAL REQUIREMENTS

01100 General Provisions 01 33 00 Submittal Procedures 01 42 00 Sources for Reference Publications 01 45 00.15 10 Resident Management System Contractor Mode (RMS CM) 01 45 04.00 10 Contractor Quality Control 01 57 20.00 12 Environmental Protection 01 78 02.00 10 Closeout Submittals

Division 02 – EXISTING CONDITIONS

02 21 10.00 12 Surveys

Division 31 – EARTHWORK

31 05 19.04 12 Separator Geotextile

Division 35 – WATERWAY AND MARINE CONSTRUCTION

35 31 19.03 12 Jetty Stone

SECTION 00010 – BIDDING SCHEDULE

Mississippi River Outlets Vicinity of Venice, LA

Baptiste Collette Bar Channel West Jetty Extension

Plaquemines Parish, Louisiana

00010-3 ED 19-010

Item DESCRIPTION Estimated Quantity

Unit Unit Price Estimated Amount

BASE WORK – STATION -00+50 – 13+25

Mobilization and Demobilization

1 JOB

0002 Separator Geotextile 14,430 SY

0003 Crushed Stone 25,000 TON

0004 Armor Stone (1500#) 26,000 TON

TOTAL BASE WORK: $

OPTIONAL WORK – STATION 13+25 – 20+00

0005 Separator Geotextile - OW 7,570 SY

0006 Crushed Stone - OW 14,000 TON

0007 Armor Stone (1500#) - OW 17,000 TON

TOTAL OPTION WORK: $

TOTAL BASE WORK + OPTION WORK: $

Award will be made as a whole to one bidder.

NOTE 1: The unit “JOB” as used in this Bidding Schedule is synonymous with the term “Lump Sum” used elsewhere within these plans and specifications.

NOTE 2: Bidders shall furnish unit prices for each item listed in the Schedule requiring a unit price. If the bidder fails to insert a unit price in the appropriate blank for required item(s), but does furnish an extended total, or an estimated amount for such item(s), the Government shall deem the unit price to be the quotient obtained by dividing the extended amount for that line item by the quantity. IF A BIDDER OMITS BOTH THE

UNIT PRICE AND THE EXTENDED TOTAL OR ESTIMATED AMOUNT FOR ANY

ITEM, HIS BID WILL BE DECLARED NON-RESPONSIVE AND THEREFORE

INELIGIBLE FOR AWARD.

NOTE 3: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items are materially unbalanced (See FAR 14.404-2, Rejection of Individual Bids).

NOTE 4: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442 after Notice of Award. The NTP will be issued immediately after

00010-4 ED 19-010

verification of acceptable performance and payment bonds. Within 24 hours after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Plan, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

NOTE 5: EVALUATION OF OPTIONS (FAR 52.217-5 JUL 1990). Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the options. The exercise of any option in part does not obligate the Government to the full extent of the options.

NOTE 6: OPTIONAL WORK (OW) ITEMS: The Government may require the delivery of the numbered line item(s), identified in the schedule as Optional Work items, in the quantity (total or part quantity) and price stated in the schedule. The Contracting Officer may exercise all or part of the Optional Work by written notice to the Contractor. Bidders shall bid on all items including the Optional Work item (see “Evaluation of Options” FAR 52.217-5). Failure to bid on all items will result in a non-responsive bid. If the Government activates the Optional Item(s), the activation will occur while the Contractor’s plant is within the limits of work. No additional mobilization/demobilization will be paid to the Contractor for the Optional Work.

NOTE 7: TIME ADJUSTMENT IN THE EVENT OF OPTIONAL WORK. In the event that OPTIONAL WORK items are exercised under the terms of the contract, the time required for completion of the contract will be adjusted in accordance with the following:

a. CLIN 0005 and CLIN 0006: No time will be added to the contract duration.

b. CLIN 0007: 30 calendar days will be added to the base contract duration of 85 calendar days established for the BASE WORK items specified in the Contract Clause entitled “COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52-211-10 – APR 1984). In the event that only a portion of CLIN 0007 is exercised, the time required for completion of CLIN 0007 item will be adjusted by prorating the calendar days using the amount of CLIN 0007 versus the total amount for said item.

NOTE 8: ASSESSMENT OF LIQUIDATED DAMAGES - Base and Option Work.

As this contract includes both BASE and OPTIONAL work items, and the durations allowed for completion of both the BASE and awarded OPTIONAL work are independent of each other, liquidated damages will be assessed if and when the Contractor goes beyond the duration allowed for completion of the BASE work, and assessed until the BASE work is completed; and if OPTONAL work is awarded, liquidated damages will be assessed if and when the Contractor goes beyond the duration allowed for completion of the awarded OPTIONAL work, and assessed until the OPTIONAL work is completed.

NOTE 9: RAPID VENDOR PAYMENT. Web based instructions for the submission of invoices may be found at the following website:

http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment

BID BOND

( See instructions on reverse)

DATE BOND EXECUTED (Must not be later than bid opening date) OMB Control Number: 9000-0045

Expiration Date: 7/31/2019 Paperwork Reduction Act Statement - This information collection meets the requirements of 44 USC § 3507, as amended by section 2 of the Paperwork Reduction Act of 1995. You do not need to answer these questions unless we display a valid Office of Management and Budget (OMB) control number. The OMB control number for this collection is 9000-0045. We estimate that it will take 25 minutes to read the instructions, gather the facts, and answer the questions. Send only comments relating to our time estimate, including suggestions for reducing this burden, or any other aspects of this collection of information to: General Services Administration, Regulatory Secretariat Division (M1V1CB), 1800 F Street, NW, Washington, DC 20405.

PRINCIPAL (Legal name and business address) TYPE OF ORGANIZATION ("X" one)

INDIVIDUAL

JOINT VENTURE

PARTNERSHIP

CORPORATION

STATE OF INCORPORATION

SURETY(IES) (Name and business address)

PERCENT

OF BID

PRICE

PENAL SUM OF BOND

AMOUNT NOT TO EXCEED

MILLION(S) THOUSAND(S) HUNDRED(S) CENTS

BID IDENTIFICATION

BID DATE

FOR (Construction, supplies, or Services)

INVITATION NUMBER

OBLIGATION

We, the Principal and Surety (ies) are firmly bound to the United States of America (hereinafter call the Government) in the above penal sum. For payment of the penal sum, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally. However, where the sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum "jointly and severally" as well as "severally" only for the purpose of allowing a joint action or actions against any or all of us. For all other purposes, each Surety binds itself, jointly and severally with the Principal, for the payment of the sum shown opposite the name of the Surety. If no limit of liability is indicated, the limit or liability is the full amount of the penal sum.

CONDITIONS:

The principal has submitted the bid identified above.

THEREFORE:

The above obligation is void if the Principal - (a) upon acceptance by the Government of the bid identified above, within the period specified therein for acceptance (sixty (60) days if no period is specified), executes the further contractual documents and gives the bond(s) required by the terms of the bid as accepted within the time specified (ten (10 days if no period is specified) after receipt of the forms by the principal; or (b) in the event of failure to executes such further contractual documents and give such bonds, pays the Government for any cost of procuring the work which exceeds the amount of the bid.

Each surety executing this instrument agrees that its obligations is not impaired by any extension(s) of the time for acceptance of the bid that the principal may grand to the Government. Notice to the surety (ies) of extensions (s) are waived. However, waiver of the notice applies only to extensions aggregating not more than sixty (60) calendar days in addition to the periods originally allowed for acceptance of the bid.

WITNESS

The principal and Surety (ies) executed this bid bond and affixed their seals on the above date.

PRINCIPAL

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1. 2.

2.

3.

3.

(Seal) (Seal) (Seal) Corporate Seal

INDIVIDUAL SURETY(IES)

SIGNATURE(S)

NAME(S)

(Typed)

1.

1.

2.

2.

(Seal) (Seal)

CORPORATE SURETY(IES)

SU

R

ET

Y

A

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

AUTHORIZED FOR LOCAL REPRODUCTION

Pervious edition is usable

STANDARD FORM 24 (REV. 10/1998)

Prescribed by GSA - FAR (48 CFR) 53.228(a)

SU

R

ET

Y

B

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

Corporate Seal

LIABILITY LIMIT ($)STATE OF INCORPORATION

2.

2.

1.

1.NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

C

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

D

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

E

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

F

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

G

INSTRUCTIONS

1. This form is authorized for use when a bid guaranty is required. Any deviation from this form will require the written approval of the Administrator of General Services.

2. Insert the full legal name and business address of the Principal in the space designated "Principal" on the face of the form. An authorized person shall sign the bond. Any person signing in a representative capacity (e.g., an attorney-in-fact) must furnish evidence of authority if that representative is not a member of the firm, partnership, or joint venture, or an officer of the corporation involved.

3. The bond may express penal sum as a percentage of the bid price. In these cases, the bond may state a maximum dollar limitation (e.g., 20% of the bid price but the amount not to exceed dollars).

4. (a) Corporation executing the bond as sureties must appear on the Department of the Treasury's list of approved sureties and must act within the limitation listed therein. Where more than one corporate surety is involved, their names and address shall appear in the spaces (Surety A, Surety B, etc.) headed "CORPORATE SURETY (IES)." In the space designed "SURETY (IES)" on the face of the form, insert only the letter identification of the sureties.

(b) Where individual sureties are involved, a completed Affidavit of Individual Surety (Standard Form 28), or each individual surety, shall accompany the bond. The Government may require the surety to furnish additional substantiating information concerning its financial capability.

5. Corporations executing the bond shall affix their corporate seals. Individuals shall execute the bond opposite the word " Corporate Seal";

and shall affix an adhesive seal if executed in Maine, New Hampshire, or any other jurisdiction requiring adhesive seals.

6. Type the name and title of each person signing this bond in the space provided.

7. In its application to negotiated contracts, the terms "bid" and "bidder" shall include "proposal" and "Offeror."

STANDARD FORM 24 (REV. 10/1998) BACK

W912P819B0059

Section 00100 - Bidding Schedule/Instructions to Bidders

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.217-5 Evaluation Of Options JUL 1990 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.225-12 Notice of Buy American Requirement - Construction Materials Under Trade Agreements

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS--CERTIFICATION (JUN 2018)

(a) This provision does not apply to acquisitions below the simplified acquisition threshold or to acquisitions of commercial items as defined at FAR 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

____ (1) The Offeror certifies that--

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/t/avc/rls/rpt/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President's or Secretary of State's determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/t/avc/rls/rpt/; or

____ (2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of non-compliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The Offeror may submit any questions with regard to this report by email to NDAA1290Cert@state.gov. To the extent feasible, the Department of State will respond to such email inquiries within 3 business days.

(d) Do not submit an offer unless--

(1) A certification is provided in paragraph (b)(1) of this provision and submitted with the offer; or

(2) In accordance with paragraph (b)(2) of this provision, the Offeror provides with its offer information that the President of the United States has--

(i) Waived application under U.S.C. 2593e(d) or (e); or

(ii) Determined under 22 U.S.C. 2593e(g)(2) that the entity has ceased all activities for which measures were imposed under 22 U.S.C.2593e(b).

(e) Remedies. The certification in paragraph (b)(1) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly submitted a false certification, in addition to other remedies available to the Government, such as suspension or debarment, the Contracting Officer may terminate any contract resulting from the false certification.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed price contract resulting from this solicitation.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

See Attached See Attached

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Economic Area 113, New Orleans, LA.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be twenty percent (20%) of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

U.S. Army Corps of Engineers, New Orleans District Attn: Melissa K. Koehn CEMVN-CT-W, Room 172 7400 Leake Avenue New Orleans, LA 70118-3651

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Kenneth Crumholt, New Orleans Area Office

Email: kenneth.w.crumholt@usace.army.mil Address: 7400 Leake Ave, New Orleans, LA 70118

Telephone: 504-862-2489

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov http://farsitehill.af.mil

Section 00600 - Representations & Certifications

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-12 CERTIFICATION REGARDING TAX MATTERS (FEB 2016)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5,000,000 (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of 1986; and

(3) Has not [ ], more than 90 days prior to certification, been notified of any unpaid Federal tax assessment for which the liability remains unsatisfied, unless the assessment is the subject of an installment agreement or offer in compromise that has been approved by the Internal Revenue Service and is not in default, or the assessment is the subject of a non-frivolous administrative or judicial proceeding.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2019)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award…