A21-W912P819B0020.pdf

Ed 18-068

IFB W912P8-19-B-0020

US Army Corps of Engineers New Orleans District

Mississippi River and Tributaries (MR&T), West Jefferson Levee District

Avondale Seepage Control Project, B/L Sta. 391+00 To B/L Sta. 409+50

Jefferson Parish, Louisiana

Construction Solicitation and Specifications

August 21 2019

REPLY TO

ATTENTION OF:

Contracting Division Project West Branch

DEPARTMENT OF THE ARMY

NEW ORLEANS DISTRICT, CORPS OF ENGINEERS

7400 LEAKE AVENUE

NEW ORLEANS, LOUISIANA 70118-3651

ATTENTION BIDDERS

In preparing your bid ----

1. Have you signed the bid? Are all blank spaces filled in?

2. If signing on behalf of your company and not an offer thereof, have you attached evidence of your authority to sign the bid?

3. Have you acknowledged receipt of all amendments?

4. Have you checked your bid for possible errors? Arithmetically?

5. Have you furnished all information required by the invitation for bids or the specifications?

6. Are you submitting your bid on time? If mailed, will it reach the place of bid opening at the designated hour?

7. If required by the invitation, have you submitted a bid bond? Is it signed? It is in the proper amount?

8. Have you identified on the face of the envelope containing your bid, the invitation number to which it pertains, and the date and hour of opening?

9. Note to bidders: Visitors will have their identifications scanned at the security gate when arriving at the installation where the bid opening will take place. The district has a policy where any visitors with a license which has been flagged by a Government entity, such as Department of Motor Vehicles, U.S. Department of Homeland Security, or the U.S. Army Corps of Engineers will not be allowed on the reservation. To avoid possible delays, ensure your representative has no outstanding flags attached to their identification.

LMN FL 1078-1

AUGUST 90 (previous editions are obsolete) Proponent: CEMVN-CT-W

SOLICITATION NUMBER: W912P8-19-B-0060

INQUIRIES REGARDING THIS SOLICITATION SHOULD BE MADE TO

THE FOLLOWING:

EDITH M BRANDON

EMAIL: EDITH.M.BRANDON@USACE.ARMY.MIL

TELEPHONE: (504) 862-1047

COLLECT CALLS NOT ACCEPTED

NOTE: FOR THE MOST PROMPT RESPONSE, SEND ALL QUESTIONS

VIA EMAIL, BY WEDNESDAY, 28 AUGUST 2019 BY 10:00 A.M. CST

ALL QUESTIONS MUST CONTAIN THE SOLICITATION NUMBER IN

THE SUBJECT LINE.

mailto:EDITH.M.BRANDON@USACE.ARMY.MIL

DEPARTMENT OF THE ARMY

CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

7400 LEAKE AVENUE

NEW ORLEANS, LA 70118-3651

Ed 18-068

SOLICITATION: W912P8-19-B-0020 August 21 2019

100% SERVICE-DISABLED, VETERAN-OWNED SMALL BUSINESSES only.

FOR: Mississippi River and Tributaries (MR&T), West Jefferson Levee District, Avondale Seepage Control Project, B/L Sta. 391+00 to B/L Sta. 409+50, Jefferson Parish, LA

TO OPEN: Monday, 23 September 2019 at 2:00 PM CST - All questions must be received via email, by Wednesday, 28 August 2019 by 10 AM CST. All questions must contain the solicitation number in the subject line.

I. NOTE THE AFFIRMATIVE ACTION PROGRAM REQUIREMENT OF THE EQUAL OPPORTUNITY

CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING FROM THIS SOLICITATION.

II. NOTE THE CERTIFICATION OF NONSEGREGATED FACILITIES IN THIS SOLICITATION.

Bidders, offerors and applicants are cautioned to note the "Certification of Non-segregated Facilities" in the solicitation. Failure of a bidder or offeror to agree to the certification will render his bid or offer non-responsive to the terms of solicitations involving awards of contracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause.

III. Prospective contractors must register in the System for Award Management (SAM). See FAR Clause 52.204-7 for required information. The website for SAM is https://www.sam.gov. You will be required to provide your company’s Dun and Bradstreet (D&B) D-U-N-S number. If you do not already have a D&B D-U-N-S number, one can be requested at http://fedgov.dnb.com/webform.

BIDDERS MUST PROVIDE FULL, ACCURATE AND COMPLETE INFORMATION AS REQUIRED BY THIS

SOLICITATION AND ITS ATTACHMENTS. THE PENALTY FOR MAKING FALSE STATEMENTS IN BIDS

IS PRESCRIBED IN 18 U.S.C. 1001. (FAR 52.214-4 APR 1984)

DESCRIPTION AND MAGNITUDE OF WORK: The work consists of saw cutting; demolition of asphalt pavement; driving steel sheet piling, excavation; placing compacted fill; asphalt pavement; geotextile; fertilizing, seeding and mulching.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time and for visitor background checks by MVN security when entering the installation at place of bid opening. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH

THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS

MANUAL", DATED NOVEMBER 2014.

ATTENTION: Contractors must complete, and submit with their bid, the provisions located in Section 00600. A bidder may also submit, in lieu of the completed Section 00600, a complete hard copy of their Online Representations and Certifications Applications (ORCA) registration with an expiration date on or after the date of award.

https://www.sam.gov/ http://fedgov.dnb.com/webform

Mississippi River and Tributaries (MR&T), West Jefferson Levee District, Avondale Seepage Control Project, B/L Sta. 387+50 to B/L Sta. 409+50, Jefferson Parish, LA

(ED 18-068)

This procurement is for 100% SERVICE-DISABLED, VETERAN-OWNED SMALL BUSINESSES only.

The work consists of saw cutting; demolition of asphalt pavement; driving steel sheet piling, excavation; placing compacted fill; asphalt pavement; geotextile; fertilizing, seeding and mulching.

The estimated dollar value for this project is between 5,000,000 - $10,000,000.

W912P8-19-B-0020 August 21 2019 1

. ED 18-068

U.S. ARMY CORPS OF ENGINEER

NEW ORLEANS DISTRICT

7400 LEAKE AVENUE

NEW ORLEANS, LA 70118-3651

U S ARMY CORPS OF ENGINEERS, NEW ORLEANS

ATTN: CEMVN-CT-W (E. Brandon)

7400 LEAKE AVENUE

NEW ORLEANS, LOUISIANA 70118-3651

Edith M. Brandon (504) 862-1047

10 270

0 2:00 PM

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

1. SOLICITATION NO. 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY 8. ADDRESS OFFER TO

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12B. CALENDAR DAYS 12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

13. ADDITIONAL SOLICITATION REQUIREMENTS:

(If "YES," indicate within how may calendar days after award in Item 12B.)

A. Sealed offers in original and (hour) local time 09/23/19 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

2. TYPE OF SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

CODE

9. FOR INFORMATION

CALL:

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

11. The Contractor shall begin performance within

SEALED BID (IFB)

NEGOTIATED (RFP)

award, notice to proceed. This performance period is mandatory, negotiable. (See FAR 52.211-10

YES NO

is, is not required.

NSN 7540-01-155-3212

STANDARD FORM 1442 (REV. APR 1985)

Prescribed by GSA APD PE v1.00 FAR (48 CFR) 53.236-1 (d) calendar days and complete it within calendar days after receiving copies to perform the work required are due at the place specified in Item 8 by calendar days for Government acceptance after the date offers are due will not be considered and

CAGE CODE NO. DUNS NO.

U.S. Army Corps of Engineers New Orleans Area Office 7400 Leake Avenue, Rm 186 New Orleans, LA 70118

USAED NEW ORLEANS

C/O USACE, FINANCE CENTER (UFC)

ATTN: CEFC-AO-P

5720 INTEGRITY DRIVE

MILLINGTON, TN 38054-5005

21. ITEMS ACCEPTED:

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

FACILITY CODE CODE

20B. SIGNATURE 20C. OFFER DATE

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE

BY

29. AWARD (Contractor is not required to sign this document.) Your offer28. NEGOTIATED AGREEMENT Contractor is required to sign this

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

document and return Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

OFFER (Must be fully completed by offeror) on this solicitation is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

AWARD (To be completed by Government)

TO SIGN (Type or print)

DATE

(Type or print)

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within (Insert any number equal to or greater than the minimum require-ment stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

22. AMOUNT

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 Copies unless otherwise specified)

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

CODE

31B. UNITED STATES OF AMERICA 31C. AWARD

10 U.S.C 2304(c) ( ) 41 U.S.C 253(c) ( )

STANDARD FORM 1442 BACK (REV. APR 1985)

APD PE v1.00

DATE

calendar days after the date offers are due.

copies to issuing office.)

PTC-i Ed 18-068

PROJECT TABLE OF CONTENTS

Division 00 – PROCUREMENT AND CONTRACTING

Solicitation, Offer and Award SF-1442 00010 Bidding Schedule 00100 Instructions, To Bidders 00600 Representations and Certifications 00700 Contract Clauses

Division 01 - GENERAL REQUIREMENTS

01100 General Provisions 01 32 17.00 20 Network Analysis Schedules (NAS) 01 33 00 Submittal Procedures 01 42 00 Sources for Reference Publications 01 45 00.15 10 Resident Management System Contractor Mode (RMS CM) 01 45 04.00 10 Contractor Quality Control 01 55 26.00 12 Traffic Control And Coordination 01 57 20.00 12 Environmental Protection 01 57 23.00 12 Storm Water Pollution Prevention Plan 01 78 02.00 10 Closeout Submittals

DIVISION 02 – SITE WORK

02 41 00 Demolition

Division 31 – EARTHWORK

31 05 19.04 12 Separator Geotextile 31 23 00.00 12 Excavation 31 24 00.00 12 Embankment 31 41 16.00 12 Steel Sheet Piling

Division 32 – EXTERIOR IMPROVEMENTS

32 12 16.00 12 Asphaltic Pavement 32 92 19.01 12 Fertilizing, Seeding, and Mulching

00010-3 Ed 18-068

SECTION 00010 – BIDDING SCHEDULE

Mississippi River and Tributaries (MR&T), West Jefferson Levee District, Avondale Seepage Control Project, B/L Sta. 391+00 to B/L Sta. 409+50, Jefferson Parish, LA

Item DESCRIPTION Estimated Quantity Unit Unit Price Estimated Amount

0001 Mobilization and Demobilization 1 JOB

0002 Abandoned Utility Removal 1 JOB

0003 Traffic Control and Coordination 1 JOB

0004 Demolition of Asphalt Pavement

0004AA First 1,040 SY 1,040 SY

0004AB All Over 1,040 SY 260 SY

0005 Separator Geotextile 1,300 SY

0006 Embankment, Compacted Fill

0006AA First 272 CY 272 CY

0006AB All Over 272 CY 68 CY

0007 Piling, Steel Sheet, Type PZ-27 73,200 SF

0008 Asphaltic Pavement 560 TON

0009 Class II Stone Base Course

0009AA First 632 TON 632 TON

0009AB All Over 632 TON 158 TON

TOTAL: $

Award will be made as a whole to one bidder.

NOTE 1: Bidders shall furnish unit prices for each item listed in the Schedule requiring a unit price. If the bidder fails to insert a unit price in the appropriate blank for required item(s), but does furnish an extended total, or an estimated amount for such item(s), the Government shall deem the unit price to be the quotient obtained by dividing the extended amount for that line item by the quantity. IF A BIDDER OMITS BOTH THE UNIT PRICE AND THE EXTENDED

TOTAL OR ESTIMATED AMOUNT FOR ANY ITEM, ITS BID SHALL BE

DECLARED NON-RESPONSIVE AND THEREFORE INELIGIBLE FOR

AWARD.

00010-4 Ed 18-068

NOTE 2: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items or sub line items are materially unbalanced (See FAR 14.404-2, Rejection of Individual Bids).

NOTE 3: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442. The NTP will be issued immediately after verification of acceptable performance and payment bonds. Within seven (7) days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Plan, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

NOTE 4: RAPID VENDOR PAYMENT: Web based instructions for the submission of invoices;

http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPaym ent.aspx http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.aspx http://www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.aspx

00010-5 Ed 18-068

EVALUATION OF SUBDIVIDED ITEMS.

Item Nos. 0004, 0006 and 0009 is subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its sub-items.

(End of Clause)

VARIATIONS IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS.

The Variations in Estimated Quantities Subdivided Items clause is applicable only in Item Nos. 0004, 0006 and 0009.

a. Variations from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

b. Where the actual quantity of work performed for Item Nos. 0004, 0006 and 0009 is less than 85% of the quantity of the first sub-item listed under such items, the Contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment in contract price shall be made in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity .

c. If the quantity of work performed under Item Nos. 0004, 0006 and 0009 exceeds 115% or is less than 85% of the total estimated quantity of the sub-items under that item, and/or if the quantity of work performed under the second sub-item or any subsequent sub-item under Item No. NONE exceeds 115% or is less than 85% of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract, the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity.

(End of Clause)

BID BOND

(See instructions on reverse)

OMB Control Number: 9000-0045 Expiration Date: 8/31/2019

PRINCIPAL (Legal name and business address) TYPE OF ORGANIZATION ("X" one)

STATE OF INCORPORATION

SURETY(IES) (Name and business address)

PERCENT

OF BID

PRICE

PENAL SUM OF BOND

AMOUNT NOT TO EXCEED

MILLION(S) THOUSAND(S) HUNDRED(S) CENTS

BID IDENTIFICATION

BID DATE INVITATION NUMBER

PRINCIPAL

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1. 2.

2.

3.

3.

(Seal) (Seal) (Seal) Corporate Seal

INDIVIDUAL SURETY(IES)

SIGNATURE(S)

NAME(S)

(Typed)

1.

1.

2.

2.

(Seal) (Seal)

CORPORATE SURETY(IES)

SU

R

ET

Y

A

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is NOT usable

STANDARD FORM 24 (REV. 8/2016)

Prescribed by GSA - FAR (48 CFR) 53.228(a)

FOR (Construction, Supplies or Services)

OBLIGATION:

We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) in the above penal sum. For payment of the penal sum, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally. However, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum "jointly and severally" as well as "severally" only for the purpose of allowing a joint action or actions against any or all of us. For all other purposes, each Surety binds itself, jointly and severally with the Principal, for the payment of the sum shown opposite the name of the Surety. If no limit of liability is indicated, the limit of liability is the full amount of the penal sum.

CONDITIONS:

The Principal has submitted the bid identified above.

THEREFORE:

The above obligation is void if the Principal - (a) upon acceptance by the Government of the bid identified above, within the period specified therein for acceptance (sixty (60) days if no period is specified), executes the further contractual documents and gives the bond(s) required by the terms of the bid as accepted within the time specified (ten (10) days if no period is specified) after receipt of the forms by the principal; or (b) in the event of failure to execute such further contractual documents and give such bonds, pays the Government for any cost of procuring the work which exceeds the amount of the bid.

Each Surety executing this instrument agrees that its obligation is not impaired by any extension(s) of the time for acceptance of the bid that the Principal may grant to the Government.

Notice to the surety(ies) of extension(s) is waived. However, waiver of the notice applies only to extensions aggregating not more than sixty (60) calendar days in addition to the period originally allowed for acceptance of the bid.

WITNESS:

The Principal and Surety(ies) executed this bid bond and affixed their seals on the above date.

DATE BOND EXECUTED (Must not be later than bid opening date)

Paperwork Reduction Act Statement - This information collection meets the requirements of 44 USC § 3507, as amended by section 2 of the Paperwork Reduction Act of 1995. You do not need to answer these questions unless we display a valid Office of Management and Budget (OMB) control number. The OMB control number for this collection is 9000-0045. We estimate that it will take 1 hour to read the instructions, gather the facts, and answer the questions. Send only comments relating to our time estimate, including suggestions for reducing this burden, or any other aspects of this collection of information to: General Services Administration, Regulatory Secretariat Division (M1V1CB), 1800 F Street, NW, Washington, DC 20405.

JOINT VENTURE

OTHER (Specify)

PARTNERSHIPINDIVIDUAL

CORPORATION

INSTRUCTIONS

1. This form is authorized for use when a bid guaranty is required. Any deviation from this form will require the written approval of the Administrator of General Services.

2. Insert the full legal name and business address of the Principal in the space designated "Principal" on the face of the form. An authorized person shall sign the bond. Any person signing in a representative capacity (e.g., an attorney-in-fact) must furnish evidence of authority if that representative is not a member of the firm, partnership, or joint venture, or an officer of the corporation involved.

3. The bond may express penal sum as a percentage of the bid price. In these cases, the bond may state a maximum dollar limitation (e.g., 20% of the bid price but the amount not to exceed dollars).

4. (a) Corporations executing the bond as sureties must appear on the Department of the Treasury's list of approved sureties and must act within the limitations listed therein. The value put into the LIABILITY LIMIT block is the penal sum (i.e., the face value) of the bond, unless a co-surety arrangement is proposed.

(b) When multiple corporate sureties are involved, their names and addresses shall appear in the spaces (Surety A, Surety B, etc.) headed "CORPORATE SURETY(IES)." In the space designated "SURETY(IES)" on the face of the form, insert only the letter identifier corresponding to each of the sureties. Moreover, when co-surety arrangements exist, the parties may allocate their respective limitations of liability under the bond, provided that the sum total of their liability equals 100% of the bond penal sum.

(c) When individual sureties are involved, a completed Affidavit of Individual Surety (Standard Form 28) for each individual surety, shall accompany the bond.

The Government may require the surety to furnish additional substantiating information concerning its financial capability.

5. Corporations executing the bond shall affix their corporate seals. Individuals shall execute the bond opposite the word "Corporate Seal"; and shall affix an adhesive seal if executed in Maine, New Hampshire, or any other jurisdiction requiring adhesive seals.

6. Type the name and title of each person signing this bond in the space provided.

7. In its application to negotiated contracts, the terms "bid" and "bidder" shall include "proposal" and "offeror."

SU

R

ET

Y

B

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

Corporate Seal

LIABILITY LIMIT ($)STATE OF INCORPORATION

2.

2.

1.

1.NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

C

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

D

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

E

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

F

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

SU

R

ET

Y

G

STANDARD FORM 24 (REV. 8/2016) BACK

W912P8-19-B-0020 ED 18-068

Section 00100 - Instructions to Bidders

CLAUSES INCORPORATED BY

REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of

Bids

NOV 1999

52.214-12 Preparation Of Bids APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.232-13 Notice Of Progress Payments APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite- quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

00100-1

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.214-5000 Apparent clerical mistakes.

ARITHMETIC DISCREPANCIES

(a) For the purpose of initial evaluations of bids, the following will be utilized in the resolving arithmetic discrepancies found on the face of bidding schedule as submitted by the bidder:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price will govern;

00100-2

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

(b) For the purpose of bid evaluation, the government will proceed on the assumption that the bidder intends his bid to be evaluated on basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

(c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

(End of statement)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm-fixed contract resulting from this solicitation.

(End of provision)

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK

(MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of provision)

00100-3

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

SEE ATTACHED SEE ATTACHED

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.

The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Jefferson Parish, LA.

(End of provision)

00100-4

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY

2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph

(c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations. (End of provision)

00100-5

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS

UNDER TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations. (End of provision)

00100-6

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Mr. Chris Nuccio, Contracting Officer US Army Corps of Engineers, New Orleans District 7400 Leake Avenue New Orleans, Louisiana 70118-3651

ATTN: CEMVN-CT-W

(504) 862-2704

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation.

Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Mr. Robert Guillot, Resident Engineer Telephone: (504) 862-1205; (504) 628-5092 Email: robert.p.guillot@usace.army.mil

(End of provision)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hil.af.mil or http://www.acquisition.gov/

(End of provision)

W912P8-19-B-0020 ED 18-068 00100-7

mailto:robert.p.guillot@usace.army.mil http://farsite.hil.af.mil/ http://www.acquisition.gov/

Section 00600 - Reps and Certs

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.222-38 Compliance With Veterans' Employment Reporting Requirements

FEB 2016

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm- fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

00600-1

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision

00600-2 applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-- Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the

Contracting Officer: [Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

00600-3

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date].