W912P8-17-B-0003.pdf

OM-17-275

IFB NO. W912P8-17-B-0003

US Army Corps of Engineers

New Orleans District

Passes of the Mississippi River

Southwest Pass Maintenance Dredging, Mile 6.0 AHP to Mile

19.5 BHP (Non-Continuous), Cutterhead Dredge Rental No.

1-2017 (OM-17-275)

Plaquemines Parish, Louisiana

Construction Solicitation and Specifications

November 16, 2016

DEPARTMENT OF THE ARMY

CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

P.O. BOX 60267

NEW ORLEANS, LOUISIANA 70160-0267

OM-17-275

REPLY TO

ATTENTION OF

16 NOVEMBER 2016

SOLICITATION:W912P8-17-B-0003

UNRESTRICTED

FOR: Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging, Non-Continous Mile 6.0 AHP to Mile 19.5 BHP, Cutterhead Dredge Rental No. 1-2017, Plaquemines Parish, LA (OM-17-275)

TO OPEN: TIME AND PLACE OF BID OPENING WILL BE ESTABLISHED IN AN AMENDMENT

I. NOTE THE AFFIRMATIVE ACTION PROGRAM REQUIREMENT OF THE EQUAL OPPORTUNITY

CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING FROM THIS SOLICITATION.

II. NOTE THE CERTIFICATION OF NONSEGREGATED FACILITIES IN THIS SOLICITATION.

Bidders, offerors and applicants are cautioned to note the "Certification of Non-segregated Facilities" in the solicitation. Failure of a bidder or offeror to agree to the certification will render his bid or offer non-responsive to the terms of solicitations involving awards of contracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause.

III. Prospective contractors must register in the System for Award Management (SAM). See FAR Clause 52.204-7 for required information. The website for SAM is https://www.sam.gov. You will be required to provide your company’s Dun and Bradstreet number. If you do not already have a D&B number, one can be obtained simply by calling Dun and Bradstreet at (800) 333-0505. Contractors must complete, and submit with their bid, the provisions located in section 00600. A bidder may also submit, in lieu of the completed section 00600, a complete hard copy of their Online Representations and Certifications which is located within the System for Award Management (SAM). Any expired or inactive Representations and Certification at time of award will be deemed unresponsive.

IV. SUBCONTRACTING PLAN WILL BE DUE WITHIN TWO HOURS (2) OF VERBAL NOTIFICATION

BIDDERS MUST PROVIDE FULL, ACCURATE AND COMPLETE INFORMATION AS REQUIRED BY THIS

SOLICITATION AND ITS ATTACHMENTS. THE PENALTY FOR MAKING FALSE STATEMENTS IN BIDS

IS PRESCRIBED IN 18 U.S.C. 1001. (FAR 52.214-4 APR 1984)

DESCRIPTION AND MAGNITUDE OF WORK: The work consists of furnishing one fully crewed and equipped cutterhead dredge, with a dredge discharge size of 30 inches diameter (ID) complete in all respects, including all attendant plant and crew. Work will be performed at the Mississippi River SWP Area and possibly in other areas of the New Orleans District.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH

THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS

MANUAL", DATED NOVEMBER 2014.

ALL INQUIRIES REGARDING THIS SOLICITATION

SHOULD BE MADE TO THE FOLLOWING:

MELISSA A. VAUGHN

AND/ OR RACHEL A.

WOODS

CONTRACT SPECIALISTS

U.S. ARMY CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

E‐MAILS: MELISSA.A.VAUGHN@USACE. ARMY.MIL

PHONE: (504) 862‐2762

AND/OR

RACHEL.A.WOODS@USACE.ARMY.M

IL PHONE: (504) 862‐1561

COLLECT CALLS NOT ACCEPTED

NOTE: FOR THE MOST PROMPT REPSONSE, PLEASE SEND ALL QUESTIONS VIA

E‐MAIL.

Mississippi River SWP Cutterhead Dredge Rental No. 1-2017 OM17275

PROJECT TABLE OF CONTENTS Page 1

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00010 BID SCHEDULE

00100 INSTRUCTION TO BIDDERS

00600 REPRESENTATIONS & CERTIFICATIONS

00700 CONTRACT CLAUSES

00800 SUPPLEMENTARY CONDITIONS

DIVISION 01 - GENERAL REQUIREMENTS

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.10 10 QUALITY CONTROL SYSTEM (QCS)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 01 50.73 SURVEYS

35 20 23.23 HYDRAULIC DREDGING

35 20 23.23 12 HYDRAULIC DREDGING – SOUTHWEST PASS

-- End of Project Table of Contents --

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) W912P8-17-B-0003 IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

(504)862-2762

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

11. The contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

U.S. Army Engineer District, New Orleans 7400 Leake Ave.

New Orleans, LA 70118-3651

Mississippi River, Baton Rouge to Gulf of Mexico, Southwest Pass Maintenance Dredging Non-continuous Mile 6.0 AHP to Mile 19.5 BHP Cutterhead Dredge Rental Contract No. 1-2017, Plaquemines Parish, LA

(OM-17-275)

This is an UNRESTRICTED procurement.

The work consists of furnishing one fully crewed and equipped cuuterhead dredge, with a dredge discharge size of 30 inches inside diameter (ID) complete in all respects, including all attendant plant, and crew. Work will be performed at the Mississippi River SWP Area and possibly in other areas of the New Orleans District.

** TO BE ESTABLISHED BY AMENDMENT

* See Paragraph 00010-1.5

U.S. Army Engineer District, New Orleans Attn: CEMVN-CT-E 7400 Leake Ave., Room 184 New Orleans, LA 70118

Melissa A. Vaughn

OM-17-275

1 211/16/2016

1 (one)

00800-3.2

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 4-85) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

20b. SIGNATURE 20c. OFFER DATE

USACE, New Orleans Area Office 7400 Leake Avenue, Room 186 New Orleans, LA 70118-3651

USAED NEW ORLEANS

C/O USACE, FINANCE CENTER (UFC)

ATTN: CEFC-AO-P

Mississippi River Southwest Pass CDR 1-2017 OM17275

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00010

BID SCHEDULE

PART 1 GENERAL

1.1 BIDDING SCHEDULE

1.1.1 Bid Form Notes

1.2 BIDDING

1.3 EVALUATION OF BIDS

1.4 CONDITIONS OF CONTRACT AWARD

1.5 BIDDER QUALIFICATIONS

1.6 PRE-AWARD INSPECTION OF PLANT

1.7 OPTION ITEMS

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section Table of Contents --

SECTION 00010 Page 1

SECTION 00010

BID SCHEDULE

PART 1 GENERAL

1.1 BIDDING SCHEDULE

SECTION 00010 - BIDDING SCHEDULE

MISSISSIPPI RIVER, BATON ROUGE TO GULF OF MEXICO,

SOUTHWEST PASS MAINTENANCE DREDGING NON-CONTINUOUS

MILE 6.0 AHP TO MILE 19.5 BHP

CUTTERHEAD DREDGE RENTAL NO. 1-2017

PLAQUEMINES PARISH, LOUISIANA

SOLICITATION NO. W912P8-17-B-0003

30 IN. INSIDE DIAMETER (ID) PUMP DISCHARGE WITH SUBMERGED PUMP

Bid Item DESCRIPTION Estimated Quantity

Unit Unit Price

Total Price

0001 MOBILIZATION AND

DEMOBILIZATION

1 JOB

0002 DREDGING: Rental of one fully operated cutterhead dredge with 30-inch ID pump discharge with a submerged pump, attendant plant and discharge pipeline as specified.

840 HOUR

Option

OPTION DREDGING - Same plant as listed in Item No. 0002 of this bid lot.

840 HOUR XXXXXXXX

Option

DREDGE TOWING SERVICE 25 MILE

Option

BIRD NESTING PREVENTION

AND AVOIDANCE MEASURES

84 DAY

TOTAL:

*SEE BID FORM NOTES

SECTION 00010 Page 2

1.1.1 Bid Form Notes

a. Bidders shall bid on all items including optional items (see "Evaluation of Options" FAR 52.217-5). Failure to bid on all items will result in a non-responsive bid.

b. Bidders shall use the Item No. 0002 unit price to compute Item No.

0003 total price.

c. Any bid may be rejected if the Contracting Officer or his/her authorized representative determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only the total price of the bid, but the prices for individual line items as well. Any bid may be rejected if the prices for any line items or subline items are materially unbalanced (see "Proposal Analysis Techniques" FAR 15.404-1(g)(3)).

d. THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442 after Notice of Award. The NTP will be issued after verification of acceptable performance and payment bonds. Within two (2) days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Quality Control System is set-up, the Accident Prevention Program and other required submittals have been submitted and approved, and all preliminary meetings called for under the contract have been conducted.

e. RAPID VENDOR PAYMENT: See the following web based instructions for the submission of invoices:

www.mvn.usace.army.mil/BusinessWithUs/Contracting/RapidVendorPayment.

f. As per FAR 9.104-2, special standards of responsibility have been established for this acquisition. A pre-award survey will be required.

Before award, the apparent low bidder shall provide documentation to satisfy the following definitive responsibility criteria. An apparent low bidder who is not able to meet the following definitive responsibility criteria will be deemed to lack responsibility and will be ineligible for award:

1. Bidders shall furnish in their bid package a completed "Cutterhead Dredge and Attendant Plant Data Sheet" (see Section 35 20 23.23 - Hydraulic Dredging). If the apparent low bidder fails to furnish the intended dredge's "Cutterhead Dredge and Attendant Plant Data Sheet" within his/her bid package, the apparent low bidder will have 24 hours after the time of the bid opening to provide the Contracting Officer a copy. If the apparent low bidder fails to furnish the intended dredge's "Cutterhead Dredge and Attendant Plant Data Sheet" to the Contracting Officer within the allotted time, the respective bid will be declared non-responsive and the next apparent low bidder will be evaluated as stated in the paragraphs below.

2. Upon receipt of the apparent low bidder's completed "Cutterhead Dredge and Attendant Plant Data Sheet" for the dredge plant that is intended to perform work under this solicitation, the "Cutterhead Dredge and Attendant Plant Data Sheet" will be evaluated to ensure that the dredge meets the equipment

SECTION 00010 Page 3 requirements as stated in Section 35 20 23.23, paragraph entitled "Size and Equipment of Dredge Plant".

a) If, after review, the Government determines that the dredge on the "Cutterhead Dredge and Attendant Plant Data Sheet" does satisfy the equipment requirements as stated in Section 35 20 23.23, paragraph entitled "Size and Equipment of Dredge Plant", the Government will proceed with award of the contract to the apparent low bidder, provided all other requirements for award have been satisfied.

b) If, after review, the Government determines that the dredge on the "Cutterhead Dredge and Attendant Plant Data Sheet" does not satisfy the equipment requirements as stated in Section 35 20 23.23, paragraph entitled "Size and Equipment of Dredge Plant", the Government will declare the apparent low bidder to be non-responsible and the bid non-responsive. The Government will thereafter perform the described pre-award survey on the next apparent low bidder, and will do so with each successive apparent low bidder until it is determined that the otherwise responsive, apparent low bidder, has submitted a "Cutterhead Dredge and Attendant Plant Data Sheet" that does satisfy the equipment requirements as stated in Section 35 20 23.23, paragraph entitled "Size and Equipment of Dredge Plant".

g. The unit "job" is a one-time payment for work performed. "Job" is synonymous with the previously used term "lump sum".

1.2 BIDDING

Bidders shall furnish unit prices for all items listed on the schedule of bid items that require unit prices. If the bidder fails to insert a unit price in the appropriate blank for required items but does furnish an extended total or an estimated amount for such items, the Government will deem the unit price to be the quotient obtained by dividing the extended estimated amount for that line item by the quantity. IF THE

BIDDER OMITS BOTH THE UNIT PRICE AND THE EXTENDED ESTIMATED AMOUNT FOR

ANY REQUIRED ITEM, THE BID WILL BE DECLARED NON-RESPONSIVE.

1.3 EVALUATION OF BIDS

a. The hourly dredging quantities have been determined based on the estimated quantity of shoal material to be removed and the nominal production rates of the dredge. The production rates shown in the chart in paragraph entitled "Minimum Production Rate Requirements" located in the Dredging Region Section(s) were used to make this determination.

b. The nominal dredge production rates listed in this solicitation were conservatively estimated based on lower-bound material face availability of this solicitation's dredging regions, which have variable and dynamic shoaling conditions. It is the bidder's responsibility to make its own assessment of the actual dredging conditions in order to prepare a bid for this work.

c. Award will be made to that responsible bidder presenting the lowest priced responsive bid in response to this solicitation.

d. The hourly quantities shown on the bid lot (Bid Items, "Dredging" and "Option Dredging") are 100% pay time hours. The actual term of the

SECTION 00010 Page 4 dredge rental may vary as a result of fractional pay time. Refer to Section 35 20 23.23, paragraph entitled "Dredging and Option Dredging Items", for additional information.

1.4 CONDITIONS OF CONTRACT AWARD

a. Award will be made as a whole to one bidder. The dredge and attendant plant offered in the bidding schedule shall be complete with full operating personnel and in operating status for the contract period. EM 385-1-1, Section 19, "Floating Plant and Marine Activities" shall be complied with at all times. NOTE: All work under these specifications shall be performed in accordance with the provisions of EM 385-1-1 "Army Corps of Engineers Safety and Health Requirements Manual", latest edition.

b. The Government may award the contract at the total bid price, comprised of the base items and option item(s); however, the Government is not obligated to exercise any option item(s).

c. The number of hours of rental time stated in the bidding schedule is an estimated quantity. The dredge and attendant plant will be retained for an approximate number of days shown in the table below starting no later than 20 calendar days after receipt of Government Notice to Proceed by the Contractor.

APPROXIMATE CUTTERHEAD DREDGE

CONTRACT DURATION

(BASE PLUS OPTION)

Discharge Line ID

(INCHES)

Submerged Pump

Approximate Number of Rental Days

30 YES 116

d. The bidder shall be capable of providing for assignment of the dredge and all attendant plant, complete and in full operating condition in all respects, no later than 20 calendar days after receipt of Notice to Proceed by the Contractor.

1.5 BIDDER QUALIFICATIONS

a. Before the Government will award a contract based on this solicitation, the apparent low bidder shall establish that it is responsible and entitled to award of the contract, by certifying that its dredge meets the appropriate production rate for the dredging region, as listed in the table in paragraph entitled "Minimum Production Rate Requirements" located in the Dredging Region Section(s). The dredge must have performed at, or above, the listed production rate for at least 85 percent of the total contract duration, on any contracts that are used to prove plant capability, within three years prior to the bid opening date of this solicitation. Failure to establish the dredge's capability to meet the required production rate will result in a finding of non-responsibility.

b. A bidder may be rejected as non-responsible if it cannot show the necessary capital, experience, or equipment needed to perform the work described under this solicitation (see "Responsible Prospective

SECTION 00010 Page 5

Contractors" FAR 9.1). The bidder must also show that the dredge and attendant plant are not already obligated for the performance of other work which would delay commencement, performance, and completion of the solicited work; and must show that delivery of the dredge and attendant plant to the site of work can be made within the time allowed in the specifications.

c. Bidders must register in the System for Award Management (SAM) database in accordance with FAR 52.204-7 and DFARS 252.204-7004 Alt A.

1.6 PRE-AWARD INSPECTION OF PLANT

a. The apparent low bidder shall make the dredge and attendant plant available for inspection, to determine compliance with these specifications, as soon as practicable after bids are opened, and prior to contract award. If deficiencies are found during the inspection, the bidder will be notified in writing, which may be transmitted by email or facsimile. Upon receipt of such notice, the bidder shall correct all deficiencies at least two calendar days in advance of the projected contract award date.

b. Two calendar days before the projected award date, or upon notification by the bidder that the deficiencies have been corrected, a Government representative will re-inspect the dredge and attendant plant. If at that time the dredge and attendant plant do not meet the requirements of these specifications, the bidder will be rejected as non-responsible.

c. The Government may choose to waive the pre-award inspection if the projected contract award date is less than five calendar days after the bid opening date. Waiver of the pre-award inspection does not relieve the bidder from the requirement to provide a dredge and attendant plant in full compliance with the specifications.

1.7 OPTION ITEMS

a. The Government may require the delivery of, in whole or part, any Option Items. The Government may exercise an Option Item by written notice to the Contractor. If the Government activates the Option Item, the activation will occur while the Contractor's equipment is in the work vicinity as described in the applicable Dredging Region Section(s). If "Option Dredging" Item work is exercised, it shall be performed as a continuance of "Dredging" Item work, which shall be activated first.

b. No additional mobilization/demobilization will be paid to the Contractor for Option Item work performed within the work region. The Contractor shall commence performance of optional work no more than 3 calendar days after the time the Contractor receives the Government's Notice to Proceed with the optional work.

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section --

SECTION 00010 Page 6

BID BOND

(See instructions on reverse)

OMB Control Number: 9000-0045 Expiration Date: 7/31/2019

PRINCIPAL (Legal name and business address) TYPE OF ORGANIZATION ("X" one)

STATE OF INCORPORATION

SURETY(IES) (Name and business address)

PERCENT

OF BID

PRICE

PENAL SUM OF BOND

AMOUNT NOT TO EXCEED

MILLION(S) THOUSAND(S) HUNDRED(S) CENTS

BID IDENTIFICATION

BID DATE INVITATION NUMBER

PRINCIPAL

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1. 2.

2.

3.

3.

(Seal) (Seal) (Seal) Corporate Seal

INDIVIDUAL SURETY(IES)

SIGNATURE(S)

NAME(S)

(Typed)

1.

1.

2.

2.

(Seal) (Seal)

CORPORATE SURETY(IES)

S U

R E

T Y

A

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is NOT usable

STANDARD FORM 24 (REV. 8/2016)

Prescribed by GSA - FAR (48 CFR) 53.228(a)

FOR (Construction, Supplies or Services)

OBLIGATION:

We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) in the above penal sum. For payment of the penal sum, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally. However, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum "jointly and severally" as well as "severally" only for the purpose of allowing a joint action or actions against any or all of us. For all other purposes, each Surety binds itself, jointly and severally with the Principal, for the payment of the sum shown opposite the name of the Surety. If no limit of liability is indicated, the limit of liability is the full amount of the penal sum.

CONDITIONS:

The Principal has submitted the bid identified above.

THEREFORE:

The above obligation is void if the Principal - (a) upon acceptance by the Government of the bid identified above, within the period specified therein for acceptance (sixty (60) days if no period is specified), executes the further contractual documents and gives the bond(s) required by the terms of the bid as accepted within the time specified (ten (10) days if no period is specified) after receipt of the forms by the principal; or (b) in the event of failure to execute such further contractual documents and give such bonds, pays the Government for any cost of procuring the work which exceeds the amount of the bid.

Each Surety executing this instrument agrees that its obligation is not impaired by any extension(s) of the time for acceptance of the bid that the Principal may grant to the Government.

Notice to the surety(ies) of extension(s) is waived. However, waiver of the notice applies only to extensions aggregating not more than sixty (60) calendar days in addition to the period originally allowed for acceptance of the bid.

WITNESS:

The Principal and Surety(ies) executed this bid bond and affixed their seals on the above date.

DATE BOND EXECUTED (Must not be later than bid opening date)

Paperwork Reduction Act Statement - This information collection meets the requirements of 44 USC § 3507, as amended by section 2 of the Paperwork Reduction Act of 1995. You do not need to answer these questions unless we display a valid Office of Management and Budget (OMB) control number. The OMB control number for this collection is 9000-0045. We estimate that it will take 25 minutes to read the instructions, gather the facts, and answer the questions. Send only comments relating to our time estimate, including suggestions for reducing this burden, or any other aspects of this collection of information to: General Services Administration, Regulatory Secretariat Division (M1V1CB), 1800 F Street, NW, Washington, DC 20405.

JOINT VENTURE

OTHER (Specify)

PARTNERSHIPINDIVIDUAL

CORPORATION

INSTRUCTIONS

1. This form is authorized for use when a bid guaranty is required. Any deviation from this form will require the written approval of the Administrator of General Services.

2. Insert the full legal name and business address of the Principal in the space designated "Principal" on the face of the form. An authorized person shall sign the bond. Any person signing in a representative capacity (e.g., an attorney-in-fact) must furnish evidence of authority if that representative is not a member of the firm, partnership, or joint venture, or an officer of the corporation involved.

3. The bond may express penal sum as a percentage of the bid price. In these cases, the bond may state a maximum dollar limitation (e.g., 20% of the bid price but the amount not to exceed dollars).

4. (a) Corporations executing the bond as sureties must appear on the Department of the Treasury's list of approved sureties and must act within the limitations listed therein. The value put into the LIABILITY LIMIT block is the penal sum (i.e., the face value) of the bond, unless a co-surety arrangement is proposed.

(b) When multiple corporate sureties are involved, their names and addresses shall appear in the spaces (Surety A, Surety B, etc.) headed "CORPORATE SURETY(IES)." In the space designated "SURETY(IES)" on the face of the form, insert only the letter identifier corresponding to each of the sureties. Moreover, when co-surety arrangements exist, the parties may allocate their respective limitations of liability under the bond, provided that the sum total of their liability equals 100% of the bond penal sum.

(c) When individual sureties are involved, a completed Affidavit of Individual Surety (Standard Form 28) for each individual surety, shall accompany the bond.

The Government may require the surety to furnish additional substantiating information concerning its financial capability.

5. Corporations executing the bond shall affix their corporate seals. Individuals shall execute the bond opposite the word "Corporate Seal"; and shall affix an adhesive seal if executed in Maine, New Hampshire, or any other jurisdiction requiring adhesive seals.

6. Type the name and title of each person signing this bond in the space provided.

7. In its application to negotiated contracts, the terms "bid" and "bidder" shall include "proposal" and "offeror."

S U

R E

T Y

B

NAME &

ADDRESS

STATE OF INCORPORATION LIABILITY LIMIT ($)

SIGNATURE(S)

NAME(S) &

TITLE(S)

(Typed)

1.

1.

2.

2. Corporate Seal

Corporate Seal

LIABILITY LIMIT ($)STATE OF INCORPORATION

2.

2.

1.

1.NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

S U

R E

T Y

C

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

S U

R E

T Y

D

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

S U

R E

T Y

E

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

S U

R E

T Y

F

Corporate Seal

LIABILITY LIMIT ($)

2.

2.

STATE OF INCORPORATION

1.

1.

NAME(S) &

TITLE(S)

(Typed)

SIGNATURE(S)

NAME &

ADDRESS

S U

R E

T Y

G

STANDARD FORM 24 (REV. 8/2016) BACK

Section 00100 - Bidding Schedule/Instructions to Bidders

CLAUSES INCORPORATED BY REFERENCE

52.214-3 Amendments To Invitations For Bids DEC 1989 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-12 Notice of Buy American Requirement - Construction Materials Under Trade Agreements

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984 252.204-7004 Alt A System for Award Management Alternate A FEB 2014

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed-price contract resulting from this solicitation.

(End of provision)

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

SEE ATTACHED SEE ATTACHED

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Plaquemines Parish, Louisiana.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be twenty percent (20%) of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Ione M. Cataldo, Contracting Officer, U.S. Army Corps of Engineers, ATTN: CEMVN-CT-E, 7400 Leake Avenue, New Orleans, LA 70118-3651, facsimile (504) 862-2889.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Mr. Charles Freeman, Area Engineer, New Orleans Area Office Address: P.O. Box 60267, New Orleans, LA 70160-0267 Telephone: 504-862-1554

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/ http://farsite.hill.af.mil/

NOTICE TO CONTRACTOR

This solicitation contains two sets of goals for minority participation in construction crafts on this contract. They are the New Orleans Hometown Plan and the New Orleans Standard Metropolitan Statistical Area (SMSA).

Contractor will determine the goals applicable to him by the following:

Hometown Plan applies only to those contractors who are signatory to the Hometown Plan and utilizing crafts signatory to the plan.

New Orleans Standard Metropolitan Statistical Area (SMSA) applies to all contractors in the New Orleans SMSA area not signatory to the Hometown Plan, or utilizing crafts not signatory to the plan.

Federal Register/Vol. 45, No. 194/Friday, October 3, 1980

SOLICITATION PROVISION NOTICE OF REQUIREMENT FOR

AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY

The Bidder’s attention is called to “EQUAL OPPORTUNITY” and “LOCAL AFFIRMATIVE ACTION PLAN” clauses of the contract.

The acceptable ranges of minority manpower utilization, expressed in percentage terms are as follows:

Goals for Minority Goals for Female Timetables Participation for Participation in Each Trade Each Trade

Indefinitely 20% - 23% 6.9%

The Bidder shall, within 5 days after a request; therefore, by the Contracting Officer of his duly authorized representative, submit the following information.

(a) A list of the construction trades he intends to use, either directly or through subcontractors at any tier, in the performance of work covered by this solicitation;

(b) A list of the labor organizations with which he has collective bargaining agreements and which are signatories to the Hometown Plan with respect to trades for which specific commitments to goals of minority manpower utilization are set forth in the Hometown Plan;

(c) A list of the labor organizations with which he has collective bargaining agreements and which are not signatories to the Hometown Plan or which are signatories thereto but with respect to trades for which no specific commitments to goals of minority manpower utilization are set forth in the Hometown Plan, and

(d) A list of all current construction work or contracts to which he is a party in any capacity in the covered area.

As used in this NOTICE and the contract to result from this solicitation:

(a) “Hometown Plan” or “Plan” means the NEW ORLEANS Plan, consisting of “An Agreement for Implementation of Employment of Minorities in the New Orleans Building Construction Industry.”

(b) “The covered area” means Orleans, Jefferson, St. Bernard, St.

Tammany, St. Charles, St. John, Lafourche, Plaquemines, Washington, Terrebonne, Tangipahoa*, Livingston** and St.

James*** Parishes, Louisiana.

(c) “Director, OFCC” means the Director, Office of Federal Contract Compliance, United States Department of Labor, or any person to whom he delegates authority; and

(d) “Minority” means Negro, Spanish-surnamed American, Oriental, and

American Indian, and includes both men and women.

* Area covered is east of the Illinois Central Railroad.

** Area covered is southeast of the line from a point of the Livingston & Tangipahoa Parish line adjacent from New Orleans and Baton Rouge.

*** Area covered is southeast of a line drawn from the town of Gramercy to the point of intersection of St. James, Lafourche and Assumption Parishes.

NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY (APRIL 1984)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation Goals for Female Participation for Each Trade for Each Trade

SMSA Counties MS 19.2% 6.9% SMSA Counties LA 31.0% 6.9% Non-SMSA Counties 27.7% 6.9%

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in the geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Program office.

(c) The Contractor’s compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled “Affirmative Action Compliance Requirements for Construction,” and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract. Executive Order 11246, as amended and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Director, Office of Federal Contract Compliance Programs, within 10 working days following award of a construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notifications shall list the –

(1) Name, address, and telephone number of the subcontractor;

(i)

Employer identification number of the subcontractor;

(2) Estimated dollar amount of the subcontract;

(3) Estimated starting and completion dates of the subcontract;

and

(4) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is (FAR 52.222-23) Economic Area 113, New Orleans, LA as follows:

Standard Metropolitan Statistical Area

(SMSA) Counties:

0920 Biloxi – Gulfport, MS - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 19.2% MS Hancock; MS Harrison; MS Stone

5560 New Orleans, LA - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 31.0% LA Jefferson; LA Orleans; LA St. Bernard; LA St. Tammany

Non-Standard Metropolitan Statistical Area (Non-SMSA) Counties - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 27.7% LA Assumption; LA Lafourche; LA Plaquemines; LA St. Charles;

LA St. James; LA St. John the Baptist; LA Tangipahoa;

LA Terrebonne; LA Washington; MS Forrest; MS Lamar; MS Marion;

MS Pearl River; MS Perry; MS Pike; MS Walthall

U.S. Army Corps of Engineers, New Orleans District Current Small Business Program Target Percentages

SUBCONTRACTING

Small Business 50%

Small Disadvantaged 17% Business

Women-Owned 18% Business

HUBZone Small 10% Business

Service-Disabled 4% Veteran Business

Veteran Owned 8.5% Business

NOTE: The above figures are subject to change

Section 00600 - Representations & Certifications

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (APR 2016)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $27.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.