AMENDMENT_0003_-_W912P6-17-R-0005_STONE_SUPPLIES.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

SUBJECT: REVISIONS TO VARIOUS SECTIONS OF THE ABOVE NUMBERED SOLICITATION W912P6-17-R-0005, "SUPPLY AND DELIVERY OF ARMOR STONE 3-7 TON AND .25-1 TON (INDIANA HARBOR AND BURNS WATERWAY

HARBOR)

SEE THE FOLLOWING PAGES FOR THE FULL DESCRIPTION OF THE REVISIONS

U.S. ARMY ENGINEER DISTRICT, CHICAGO

231 SOUTH LASALLE STREET SUITE 1500

CHICAGO IL 60604-1437

See Item 6

W81G6670767495

W912P6-17-R-0005

1 3

24-May-2017

11-May-2017

24-MAY-2017

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this Amendment 0003:

A. PROPOSAL DUE DATE: The Proposal Due Date is NOT EXTENDED by this Amendment;

therefore, Contractor’s proposals must be furnished to the USACE by 1:00 pm CDT on May 25, 2017 to be considered timely submitted. Detailed information regarding the submission of proposals is located in SECTION A and L of the Solicitation (RFP) document.

B. AMENDED SOLICITATION SECTIONS:

(1) Section’s A, B, C, F, I & L (and any other area of the RFP): Whereas stated deliveries locations are the CHICAGO HARBOR STONE STORAGE DOCK and the CALUMET HARBOR STONE DOCK , these locations are one in the same; although the nomenclature may differ, the stone dock is located at the very same address, wherein the following address applies and is set forth correctly throughout the Solicitation. Address: 8555 South Green Bay Avenue, Chicago, IL 60617. Therefore, offerors are to price stone deliveries to this address wherein applicable to the relevant line items in Section B of the RFP.

(2) Section F: The following full text Clause is hereby added (NOTE: Crane Operator delays Will not be considered contractor delays.)

52.211-11 Liquidated Damages—Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $34,020.80 per calendar day of delay [this amount represents the USACE’s labor & 2 Floating Plants per day at $32,611.47].

(b) If the Government terminates this contract in whole or in part under the Default—Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default—Fixed-Price Supply and Service clause in this contract.

(End of clause)

(3) Section I (Contract Clauses) : The government hereby deletes the bonding requirement from this Solicitation, therefore, the applicable clauses are deleted in their entirety, specifically as follows:

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-16 PERFORMANCE AND PAYMENT BONDS--OTHER THAN CONSTRUCTION (NOV 2006)

(4) Section I (Contract Clauses): By this Amendment 0003, the government adds the following Clause in full text:

52.232-23 Assignment of Claims (May 2014)

(a) The Contractor, under the Assignment of Claims Act, as amended, 31 U.S.C. 3727, 41 U.S.C. 6305 (hereafter referred to as “the Act”), may assign its rights to be paid amounts due or to become due as a result of the performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency. The assignee under such an assignment may thereafter further assign or reassign its right under the original assignment to any type of financing institution described in the preceding sentence.

(b) Any assignment or reassignment authorized under the Act and this clause shall cover all unpaid amounts payable under this contract, and shall not be made to more than one party, except that an assignment or reassignment may be made to one party as agent or trustee for two or more parties participating in the financing of this contract.

(c) The Contractor shall not furnish or disclose to any assignee under this contract any classified document (including this contract) or information related to work under this contract until the Contracting Officer authorizes such action in writing.

(End of clause)

(5) Section L (Instructions, Conditions and Notices to Bidders) : Based upon the aforementioned paragraph, wherein the bonding requirement has been deleted, the following clause is hereby deleted in its entirety. Therefore, the Contractor is no longer required to submit a bid guarantee with its proposal (Re: RFP & Amendment 0001). The following Clause is the relevant Clause being deleted:

52.228-1 BID GUARANTEE (SEP 1996)

C. The Points of Contact for this Amendment is Regina Blair, Chicago District Contracting Chief at 312-846-5371 and Thomas Russell, Contract Specialist at 312-846-5376

End of Amendment 0003