W912P519B0013_Amend_01_OLD_Hickory_NRS_Substation_Upgrade.pdf

CONTRACTING DIVISION (RK)

110 9TH AVENUE SOUTH, ROOM A680

NASHVILLE TN 37203

W38XDD91698547

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Extend questions due date from 15-Aug-2019 to 21-Aug-2019 the time stays the same.

FAR 52.252-3 is updated.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 9

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 16-Aug-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912P519B0013

X 9B. DATED (SEE ITEM 11)

31-Jul-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

16-Aug-2019

CODE

US ARMY CORPS OF ENGINEERS-CELRN-RC-N

DIRECTORATE OF CONTRACTING

110 9TH AVENUE SOUTH, RM A680

NASHVILLE TN 37203

W912P5 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE W912P5

FACILITY CODECODE

EMAIL:TEL:

W912P519B0013

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 21 00 - INSTRUCTIONS

The following have been modified:

INSTRUCTIONS

INSTRUCTIONS, CONDITIONS & NOTICES TO BIDDERS

1.0 GENERAL INFORMATION

1.1 Intent: The intent of this solicitation is to award one Firm Fixed Priced Construction contract for Installation of IPA, Switchgear and Transformers for the Old Hickory Lock and Nashville Area Office complex in Davidson County, TN.

1.2 Disclosure of Magnitude of Construction Project: The estimated magnitude of this requirement is between $500,000 and $1,000,000.

1.3 Basis of Selection of Award: Award shall be made to the lowest priced bidder who is found to be responsive and responsible. See Federal Acquisition Regulation (FAR) clause 52.214- 19, Contract Award—Sealed Bidding—Construction, for more information.

In accordance with FAR 52.217-5, Evaluation of Options, the Government intends to evaluate bids for award purposes by adding the total price for all options to the total price for the basic requirement.

1.4 Type of Contract: The Government intends to award one firm-fixed price construction contract.

1.5 Who May Submit: The procurement is 100% Small Business Set-Aside.

1.6 North American Industry Classification System (NAICS) Code and Small Business Size Standard: The NAICS code for this project is 238210 Electric Contractors and Other Wiring Installation Contractors, with a size standard of $15,000,000.

1.7 Specifications and Drawings: Specifications and Drawings will be provided as separate files and will be available in FBO. See the complete drawings and specifications package located at www.fbo .gov.

The Specifications and Drawings are part of the contract and shall be considered in that respect (see DFARS 252.236-7001, Contract Drawings and Specifications).

1.8 Pre-Bid Site Visit: An oranized site visit has been scheduled to occur during the solicitation period. Bidders should inspect the job site prior to submitting a bid. Bidders should take such other steps as may be reasonably necessary to ascertain the nature and location of the work and the general and local conditions that can affect the work or the cost thereof.

http://www.fbo.gov/

Failure to do so will not relieve Bidders from the responsibility for properly estimating the difficulty or cost of successfully performing the work. The Government assumes no responsibility for any understanding or representations concerning conditions made by any of its officers, agents or employees, unless included in the solicitation, the specifications or related documents. Please refer to the Federal Acquisition Regulations (FAR) clause 52.236-27 ALT I, Site Visit (Construction), incorporated by full text in this solicitation, for information pertaining to the scheduled site visit.

REGISTRATION: Only registered persons will be permitted to attend the site visit. In addition to the information below, please also provide your firm’s name, firm’s CAGE and/or DUNS number, and name and position title of primary point-of-contact and their telephone number and email address. Please provide this information via email to Ray.Kendrick@usace.army.mil.

Contractors and/or potential contractors wishing to attend a pre-bid meeting held at or in LRN restricted/controlled areas (such as a Power Plant or Navigation Lock) shall submit a Nashville District (LRN) Security Access Form to the Contract Specialist five (5) business days prior to the site visit or meeting. If submitting the document in less than five business days, the Offeror may not receive approval for participation. The Contract Specialist will notify the Contractor if the request is approval or denied. Any pre-bid meeting which will cover anything other than public domain information shall be limited to US Citizens, except under unique circumstances.

U.S. CITIZENS: The Offeror shall submit a Nashville District Corps of Engineers U.S.

Citizen Pre-Bid and/or Site Visit Request Form to the LRN Point of Contact, Contract Specialist Ray Kendrick, no later than five (5) business days prior to the site visit. If submitting the document in less than five business days, the bidded may not receive approval for participation. The LRN POC will notify the individual(s) if the request is approved or denied. The Security Access Form and guidance is available as a pdf attachment on www.fbo.gov with this solicitation and is titled Pre-Bid Meeting and/or Site Visit Request Form.

FOREIGN NATIONALS (FNs): All non-U.S. Citizens, including permanent residents wishing to attend the site visit must be approved in advance. FNs wishing to attend a site visit shall submit a completed Nashville District Corps of Engineers Foreign National Pre-Bid Meeting Request Form and legible color copies of two of the following documents: Passport (unexpired or expired), Certificate of U.S. Citizenship (INS Form N-560 04 N-561), Certificate of Naturalization (INS Form N-550 or N-570), unexpired foreign Passport with I- 551 stamp or attached INS Form I-94 indicating unexpired employment authorization, an Alien Registration Receipt Card with photo (INS Form I-151 or I-551), unexpired Temporary Resident Card (INS Form I-688), unexpired Employment Authorization Card (INS Form I- 688A), unexpired Reentry Permit (INS Form I-327), unexpired Refugee Travel Document (INS Form I-571), or unexpired Employment Authorization Documentation issued by the INS which contains a photograph (INS Form I-688B) to the LRN Point of Contact, Contract Specialist Ray Kendrick. These documents must be submitted two (2) weeks prior to the site visit. FN requests require approval at the Headquarters U.S. Army Corps of Engineers mailto:Ray.Kendrick@usace.army.mil

(HQUSACE) level. Exceptions will be considered on a case by case basis but will be limited.

The form is available as a pdf attachment on www.fbo.gov with this solicitation and is titled Foreign National Pre-Bid Meeting Request Form.

POINT-OF-CONTACT: For questions and /or concerns regarding the site visit, please contact Contract Specialist Ray Kendrick via email at the address referenced above.

This will be the only site visit for this project. If you miss the scheduled site visit, no other arrangements will be made due to personnel and time restrictions.

1.9 POC for Communication/Questions: Any communications regarding this procurement must be made in writing to the Nashville Contracting Branch, Attn: Ray Kendrick at email Ray.Kendrick@usace.army.mil. Inquiries must identify the solicitation number, the requestor’s company name, address, email address, telephone and facsimile numbers to include area code.

Phone calls or requests to arrange meetings at the Nashville District during the solicitation period to discuss project requirements or company’s capabilities are highly discouraged and will not be scheduled.

QUESTIONS: Questions regarding the solicitation must be submitted to Ray Kendrick via email at Ray.Kendrick@usace.army.mil on 21-Aug-2019 no later than 12:00 PM

Central Time.

1.10 Amendments Prior to Date Set for Closing of IFB. The right is reserved as the interest of the Government may require, to revise or amend the specifications or drawings or both prior to the date set for submission of bid. Such revisions and amendments, if any will be announced by an amendment or amendments to this IFB. If the revisions and amendments are of a nature which requires material changes in quantities or prices proposed or both, the date set for receipt of bids may be postponed by such number of days as in the opinion of the issuing officer will enable bidder to revise their bid. In such cases, the amendment will include an announcement of the new date for receipt of bid.

1.11 NOTICE TO BIDDER: Use of Class I Ozone-Depleting Substances

a. In accordance with Section 326 of P.L. 102-484, the Government is prohibited from awarding any contract which includes a specification or standard that requires the use of a Class I ozone-depleting substance (ODS) identified in Section 601(a) of the Clean Air Act, (42 U.S.C 767a(a)), or that can be met only through the use of such a substance unless such use has been approved, on an individual basis, by a senior acquisitions official who determines that there is no suitable substitute available.

b. To comply with this statute, the Government has conducted a best effort mailto:Ray.Kendrick@usace.army.mil screening of the specifications and standards associated with this acquisition to determine whether they contain any ODS requirements. This requirement has no relationship to ODSs.

c. If the bidder possesses any special knowledge about any other ODSs required directly or indirectly at any level of contract performance, the U.S. Army would appreciate if such information were surfaced to the Contracting Officer for appropriate action. To preclude delay to the procurement, the bidder should provide any information as soon as possible after release of this IFB and prior to the submission of bids to the extent practicable. It should be understood that there is no obligation on the bidder to comply with the request and that no compensation can be provided for doing so.

2.0 WHAT, HOW AND WHERE TO SUBMIT BID

2.1 The following documents must be submitted with your IFB in original and one (1) copy:

(1) SF 1442, Solicitation, Offer and Award

a. Should include:

i. Unique Entity Identifier (known as DUNS

ii. CAGE number

iii. Tax Payer ID number

(2) Solicitation amendments acknowledged, if applicable

(3) Bid Schedule

(4) Original Bid Bond with Power of Attorney

(5) Representations and Certifications, unless you are currently registered in SAM.

NOTE: To establish its responsibility the bidder may be requested by the Government to submit a statement regarding previous experience in performing comparable work, business and technical organization, financial resources, and plant available to be used in performing the work. The requested statement submitted will have the following: a minimum of one

(1) up-to-date banking reference for their firm and a minimum of three (3) past performance references for similar work.

a. The banking reference shall include the financial institution’s legal name, complete physical address, a point-of-contact (POC) at the financial institution, the POC’s telephone number, and email address.

b. The past performance references shall include firm’s name, the contract number, the contract period of performance and/or contract completion date, the contract’s aggregate value, a brief description of the project, a POC, the POC’s telephone number, and email address.

2.2 PUBLIC OPENING OF BIDS: Bids will be publicly opened at the time set for opening in

Block 13 of the SF1442 at the Estes Kefauver Federal Building, USACE Conference Room A681, 110 9th Avenue South, Nashville, Tennessee, 37203. The content will be made public for the information of bidders and others interested, who may be present.

Unbalanced bids may be rejected.

2.3 Bidders shall submit sealed IFB packages to the USACE address listed below. Receipt of delivery is highly recommended. The Government will accept sealed IFB packages prior to the due date. It is highly recommended that IFB packages be received at the address listed below at least one (1) day prior to due date to avoid a possible late bid situation.

The Government will accept hand delivered packages until the time of bid closing but will not accept bids submitted via email or fax. The Government must be in receipt of your IFB by the bid closing time set forth in Block 13 of the SF1442.

If being hand delivered:

Arrive at address shown below and call Ray Kendrick at 615-736-7932 or Melissa Scogin at 615-736-7917 to gain access to 6th floor from elevator lobby.

U.S. Army Corps of Engineers Nashville District Contracting Branch, CELRN-RC-N ATTN: Ray Kendrick Solicitation W912P519B0013 110 9th Avenue South, Room A-680, Sixth Floor Nashville, Tennessee 37203

Physical address for mail delivery (USPS or carrier):

U.S. Army Corps of Engineers Nashville District Contracting Branch, CELRN-RC-N ATTN: Ray Kendrick Solicitation W912P519B0013 110 9th Avenue South, Room A405 (Mailroom) Nashville, Tennessee 37203

3.0 INSURANCE/BONDS:

3.1 BID GUARANTEE. In accordance with FAR 52.228-1, Bid Guarantee, the bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond (use Standard Form 24) supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The bid guarantee amount shall be at least 20 percent of the bid price but shall not exceed $3,000,000.00. If using a Bid Bond, it must be submitted on SF 24. The SF 24 can be found at the GSA Forms Library at https://www.gsa.gov/forms.

3.2 INSURANCE. Contractor shall carry Liability and Insurance. See FAR 52.228-5, Insurance – Work on a Government Installation.

3.3 The bidder whose bid is accepted will be required to comply with the following within the time established in the invitation for bid:

a. PERFORMANCE BONDS (SF 25). Pursuant to FAR 52.228-15, Performance and

Payment Bonds—Construction, the penal amount of the performance bond shall equal one hundred percent (100%) of the contract price. Bonds shall be received on a SF 25A within ten (10) calendar days after receipt of contract award. The SF 25A can be found at the GSA Forms Library at https://www.gsa.gov/forms.

b. PAYMENT BONDS (SF 25A). Pursuant to FAR 52.228-15, Performance and

Payment Bonds—Construction, the penal amount of the payment bond shall equal one hundred percent (100%) of the contract price. Bonds shall be received on a SF 25 within ten (10) calendar days after receipt of award. The SF 25 can be found at the GSA Forms Library at https://www.gsa.gov/forms.

4.0 SYSTEM FOR AWARD MANAGEMENT (SAM) AND ANNUAL REPREENTATIONS

AND CERTIFICATIONS

In accordance with FAR 52.204-7, System for Award Management, registration is required in the System for Award Management (SAM) database located at www.sam.gov. More specifically, "An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation." (See FAR 52.204-7(b)(1)).

For SAM Customer Service, contact:

Federal Service Desk URL:

www.fsd.gov Hours: 8am - 8pm (Eastern Time)

US Calls: 866-606-8220 International Calls: 334-206-7828 https://www.gsa.gov/forms https://www.gsa.gov/forms https://www.gsa.gov/forms http://www.fsd.gov/

DSN: 866-606-8220

IMPORTANT NOTICE: Effective June 29, 2018 vendors creating or updating their registration can have their registration activated prior to the approval of the required notarized letter. However, the signed copy of the notarized letter must be sent to the GSA Federal Service Desk (FSD) within 30 calendar days of activation or the vendor risks no longer being active in SAM.

Vendors can check whether an account is active by performing a query by their CAGE or Unique Entity Identifier (known as DUNS).

The new registration process may now take several weeks, so vendors are highly encouraged to begin registering as soon as possible to avoid any possible delays in future contract awards. Remember, there is no cost to use SAM.

To find out additional information about the changes of the SAM registration process, contractors should visit the Frequently Asked Questions (FAQ) link located at the top of the SAM homepage (www.sam.gov)

5.0 BIDDERS CHECKLIST

All information required by the terms of the Solicitation must be furnished. MISTAKES OR OMISSIONS CAN BE COSTLY. Important items for you to check are included in but not limited to those listed below. This checklist is furnished only to assist you in submitting a proper bid. The Government shall not be responsible for items not described below. It is not required to be return with your bid.

[ ] Is your bid guarantee in the proper form?

[ ] If signing on behalf of your company, have you attached evidence of your authority to sign the bid?

[ ] Have you acknowledged all amendments? Have you submitted your bid on the latest amended bid schedule?

[ ] Is the name in which you submitted your bid the same as on the bid bond?

[ ] Have you entered a unit price for each bid item?

[ ] Have you checked your bid for possible errors? Arithmetically?

[ ] Are all erasures or corrections initialed by the person signing the bid?

[ ] The Government may reject a bid as nonresponsive if it is materially and mathematically unbalanced as to price for any bid item or combination of items. A bid is unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated for other work.

[ ] Is the envelope containing your bid properly identified that it is a sealed bid and does it contain the correct solicitation number and bid opening time? See FAR Clause 52.214-5, Submission of Bids.

[ ] Will your bid arrive on time? See FAR Clause 52.214-7, Late Submissions, Modifications, and Withdrawals of Bids.

[ ] Have you furnished all information required by the invitation for bids solicitation and/or the specification?

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

Amendment 01:

Extend questions due date from 15-Aug-2019 to 21-Aug-2019 the time stays the same.

FAR 52.252-3 is updated.

(End of Summary of Changes)