Solicitation_W912P5-17-T-0059.pdf

SEE ADDENDUM

(No Collect Calls)

W912P517T0059 15-Aug-2017

b. TELEPHONE NUMBER 8. OFFER DUE DATE/LOCAL TIME

01:00 PM 30 Aug 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912P59. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

FANNIE M ROBERTSON

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

US ARMY CORPS OF ENGINEERS-CELRN-RC-N

DIRECTORATE OF CONTRACTING

110 9TH AVENUE SOUTH, ROOM A680

NASHVILLE TN 37203

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE H3R0KG0 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

MID-CUM.AREA DALE HOLLOW P.P.

DALE HOLLOW POWER PLANT 305 POWERHOUSE ROAD

CELINA TN 38551-9711

TEL: FAX:

615-736-7124FAX:

TEL: 615-736-7932 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$15,000,000

NAICS:

238220

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF69

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W912P517T0059

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Water Source Heat Pump System & Install

FFP

In accordance with the attached performance of work statement FOB: Destination

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 22-SEP-2017 TO

22-DEC-2017

N/A MID-CUM.AREA DALE HOLLOW P.P.

DALE HOLLOW POWER PLANT 305

POWERHOUSE ROAD

CELINA TN 38551-9711

FOB: Destination

H3R0KG0

QUOTE INSTRUCTIONS

QUOTE INSTRUCTIONS FOR SUPPLY, DELIVERY, REMOVE, AND INSTALL OF

WATER SOURCED HEAT PUMP

1. DESCRIPTION: This is a Total Small Business Set-Aside for the removal and disposal of the existing Carrier 50VQL water source heat pump (WSHP) system, and the installation of a new WSHP system and associated equipment in accordance with the attached specifications and performance work statement (PWS). All items provided shall be the brand name and model number specified or an approved equal.

2. TYPE OF CONTRACT: The Government intends to award a Firm-Fixed Price supply contract

3. BASIS FOR SELECTION OF AWARD: Award shall be made to the lowest priced offeror who is found to be responsible. Quote must meet or exceed the requirements within this RFQ and contract PWS to be considered for award. Offeror shall include sufficient detail of the items being quoted to ensure quote meets specifications and/or is equvalent to the specified products.

4. PLACE OF DELIVERY: Dale Hollow Power Plant, 305 Powerhouse Road, Celina, TN 38551.

5. PERIOD OF PERFORMANCE: The period of performance is 90 days after contract award.

See PWS for additional information.

6. POC FOR COMMUNICATIONS: Any communications regarding this procurement before award must be made in writing to the Contracting Division, Attn: Fannie Robertson at email fannie.m.robertson@usace.army.mil.

Inquiries must identify the solicitation number, the requestor’s company name, address, email address, telephone and facsimile numbers to include area code.

7. QUESTIONS: Questions must be submitted to Fannie Robertson at email fannie.m.robertson@usace.army.mil. by August 22, 2017 at 12:00 p.m. Central Standard Time.

Phone calls or requests to arrange meetings at the Nashville District during the solicitation period to discuss project requirements or company’s capabilities are highly discouraged and will not be allowed.

8. QUOTE SUBMISSION:

a. Quotes can be e-mailed to Fannie Robertson at fannie.m.robertson@usace.army.mil or mailed to:

US ARMY CORPS OF ENGINEERS

RIVERS CONTRACTING DIVISION

NASHVILLE CONTRACTING BRANCH

ATTN: FANNIE ROBERTSON

110 Ninth Ave. South Room#A405 (Mailroom) Nashville, TN 37203

b. The quote shall include the following elements to be considered for award:

(1) SF 1449: Filled out by the vendor for: Block 17a, Block 17b (if applicable), Block 30a, Block 30b, and Block 30c

(2) Acknowledge all (SF 30s), Amendment of Solicitation (if applicable).

(3) CLIN: To include the Total Price for Contract Line Item Numbers 0001.

(4) Technical description of the items being quoted in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other document, if necessary.

(5) Contractors must be registered in the System for Award Management (SAM) database (www.sam.gov) to receive an award.

For SAM Customer Service, contact:

Federal Service Desk URL: www.fsd.gov Hours: 8am - 8pm (Eastern Time) US Calls: 866-606-8220 International Calls: 334-206-7828

DSN: 866-606-8220

(6) Contractors shall have representations and certifications completed in www.sam.gov OR provide completed paragraphs (c) thru (m) in FAR clause 52.212-3 Alternate 1 (Annual Representations and Certifications) found in the “Clauses Section” of this solicitation. If completing the aforementioned clause, provide with submitted quote.

(7) Provide business Unique Entity Identifier Number: _______________________________ (phone 800-333-0505).

(8) Provide business CAGE code: _________________________________

(9) Tax Identification Number: ___________________________________

9. APPARENT SUCCESSFUL OFFEROR: The following is required from the apparent successful offeror prior to actual award of the contract:

a. A minimum of one (1) banking reference for their firm and a minimum of three (3) past performance references for similar contracted work.

(1) The banking reference should include the financial institution’s legal name, complete physical address, a point-of-contact (POC) at the financial institution, the POC’s telephone number, fax number, and email address.

(2) The past performance references should include firm’s name, the contract number, the contract period of performance and/or contract completion date, the contract’s aggregate value, a brief description of the project, a POC, the POC’s telephone number, fax number, and email address.

10. CONTRACTOR FEEDBACK: Help us in BUILDING STRONG. Please provide us with your feedback, comments and recommendations for improvement by visiting our Interactive Customer Evaluation (ICE) website at:

http://ice.disa.mil/index.cfm?fa=card&service_provider_id=110826&site_id=856&service_categ ory_ID=14

PERFORMANCE WORK STATEMENT

Dale Hollow Power Plant

Removal, Purchase & Installation of a Water Source Heat Pump System & Accessories

The Contractor shall remove and dispose of the existing Carrier 50VQL water source heat pump (WSHP) system, and provide and install a new WSHP system and associated equipment as specified below.

BRAND NAME AND MODEL NUMBER SPECIFIED OR EQUAL

The Contractor shall provide the brand name and model number specified or equal. To be considered equal, alternate equipment proposed shall meet the salient characteristics listed. The Contractor shall submit catalog cut / documentation with their price quote. If an alternate is proposed, the Government shall make the comparison to verify that it is equal to the model number specified and that it can meet the salient characteristics.

Information provided in the catalog cut documents shall be complete and of the level of detail to allow the Government to make the comparison. The Contractor shall not deliver equipment prior to the Government's approval.

SUPPLY

The WSHP system and associated equipment shall consist of the following:

Geo Excel RD210-4VTN-FBTBUA-XAG 17.5 Ton WSHP pump or approved equal Extended Range Package 15 KW auxiliary electric duct heater including wiring and controls New water regulating valve system Electrical materials as required to accommodate the new system Duct work materials as required to accommodate the new system Plumbing materials as required to accommodate the new system

SALIENT CHARACTERISTICS, Geo Excel - 17.5 Ton WSHP system

Size: 17.5 Ton Voltage (V/Hz/Ph): 460/60/3 Cabinet Configuration: Vertical Coax Options: Cupro-Nickel (Cu-Ni) Water Connections: Front Return Air Configuration: Back Discharge Air Configuration: Top

Fan/Motor: Minimum 1.5 HP Belt Drive Air Coil Protection: DuoGuard Application: Extended Range with Schrader Valves (Geothermal) Filtration: 2-inch two-sided filter rack with 1-inch filter Transformer: 75 VA

DESCRIPTION OF WORK

The Contractor shall provide all services, labors, tools and like materials to remove and dispose of the old WSHP system and successfully install and commission the new WSHP system and above mentioned associated equipment, in accordance with the manufacturer’s installation and operating manual (IOM). This includes any additional electrical, ducting, and plumbing like materials as required to install and accommodate the new WSHP pump system. The Contractor installing the system shall be a trained labor technician in WSHP systems. The Contractor shall provide all additional laborers needed to assist in removal and installation of the WSHP system. The Contractor shall ensure that the work is completed in a timely manner and in accordance with time and delivery specifications mentioned below. Disposal of equipment being replaced shall be done in accordance with Federal, State, and local laws and regulations. The Contractor shall provide documentation assuring Freon has been collected according to all required laws and regulations. All work shall be performed in accordance with the USACE EM 385-1-1 Safety and Health Requirements Manual. No work activities shall occur until the Contractor submits both an Activity Hazard Analysis and Accident Prevention Plan that has been reviewed and approved by the Contracting Officer’s Representative (COR) or other designated Government official. The Contractor shall designate a Site Supervisor employed by the Prime Contractor that is responsible for addressing and enforcing all safety, workmanship and quality assurance matters. The Site Supervisor shall be on-site during all phases of work. The Contractor shall provide all manuals, warranty information and training on operation and maintenance of the units.

WARRANTY

The Contractor shall provide a parts and labor warranty for the WSHP system for a period of one year, or for a period as provided by the manufacturer’s standard warranty provisions, whichever period is greater. The warranty period shall commence on the date that the Contractor’s invoice and properly executed Final Release of Claims has been received and approved by the Government. All products shall be warranted to be free from defects in material and workmanship. During the term of the warranty period, parts, assemblies, or components deemed to be defective will be repaired or replaced by the Contractor at no cost to the Government.

PACKAGING & PROTECTION

All transportation, delivery, and storage costs shall be included in the quote. Any damage shall be repaired or replaced by the Contractor with no additional cost to the Government.

DELIVERY & INVOICE

Upon award of the contract, the Contractor is required to supply the materials and perform the work necessary to install and commission the above listed items and remove the existing system within a 90 day period of performance. The commissioning of the new WSHP system shall occur within 24 calendar days of mobilization.

The Contractor shall contact the Plant Superintendent at 931-243-3135 prior to delivery or arrival of the new WSHP unit. Delivery shall be made from Monday thru Thursday, 0730-1600 except Federal Holidays. A single invoice for completed work and materials, accompanied by a properly executed Final Release of Claims, shall be sent (postal or email) to the Plant Superintendent as follows:

Dale Hollow Power Plant Attention: Stanley R. Carter, Jr.

305 Powerhouse Road Celina, TN 38551 stanley.r.carter.jr@usace.army.mil

SECURITY

All contractor and associated sub-contractor employees shall comply with all applicable project and local security policies and procedures (provided by the district representative).

The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by the District Security Management Office. Contractor workforce must comply with all personal identity verification requirements (FAR Clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

Since the work is being done within a controlled area but is expected to last less than six months, the investigation requirements fall under Category B1 for US Citizens and Category C for Foreign Nationals. Contract employees will need to be supervised/ escorted by a Corps employee while within the restricted area. In the event it is determined the contract will extend beyond six months, the contractor will need to comply with the requirements in Category B2 for US Citizens. Guidance and forms for the requirements are available on the Nashville District Public Website:

http://www.lrn.usace.army.mil/BusinessWithUs/ContractSecurityRequirements.aspx.

Convict Labor: Because the work is being performed in a restricted area, there are restrictions on use of persons either imprisoned or previously convicted of a felony. The Contractor shall not employ in the performance of this contract any person undergoing a sentence of imprisonment imposed by any court of a State, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, or the U.S. Virgin Islands, or the US Federal Government. The Contractor shall not employ in the performance of this contract any person who has been convicted of a felony imposed by any court of a State, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, or the US Federal Government.

All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

Pre-screen candidates using E-Verify Program. The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

The Contractor is responsible for taking the action necessary to protect Contractor supplies, materials and equipment, and the personal property of Contractor employees from loss, damage or theft. The Government assumes no responsibility for theft, damage, etc., of the above. All incidents of theft (or suspected theft) of contractor materials, supplies, or equipment from project lands shall be reported to the COR.

Please ensure ALL reports of theft, suspected theft, vandalism, or ANY crime of Government OR Contractor property, OR crime against/by Contractor personnel is forwarded to the District Security Office. This information is critical for threat and risk assessments and may assist in obtaining funds for additional security measures.

CONDUCT OF CONTRACT EMPLOYEES: All contract employees and subcontractors shall conduct themselves in a proper manner at all times. No alcoholic or intoxicating beverages or substances or illegal drugs or controlled substances not prescribed by a physician shall be possessed, consumed, or be under the influence of any such substance while on Government property.

The Contractor shall remove from the site any individual whose continued employment is deemed by the appointed receiving agent to be contrary to the public interest or inconsistent with the best interests of the U.S. Army Corps of Engineers.

The Contracting Officer or the appointed receiving agent will require the Contractor to immediately remove from the work site anyone who is incompetent or who endangers persons or property or whose physical or mental condition is such that it would impair the employee’s ability to satisfactorily perform the work. Notification to the Contractor will be made in writing if time and circumstances permit. Otherwise, notification will be verbal and will be confirmed in writing as soon as possible. No such removal, however, will reduce the Contractor's obligation to perform all work required under this contract and immediate replacement shall be made as required.

SUSTAINABILITY

The Contractor shall provide energy- and water-efficient building-related products and equipment per the following website:

http://energy.gov/eere/femp/find-product-categories-covered-efficiency-programs) for updates.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.211-6 Brand Name or Equal AUG 1999 52.212-1 Instructions to Offerors--Commercial Items JAN 2017 52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.245-1 Government Property JAN 2017 52.245-9 Use And Charges APR 2012 52.247-34 F.O.B. Destination NOV 1991 52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7036 Alt I Buy American--Free Trade Agreement--Balance of Payments

Program--Alternate I (Dec 2016)

DEC 2016

252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name.

The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212- 3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ .

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on ORCA.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a women-owned small business concern.

Note to paragraphs (c)(8) and (9): Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ -.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). (Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Certifications and representations required to implement provisions of Executive Order 11246--

(1) Previous Contracts and Compliance. The offeror represents that--

(i) It ( ___ ) has, ( ___ ) has not, participated in a previous contract or subcontract subject either to the Equal Opportunity clause of this solicitation, the and

(ii) It ( ___ ) has, ( ___ ) has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that--

(i) It ( ___ ) has developed and has on file, ( ___ ) has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR Subparts 60-1 and 60-2), or

(ii) It ( ___ ) has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American --Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American--Supplies.”

(2) Foreign End Products:

Line Item No. Country of Origin

(List as necessary)

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)(1) Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms ``Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,'' ``commercially available off-the-shelf (COTS) item,'' ``component,'' ``domestic end product,'' ``end product,'' ``foreign end product,'' ``Free Trade Agreement country,'' ``Free Trade Agreement country end product,'' ``Israeli end product,'' and ``United States'' are defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act.''

(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act'':

Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products:

[List as necessary]

(iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of “domestic end product.”

Other Foreign End Products:

Line Item No. Country of Origin

(iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(2) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I (Jan 2004). If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American -Free Trade Agreements-Israeli Trade Act":

Canadian End Products:

Line Item No.

(3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II (Jan 2004). If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision:

(g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act":

Canadian or Israeli End Products:

Line Item No. Country of Origin

(4) Buy American--Free Trade Agreements--Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of…