B.08.03 AMEND 0002 W912HY21B0021 20210827.pdf

451902

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

SEE SECTION SF 30 BLOCK 14 CONTINUATION PAGE

Bid Opening Extened to September 10, 2021 2pm Local Time

1. CONTRACT ID CODE PAGE OF PAGES

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HY21B0021

X 9B. DATED (SEE ITEM 11)

05-Aug-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

27-Aug-2021

CODE

US ARMY CORPS OF ENGINEERS

GALVESTON DISTRICT

CONTRACTING DIVISION

2000 FORT POINT ROAD

GALVESTON TX 77550-1229

W912HY 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HY21B0021

A0002-2

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

1. The specifications for Solicitation No. W912HY21B0021, Houston Ship Channel, Texas, Bolivar

Roads to Redfish Reef in Galveston County, Texas, Dollar Reef Oyster Mitigation, are hereby amended as follows:

a) Specifications.

(1) SECTION 00 21 00, INSTRUCTIONS – The enclosed SECTION 00 21 00 entitled

INSTRUCTIONS supersedes Section 1.1 - 1.8.

(1) SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS, STANDARD – The enclosed SECTION 00 73 00.01 45 entitled SPECIAL CONTRACT REQUIREMENTS, STANDARD supersedes that issued with this Solicitation.

2. This amendment shall be attached to and become a part of the solicitation.

2 Encls:

1. SECTION 00 21 00, INSTRUCTIONS

2. SECTION 00 73 00.01 45, SPECIAL CONTRACT REQUIREMENTS, STANDARD

SWG FILE NO.: HSC 401-585 SOLICITATION NO.: W912HY21B0021

Section 00 21 00 - Page 1

TO ACCOMPANY AMENDMENT NO. 0002 TO SOLICITATION W912HY21B0021

SECTION 00 21 00 - INSTRUCTIONS

AMENDMENT NO. 0002

The following have been modified:

00 21 00

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (APR 1985) (FAR 36.204)

The estimated price range of the proposed construction is between $10,000,000 and $25,000,000.

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON SAM.GOV WEBSITE (FAR

5.102(a)(1))

After solicitation issuance, contractors may register to be placed on the

Interested Vendors List, view and/or download this solicitation and all amendments at https://sam.gov/ .

Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the Beta Sam website daily (using the above link) for amendments to the solicitation. You must be registered in the System For Award Management (SAM) to receive a government contract award. The website for SAM https://www.sam.gov/SAM/ .

1.3 PREAWARD INFORMATION CONSTRUCTION (FAR 9.105-1)

Bidders shall submit a statement not later than the response date and time indicated in the solicitation, of whether he is now or has ever been engaged in any work similar to that covered by the specifications herein, the dollar value thereof, the year in which such work was performed, and the manner of its execution, and giving such information as will tend to show the bidder's ability to prosecute the required work. The "such other information" referred to above shall include but is not limited to the following:

(a) The name and address of the office or firm under which such similar work was performed.

(b) A list of key personnel available for the instant project and their qualifications.

(c) A copy of bidder's last year's financial statement, including the names of banks or other financial institutions with which the bidder conducts business. Such statement will be confidential.

(d) Business Financial Condition Evaluation. The evaluation factors listed below shall be prepared by the contractor's certified public accountant.

(1) Liquidity

- Current Ratio __________________

- Quick Ratio __________________

(2) Leverage

-Debit/Net Worth __________________

(3) Operating Efficiency https://sam.gov/ https://www.sam.gov/SAM/

Section 00 21 00 - Page 2

TO ACCOMPANY AMENDMENT NO. 0002 TO SOLICITATION W912HY21B0021

- Return On Assets __________________

- Asset Turnover __________________

(4) Profitability

- % Return On Equity __________________

- % Return On Sales __________________

(e) A list of present commitments, including the dollar value thereof, and name of office under which the work is being performed.

(f) A preliminary schedule showing anticipated dates for start of work, based upon availability of contractor resources, and the plan for completing work within the contract performance period.

(g) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within Not Applicable.

1.4 BIDDER'S QUALIFICATIONS (FAR 9.105-1)

Before a bid is considered for award, the bidder may be requested by the

Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

1.5 CAUTIONS & REMINDERS TO BIDDERS (FAR 52.214-18)

All information required by the terms of the solicitation must be furnished.

MISTAKES OR OMISSIONS CAN BE COSTLY. Important items for you to check are included in but not limited to, those listed below. This checklist is furnished only to assist you in submitting a proper offer. Check as you read.

Have you acknowledged all amendments?

Have you completed SECTION 00 45 00, REPRESENTATIONS & CERTIFICATIONS portion of the solicitation package to include 52.204-24 and 52.204-26?

Is your offer properly signed?

If a bid guarantee is required, is it included with your offer? (A late bid guarantee is treated the same as a late offer).

Is your bid guarantee in the proper amount? Bid guarantee shall be in the amount of 20 percent of the amount of the offer, or $3 million, whichever is less.

If your bid guarantee is in the form of a bid bond, is the bond properly signed by both the bidder and surety and are all required seals affixed?

Is the name in which you submitted the offer the same as your bid bond?

If required have you entered a unit price for each item? (The solicitation will specifically state when this is necessary).

Are decimals in unit prices in the proper places? Are your figures legible?

Section 00 21 00 - Page 3

Are the extensions of your unit prices, and your total offer price correct?

Are all erasures or corrections initialed by the person signing the offer?

I have not restricted my offer by altering the provisions of the solicitation.

REMINDER TO BIDDERS

REMINDER #1 - Acknowledge all Amendments on the reverse side of SF 1442, Item

19, Solicitation, Offer, and Award.

REMINDER #2 - The Contracting Officer signing this contract is the Primary

Contracting Officer. However, any Contracting Officer assigned to the

Galveston District may take formal action. See Section entitled "Specific

Project Requirements".

1.6 SPECIAL INSTRUCTIONS PERTAINING TO ELECTRONIC BID SUBMISSION: (FAR

14.302 and 14.304)

Bids and a copy of the SF24 Bid Bond and Preaward Information as indicated in

Section 002100, Paragraph 1.3, PreAward Information Construction must be submitted via email to: SWG-CT-Execution-Proposals@usace.army.mil , not later than the response date and time indicated in the solicitation. Identify the

Solicitation Number W912HY21B0021 and HOUSTON SHIP CHANNEL EXPANSION CHANNEL

IMPROVEMENT PROJECT BOLIVAR ROADS TO REDFISH REEF DOLLAR POINT OYSTER

MITIGATION, GALVESTON COUNTY, TEXAS in subject line of the emai1.

Bid Opening will be held by teleconference.

Teleconference No.

+1-844-800-2712 US Toll Free

+1-669-234-1177 US Toll

Access code:199 858 9518

1.7 BIDDER INQUIRY – PROJNET (FAR 14.211)

1. Prospective Offerors should submit questions concerning this solicitation via Bidder Inquiry in ProjNet at www.projnet.org/projnet .

A. To submit and review bid inquiry items, bidders will need to be a current registered user or self-register into the system. To self-register, go to the aforementioned web page and click on the BID tab. Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

***Please Note: Offerors shall only submit one question per inquiry.

Inquiries containing multiple questions may be rejected.

mailto:SWG-CT-Execution-Proposals@usace.army.mil http://www.projnet.org/projnet

Section 00 21 00 - Page 4

B. From this page, you may view all bidder inquiries or add inquiry.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

D. The Solicitation Number is: W912HY21B0021

The Bidder Inquiry Key is: EHA383-IC4YT2

2. The Bidder Inquiry System will be unavailable for new inquires fifteen

(15) calendar days prior to offer submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone

(Chicago). The telephone number for the Call Center is 800-428-HELP.

1.8 CONSTRUCTION WAGE RATE REQUIREMENTS (FAR 52.222-6)

Paragraph entitled CONSTRUCTION WAGE RATE REQUIREMENTS of (CONTRACT CLAUSES -

Section 00 72 00, FAR 52.222-6) is applicable to this solicitation. Wage

Rates will be incorporated by amendment, if they are not included in this solicitation.

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

DOCUMENT 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD AMENDMENT NO. 0002

PART 1 GENERAL AM#2

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

1.5 PERFORMANCE OF WORK BY THE CONTRACTOR

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section Table of Contents --

DOCUMENT 00 73 00.01 45 Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

DOCUMENT 00 73 00.01 45 Page 2

DOCUMENT 00 73 00.01 45

SPECIAL CONTRACT REQUIREMENTS, STANDARD

AMENDMENT NO. 0002

PART 1 GENERAL AM#2

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed;

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than 188278 calendar days after the date the Contractor receives the Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000) (FAR 52.211-12)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,609.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

1.3 PHYSICAL DATA (APR 1984) (FAR 52.236-4)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations as described on the drawings.

(b) Weather Conditions. Under ordinary conditions, the mean tidal range is about 1 foot. The height of tide is largely dependent on the force, direction, and duration of the wind. Strong northerly winds may depress the water surface by as much as, and in some instances more than, 2 feet, while southerly winds may raise the water surface by as much as, and in some instances more than, 2 feet .

(c) Transportation Facilities. The immediate vicinity is served by railroad, highway, and deep and shallow draft channels. The work site is accessible by open water in Galveston Bay via the Houston Ship Channel. Public wharves, rail and highway connections are available

DOCUMENT 00 73 00.01 45 Page 3 throughout the Houston and Galveston Region.

1.4 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE(MAR 1995)

(a) This special contract requirement does not apply to terminations.

See 52.249-5000, Basis for Settlement of Proposals, and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the con-tractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VI. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

NOTE: A copy of EP 1110-1-8, "CONSTRUCTION EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE," is available at the following website:

http://www.publications.usace.army.mil/USACEPublications/EngineerPamphlets.aspx.

1.5 PERFORMANCE OF WORK BY THE CONTRACTOR

See Section 00 72 00, FAR 52.219-14, Limitation of Subcontracting (MAR 2020)

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Document --

DOCUMENT 00 73 00.01 45 Page 4