B.08.03 - Amendment 0001 (released) - W912HP20B0004 - Post 45 Dredging Contract 5.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to make the follow ing updates:

1) Block 10 of the SF1442 is hereby updated to reflect the updated scope.

2) The CLINS/Bid Schedule are hereby updated.

3) The follow ing clauses are hereby added: 52.204-25, 252.203-7000, 252.225-7048, 252.232-7003. Provision 52.204-24 is added w ith full text.

4) Clauses 52.211-10 and 252.236-7001 are hereby updated.

5) Specification Section 35 20 23 Dredging is hereby updated.

6) Specifications Table of Contents is hereby updated.

7) Additional permit documents are hereby added to the solicitation package.

8) Draw ing Sheets are hereby updated w ith changes to C-01, C-10, C-11, C-12 and added sheets C-13 and C-14.

9) Utility location information is hereby provided.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 7

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 18-Aug-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912HP20B0004

X 9B. DATED (SEE ITEM 11)

23-Jul-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

18-Aug-2020

CODE

U.S. ARMY CORPS OF ENGINEERS, CHARLESTON

DISTRICT, CONTRACTING DIVISION

69-A HAGOOD AVENUE

CHARLESTON SC 29403

W912HP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HP20B0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION, CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE

The required performance has changed from Post 45 Contract 5 Charleston Upper Harbor Maintenance and New Work Dredging, Charleston, SCThe work consists of maintenance and new work dredging of a base amount of approximately 4.021 million cubic yards of unclassified material from the Charleston Upper Harbor (from the Hugh Leatherman Terminal to the North Charleston Terminal). The work is located in Charleston and Berkeley Counties, South Carolina. The work includes complying with the requirements of the Endangered Species Act and Marine Mammals Protection Act. Due to environmental considerations, Hopper Dredges may not be utilized in the execution of work under this contract.MAGNITUDE OF WORK:

$25,000,000 TO $100,000,000.The acquisition is UNRESTRICTED.The NAICS Code is 237990 Other Heavy and Civil Engineering Construction (Dredging) with SBA Business Size Standard of $30 Million.The Contractor must be registered in the System for Award Management (SAM.gov).The Solicitation and subsequent Amendments will only be available in electronic format downloadable from www.beta.SAM.gov. Bidders must be registered at the www.beta.SAM website in order to view or download the Solicitation documents and possible amendments. to Post 45 Contract 5 Charleston Upper Harbor Maintenance and New Work Dredging, Charleston, SCThe work consists of maintenance and new work dredging of a base amount of approximately 4,372,000 million cubic yards of unclassified material from the Charleston Upper Harbor, Joint Base Charleston Pier X-Ray, TC Dock, and MARADS Piers S,T, U. The work is located in Charleston and Berkeley Counties, South Carolina. The work includes complying with the requirements of the Endangered Species Act and Marine Mammals Protection Act. Due to environmental considerations, Hopper Dredges may not be utilized in the execution of work under this contract.MAGNITUDE OF WORK: $25,000,000 TO $100,000,000.The acquisition is UNRESTRICTED.The NAICS Code is 237990 Other Heavy and Civil Engineering Construction (Dredging) with SBA Business Size Standard of $30 Million.The Contractor must be registered in the System for Award Management (SAM.gov).The Solicitation and subsequent Amendments will only be available in electronic format downloadable from www.beta.SAM.gov. Bidders must be registered at the www.beta.SAM website in order to view or download the Solicitation documents and possible amendments..

CLIN 0006

The CLIN description has changed from Mobilization and Demobilization to Option 1 Mobilization and Demobilization.

CLIN 0007

The CLIN description has changed from Dredging of Unclassified to Option 1 Dredging of Unclassified.

CLIN 0008 is added as follows:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0008 1 Job OPTION Option 2 Mobilization and DemobilizationFFP

Maintenance Dredging Marads Piers S, T, U FOB: Destination

NET AMT

CLIN 0009 is added as follows:

0009 138,000 Cubic

Yard

OPTION Option 2 Dredging of UnclassifiedFFP Maintenance Material Marads Piers S, T, U

CLIN 0010 is added as follows:

Option 3 Dredging of UnclassifiedFFP

Material TC Dock

SUBCLIN 0010AA is added as follows:

0010AA 1 Job OPTION Mobilization and DemobilizationFFP

Maintenance Dredging in Joint Base Charleston Channel TC Dock

SUBCLIN 0010AB is added as follows:

0010AB 1 Job

OPTION DREDGING OF UNCLASSIFIEDFFP

MATERIAL TC DOCK DESC (Sta. 1703+90 to 1704+90)

SUBCLIN 0010AC is added as follows:

0010AC 48,000 Cubic

Yard

OPTION DREDGING OF UNCLASSIFIEDFFP

MATERIAL TC DOCK MSDDC (Sta. 1704+90 to 1720+83)

The following have been modified:

TOTALS

TOTAL COMBINATION OF BASE BID ITEMS (0001-0005) $_______________________

TOTAL COMBINATION OF OPTION BID ITEMS (0006-0010) $_______________________

TOTAL COMBINATION OF ALL BID ITEMS (0001-0010) $_______________________

STATEMENTS

1) Enter prices where space is provided for ALL items. Failure to follow this instruction may render the bid non-responsive and the bid will not be considered for award.

2) All bidders are advised materially unbalanced bids may be rejected as nonresponsive. See FAR 52.214-19

Contract Award – Sealed Bidding – Construction.

3) Quantities indicated are ESTIMATED and are comprised of material within the required channel prism including the maximum pay slope material and the allowable overdepth as defined in the contract drawings.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 641 calendar days. * The time stated for completion shall include final cleanup of the premises.

Supplemental Instructions:

1. Charleston Upper Harbor (Acceptance Sections 1-8), Pier X-Ray South, TC Dock, MARADS Piers S,T,U

(a) Prosecution of Work

The actual dredging work required shall be completed in its entirety, including cleanup operations by 22 July 2022.

The Contractor shall provide the Government a schedule not later than 10 calendar days after date of the Notice to Proceed depicting, at a minimum, the following information.

- Commencement dates of initial mobilization and all subsequent demobilizations (if any) and remobilizations (if any) including the final demobilization

- Date dredging shall begin following each mobilization effort

- Duration of dredging (must at least meet specified completion date)

- Date dredging is to be completed, at a minimum, for each acceptance section

- Anticipated schedule of earnings

Once this schedule is approved, it will be incorporated into the contract by a no cost modification and become the performance period for the contract. Liquidated damages will be assessed for every day work continues beyond this incorporated scheduled completion date (as adjusted for excusable delays as allowed per other clauses within the contract).

(End of clause)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

TITLE FILE DRAWING NO.

POST 45 CHARLESTON UPPER

HARBOR MAINTENANCE AND NEW

WORK DREDGING (in 14 sheets)

9620 W912HP20B0004

(End of clause)

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following Acceptance/Inspection Schedule was added for CLIN 0008:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

N/A N/A N/A Government

The following Acceptance/Inspection Schedule was added for CLIN 0009:

The following Acceptance/Inspection Schedule was added for CLIN 0010:

N/A N/A N/A N/A

The following Acceptance/Inspection Schedule was added for SUBCLIN 0010AA:

The following Acceptance/Inspection Schedule was added for SUBCLIN 0010AB:

The following Acceptance/Inspection Schedule was added for SUBCLIN 0010AC:

(End of Summary of Changes)