SF1449_PACKAGE_W912HP-13-R-0043.pdf

U.S. ARMY CORPS OF ENGINEERS, CHARLESTON

DISTRICT, CONTRACTING DIVISION

69-A HAGOOD AVENUE

CHARLESTON SC 29403

843-329-8060

843-329-2322

UNDER DPAS (15 CFR 700)

11. DELIVERY FOR FOB

RFQ

SEE SCHEDULE

14. METHOD OF SOLICITATION

IFB RFP

CODE

SEE ADDENDUM

BLOCK IS MARKED

DESTINATION UNLESS

12. DISCOUNT TERMS

(No Collect Calls)

$33.5M

13b. RATING

13a. THIS CONTRACT IS A RATED ORDER

X

CODE

W912HP-13-R-0043 07-Oct-2013

b. TELEPHONE NUMBER

843-329-8071

8. OFFER DUE DATE/LOCAL TIME

10:00 AM 19 Nov 2013

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV 3/2005)

Prescribed by GSA

FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER) 31c. DATE SIGNED

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

22. UNIT 23. UNIT PRICE 24. AMOUNT21. QUANTITY

CODE 10. THIS ACQUISITION IS

UNRESTRICTED

FAX: NAICS:

TEL:

CODE 18a. PAYMENT WILL BE MADE BYOFFEROR

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TEL.

W912HP

SIZE STD:

9. ISSUED BY

FACILITY

CODE

17a.CONTRACTOR/

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

JOSHUA D MUELLER

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

19. ITEM NO. 20. SCHEDULE OF SUPPLIES/ SERVICES

SEE SCHEDULE

561210

TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS

SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS

SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

SB

HUBZONE SB

SET ASIDE: 100 % FOR

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

TEL: EMAIL:

2 COPIES

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

.OFFER DATED YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 29. AWARD OF CONTRACT: REFERENCE

X

8(A)

SVC-DISABLED VET-OWNED SB

EMERGING SB

X

X

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

SEE SCHEDULE

19. ITEM NO. 20. SCHEDULE OF SUPPLIES/ SERVICES 21. QUANTITY 22. UNIT 24. AMOUNT

PAGE 2 OF

23. UNIT PRICE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV 3/2005) BACK

Prescribed by GSA

FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

W912HP-13-R-0043

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 12 Months Facilities Maint. Svcs Base Pd - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraphs 3.2, 3.3, 3.4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal schedule.

FOB: Destination

NET AMT

0002 500 Each Svc Calls Base Pd - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 3.1 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal schedule.

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0003 UNDEFINED Lump Sum

Unit Priced Labor IDIQ Base PdFFP IDIQ Line Item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal schedule.

MAX

1001 12 Months OPTION Facilities Maint. Svcs Opt Pd 01 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraphs 3.2, 3.3, 3.4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal schedule.

1002 500 Each OPTION Svc Calls Opt Pd 01 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 3.1 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal

UNIT UNIT PRICE MAX AMOUNT

1003 UNDEFINED Lump

OPTION Unit Priced Labor IDIQ Opt Pd 01FFP accordance with paragraph 4 of the Performance Work Statement (PWS)

2001 12 Months OPTION Facilities Maint. Svcs Opt Pd 01 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraphs 3.2, 3.3, 3.4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the

2002 500 Each OPTION Svc Calls Opt Pd 02 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 3.1 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal

UNIT UNIT PRICE MAX AMOUNT

2003 UNDEFINED Lump

OPTION Unit Priced Labor IDIQ Opt Pd 02FFP accordance with paragraph 4 of the Performance Work Statement (PWS)

3001 12 Months OPTION Facilities Maint. Svcs Opt Pd 03 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraphs 3.2, 3.3, 3.4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the

3002 500 Each OPTION Svc Calls Opt Pd 03 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 3.1 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal

UNIT UNIT PRICE MAX AMOUNT

3003 UNDEFINED Lump

OPTION Unit Priced Labor IDIQ Opt Pd 03FFP accordance with paragraph 4 of the Performance Work Statement (PWS)

4001 12 Months OPTION Facilities Maint. Svcs Opt Pd 04 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraphs 3.2, 3.3, 3.4 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the

4002 500 Each OPTION Svc Calls Opt Pd 02 - FFP Line item. Contractor shall inspect, maintain and repair faciltiies in accordance with paragraph 3.1 of the Performance Work Statement (PWS) provided in Section C 1502000. See also the notes to the proposal

UNIT UNIT PRICE MAX AMOUNT

4003 UNDEFINED Lump

OPTION Unit Priced Labor IDIQ Opt Pd 04FFP accordance with paragraph 4 of the Performance Work Statement (PWS)

NOTES TO THE PROPOSAL SCHEDULE

Preventative Maintenance

PROPOSAL SCHEDULE NOTES

1. See also Section J, Attachment J-020000-07, Exhibit Line Item Numbers (ELINS). Offerors shall complete and submit Attachment J-020000-07 in MS Excel Format. The total price for each CLIN submitted in the proposal schedule above shall equal the total price displayed on the "CLIN Summary" tab of Attachment J-020000-07. All subCLIN and ELIN prices shall be complete in Attachment J-020000-

07. All subCLINs will be incorporated into the award resulting from this solicitation. Failure to bid on all the items in the proposal schedule and/or Attachment J-020000-07 may cause the bid to be considered nonresponsive and therefore ineligible for contract award.

2. Firm Fixed Price (FFP) Items. Prices for all FFP items shall cover all work, complete and in accordance with the PWS and shall be considered full compensation for all work in connection therewith, to include all labor, supervision, management, tools, material, equipment, facilities, incidental engineering, vehicles, transportation, costs related to quality control, and other items necessary to perform the work, except as otherwise specified to be furnished by the Government. Payments for FFP items at the contract price shall constitute full and final compensation. Full performance for all FFP items shall begin on the dates specified in the PWS. The Contractor will have a minimum of 10 calendar days prior to full performance to implement any necessary phase-in / transition efforts. The Government will not pay for phase-in / transition efforts.

3. Indefinite Delivery / Indefinite Quantity (IDIQ) Items. See also paragraph 2.14 of the PWS

Section C 0200000. Prices for IDIQ CLINs refer to a “Not to Exceed” (NTE) capacity amount, and will be derived from the estimated quantity for the unit priced labor after applying the Contractor’s proposed coefficient. The total ordering value of all task orders issued under IDIQ CLINs of the contract resulting from this solicitation shall not exceed the capacities proposed and/or negotiated during the formation of the base contract. NOTE: See the IQ tabs within Attachment J-020000-07 for the estimated quantity for proposal purposes.

-- End of Section –

Section C - Descriptions and Specifications

PERFORMANCE WORK STATEMENT

This section is PROVIDED IN THE PWS made available for download the following website:

http://www.FBO.gov. OFFERORS ARE RESPONSIBLE FOR MONITORING THIS WEBSITE TO ENSURE THEY HAVE THE MOST RECENT VERSION OF ALL DOCUMENTS. Any struck-through items (SAMPLE) in these documents is included to indicate that those items are NOT to be included in the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY REFERENCE

52.246-4 Inspection Of Services--Fixed Price AUG 1996 52.246-12 Inspection of Construction AUG 1996 52.246-15 Certificate of Conformance APR 1984

Section F - Deliveries or Performance

DELIVERABLE AND SUBMITTALS

This section is PROVIDED IN THE PWS made available for download the following website:

http://www.FBO.gov. OFFERORS ARE RESPONSIBLE FOR MONITORING THIS WEBSITE TO ENSURE THEY HAVE THE MOST RECENT VERSION OF ALL DOCUMENTS. Any struck-through the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

52.247-34 F.O.B. Destination NOV 1991

CONTRACTOR MANPOWER REPORTING

The Contractor Manpower Reporting Application (CMRA) is a business process that has been approved by the Army as a means for collecting information on contracts that provide services to the Department of the Army. Contractors are required to register and report information via the CMRA website located at https://cmra.army.mil/. Additional information such as links to user guides, frequently asked questions and help desk information is available via the CMRA website.

Section G - Contract Administration Data

CONTRACT ADMINISTRATION INFO

G.1. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

a. The Contractor shall not accept any instructions issued by any person, employed by the Government or otherwise, other than the Contracting Officer or the Contracting Officer’s Representative (COR) acting within the limits of the COR’s Authority. Only a warranted Contracting Officer (either a Procuring Contracting Officer (PCO), or an Administrative Contracting Officer (ACO)), acting within their delegated limits, has the authority to issue modifications, task orders, or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

b. Administration of the actions under this contract will be performed by the Contracting Office, USACE Charleston District.

Section H - Special Contract Requirements

WAGE DETERMINATION

This section is PROVIDED IN THE PWS made available for download the following website:

http://www.FBO.gov. OFFERORS ARE RESPONSIBLE FOR MONITORING THIS WEBSITE TO ENSURE THEY HAVE THE MOST RECENT VERSION OF ALL DOCUMENTS. Any struck-through the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

UNUSUAL WEATHER TIME EXTENSION

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (Ref. FAR 52.249-10)

In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORKDAYS BASED ON 5-DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(c) Upon acknowledgment of the Notice to Proceed and continuing through-out the contract, the Contractor will record on the daily Contractor Quality Control report the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the contract clause entitled

DEFAULT (FIXED PRICE CONSTRUCTION).

Notice; This clause will be included in Task Orders as applicable.

Section I - Contract Clauses

52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(Sep 2006) -- Alternate I

OCT 1995

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

MAY 2012

52.211-18 Variation in Estimated Quantity APR 1984 52.212-4 Contract Terms and Conditions--Commercial Items JUL 2013 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2004 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns JUL 2013 52.219-14 Limitations On Subcontracting NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-3 Convict Labor JUN 2003 52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 Payrolls and Basic Records JUN 2010 52.222-9 Apprentices and Trainees JUL 2005 52.222-11 Subcontracts (Labor Standards) JUL 2005 52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-17 Nondisplacement of Qualified Workers JAN 2013 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-26 Equal Opportunity MAR 2007 52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010 52.222-36 Affirmative Action For Workers With Disabilities OCT 2010 52.222-37 Employment Reports on Veterans SEP 2010 52.222-50 Combating Trafficking in Persons FEB 2009 52.222-54 Employment Eligibility Verification AUG 2013 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.232-27 Prompt Payment for Construction Contracts JUL 2013 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-5 Material and Workmanship APR 1984

52.236-7 Permits and Responsibilities NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.237-1 Site Visit APR 1984 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.237-3 Continuity Of Services JAN 1991 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.244-2 Subcontracts OCT 2010 52.246-1 Contractor Inspection Requirements APR 1984 52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.232-7011 Payments in Support of Emergencies and Contingency

Operations

MAY 2013

252.236-7001 Contract Drawings, and Specifications AUG 2000 252.236-7003 Payment for Mobilization and Preparatory Work JAN 1997 252.236-7004 Payment for Mobilization and Demobilization DEC 1991 252.236-7013 Requirement for Competition Opportunity for American Stell

Producers, Fabricators, and Manufacturers

JUN 2013

252.242-7000 POST AWARD CONFERENCE MAY 2007

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within (Contracting Officer insert number) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than . * The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (AUG 2013) (DEVIATION)

(a) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(a) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times, the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(b)(1) Notwithstanding the requirements of any other clause in this contract, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (b)(i) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (APR 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note).

(ii) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iii) Reserved.

(iv) 52.222-26, Equal Opportunity (MAR 2007) (E.O. 11246).

(v) 52.222-35, Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (SEP 2006) (38 U.S.C. 4212).

(vi) 52.222-36, Affirmative Action for Workers with Disabilities (JUN 1998) (29 U.S.C. 793).

(vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O.

13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(viii) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.).

(ix) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)).

___ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)).

(x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.).

(xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services-- Requirements (FEB 2009) (41 U.S.C. 351, et seq.).

(xii) 52.222-54, Employment Eligibility Verification (JUL 2012).

(xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (MAR 2009) (Pub. L. 110-247).

Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xiv) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a FIRM FIXED PRICE contract resulting from this solicitation.

(End of provision)

52.216-18 ORDERING. (OCT 1995)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the Schedule. Such orders may be issued from DATE OF CONTRACT AWARDthrough DATE OF CONTRACT EXPIRATION.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c) If mailed, a delivery order or task order is considered "issued" when the Government deposits the order in the mail. Orders may be issued orally, by facsimile, or by electronic commerce methods only if authorized in the Schedule.

52.216-19 ORDER LIMITATIONS. (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $2,000.00 (insert dollar figure or quantity), the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor:

(1) Any order for a single item in excess of $500,000.00 (insert dollar figure or quantity);

(2) Any order for a combination of items in excess of 500,000.00 (insert dollar figure or quantity); or

(3) A series of orders from the same ordering office within 30 days that together call for quantities exceeding the limitation in subparagraph (1) or (2) above.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) above.

(d) Notwithstanding paragraphs (b) and (c) above, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 2 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons.

Upon receiving this notice, the Government may acquire the supplies or services from another source.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract 30 days after last Task Order.

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 60 DAYS;

provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 DAYS days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 5 years and 6 month after the day of contract expiration..

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (APR 2012)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 561210.

(2) The small business size standard is $33.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is N/A employees.

(b) Representations.

(1) The offeror represents as part of its offer that it ( ) is, ( ) is not a small business concern.

(2) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents, for general statistical purposes, that it ( ) is, ( ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (b)(3) of this provision.] The offeror represents as part of its offer that--

(i) It ( ) is, ( ) is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ----------.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (b)(4) of this provision.] The offeror represents as part of its offer that--

(i) It ( ) is, ( ) is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ----------.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a veteran-owned small business concern.

(7) (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (b)(6) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a service-disabled veteran-owned small business concern.

(8) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents, as part of its offer, that--

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (b)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: --------.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(c) Definitions. As used in this provision--

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern," means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (a) of this provision.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned small business concern," means a small business concern --

(1) That is at least 51 percent owned by one or more women; in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000 whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by . . . . . . . . . [insert a description of investigational methods used, such as surveys, auger borings, core borings, test pits, probings, test tunnels].

(b) Weather conditions . . . . . . . . . (insert a summary of weather records and warnings).

(c) Transportation facilities . . . . . . . . . (insert a summary of transportation facilities providing access from the site, including information about their availability and limitations.

(d) . . . . . . . . . . (insert other pertinent information).

52.249-4 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (SERVICES) (SHORT FORM)

(APR 1984)

The Contracting Officer, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the Government shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination.

52.249-4 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (SERVICES) (SHORT FORM)

(APR 1984)

The Contracting Officer, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the Government shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://farsite.hill.af.mil

(End of provision

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://farsite.hill.af.mil

252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (NOV

2011)

(a) Definition. Covered DoD official is defined in the clause at 252.203-7000, Requirements Relating to Compensation of Former DoD Officials.

(b) By submission of this offer, the offeror represents, to the best of its knowledge and belief, that all covered DoD officials employed by or otherwise receiving compensation from the offeror, and who are expected to undertake activities on behalf of the offeror for any resulting contract, are presently in compliance with all post-employment restrictions covered by 18 U.S.C. 207, 41 U.S.C. 2101-2107, and 5 CFR parts 2637 and 2641, including Federal Acquisition Regulation 3.104-2.

252.204-7004 ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (MAY 2013)

(a) Definitions. As used in this clause--

``System for Award Management (SAM) database'' means the primary Government repository for contractor information required for the conduct of business with the Government.

``Commercial and Government Entity (CAGE) code'' means—

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an ``NCAGE code.''

``Data Universal Numbering System (DUNS) number'' means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

``Data Universal Numbering System +4 (DUNS+4) number'' means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR 32.11) for the same parent concern.

``Registered in the System for Award Management (SAM) database'' means that—

(1) The contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, and Contractor and Government Entity (CAGE) code into the SAM database;

(2) The contractor has completed the Core Data, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as part of the SAM registration process; and

(4) The Government has marked the record ``Active.''

Section J - List of Documents, Exhibits and Other Attachments

ATTACHMENTS

This section is PROVIDED IN THE PWS made available for download the following website:

http://www.FBO.gov. OFFERORS ARE RESPONSIBLE FOR MONITORING THIS WEBSITE TO ENSURE THEY HAVE THE MOST RECENT VERSION OF ALL DOCUMENTS. Any struck-through the requirements at this time. Offerrors are NOT required to submit pricing for struck-through items.

Section K - Representations, Certifications and Other Statements of Offerors

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

CLAUSES INCORPORATED BY FULL TEXT

52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)

(a) The offeror certifies that --

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to –

(i) Those prices,

(ii) The intention to submit an offer, or

(iii) The methods of factors used to calculate the prices offered:

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --

(1) Is the person in the offeror's organization responsible for determining the prices offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; or

(2) (i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provison ______________________________________________________ (insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization);

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) above have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) of this provision, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine,…