W912ES22Q0061 Solicitation.pdf

This Request for Quotes (RFQ) is being conducted using FAR Part 13 Simplif ied Acquisition Procedures (SAP).

This is not an Invitation for Bids (IFB) and no bid bond is required.

This procurement is set-aside 100% for Service Disabled Veteran Owned (SDVOSB) small business concerns under North American Industry Classification System (NAICS) code 238310; Drywall and Insulation Contractors, with a small business size standard of $16,500,000.

This construction contract w ill involve removing existing ceiling insulation and lighting from the shop building at Leech Lake, near Federal Dam, in Cass County, MN. The contractor w ill spray closed cell foam insulation on the ceiling and w alls, install Government furnished LED lighting, and supply and install an LP gas heater. If the price exceeds $35,000, the contractor shall provide Payment and Performance Bonds.

The estimated magnitude of construction is betw een $25,000 and $100,000.

JOHN P RIEDERER 651-290-5614

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

21-Apr-2022

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10 Alt1

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________11 May 2020 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______45 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIVISION

USACE - ST PAUL

180 FIFTH STREET EAST

SUITE 700

SAINT PAUL MN 55101-1678

W912ES

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

11:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 651-290-5414 TEL: FAX:

W912ES22Q0061 55

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912ES22Q0061

Section 00 00 00 - Procurement and Contracting Requirements

STATEMENT OF WORK

REMOVAL AND REPLACEMENT OF CEILING & WALL INSULATION, LIGHTING AND

INSTALLING A NEW HEATER IN THE LEECH SHOP

US Army Corps of Engineers

(USACE)

01217 Federal Dam NE Federal Dam, MN 56641-0111

651-290-5808

1. GENERAL: The contractor shall supply all equipment, labor and materials necessary to remove and properly dispose of all the existing ceiling insulation, lighting and replace with new closed cell spray foam insulation, LED lighting and a LP gas heater in accordance with the manufacturer’s recommendations and local building codes.

2. MEASUREMENT AND PAYMENT: The payment provided for in the contract shall constitute full compensation for furnishing all materials and for performing all work under the contract in a complete and acceptable manner. The contract work shall include providing plant, equipment, tools, supplies, labor, supervision, incidental materials, quality control, environmental protection, testing and meeting safety requirements, and for performing all work required for which separate payment is not otherwise provided. Compensation for all work shown, specified, or essential to completion of the project (whether or not the specific material or operation is indicated) shall be included on the bidding schedule. Payment provided for in the contract includes compensation for all risk, loss, damage, and expense arising out of the nature of the work or its prosecution, subject to conditions of the contract.

Payment will be made upon completion and acceptance of all contract work. The contractor must submit a detailed invoice to the Section Supervisor, Jeff Steere for payment at the following address:

US Army Corps of Engineers, Mississippi Headwaters Office, PO Box 625, 34385 US Highway 2 West, Grand Rapids, Minnesota 55744 or emailed to Jeffrey.l.steere@usace.army.mil

2.1 Unit Prices: Payment items for the work of this contract are listed in the PRICING SCHEDULE and described below. The payment items provided for on the bidding schedule embody the work; but the work descriptions provided below do not specifically discuss all incidental work and materials required to complete the contract work.

3. Leech Lake SHOP:

3.1. Description: The Leech Shop is a one level cedar wood covered steel building that was converted into offices and shop in the 1990’s. The framework consists of red metal beams with steel sheeting attached to the metal beams. The approximate size of the shop area to be insulated is 2,400 square feet with 12.5-foot sidewalls, a 14-foot peak and two 10-foot wide by 10-foot-high overhead electric garage doors and one 16-foot high by 10-foot-wide garage door. The existing shop ceiling has two layers of insulation that need to be removed prior to applying the spray foam in the heated bay 20-foot by 40-foot and one layer of insulation in the cold storage bay 40-foot by 40-foot. The first layer of insulation is a 2-inch-thick foil faced hard foam board fastened to 2” by 4” wood furring strips attached to the red metal frame in the heated bay. The layer of insulation next to the steel roof is a one inch layer of fiberglass plastic faced insulation. The lighting is a combination of incandescent light fixtures (12) mounted to the red metal beams in the cold storage bay and fluorescent hanging fixtures (32 feet) above the shop work bench in the heated bay.

4. SPECIFICATIONS:

4.1. Protective Coverings: The contractor shall cover the floors and windows with plastic or tarps to protect the floor and windows from being damage during the spraying of the foam insulation. It is the contractor’s responsibility to remove any materials accidently sprayed on the floors, windows or work bench.

4.2. Removal Ceiling/Wall Insulation and Lighting: The contractor shall supply all equipment, labor and materials required to remove and dispose of the two layers of ceiling insulation, the 2” by 4” wood furring strips that secure the 2” hard foam insulation to the red metal on the ceiling, and all of the incandescent and fluorescent light fixtures, conduit and wiring. The approximate square footage of the ceiling is 2,400 square feet and the square footage of the walls is 2,360 square feet. All materials shall be disposed of in accordance with all required Local and State of Minnesota disposal regulations.

4.3. Spray Foam: The contractor shall spray Closed Cell Spray Polyurethane Foam (here-in referred to as ccSPF) insulation to the underside of the steel shop roof and on all exterior walls. The ceiling insulation should be sprayed to obtain a spray foam R-value of at least R49 (approximately 7 inches) and the walls should be sprayed to obtain a spray foam R-value of at least R21 (approximately 3 inches). The shop area is approximately 40 feet by 60 feet with 12.5-foot walls and a 14-foot peak.

The interior of all the exterior walls within the shop shall be sprayed with enough ccSPF insulation to totally envelope the ceiling, top red steel sill plate and walls. No gaps shall remain unsprayed between the wall and the ceiling. It is the responsibility of the contractor to determine quantity prior to quoting the job, as no allowance will be made for any additional quantities required.

The installing contractor shall have current industry recognized professional training or accreditation for high pressure spray polyurethane foam insulation. Proof of training or accreditation shall be provided at the pre-work conference. Upon completion of the foaming the contractor shall provide the park manager with a summary of the installation, including at a minimum: manufacturer of the insulation, R-value of the product, date of installation, and the contractor’s certification that the installation has been performed in accordance with local code requirements.

Installation of the ccSPF shall be in compliance with all federal, state, and local regulations, including, but not limited to, OSHA National Emphasis Program guidance on Isocyanates. Installation shall comply with all manufacturer’s specifications for installation and utilize industry best practices. The Contractor will be responsible for placement of health and safety barriers within the work zone and is responsible for all clean-up, removal and disposal of materials associated with spray polyurethane foam installation including, but not limited to: decontamination of any surfaces that have come into contact with isocyanates or other ccSPF chemicals, all dust, debris, foam trimmings, empty and partially used containers or drums in accordance with applicable federal, state, and local requirements.

Closed Cell Spray Polyurethane Foam Specifications:

Interior grade Two-component closed-cell foam High pressure application

4.4. Fire-Retardant Topcoat: The contractor shall apply a gray Fire-Retardant topcoat to protect the exposed finished foam insulation according to the manufacturer’s recommendation.

4.5. Spray Foam Warranty: The contractor shall provide any warranty(s) offered by the manufacturer, or which they provide to their other customers in excess of the one-year warranty that is mandated under FAR Clause 52.246-21 Warranty of Construction.

4.6. LED Lighting: The contractor shall supply all equipment, labor and materials required to install new LED lighting in the same location as the existing lighting. The two outside rows of lights in the cold storage shop shall be hung approximately 11 feet off of the floor and the center row of lights shall be mounted flush to the underside of the red I beam in the same location as the existing shop lights.

The new LED lights in the heated shop shall be mounted in the same location as the existing lights.

The new LED lights shall be mounted and hung according to the manufacturer’s recommendations.

The new lighting shall run off the existing light switch located next to the service entry door. All lights and fixtures will be supplied by the Government. The contractor is required to provide new electrical wiring, conduit, fasteners, connecters, junction boxes and light switches necessary to install the new lighting according to the National Electric Code.

Government Supplied Lighting:

Lithonia Lighting LED Linear Strip Light, LED 96” Nominal Length, 3-1/2” Nominal Width, 38.2 Max Fixture Wattage.

Model: CLX L96 600 LM SEFFDLMVOLTG

4.7. High Efficiency Furnace: The contractor shall supply and install a new REZNOR UDAP-75- AA2 power vented LP gas fired unit heater or similar with a wall mounted thermostat, which is capable of efficiently heating the entire cold storage shop 40 foot by 40 foot. The unit shall be suspended from the red metal ceiling support beams near the east wall of the shop. The exact location of the unit shall be determined on-site by the Contractor and Site Ranger. All work shall be completed according to code. The unit shall have the following characteristics:

Aluminum Heat Exchanger Liquid Propane Gas Power Vent (Horizontal) Minimum Heating Capacity 62,000 BTU Maximum Input Capacity 75,000 BTU Efficiency at least 83% Minimum Air Flow 950 CFM Maximum Air Flow 1,000 CFM

Voltage 115 volts Phase Single Frequency 60 Hz Flue Connection 4 inch Parts Warranty 1 Year Heat Exchanger Warranty 10 Years

5. DESCRIPTION AND LOCATION: Leech Lake Dam is a USACE-managed facility that is heavily utilized by the public. The Shop building is located in Federal Dam, MN off State Highway 8 on the Leech River in Cass County. The address is 01217 Federal Dam NE, Federal Dam, MN 56641- 0111.

6. CONTRACT PERIOD: All contract work must be completed by 30 September 2022.

Visitors shall be warned with signs &/or barricades and not be allowed in the work areas while work is being performed.

7. SAFETY: All work shall be performed in accordance with all Federal, State and local laws and regulations and the Corps of Engineers Safety and Health Manual, EM-385-1-1. A copy of this manual can be found on-line at http://140.194.76.129/publications/eng-manuals/em385-1- 1/2008 English/toc.html.

8. ORIENTATION: Prior to the start of work, the Government will provide an orientation to the Contractor and contract personnel which will include discussion of contract requirements, facility inventory, safety considerations, quality control, security and administration. Contractors are encouraged to make a site visit to inspect the Leech Lake project before submitting a bid.

Visits can be prearranged by contacting Jeff Steere at 651-290-5808 or by email at jeffrey.l.steere@usace.army.mil Monday-Friday between the hours of 8:00 am and 4:30 pm.

9. WORK PLAN: The contractor shall submit a Work Plan that details the sequence and scheduling of the proposed work during a Monday-Friday work week. The Work Plan shall be submitted within 10 days of notice to proceed and shall be discussed at the initial pre-construction meeting to be held at the Leech Lake Federal Dam Office. The Work Plan shall be approved prior to start of work.

10. DISPOSAL: All excess materials shall be disposed of off-site in accordance with all local, State and Federal Disposal Codes.

11. SECURITY: The Contractor is responsible for securing the work areas so that park visitors have to maintain a safe distance from all work areas. The Contractor is also responsible for securing the Leech Lake Shop when work is not being performed if Corps personnel are not present so that the shop is not vandalized during the construction phase.

12. WORK AREA: The Contractor is responsible for leaving the work area in the same condition as before the start of the contract work. Any damages to USACE property shall be repaired at the Contractor’s expense.

13. PHOTOS:

13.1. Leech Lake Shop Lighting

13.3. Photo of Steel Framework in Shop with 1” Fiberglass Ceiling Insulation

13.4 Existing Exterior Shop Wall in the Cold Storage Bay

13.5 Existing Heated Shop Ceiling, Lighting & Walls

13.5 Hanging LP Gas Shop Furnace

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Insulation and Lighting Removal

FFP

Remove and Dispose of existing ceiling and wall insulation, light fixures, conduit and wiring.

FOB: Destination

PSC CD: Y1JZ

NET AMT

0002 1 Job Spray Foam Insulation

FFP

Closed Cell Spray Polyurethane Foam insulation on underside of roof and all exterior walls per SOW specifications.

0003 1 Job Fire Retardant Top Coating

FFP

Apply gray fire-retardant topcoat to exposed finish foam insulation

0004 1 Job Install LED Lighting

FFP

Install Government-furnished LED lighting in same location as existing lights.

0005 1 Job Supply and Install LP Gas Heater

FFP

Supply and install high efficiency LP gas fired unit heater with wall mounted thermostat.

0006 1 Job Payment Bonds

FFP

Only required if total price is $35,000 or higher.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 30-SEP-2022 1 LEECH LAKE

JEFF STEERE

01217 FEDERAL DAM DR. NE

FEDERAL DAM MN 56641-0111

651-290-5808

966309

0002 30-SEP-2022 1 (SAME AS PREVIOUS LOCATION)

0003 30-SEP-2022 1 (SAME AS PREVIOUS LOCATION)

0004 30-SEP-2022 1 (SAME AS PREVIOUS LOCATION)

0005 30-SEP-2022 1 (SAME AS PREVIOUS LOCATION)

0006 10 dys. ADC 1 CONTRACTING DIVISION

JOHN RIEDERER

USACE - ST. PAUL

180 FIFTH STREET EAST

SUITE 700

SAINT PAUL MN 55101-1678

(651) 290-5614

966323

Section 00 21 00 - Instructions

INSTRUCTIONS TO OFFEROR

PLEASE E-MAIL ALL QUESTIONS to John Riederer, Contract Specialist, John.P.Riederer@usace.army.mil

This is a 100% Service Disabled Veteran Owned Small Business (SDVOSB) Set-Aside request for quotes (RFQ).

NAICS Code: 238310 Size Standard: $16.5 million

It is preferred that the quote is e-mailed to:

John Riederer, Contract Specialist, John.P.Riederer@usace.army.mil

OFFEROR SHALL BE REGISTERED IN SAM (System for Award Management) https://www.sam.gov to include the FAR and DFARS Reps and Certs sections with the NAICS code applicable to the solicitation.

For assistance with SAM, contact information is below:

SAM by GSA Hours of Operation: Monday – Friday 8am to 8pm ET, U.S. Calls 866-606-8220, Service desk website: http://www.fsd.gov/

Quotes must be RECEIVED no later than the Offer Due Date/Time listed in the SAM.gov solicitation posting.

Quotes received after the deadline are considered late, and may not be considered for award.

Quotes must include specific acknowledgement of all amendments to the solicitation (if any).

Quotes that do not acknowledge amendments may not be considered for award.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Alt I Notice of Buy American Requirement--Construction Materials (Feb 2009) Alternate I

MAY 2014

CLAUSES INCORPORATED BY FULL TEXT

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance

Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

2.2 percent 6.9 percent

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Leech Lake Recreation Area, near Federal Dam, in Cass County, Minnesota.

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Jeff Steere Address: Jeffrey.L.Steere@usace.army.mil Telephone: 651-290-5808

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquistion.gov/

Section 00 45 00 - Representations and Certifications

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting AUG 2020 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2022)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238310.

(2) The small business size standard is $16,500,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(D) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-

Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government 0005 N/A N/A N/A Government 0006 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

DEC 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

DEC 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

DEC 2021

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-6 Brand Name or Equal AUG 1999 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-19 Child Labor -- Cooperation with Authorities and Remedies JAN 2022

52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-50 Combating Trafficking in Persons DEC 2021 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.223-20 Aerosols JUN 2016 52.223-21 Foams JUN 2016 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2021

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-12 Cleaning Up APR 1984 52.236-14 Availability and Use of Utility Services APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Products and Commercial

Services

JAN 2022

52.245-1 Government Property SEP 2021 52.246-21 Alt I Warranty of Construction (Mar 1994) - Alternate I APR 1984 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 September 2022. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 15 June 2022. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES) (JAN 2022)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (NOV 2021) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii)…