Amendment 4 W912ES22B0001.pdf

W81G6713232523

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Please see the Section SF 30 Block 14 Continuation Page Summary of Changes for the purpose of this amendment.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 10-Feb-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912ES22B0001

X 9B. DATED (SEE ITEM 11)

18-Jan-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

10-Feb-2022

CODE

CONTRACTING DIVISION

USACE - ST PAUL

180 FIFTH STREET EAST

SUITE 700

SAINT PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES22B0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 4

The purpose of this amendment is as follows:

1. Revise 52.211-10 Alternate I, from:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 07/31/2023 for all sites. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 04/08/2022. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

To:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than as follows:

All base construction (CLIN’s/bid item numbers 0001-0016) for LD6 shall be completed by 07/31/2023.

Completion date for option 1 work (CLIN’s/bid item number 0017) for LD6: if the option is exercised and the contractor does not have 180 days from the option exercise date to complete the work, the completion date for LD6 will be adjusted to provide 180 days from the exercise of option date.

All construction for LD10 shall be completed by 07/31/2023.

The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 04/08/2022. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

2. Revise the Option For Additional Work Supplementary condition from:

Option For Additional Work

The option for this procurement is for the LD6 project only.

The Government may require the Contractor to perform the work identified in the LD6 bid schedule only as option item number 0017 at the price stated in the schedule. The Contracting Officer may exercise the option by written notice to the Contractor on or before June 30, 2023. Exercise of the option does not extend the completion date detailed in FAR clause 52.211-10 Alt. I.

To:

Option For Additional Work

The option for this procurement is for the LD6 project only.

The Government may require the Contractor to perform the work identified in the LD6 bid schedule only as option item number 0017 at the price stated in the schedule. The Contracting Officer may exercise the option by written notice to the Contractor on or before June 30, 2023. See FAR clause 52.211-10 Alt. I regarding the completion date for the option if exercised.

Changes/additions are highlighted in yellow; deletions are not shown. All other terms and conditions remain unchanged.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than as follows:

All base construction (CLIN’s/bid item numbers 0001-0016) for LD6 shall be completed by 07/31/2023.

Completion date for option 1 work (CLIN’s/bid item number 0017) for LD6: if the option is exercised and the contractor does not have 180 days from the option exercise date to complete the work, the completion date for LD6 will be adjusted to provide 180 days from the exercise of option date.

All construction for LD10 shall be completed by 07/31/2023.

The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 04/08/2022. The completion date will be extended by the number of calendar days after the above date that the

Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

OPTION FOR ADDITIONAL WORK

The option for this procurement is for the LD6 project only.

The Government may require the Contractor to perform the work identified in the LD6 bid schedule only as option item number 0017 at the price stated in the schedule. The Contracting Officer may exercise the option by written notice to the Contractor on or before June 30, 2023. See FAR clause 52.211-10 Alt. I regarding the completion date for the option if exercised.

(End of Summary of Changes)