17-T-0099-0001.pdf

W81G6771776154

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The reason for this amendment is to adjust the specifications for the bench and trashcan.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 11

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 07-Aug-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912ES17T0099

X 9B. DATED (SEE ITEM 11)

20-Jul-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

07-Aug-2017

CODE

CONTRACTING DIVISION

USACE - ST. PAUL

180 5TH STREET E SUITE 700

ST. PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES17T0099

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 28-Jul-2017 03:00 PM to 10-Aug-2017 11:00 AM.

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

06-OCT-2017 1 N/A

FOB: Destination

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

13-OCT-2017 1 N/A

FOB: Destination

The following have been modified:

SCOPE OF WORK

SUPPLY AND INSTALL NEW PLAY SYSTEM, CONTAINMENT SYSTEM, AND SURFACING

The work site is located at the U.S. Army Corps of Engineers, Eggert’s Landing Recreation Area ‐ 13 miles north of Valley City, North Dakota off of County Highway 1 in Barnes County. All work is to be performed in strict accordance with these specifications and according to County, State and National Safety Standards and ADA Accessibility Guidelines. The contractor shall supply all equipment, labor and materials required to furnish and install new commercial grade play system and playground boarder, to be filled with a base of Pea Rock and engineered wood fiber fall protection media, throughout the playground complex. For location of the play area at the Eggert’s Landing Recreation Area, see the attached campground site map.

US ARMY CORPS OF ENGINEERS

Lake Ashtabula / Baldhill Dam Recreation Area

2630 114th Ave. SE Valley City, ND 58072

701‐845‐2970

DESCRIPTION/SPECS/PERFORMANCE WORK STATEMENT

SUPPLY/DELIVERY/INSTALL NEW PLAY SYSTEM AT EGGERTS’S LANDING RECREATION AREA

1. GENERAL.

1.1. Scope of Work. The work to be performed under this contract consists of furnishing all plant, materials, equipment, supplies, labor and transportation and performing all work as required by the contract, in strict accordance with the specifications and in accordance with federal, state and local laws and regulations. All work materials and services not expressly called for in the specifications but which are necessary for completion of the contract requirements shall be performed and furnished by the Contractor at no increase in price to the Government.

1.2. Payment. The contractor must submit a copy of the payrolls and ENG93 to the Section Supervisor at the following address: US Army Corps of Engineers, Lake Ashtabula / Baldhill Dam 2630 114th Ave. SE Valley City, ND 58072.

1.3. Description and Location. The Eggert’s Landing Recreation Area is a Corps of Engineers managed recreation area with heavily utilized facilities including a campground, boat ramp, beach, playgrounds, etc. It is located approximately 13 miles North of Valley City, ND 58072.

1.4. Contract Period. All contract work must be completed by 6 October 2017. A 2‐week notice must be given to the POC before installation may proceed to allow time for site preparation.

1.5. Safety. All work shall be performed in accordance with all state, federal and local laws and regulations and the Corps of Engineers Safety and Health Manual, EM‐385‐1‐1. A copy of this manual can be found online at:

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385‐1‐ 1.pdf

2 SPECIFICATIONS

2.1 General Description: Work under this contract includes:

Installation of new play systems, 8’ bench with back rest, garbage can, linear high‐density polyethylene border, pea rock and engineered wood fiber media as described below. All product colors must be approved by project POC prior to ordering. The garbage receptacle shall have a domed push lid, and contain a 24 gallon can. An example playground layout has been provided. The layout is provided for informational purposes only and does not mandate any make or model of playground equipment to be provided under the resulting contract.

2.2. Delivery: The Contractor shall coordinate all Deliveries of materials through the project POC’S Joel Zietz and/or Chris Botz. They can be reached at 701‐845‐2970.

2.3. Installation of Play System Components: The Contractor shall install new commercial grade playground system components as follows. See Exhibit A for approximate installation location.

2.3.1. Play system: The Contractor shall install new Commercial Playground Systems equivalent to the following material specifications provided by Dakota Playground of landscape structures. The play system shall be installed within a 44’ by 80’ impact area to accommodate the safety use zone required.

o Slides and plastic components of the play system are to be Tan in color, platforms shall be Brown in color, and posts shall be green in color and the rails brown in color.

o At least one climbing structure (rock wall type) shall be installed on the main play system and have a minimum vertical height of 72”.

o Play system should be designed for children 5 to 12 years of age.

o The plastic tube slides and spiral slides shall have a minimum 5 year warranty free from defects in materials and workmanship.

o Post(s) diameter shall be no less than 5” o Minimum Number of Play Activities: 15 (Example: tube slide, spiral slide, shimmy bars, monkey bars, bubble panel, binoculars, rock wall, stair climber, cargo chain ladder ship’s wheel) o Child Capacity: The play system shall be designed to handle a minimum 20 kids at a time.

2.3.2. A 2 Bay Swing Set, shall be installed on the west side of the Play System, centered in a manner so that the manufacturers use zone requirements for the component are met.

o Swings for the component shall include: 2 qty belt swings and 1 qty ADA adaptive swing seat (rated to hold 125 pounds) and 1 swing seat with molded seat/Harness.

o Swing set legs & top rail shall be constructed of at least 5” in diameter aluminum/steel with a beam height of 8 feet.

o Swing hangers shall be self‐lubricating

2.3.3 Single Child Play Items, The Contractor shall install two (2) freestanding single child play items. One (1) coil spring type bobble ride and one (1) spinning seat (saddle spinner, Spinner Bowl) type item.

o The coil spring for the bobble type ride shall be designed in a way to prevent children from pinching their fingers in the spring.

o Play items should be designed for children 5 to 12 years of age.

2.4. Installation of Play System: The play system shall be installed according to manufacturer’s recommendations and must meet all national, state and local playground safety and ADA codes.

2.5. Installation of Containment Border: The Contractor is responsible for installing a playground containment border around the 44’ X 80 impact area.

2.5.1 Border. U.V. stabilized high –density polyethylene 4’’ wide by 12” high shall be used as the playground containment border.

o The border shall be installed level, plumb, and have 90 degree corners and straight sides.

2.5.2 Installation of ADA Threshold Ramp: One threshold ramp, consistent with ADA guidelines for playgrounds, shall be installed on the main play area containment border.

o Ramp shall be made from U.V. stabilized linear low density polyethylene black in color.

o Ramp shall be secured with in accordance with the manufacturer’s installation instructions.

2.6. Playground Surfacing Material (Impact Media). A weed preventive geotextile fabric barrier shall be laid down and base layer of pea rock (washed smooth rounded stones roughly the size of a pea) shall be installed 3” deep over the geotextile prior to placement of engineered wood fiber playground surfacing material. Surfacing material shall be laid at a continuous depth of 12 inches (non‐compacted) within the containment border. The Surfacing material shall be raked level.

2.7. Size of Play System/Swing Set Impact Area: All playground areas in the complex shall have impact media installed. The impact area of the play system with new components shall be 44 feet wide by 80 feet long.

2.8. Work Area: Any damages to facilities or the lawn area shall be repaired at the contractor’s expense. All construction debris shall be removed and disposed of off‐site in accordance with local and state regulations.

C‐3.0. ATTACHMENTS

C‐3.1. Exhibit A. Installation location of Playground

SECTION 00700 - CONTRACT CLAUSES

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 13 October 2017 The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 25 August 2017. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

WAGE RATES

General Decision Number: ND170015 07/07/2017 ND15

Superseded General Decision Number: ND20160015

State: North Dakota

Construction Type: Heavy

Counties: Adams, Barnes, Benson, Billings, Bottineau, Bowman, Burke, Cavalier, Dickey, Divide, Dunn, Eddy, Emmons, Foster, Golden Valley, Grant, Griggs, Hettinger, Kidder, La Moure, Logan, McHenry, McIntosh, McKenzie, McLean, Mercer, Mountrail, Nelson, Oliver, Pembina, Pierce, Ramsey, Ransom, Renville, Richland, Rolette, Sargent, Sheridan, Sioux, Slope, Stark, Steele, Stutsman, Towner, Traill, Walsh, Ward, Wells and Williams Counties in North Dakota.

HEAVY CONSTRUCTION PROJECTS (including Sewer & Water Line Construction & Drainage Projects and Excluding Industrial and Processing Plants and Refineries)

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.20 for calendar year 2017 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.20 (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2017.

The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2017 1 07/07/2017

* ELEC0714-009 07/01/2017

ADAMS, BILLINGS, BOTTINEAU, BOWMAN, BURKE, DIVIDE, DUNN,

EMMONS, GOLDEN VALLEY, GRANT, HETTINGER, MCHENRY, MCKENZIE,

MCLEAN, MERCER, MOUNTRIAL, OLIVER, PIERCE, RENVILLE, ROLLETTE,

SHERIDAN, SOIUX, SLOPE, STARK, WARD, & WILLIAMS COUNTIES:

Rates Fringes

CABLE SPLICER....................$ 40.91 9.10+10.5%

ELECTRICIAN......................$ 40.51 9.10+10.5%

ELEC1426-012 12/01/2016

BARNES, BENSON, CAVALIER, DICKEY, EDDY, FOSTER, GRIGGS, KIDDER,

LAMOURE, LOGAN, MCINTOSH, NELSON, PEMBINA, RAMSEY, RANSOM,

RICHLAND, SARGENT, STEELE, STUTSMAN, TOWNER, TRAILL, WALSH, &

WELLS COUNTIES:

Rates Fringes

ELECTRICIAN

CABLE SPLICER...............$ 28.30 11.26

ELECTRICIAN.................$ 29.77 11.82

ENGI0049-037 10/01/2016

Rates Fringes

Power equipment operators:

GROUP 1.....................$ 27.90 15.60

GROUP 2.....................$ 27.00 15.60

GROUP 3.....................$ 26.75 15.60

GROUP 4.....................$ 26.60 15.60

GROUP 5.....................$ 25.75 15.60

POWER EQUIPMENT OPERATORS CLASSIFICATIONS:

GROUP 1: All Terrain Vehicle Cranes 80 tons and over, Hydro, Cranes, 80 Tons and over, Crane Operator with 135' boom and Over, Gantry Crane Operator, & Traveling Tower Crane.

GROUP 2: All Terrain Vehicle Cranes over 20 tons and up to 80 tons, Hydro Cranes 20 tons up to 80 tons, Creter Crane, & Crane Operator up to 135' Boom.

GROUP 3: All Terrain Vehicle Cranes thru 20 tons, Hydro Cranes thru 20 tons, Tractor with boom attachment.

GROUP 4: Push Tractor Roller

GROUP 5: Tractor pulling Compaction or Areating Equipment

TEAM0638-001 10/01/2016

Rates Fringes

TRUCK DRIVER

ARTICULATED OFF ROAD HAULER.$ 28.05 12.05

SUND2000-007 05/04/2000

Rates Fringes

CARPENTER

CARPENTER (Including Form building & Concrete Forms).$ 13.98

Concrete Finisher/Cement Mason...$ 14.37 3.67

Ironworker

REINFORCING.................$ 17.03

Laborers:

Common......................$ 9.96 Pipelayers..................$ 10.48

PAINTER (Brush and Spray)........$ 18.14

Power equipment operators:

Backhoes....................$ 14.00 3.74 Bobcat......................$ 12.82 2.35 Bulldozer...................$ 14.06 4.00 Excavator...................$ 12.05 Front End Loader............$ 13.15 3.17 Mechanic....................$ 15.16 5.31 Motor Grader................$ 14.74 4.51 Scraper.....................$ 13.85 4.25 Self Propelled Packer.......$ 11.55 4.25 Sheepsfoot..................$ 12.57 3.23 Skidster....................$ 11.06 2.05

TRUCK DRIVER

Dump (Excludes Semi and Tandem Dump Trucks).........$ 11.39 3.60 Semi (Includes Semi Dump Trucks).....................$ 11.52 .23 Tandem (Includes Tandem Dump Trucks)................$ 11.14 1.63

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour

Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

(End of Summary of Changes)