Devils_Lake_Amendment_1.pdf

W81G6771565286

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Please see the block 14 continuation page for the purpose of this amendment.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-Aug-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912ES17B0008

X 9B. DATED (SEE ITEM 11)

08-Aug-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Aug-2017

CODE

CONTRACTING DIVISION

USACE - ST. PAUL

180 5TH STREET E SUITE 700

ST. PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES17B0008

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

AMENDMENT 1

The purpose of this amendment is as follows:

1.) The contract completion date was revised from November 30, 2017 to June 30, 2018.

2.) Line item number 0005 was revised to the following. Please use the attached Devils Lake Amendment 1 Bid Schedule.

0005 Filter Stone Cap 0005AA Filter Stone Cap – First 8,835 TON 8,835 TON $ $

0005AB Filter Stone Cap – Over 8,835 TON 1,560 TON $ $

3.) Changes to the following Specification Sections are being made.

a) Section 32 92 19.00 13 – Seeding, paragraph 2.1.2 Seeding Species and Mixtures, delete table and replace with the following table:

Mix Designation Pounds Pure Live Seed

Per Acre

Permanent Seed Species (see note 1)

Class II ‐ Season Late Early

Western Wheatgrass 9.6 9.6

Switchgrass 1.6 3.2

Green Needlegrass 3.6 2.4

Canada Wild‐rye 5.2

Sideoats Grama 3.6

Slender Wheatgrass 5.0 5.0

TOTAL 25.0 23.8

Temporary Seed Species

Oats 64.0 64.0

Note 1 ‐ If dormant seeding methods apply, provide late season permanent seed species at twice the rate specified.

b) Section 32 92 19.00 13 – Seeding, paragraph 3.1.2 Seeding Time, delete paragraph and replace with the following paragraph:

3.1.2 Seeding Time

Fall seeding shall be installed using dormant seeding methods. Seed after October 20 and when soil temperature is at or below 40 degrees at 1‐inch depth. Fall seeding shall use Class II late season seed mix. Spring seeding will occur after April 20 and will use Class II early season seed mixture.

No finished construction area shall be left untopsoiled and unseeded. When substantially complete areas are not seeded within the specified seeding times, a temporary cover shall be placed.

4.) Changes to the following Plan Sheets are being made.

a) Drawing CS‐501, Detail A4 – Filter Stone Cap Detail 5, is changed as noted on the attached drawing.

All other terms and conditions remain unchanged.

SECTION 00 10 00 - SOLICITATION

SUBCLIN 0005AA

The pricing detail quantity has decreased by 745.00 from 9,580.00 to 8,835.00.

SUBCLIN 0005AB

The pricing detail quantity has decreased by 130.00 from 1,690.00 to 1,560.00.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than June 30, 2018. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by October 11, 2017. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,156.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)