Revised Specs 01 11 00 par 1.3.pdf

St. Francis Barracks Seawall Improvements CAP (Sec-14), Shoreline Erosion Protection Project

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

03/20

PART 1 GENERAL

1.1 REFERENCES

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.2.3 Work Restrictions

1.2.3.1 Work Hours and Workdays

1.2.3.2 Work Performance

1.2.4 Safety Requirements

1.2.5 Work Performed by Others

1.3 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

1.4 LIQUIDATED DAMAGES - CONSTRUCTION

1.5 PHYSICAL DATA

1.5.1 Physical Conditions

1.5.2 Weather, Water Stage and Tide Data

1.5.3 Contractor Investigation

1.6 LAYOUT OF WORK

1.6.1 Established Project Control

1.6.2 Layout

1.6.3 Survey

1.7 DAMAGE TO WORK

1.8 EXISTING WORK

1.9 LOCATION OF UNDERGROUND FACILITIES

1.9.1 Notification Prior to Excavation

1.10 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 1989)

1.10.1 Schedule of Monthly Anticipated Adverse Weather Delays

1.10.2 Contractor Responsibility

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1 W912EP22R0007 Amendment 0002

SECTION 01 11 00

SUMMARY OF WORK

03/20

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

GDR Section 00 31 32, Geotechnical Data Report for St. Francis Barracks Seawall, Continuing Authorities Program (Sec-14), Shoreline Erosion Protection Project, St.

Johns, Florida

EM 385-1-1 Safety and Health Requirements Manual

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes the following construction tasks: install a gravel "French style" drain system enclosed within a geotextile fabric lining and, through the wall, weep drains along the entire 527 feet long coquina block seawall (except along the 54 feet wooden building and 20 feet rear porch slab), patch/fill existing block voids/cracks, realign 20 feet(+/-) of granite capstone, as well as repoint all mortar joints over the entire northern 472 feet portion of the seawall, install a concrete trench "gutter style" drain between the seawall and the existing wooden building, fill any soil voids encountered under the rear porch slab, immediately adjacent to the gravel and trench drains, with an approved Controlled Low Strength Material (CLSM), install 53 feet of cast-in-place fronting wall with eight through-wall tie rods anchoring into one of the two concrete deadman at the southern end or corner of the seawall, install outfall piping and sodding, relocate sprinklers and electrical conduit.

1.2.2 Location

The project is located in downtown St. Augustine, south of the Bridge of Lions along the Matanzas River, immediately to the east of the Florida National Guard Headquarters, in St. Johns County, Florida.

1.2.3 Work Restrictions

1.2.3.1 Work Hours and Workdays

Work hours are Monday through Friday, 8AM to 6PM, excluding Federal Holidays both actual and observed. Any work outside these stated hours must be coordinated and approved in advance by the Contracting Officer a minimum of one week, five business days prior to the need to work outside

SECTION 01 11 00 Page 2 stated hours.

1.2.3.2 Work Performance

All work on this contract must be performed from land. Work from the water, using a barge or other floating platform, is not pemitted.

Ground disturbing activities are not permitted without physical presence of the Florida National Guard Archaelogical Monitor onsite. Contractor must provide a minimum one week, five businesss days written notice to the Contracting Officer prior to conducting any ground disturbing activities, as well as preparatory meetings relating to such activities.

Ground disturbing activities are not permitted until all contractor and subcontractor personnel working on the site have completed Cultural Resource Training required by paragraph CULTURAL RESOURCE TRAINING in section 01 57 20 ENVIRONMENTAL PROTECTION. Contractor is responsible to maintain a record of this training for employees.

1.2.4 Safety Requirements

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and EM 385-1-1 .

1.2.5 Work Performed by Others

See paragraph PROJECT COORDINATION of Section 01 30 00 ADMINISTRATIVE

PROCEDURES.

1.3 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

Read this paragraph in conjunction with the Clause COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10) of Section 00700 CONTRACT CLAUSES in Volume 1. Grass must be established not later than the time stated in the Clause COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10) of Section 00700 CONTRACT CLAUSES in Volume 1. The time stated for completion includes final cleanup of the premises. The time stated for completion does not include the 3 month Sod Establishment Period required by Section 32 92 23 SODDING, paragraph SOD ESTABLISHMENT

PERIOD.

1.4 LIQUIDATED DAMAGES - CONSTRUCTION

Refer to the Clause LIQUIDATED DAMAGES - CONSTRUCTION (FAR 52.211-12) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5 PHYSICAL DATA

Read this paragraph in conjunction with the Clause PHYSICAL DATA (FAR 52.236-4) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5.1 Physical Conditions

The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys and/or by core borings. When the indicated physical conditions are the result of site investigations by core borings, the core boring logs and laboratory data are in Section 00 31 32 GEOTECHNICAL DATA REPORT ( GDR) and the core boring locations are shown on the drawings. Also, see the GDR for instructions concerning availability of core borings for inspection.

SECTION 01 11 00 Page 3

1.5.2 Weather, Water Stage and Tide Data

See Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA.

1.5.3 Contractor Investigation

Refer to the Clause SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (FAR 52.236-3) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6 LAYOUT OF WORK

Read this paragraph in conjunction with the Clause LAYOUT OF WORK (FAR 52.236-17) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6.1 Established Project Control

The Government has established monuments along the work site(s). Each monument is represented in the contract drawings by a Designation and in most cases, an alphanumeric Permanent Identifier (PID). Information concerning the location and elevations can be found within the Survey Notes on the plan sheets. The Survey Notes for each included field survey will cite a particular survey number, and specify the control used to conduct that survey. Additional information is included in the Survey Notes that must be duplicated if an attempt to recreate the subject survey is desired.

For navigation channels, the Government has established tidal calibration sites for projects constructed and maintained to a tidal datum. Each tidal calibration site is represented in the plan sheet drawings by Station ID, and is cited in the Survey Notes. All projects constructed and maintained to a tidal datum shall be calibrated to the Station ID specified in the plan sheet drawings. Information regarding the location and associated benchmarks of the referenced Station ID is included in the Monument Description section of these specifications.

See Section 00 31 21 CONTROL MONUMENT DESCRIPTIONS.

1.6.2 Layout

From the monuments, control data and elevations established by the Government, complete the layout of the work and obtain all measurements that may be required for the execution of the work to the location and limit marks prescribed in the specifications or on the contract drawings, subject to such modifications as the Contracting Officer may require to meet changed conditions or as a result of necessary modifications to the contract work.

1.6.3 Survey

Provide equipment, tools, material, labor for laying out any part of the work from the monuments, control data, and elevations established by the Government. Maintain and preserve all monuments, stakes and other marks established by the Contracting Officer until authorized to remove them, and if such marks or monuments are destroyed by the Contractor or through negligence, prior to their authorized removal, they may be replaced by the Contracting Officer, at their discretion, and the expense of replacement will be deducted from any amounts due or to become due the Contractor.

The Contracting Officer may require that work be suspended at any time

SECTION 01 11 00 Page 4 when location and limit marks established by the Contractor are not reasonably adequate to permit checking of the work.

1.7 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work will be as set forth in Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1. However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood, earthquake, hurricane, or tornado, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable Contract unit or job prices as fixed and established in the Contract. If, in the opinion of the Contracting Officer, there are no contract unit or job prices applicable to any part of such work, an equitable adjustment pursuant to Clause CHANGES of Section 00700 CONTRACT CLAUSES in Volume 1 will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or job prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant shall be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

1.8 EXISTING WORK

In addition to FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.9 LOCATION OF UNDERGROUND FACILITIES

Scan the construction site with electromagnetic or sonic equipment, and mark the surface of the ground where existing underground utilities are discovered. Verify the elevations of existing piping, utilities, and any type of underground obstruction not indicated or specified to be removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made. Perform toning where indicated or shown by the Contracting Officer.

1.9.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work. Contact Florida utility 5 days prior to excavating.

Contractor is responsible for marking all utilities not marked by Florida utility.

SECTION 01 11 00 Page 5

1.10 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 1989)

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Clause DEFAULT (FIXED-PRICE CONSTRUCTION) of Section 00700 CONTRACT CLAUSES in Volume 1. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

1.10.1 Schedule of Monthly Anticipated Adverse Weather Delays

The schedule of monthly anticipated adverse weather delays is based upon National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

See Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA to obtain AVERAGE MONTHLY ANTICIPATED ADVERSE WEATHER DAYS BASED ON 5-DAY WORK WEEK. The Contractor will estimate a reasonable number of anticipated weather delay work days with precipitation greater than that indicated in Section

00 33 50 WEATHER, WATER STAGE AND TIDE DATA.

1.10.2 Contractor Responsibility

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the Contract, record on the daily CQC report the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day. Include the number of actual adverse weather delay days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA (rounded to the nearest whole number), the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Clause DEFAULT (FIXED PRICE CONSTRUCTION) of Section 00700 CONTRACT CLAUSES in Volume 1.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 11 00 Page 6