18B0015_Amendment_0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Flood Control and Coastal Emergency, Beach Erosion Control Project, Broward County, Florida, Broward County Segment III

A. See Continuation Sheet For Amendments details.

B. The Proposal Due Date Remain Unchanged 20 Nov 2018 @ 2:00 PM Local Time.

C. All Other Terms And Conditions Remain Unchanged

1. CONTRACT ID CODE PAGE OF PAGES

1 128

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EP18B0015

X 9B. DATED (SEE ITEM 11)

26-Oct-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

26-Oct-2018

CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

W912EP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

SF 30 CONTINUATION SHEET

Flood Control and Coastal Emergency, Beach Erosion Control Project, Broward County, Florida, Broward County Segment III

W912EP18B0015 2 Amendment 0001

SUMMARY OF CHANGES

1. SPECIFICATIONS:

The text changes have been updated with additions noted by underlined text and deletions noted by line/cross-outs, and pertain only to changes made by this amendment. The entire section is replaced if there is any change.

DELETE Standard Form 1442 and REPLACE with the attached revised Standard Form 1442.

DELETE Section 00010A and REPLACE with the attached revised Section 00010A.

Changes to Section 00700 CONTRACT CLAUSES:

DELETE Clause 52.211-10 and REPLACE with the below revised Clause 52.211-10.

DELETE Clause 52.211-12 and REPLACE with the below revised Clause 52.211-12.

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OFWORK

The Contractor shall be required to (a) commence work under this contract within 45 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than April 29, 2019. The time stated for completion shall include final cleanup of the premises.

Coastal vegetation shall be established no later than May 29, 2019.

52.211-12 LIQUIDATEDDAMAGES--CONSTRUCTION

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $3,743.00 for construction and $936.00 for coastal vegetation establishment for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Add to Section 00700 FAR Clause 52.211-13 TIME EXTENSIONS (SEP 2000), as follow:

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule. (End of clause)

DELETE Section 01 11 00 and REPLACE with the attached revised Section 01 11 00.

DELETE Section 01 22 00 and REPLACE with the attached revised Section 01 22 00.

DELETE Submittal Register and REPLACE with the attached revised Submittal Register.

DELETE Section 01 55 26 and REPLACE with the attached revised Section 01 55 26.

DELETE Section 01 57 20 and REPLACE with the attached revised Section 01 57 20.

DELETE Section 02 22 13 and REPLACE with the attached revised Section 02 22 13.

DELETE Section 32 93 00 and REPLACE with the attached revised Section 32 93 00.

DELETE Section 35 30 00 and REPLACE with the attached revised Section 35 30 00.

See next page for changes to drawings.

SF 30 CONTINUATION SHEET

Flood Control and Coastal Emergency, Beach Erosion Control Project, Broward County, Florida, Broward County Segment III

W912EP18B0015 3 Amendment 0001

2. DRAWINGS (Separate Electronic File):

DELETE Sheet ID G-01 and REPLACE with the attached revised Sheet ID G-01.

DELETE Sheet ID G-02 and REPLACE with the attached revised Sheet ID G-02.

DELETE Sheet ID G-03 and REPLACE with the attached revised Sheet ID G-03.

DELETE Sheet ID G-04 and REPLACE with the attached revised Sheet ID G-04.

DELETE Sheet ID G-05 and REPLACE with the attached revised Sheet ID G-05.

DELETE Sheet ID C-01 and REPLACE with the attached revised Sheet ID C-01.

DELETE Sheet ID C-02 and REPLACE with the attached revised Sheet ID C-02.

DELETE Sheet ID C-03 and REPLACE with the attached revised Sheet ID C-03.

DELETE Sheet ID C-04 and REPLACE with the attached revised Sheet ID C-04.

DELETE Sheet ID C-05 and REPLACE with the attached revised Sheet ID C-05.

DELETE Sheet ID C-06 and REPLACE with the attached revised Sheet ID C-06.

DELETE Sheet ID C-07 and REPLACE with the attached revised Sheet ID C-07.

DELETE Sheet ID C-08 and REPLACE with the attached revised Sheet ID C-08.

DELETE Sheet ID C-09 and REPLACE with the attached revised Sheet ID C-09.

DELETE Sheet ID C-10 and REPLACE with the attached revised Sheet ID C-10.

DELETE Sheet ID C-11 and REPLACE with the attached revised Sheet ID C-11.

DELETE Sheet ID C-12 and REPLACE with the attached revised Sheet ID C-12.

DELETE Sheet ID C-13 and REPLACE with the attached revised Sheet ID C-13.

DELETE Sheet ID C-14 and REPLACE with the attached revised Sheet ID C-14.

DELETE Sheet ID C-15 and REPLACE with the attached revised Sheet ID C-15.

DELETE Sheet ID C-16 and REPLACE with the attached revised Sheet ID C-16.

DELETE Sheet ID C-17 and REPLACE with the attached revised Sheet ID C-17.

DELETE Sheet ID C-18 and REPLACE with the attached revised Sheet ID C-18.

DELETE Sheet ID C-19 and REPLACE with the attached revised Sheet ID C-19.

DELETE Sheet ID C-20 and REPLACE with the attached revised Sheet ID C-20.

DELETE Sheet ID C-21 and REPLACE with the attached revised Sheet ID C-21.

DELETE Sheet ID C-22 and REPLACE with the attached revised Sheet ID C-22.

DELETE Sheet ID C-23 and REPLACE with the attached revised Sheet ID C-23.

DELETE Sheet ID C-24 and REPLACE with the attached revised Sheet ID C-24.

DELETE Sheet ID C-25 and REPLACE with the attached revised Sheet ID C-25.

DELETE Sheet ID C-26 and REPLACE with the attached revised Sheet ID C-26.

ADD the attached new Sheet ID C-27.

ADD the attached new Sheet ID C-28.

ADD the attached new Sheet ID C-29.

ADD the attached new Sheet ID C-30.

ADD the attached new Sheet ID C-31.

ADD the attached new Sheet ID C-32.

ADD the attached new Sheet ID C-33.

ADD the attached new Sheet ID C-34.

ADD the attached new Sheet ID C-35.

ADD the attached new Sheet ID C-36.

ADD the attached new Sheet ID C-37.

ADD the attached new Sheet ID C-38.

ADD the attached new Sheet ID C-39.

(End of Summary of Changes)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

W912EP18B0015

2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

X SEALED BID (IFB)

NEGOTIATED (RFP)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY CODE W912EP 8. ADDRESS OFFER TO (If Other Than Item 7) CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

TEL: FAX:

See Item 7

TEL: FAX:

9. FOR INFORMATION

CALL:

A. NAME

TONYA M ROGERS

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

904-232-1084

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

Flood Control and Coastal Emergency, Beach Erosion Control Project, Brow ard County, Florida, Brow ard County Segment III

DESCRIPTION OF WORK: REFER TO SECTION 01 11 00 FOR COMPLETE PROJECT DESCRIPTION

DRAWINGS: SEE SECTION 00700, DFARS CLAUSE 252.236-7001.

MAGNITUDE OF CONSTRUCTION IS BETWEEN $5,000,000.00 AND $10,000,000.00.

THIS IS A SMALL BUSINESS SET-ASIDE SOLICITATION. THE NAICS CODE IS 237990 AND SMALL BUSINESS SIZE STANDARD IS $36.5 MILLION.

A SITE VISIT HAS NOT BEEN SCHEDULED. SEE SECTION 00100, FAR CLAUSE 52.236-27 FOR DETAILS.

YOU MUST BE REGISTERED IN SAM IN ORDER TO RECEIVE AN AWARD FROM THIS SOLICITION. THE SAM WEBSITE IS LOCATED AT

WWW.SAM.GOV.

***BLOCK 11 - SEE SECTION 00700, FAR CLAUSE 52.211-10 FOR PERIOD OF PERFORMANCE

11. The Contractor shall begin performance w ithin 45 calendar days and complete it w ithin 112*** calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See SEC 00700 .)

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 0 copies to perform the w ork required are due at the place specified in Item 8 by 02:00 PM (hour) local time 20 Nov 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

Amendment 0001

17 Oct 2018 http://www.sam.gov/ http://www.sam.gov/

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

OFFER (M ust be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

See Item 14

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specified below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

26. ADMINISTERED BY CODE K3M1F20 27. PAYMENT WILL BE MADE BY: CODE 964145

Miami Resident Office 3000 SW 148th Ave Suite 251 Mirmar, FL 33027

USACE Finance Center 5722 Integrity Drive

ATTN: CEFC-AO-P

Millington, TN 38054-5005

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this 29. AWARD (Contractor is not required to sign this document.)

document and return _ copies to issuing office.) Contractor agrees to f urnish and deliv er all items or perf orm all work, requisitions identif ied on this f orm and any continuation sheets f or the consideration stated in this contract. The rights and obligations of the parties to this contract shall be gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

Y our of f er on this solicitation, is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Gov ernment solicitation and y our of f er, and (b) this contract award. No f urther contractual document is necessary .

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

TEL: EMAIL:30B. SIGNATURE 30C. DATE

NSN 7540-01-155-3212 STANDARD FORM 1442 BACK (REV. 4-85)

Amendment 0001

SECTION 00010A

LINE ITEMS AND PRICING SCHEDULE

FLOOD CONTROL AND COASTAL EMERGENCY

BEACH EROSION CONTROL PROJECT

BROWARD COUNTY, FLORIDA

BROWARD COUNTY SEGMENT III

W912EP18B0015 00010A-1 Amendment 0001

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

0001 BEACH FILL (ESTIMATED QUANTITY) 125,000 CUBIC YARD $___________ $_______________

0002 BEACH TILLING (ESTIMATED QUANTITY) 43 ACRE $___________ $_______________

0003 CONSTRUCTION/VIBRATION CONTROL AND

MONITORING JOB $_______________

0004 ENVIRONMENTAL SPECIES MONITORING JOB $_______________

0005 STANDBY TIME (SEE NOTE 6) 72 HOUR $___________ $_______________

0006 BEACH DEBRIS REMOVAL (SEE NOTE 7) 10 CUBIC YARD $___________ $_______________

0007 PARTNERING REGROUP (SEE NOTE 7) 1 EACH $___________ $_______________

TOTAL BID (LINE ITEMS 0001 THROUGH 0007) $_______________

NOTES: (1) OFFER MUST PRICE ALL LINE ITEMS.

(2) ACTUAL QUANTITIES MAY VARY.

(3) FULL PAYMENT UNDER LINE ITEM "BEACH FILL" IS CONDITIONED ON REPAIRING ALL STAGING AND ACCESS AREAS TO PRECONSTRUCTION CONDITION. SEE SECTION 01 22 00 MEASUREMENT AND PAYMENT.

(4) ANY VEGETATION IMPACTED BY CONSTRUCTION ACTIVITIES SHALL BE REPLACED.

(5) BEACH FILL QUANTITY SHOWN IS THE ESTIMATED QUANTITY FOR THE FILL TEMPLATE AND DOES NOT

TAKE COMPACTION INTO CONSIDERATION.

(6) STANDBY TIME SHALL BE UTILIZED WHEN THE PRESENCE OF A FLORIDA DEPARTMENT OF TRANSPORTATION (FDOT) CONTRACTOR IN THE IMMEDIATE VICINITY OF THE STAGING/ACCESS AREA(S) WHICH THE CONTRACTOR IS ACTIVELY USING PROHIBITS THE CONTRACTOR FROM DELIVERING AND PLACING BEACH FILL. IT WILL NOT BE UTILIZED FOR DELAYS CAUSED BY INCREASED TRAFFIC AS A RESULT OF FDOT CONSTRUCTION OR ANY OTHER CONDITIONS UNLESS DIRECTED BY THE CONTRACTING OFFICER. STANDBY TIME IS NOT AFFORDED FOR DELAYS CAUSED BY ADVERSE WEATHER CONDITIONS OR IF THE CONTRACTING OFFICER DETERMINES THE DELAY IS CAUSED BY THE CONTRACTOR OPERATING IN A NEGLIGENT MANNER. PAYMENT WILL NOT BE MADE UNDER THIS LINE ITEM UNLESS IT IS EXERCISED BY THE CONTRACTING OFFICER OR ADMINSTRATIVE CONTRACTING OFFICER.

THIS LINE ITEM IS NOT SUBJECT TO THE VARIATION IN ESTIMATED QUANITITY CLAUSE, AND PAYMENT WILL ONLY BE MADE FOR ACTUAL STANDBY TIME REQUIRED BY THE CONTRACTING OFFICER. SEE SECTION 01 22 00

MEASUREMENT AND PAYMENT.

(7) THIS LINE ITEM IS NOT SUBJECT TO THE VARIATION IN ESTIMATED QUANTITY CLAUSE, AND PAYMENT WILL ONLY BE MADE FOR ACTUAL AMOUNT OF BEACH DEBRIS REMOVED OR NUMBER OF PARTNERING REGROUPS CONDUCTED.

FCCE, Beach Er osi on Cont r ol Pr oj ect , Br owar d Count y, Fl or i da Br owar d Count y Segment I I I

SECTI ON TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

SECTI ON 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1. 1 REFERENCES

1. 2 DEFI NI TI ONS

1. 3 WORK COVERED BY CONTRACT DOCUMENTS

1. 3. 1 Pr oj ect Descr i pt i on

1. 3. 2 Locat i on

1. 3. 3 Saf et y Requi r ement s

1. 3. 4 Wor k Rest r i ct i ons

1. 3. 4. 1 Del i ver y of Mat er i al

1. 3. 4. 2 Wor k on t he Beach

1. 3. 4. 3 St agi ng Ar eas f or Const r uct i on Equi pment on t he Beach

1. 3. 5 Wor k Per f or med by Ot her s

1. 4 COMMENCEMENT, PROSECUTI ON AND COMPLETI ON OF WORK

1. 5 LI QUI DATED DAMAGES - CONSTRUCTI ON

1. 6 PHYSI CAL DATA

1. 6. 1 Weat her , Wat er St age and Ti de Dat a

1. 6. 2 Cont r act or I nvest i gat i on

1. 6. 3 Sur veys

1. 7 LAYOUT OF WORK

1. 7. 1 Est abl i shed Pr oj ect Cont r ol

1. 7. 2 Layout

1. 7. 3 Sur vey

1. 8 DAMAGE TO WORK

1. 9 TI ME EXTENSI ONS FOR UNUSUALLY SEVERE WEATHER ( 31 OCT 1989)

1. 9. 1 Schedul e of Mont hl y Ant i c i pat ed Adver se Weat her Del ays

1. 9. 2 Cont r act or Responsi bi l i t y

PART 2 PRODUCTS ( NOT APPLI CABLE)

PART 3 EXECUTI ON ( NOT APPLI CABLE)

- - End of Sect i on Tabl e of Cont ent s - -

SECTI ON 01 11 00 Page 1 W912EP18B0015 Amendment 0001

SECTI ON 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1. 1 REFERENCES

The publ i cat i ons l i s t ed bel ow f or m a par t of t hi s speci f i cat i on t o t he ext ent r ef er enced. The publ i cat i ons ar e r ef er r ed t o i n t he t ext by t he basi c desi gnat i on onl y.

U. S. ARMY CORPS OF ENGI NEERS ( USACE)

EM 385- 1- 1 Saf et y and Heal t h Requi r ement s Manual

1. 2 DEFINITIONS

a. " Adver se weat her " occur s when at mospher i c condi t i ons at a def i ni t e t i me and pl ace t hat ar e unf avor abl e t o const r uct i on act i v i t i es and i s based on c l i mat ol ogi cal and met eor ol ogi cal obser vat i ons and dat a sour ces pr ovi ded i n Sect i on 00 33 50 WEATHER, WATER STAGE AND TI DE DATA.

b. " Unusual l y sever e weat her " i s weat her t hat i s mor e sever e t han t he adver se weat her ant i c i pat ed by t he Cont r act or f or t he season or l ocat i on i nvol ved. Adver se weat her del ays ar e consi der ed unusual l y sever e weat her i f adver se weat her del ay days pr event wor k f or 50 per cent or mor e of t he Cont r act or ' s schedul ed wor k day.

1. 3 WORK COVERED BY CONTRACT DOCUMENTS

1. 3. 1 Pr oj ect Descr i pt i on

Pr oj ect wor k wi l l r enour i sh t wo segment s of cr i t i cal l y er oded shor el i ne usi ng upl and mat er i al . A 1. 5 mi l e l ong segment bet ween Fl or i da Depar t ment of Envi r onment al Pr ot ect i on ( FDEP) Range Monument s R- 86 t o R- 94, known l ocal l y as t he Mi zzel l - Eul a Johnson St at e Par k and 5. 8 mi l es l ong segment R- 98 t o R- 128 wi t hi n t he Ci t i es of Dani a, Hol l ywood, and Hal l andal e. The wi dt h of t he r enour i shed ar ea i s cont r ol l ed bet ween t he pr e- pr oj ect mean hi gh wat er ( MHW) shor el i ne and t he Er osi on Cont r ol Li ne ( ECL) . Because of ext ensi ve har d bot t om ar eas of f shor e of t he pr oj ect , f i l l pl aced seawar d of t he MHW shal l not occur . The sand sour ce f or t he pr oj ect wi l l come f r om an upl and sour ce and wi l l be t r ucked haul t o t he pl acement l ocat i ons. The upl and sour ce wi l l be sel ect ed by t he Cont r act or meet i ng cr i t er i a r equi r ed i n t he speci f i cat i ons and subj ect t o Cont r act i ng Of f i cer ' s appr oval .

Pr oj ect wor k al so i ncl udes endanger ed speci es and vi br at i on moni t or i ng.

1. 3. 2 Location

The wor k i s l ocat ed i n Br owar d Count y, Fl or i da on t he bar r i er i s l and sout h of Por t Ever gl ades and r uns sout h t o t he Br owar d Count y Li ne wi t h Dade County .

SECTI ON 01 11 00 Page 2

1. 3. 3 Saf et y Requi r ement s

See Sect i on 01 35 26 GOVERNMENTAL SAFETY REQUI REMENTS and EM 385- 1- 1.

1. 3. 4 Wor k Rest r i ct i ons

Ni ght t i me wor k i s not per mi t t ed under t hi s cont r act .

1. 3. 4. 1 Del i ver y of Mat er i al

Del i ver y of t he mat er i al f r om t he Cont r act or ' s sel ect ed sour ce t o t he desi gnat ed st agi ng and access ar eas shown on t he dr awi ngs wi l l be per mi t t ed bet ween t he hour s of 6: 00am and 11: 00pm dur i ng dayl i ght hour s.

1. 3. 4. 2 Wor k on t he Beach

No wor k shal l be per f or med seawar d of t he Er osi on Cont r ol Li ne ( ECL) pr i or t o sunr i se or af t er sunset . Sunr i se and sunset wi l l var y dependi ng on t he t i me of year ; however , no wor k wi l l be per mi t t ed pr i or t o 7: 00am or af t er 7: 00pm shoul d t he sun r i se bef or e 7: 00am and/ or t he sun set af t er 7: 00pm.

1. 3. 4. 3 St agi ng Ar eas f or Const r uct i on Equi pment on t he Beach

See Sect i on 01 57 20 ENVI RONMENTAL PROTECTI ON f or per i ods when st agi ng ar eas f or const r uct i on equi pment on t he beach i s not per mi t t ed.

1. 3. 5 Wor k Per f or med by Ot her s

See par agr aph PROJECT COORDI NATI ON of Sect i on 01 30 00 ADMI NI STRATI VE

PROCEDURES.

1. 4 COMMENCEMENT, PROSECUTI ON AND COMPLETI ON OF WORK

a. Read t hi s par agr aph i n conj unct i on wi t h t he Cl ause COMMENCEMENT, PROSECUTI ON, AND COMPLETI ON OF WORK ( FAR 52. 211- 10) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

b. I n addi t i on t o t he above, t he f ol l owi ng shal l appl y: The t i me f or compl et i on does not i ncl ude est abl i shment of coast al veget at i on.

Veget at i on shal l be est abl i shed not l at er t han t he t i me st at ed i n t he Cl ause COMMENCEMENT, PROSECUTI ON, AND COMPLETI ON OF WORK ( FAR

52. 211- 10) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1 pl us t he t i me st at ed f or t he est abl i shment of veget at i on. See par agr aph ORDER OF WORK of Sect i on 32 93 00 COASTAL VEGETATI ON PLANTI NG.

1. 5 LI QUI DATED DAMAGES - CONSTRUCTI ON

Ref er t o t he Cl ause LI QUI DATED DAMAGES - CONSTRUCTI ON ( FAR 52. 211- 12) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

1. 6 PHYSI CAL DATA

Read t hi s par agr aph i n conj unct i on wi t h t he Cl ause PHYSI CAL DATA ( FAR

52. 236- 4) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

1. 6. 1 Weat her , Wat er St age and Ti de Dat a

See Sect i on 00 33 50 WEATHER, WATER STAGE AND TI DE DATA f or appl i cabl e dat a l i nks and i nf or mat i on t o wher e t he Cont r act or can ascer t ai n t he weat her

SECTI ON 01 11 00 Page 3 condi t i ons t hat coul d be encount er ed at t he pr oj ect l ocat i on. The i nf or mat i on pr ovi ded does not pr ecl ude t he Cont r act or f r om assessi ng and schedul i ng f or adver se weat her .

1. 6. 2 Cont r act or I nvest i gat i on

Ref er t o t he Cl ause SI TE I NVESTI GATI ON AND CONDI TI ONS AFFECTI NG THE WORK ( FAR 52. 236- 3) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

1. 6. 3 Surveys

Sur vey shown on t he dr awi ngs was per f or med by Mor gan and Ekl und f or Br owar d Count y ( 2017) .

1. 7 LAYOUT OF WORK

Read t hi s par agr aph i n conj unct i on wi t h t he Cl ause LAYOUT OF WORK ( FAR

52. 236- 17) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

1. 7. 1 Est abl i shed Pr oj ect Cont r ol

The Gover nment has est abl i shed monument s al ong t he wor k s i t e( s) . Each monument i s r epr esent ed i n t he cont r act dr awi ngs by a Desi gnat i on and i n most cases, an al phanumer i c Per manent I dent i f i er ( PI D) . I nf or mat i on concer ni ng t he l ocat i on and el evat i ons can be f ound wi t hi n t he Sur vey Not es on t he pl an sheet s. The Sur vey Not es f or each i nc l uded f i el d sur vey wi l l c i t e a par t i cul ar sur vey number , and speci f y t he cont r ol used t o conduct t hat sur vey. Addi t i onal i nf or mat i on i s i ncl uded i n t he Sur vey Not es t hat must be dupl i cat ed i f an at t empt t o r ecr eat e t he subj ect sur vey i s desi r ed.

For navi gat i on channel s, t he Gover nment has est abl i shed t i dal cal i br at i on s i t es f or pr oj ect s const r uct ed and mai nt ai ned t o a t i dal dat um. Each t i dal cal i br at i on s i t e i s r epr esent ed i n t he pl an sheet dr awi ngs by St at i on I D, and i s c i t ed i n t he Sur vey Not es. Al l pr oj ect s const r uct ed and mai nt ai ned t o a t i dal dat um shal l be cal i br at ed t o t he St at i on I D speci f i ed i n t he pl an sheet dr awi ngs. I nf or mat i on r egar di ng t he l ocat i on and associ at ed benchmar ks of t he r ef er enced St at i on I D i s i ncl uded i n t he Monument Descr i pt i on sect i on of t hese speci f i cat i ons.

See Sect i on 00 31 21 CONTROL MONUMENT DESCRI PTI ONS f or descr i pt i ons f r om Sur vey Number 18- 204.

1. 7. 2 Layout

Fr om t he monument s, cont r ol dat a and el evat i ons est abl i shed by t he Gover nment , t he Cont r act or shal l compl et e t he l ayout of t he wor k and shal l be r esponsi bl e f or al l measur ement s t hat may be r equi r ed f or t he execut i on of t he wor k t o t he l ocat i on and l i mi t mar ks pr escr i bed i n t he speci f i cat i ons or on t he cont r act dr awi ngs, subj ect t o such modi f i cat i ons as t he Cont r act i ng Of f i cer may r equi r e t o meet changed condi t i ons or as a r esul t of necessar y modi f i cat i ons t o t he cont r act wor k.

1. 7. 3 Survey

The Cont r act or shal l f ur ni sh, at hi s own expense, such st akes, t empl at es, pl at f or ms, equi pment , t ool s and mat er i al , and al l l abor as may be r equi r ed i n l ayi ng out any par t of t he wor k f r om t he monument s, cont r ol dat a and el evat i ons est abl i shed by t he Gover nment . I t shal l be t he r esponsi bi l i t y of t he Cont r act or t o mai nt ai n and pr eser ve al l s t akes and ot her mar ks

SECTI ON 01 11 00 Page 4 est abl i shed by t he Cont r act i ng Of f i cer unt i l aut hor i zed t o r emove t hem, and i f such mar ks ar e dest r oyed by t he Cont r act or or t hr ough hi s negl i gence, pr i or t o t hei r aut hor i zed r emoval , t hey may be r epl aced by t he Cont r act i ng Of f i cer , at hi s di scr et i on, and t he expense of r epl acement wi l l be deduct ed f r om any amount s due or t o become due t he Cont r act or . The Cont r act i ng Of f i cer may r equi r e t hat wor k be suspended at any t i me when l ocat i on and l i mi t mar ks est abl i shed by t he Cont r act or ar e not r easonabl y adequat e t o per mi t checki ng of t he wor k.

1. 8 DAMAGE TO WORK

The r esponsi bi l i t y f or damage t o any par t of t he per manent wor k shal l be as set f or t h i n Cl ause PERMI TS AND RESPONSI BI LI TI ES of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1. However , i f , i n t he j udgment of t he Cont r act i ng Of f i cer , any par t of t he per manent wor k per f or med by t he Cont r act or i s damaged by f l ood, ear t hquake, hur r i cane, or t or nado, whi ch damage i s not due t o t he f ai l ur e of t he Cont r act or t o t ake r easonabl e pr ecaut i ons or t o exer ci se sound engi neer i ng and const r uct i on pr act i ces i n t he conduct of t he wor k, t he Cont r act or wi l l make t he r epai r s as or der ed by t he Cont r act i ng Of f i cer and f ul l compensat i on f or such r epai r s wi l l be made at t he appl i cabl e cont r act uni t or l ump sum pr i ces as f i xed and est abl i shed i n t he cont r act . I f , i n t he opi ni on of t he Cont r act i ng Of f i cer , t her e ar e no cont r act uni t or l ump sum pr i ces appl i cabl e t o any par t of such wor k, an equi t abl e adj ust ment pur suant t o Cl ause CHANGES of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1 wi l l be made as f ul l compensat i on f or t he r epai r s of t hat par t of t he per manent wor k f or whi ch t her e ar e no appl i cabl e cont r act uni t or l ump sum pr i ces. Except as her ei n pr ovi ded, damage t o al l wor k ( i ncl udi ng t empor ar y const r uct i on) , ut i l i t i es, mat er i al s, equi pment and pl ant shal l be r epai r ed t o t he sat i sf act i on of t he Cont r act i ng Of f i cer at t he Cont r act or ' s expense, r egar dl ess of t he cause of such damage.

1. 9 TI ME EXTENSI ONS FOR UNUSUALLY SEVERE WEATHER ( 31 OCT 1989)

Thi s pr ovi s i on speci f i es t he pr ocedur e f or t he det er mi nat i on of t i me ext ensi ons f or unusual l y sever e weat her i n accor dance wi t h t he Cl ause DEFAULT ( FI XED- PRI CE CONSTRUCTI ON) of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1. I n or der f or t he Cont r act i ng Of f i cer t o awar d a t i me ext ensi on under t hi s c l ause, t he f ol l owi ng condi t i ons must be sat i sf i ed:

a. The weat her exper i enced at t he pr oj ect s i t e dur i ng t he cont r act per i od must be f ound t o be unusual l y sever e; t hat i s , mor e sever e t han t he adver se weat her ant i c i pat ed f or t he pr oj ect l ocat i on dur i ng any gi ven mont h.

b. The unusual l y sever e weat her must act ual l y cause a del ay t o t he compl et i on of t he pr oj ect . The del ay must be beyond t he cont r ol and wi t hout t he f aul t or negl i gence of t he Cont r act or .

1. 9. 1 Schedul e of Mont hl y Ant i c i pat ed Adver se Weat her Del ays

The schedul e of mont hl y ant i c i pat ed adver se weat her del ays i s based upon Nat i onal Oceani c and At mospher i c Admi ni st r at i on ( NOAA) or s i mi l ar dat a f or t he pr oj ect l ocat i on and wi l l const i t ut e t he base l i ne f or mont hl y weat her t i me eval uat i ons. The Cont r act or ' s pr ogr ess schedul e must r ef l ect t hese ant i c i pat ed adver se weat her del ays i n al l weat her dependent act i v i t i es.

See Sect i on 00 33 50 WEATHER, WATER STAGE AND TI DE DATA.

SECTI ON 01 11 00 Page 5

1. 9. 2 Cont r act or Responsi bi l i t y

The pr oj ect ar ea may be af f ect ed by st or my, wi ndy and/ or r ai ny weat her , i ncl udi ng t hunder st or ms, dur i ng any t i me of t he year . The Cont r act or shal l be r esponsi bl e f or obt ai ni ng i nf or mat i on concer ni ng r ai n, wi nd and wave condi t i ons t hat coul d i nf l uence saf et y, haul i ng and pl acement oper at i ons pr i or t o submi t t i ng a pr oposal or bi d. The Cont r act or ' s pr ogr ess schedul e must r ef l ect t hese ant i c i pat ed adver se weat her del ays i n al l - weat her dependent act i v i t i es. A l i s t of pot ent i al sour ces pr ovi di ng c l i mat ol ogi cal and met eor ol ogi cal obser vat i ons and dat a f or t he pr oj ect ar ea i s pr ovi ded.

a. Cont r act or shal l r esear ch t he pr oj ect s i t e condi t i ons and i ncor por at e pot ent i al adver se weat her del ays i nt o t hei r schedul e pr i or t o submi t t i ng a pr oposal or bi d. The Cont r act or shal l devel op a schedul e of mont hl y ant i c i pat ed adver se weat her based on t he equi pment t o be used t o compl et e t he pr oj ect and det er mi ne t he condi t i ons t hat woul d cause t hem t o cease oper at i ons usi ng t he sour ces pr ovi ded i n Section 00 33 50 WEATHER, WATER STAGE AND TI DE DATA. The Cont r act or ' s pr ogr ess schedul e must r ef l ect t hese ant i c i pat ed adver se weat her del ays i n al l weat her dependent act i v i t i es.

b. Upon acknowl edgment of t he Not i ce t o Pr oceed ( NTP) and cont i nui ng t hr oughout t he cont r act , t he Cont r act or wi l l r ecor d on t he dai l y CQC r epor t t he occur r ence of adver se weat her and unusual l y sever e weat her wi t h t he pur pose t o not e i mpact t o nor mal l y schedul ed wor k. Act ual adver se weat her del ay days must pr event wor k on cr i t i cal act i v i t i es f or 50 per cent or mor e of t he Cont r act or ' s schedul e t o be consi der ed " unusual l y sever e weat her " .

c. The number of act ual adver se weat her del ay days shal l i ncl ude days i mpact ed by act ual adver se weat her , be cal cul at ed chr onol ogi cal l y f r om t he f i r st t o t he l ast day of each mont h, and be r ecor ded as f ul l days.

I f t he number of act ual adver se weat her del ay days exceeds t he number of days ant i c i pat ed f or adver se weat her by t he Cont r act or , t he Cont r act i ng Of f i cer may conver t any qual i f y i ng del ays t o cal endar days, gi v i ng f ul l consi der at i on f or equi val ent f ai r weat her wor k days t hat shoul d have been ant i c i pat ed f or t he condi t i ons at t he pr oj ect l ocat i on.

PART 2 PRODUCTS ( NOT APPLI CABLE)

PART 3 EXECUTI ON ( NOT APPLI CABLE)

- - End of Sect i on - -

SECTI ON 01 11 00 Page 6

SECTI ON TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

SECTI ON 01 22 00

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1. 1 SUMMARY

1. 2 RESI DENT MANAGEMENT SYSTEM ( RMS)

1. 2. 1 Def i ni t i on

1. 2. 2 I nst r uct i ons

1. 3 DEFI NI TI ONS

1. 3. 1 Compensat i ng Sl opes

1. 4 SUBMI TTALS

1. 5 JOB PAYMENT I TEMS

1. 5. 1 Const r uct i on/ Vi br at i on Cont r ol and Moni t or i ng ( Li ne I t em 0003)

1. 5. 2 Envi r onment al Speci es Moni t or i ng ( Li ne I t em 0004)

1. 6 UNI T PRI CE PAYMENT I TEMS

1. 6. 1 Beach Fi l l ( Li ne I t em 0001)

1. 6. 1. 1 Payment

1. 6. 1. 2 Measur ement

1. 6. 1. 3 Uni t of Measur e

1. 6. 2 Beach Ti l l i ng ( Li ne I t em 0002)

1. 6. 2. 1 Payment

1. 6. 2. 2 Measur ement

1. 6. 2. 3 Uni t of Measur e

1. 6. 3 St andby Ti me ( Li ne I t em 0005)

1. 6. 3. 1 Payment

1. 6. 3. 2 Measur ement

1. 6. 3. 3 Uni t of Measur e

1. 6. 4 Beach Debr i s Removal ( Li ne I t em 0006)

1. 6. 4. 1 Payment

1. 6. 4. 2 Measur ement

1. 6. 4. 3 Uni t of Measur e

1. 6. 5 Par t ner i ng Regr oup ( Li ne I t em 0007)

1. 6. 5. 1 Payment

1. 6. 5. 2 Measur ement

1. 6. 5. 3 Uni t of Measur e

PART 2 PRODUCTS ( NOT APPLI CABLE)

PART 3 EXECUTI ON

3. 1 PAYMENT PROCEDURES

3. 1. 1 Request i ng Pr ogr ess Payment

3. 1. 2 Opt i ons and Modi f i cat i on CLI NS

- - End of Sect i on Tabl e of Cont ent s - -

SECTI ON 01 22 00 Page 1

SECTI ON 01 22 00

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1. 1 SUMMARY

Thi s sect i on descr i bes how Li ne I t ems wi l l be measur ed and pai d f or when maki ng pr ogr ess payment s. Wor k t o be measur ed i s descr i bed i n speci f i cat i on sect i ons l i s t ed f or each Li ne I t em. Measur ement pr ocedur es f or payment , r equi r ed quant i t y sur vey or pr ocur ement document at i on and payment r est r i c t i ons ar e descr i bed i n appl i cabl e speci f i cat i on sect i ons.

Al l ocat e cost s f or wor k not speci f i cal l y ment i oned t o t he Li ne I t em most c l osel y associ at ed wi t h wor k i nvol ved. Unl ess t her e i s a speci f i c Li ne I t em f or admi ni st r at i ve cost s, such as Qual i t y Cont r ol and Saf et y, al l ocat e such cost s pr opor t i onal l y acr oss al l Li ne I t ems.

1. 2 RESI DENT MANAGEMENT SYSTEM ( RMS)

1. 2. 1 Definition

The t er ms " Cont r act Li ne I t em Number ( CLI N) " and " Li ne I t em" ar e i nt er changeabl e her ei n ( e. g. : CLI N 0001 i s Li ne I t em 0001) . The t er m " CLI N" i s a cont r act i ng t er m used i n t he Resi dent Management Syst em ( RMS) payment dat a base.

1. 2. 2 Instructions

See Sect i on 01 45 00 RESI DENT MANAGEMENT SYSTEM CONTRACTOR MODE ( RMS CM) f or mor e i nf or mat i on on CLI Ns, schedul e of val ues of pay act i v i t i es and const r uct i on schedul e, and payment pr ocedur es. The Cont r act or mode user manual wi t h i n- dept h i nst r uct i ons can be downl oaded f r om t he RMS web si t e i ndi cat ed i n Sect i on 01 45 00 RESI DENT MANAGEMENT SYSTEM CONTRACTOR MODE

( RMS CM) .

1. 3 DEFINITIONS

1. 3. 1 Compensat i ng Sl opes

The al l owance f or mat er i al t o be pl aced above t he speci f i ed f i l l t ol er ance t o compensat e f or t he speci f i ed f or eshor e s l ope bei ng bel ow gr ade due t o sedi ment r el ocat ed by nat ur al f or ces bet ween t he t i me of pl acement and payment sur veys. Thi s i s per mi t t ed f or payment pur poses onl y.

1. 4 SUBMITTALS

Gover nment appr oval i s r equi r ed f or submi t t al s wi t h a " G" desi gnat i on;

submi t t al s not havi ng a " G" desi gnat i on ar e f or i nf or mat i on onl y. When used, a desi gnat i on f ol l owi ng t he " G" desi gnat i on i dent i f i es t he of f i ce t hat wi l l r evi ew t he submi t t al f or t he Gover nment . Tr ansmi t submi t t al i t ems i n accor dance wi t h Sect i on 01 33 00 SUBMI TTAL PROCEDURES:

SD- 01 Pr econst r uct i on Submi t t al s

SECTI ON 01 22 00 Page 2

Schedul e of Val ues; G, RO

Pr ovi de a br eakdown of j ob i t ems i nt o pr oposed pay act i v i t i es as par t of t he i ni t i al pr oj ect schedul e. Schedul e of Val ues wi l l become basi s f or CLI N and Pay Act i v i t y dat a i n t he RMS payment dat a base.

SD- 07 Cer t i f i cat es

Cer t i f i ed Del i ver y Ti cket s; G, RO

The Cont r act or shal l pr ovi de St at e cer t i f i ed del i ver y t i cket s per t r anspor t at i on uni t f or al l beach wr ack debr i s haul ed of f t he const r uct i on s i t e t o di spose of f or t he pur pose of payment .

Tot al - vol ume of mat er i al per t r uck met hod shal l be appr oved by t he Cont r act i ng Of f i cer .

1. 5 JOB PAYMENT I TEMS

Payment i t ems f or t he wor k of t hi s cont r act f or whi ch cont r act l ump sum payment s wi l l be made ar e l i s t ed i n t he LI NE I TEMS AND PRI CI NG SCHEDULE wi t h t he uni t " JOB" and descr i bed bel ow. Al l cost s f or i t ems of wor k, whi ch ar e not speci f i cal l y ment i oned t o be i ncl uded i n a par t i cul ar j ob or uni t pr i ce payment i t em, shal l be i ncl uded i n t he l i s t ed j ob i t em most c l osel y associ at ed wi t h t he wor k i nvol ved. The j ob pr i ce and payment made f or each i t em l i s t ed shal l const i t ut e f ul l compensat i on f or f ur ni shi ng al l pl ant , l abor , mat er i al s, and equi pment , and per f or mi ng any associ at ed Cont r act or qual i t y cont r ol , envi r onment al pr ot ect i on, meet i ng saf et y r equi r ement s, t est s and r epor t s, and f or per f or mi ng al l wor k r equi r ed f or whi ch separ at e payment i s not ot her wi se pr ovi ded.

Pr ogr ess payment s f or j ob CLI Ns wi l l be made i n accor dance wi t h t he Payment s Under Fi xed- Pr i ce Const r uct i on Cont r act s c l ause of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1. Submi t a l i s t of pay act i v i t i es, ( Schedul e of Val ues) t o br eakdown bi d f or each j ob CLI N. The Schedul e of Val ues shal l be submi t t ed f or Gover nment appr oval wi t h t he basel i ne schedul e submi t t al ( see Sect i on 01 32 01 PROJECT SCHEDULE) . An unbal anced Schedul e of Val ues and Pay Act i v i t y Schedul e wi l l be r et ur ned f or r evi s i on. I f t hi s cont r act cont ai ns ei t her t he Cont i nui ng Cont r act s c l ause or t he Cont i nui ng Cont r act s ( Al t er nat e) c l ause, t he Cont r act or shoul d t ake i nt o account t he amount r eser ved f or cont r act payment s when pr epar i ng t he const r uct i on schedule.

1. 5. 1 Const r uct i on/ Vi br at i on Cont r ol and Moni t or i ng ( Li ne I t em 0003)

Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o t he pr ot ect i on of ex i st i ng st r uct ur es f r om const r uct i on act i v i t i es and moni t or i ng. See Sect i on 02 22 13 VI BRATI ON MONI TORI NG REQUI REMENTS FOR

EXI STI NG STRUCTURES.

1. 5. 2 Envi r onment al Speci es Moni t or i ng ( Li ne I t em 0004)

Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o dai l y coor di nat i on wi t h Br owar d Count y on t hei r dai l y management of t he moni t or i ng of sea t ur t l es, mi gr at or y bi r ds, and ot her endanger ed speci es.

Cont act s t o Br owar d Count y wi l l be pr ovi ded at t he Pr e- const r uct i on conf er ence. See Sect i on 01 57 20 ENVI RONMENTAL PROTECTI ON.

SECTI ON 01 22 00 Page 3

1. 6 UNI T PRI CE PAYMENT I TEMS

Payment i t ems f or t he wor k of t hi s cont r act on whi ch t he cont r act uni t pr i ce payment s wi l l be made ar e l i s t ed i n t he LI NE I TEMS AND PRI CI NG SCHEDULE and descr i bed bel ow. The uni t pr i ce and payment made f or each i t em l i s t ed shal l const i t ut e f ul l compensat i on f or f ur ni shi ng al l pl ant , l abor , mat er i al s , and equi pment , and per f or mi ng any associ at ed Cont r act or qual i t y cont r ol , envi r onment al pr ot ect i on, meet i ng saf et y r equi r ement s, t est s and r epor t s, and f or per f or mi ng al l wor k r equi r ed f or each of t he uni t pr i ce i t ems.

Each Uni t Pr i ce CLI N may be a s i ngl e pay act i v i t y i t em or may be br oken down i nt o pay act i v i t i es wi t h smal l er quant i t i es equal t o CLI N t ot al .

Cont r act uni t pr i ce mul t i pl i ed by agr eed quant i t y i s f ul l compensat i on.

1. 6. 1 Beach Fi l l ( Li ne I t em 0001)

1. 6. 1. 1 Payment

a. Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o pr epar at i on of access ar eas, bar r i cades and si gns, debr i s r emoval , pi pel i ne cr ossi ng, excavat i on and t r anspor t at i on of beach f i l l , const r uct i ng t he beach pr of i l e and f i nal dr essi ng; noi se cont r ol ;

condi t i on sur veys; and r est or at i on of al l access ar eas t o pr econst r uct i on condi t i on or as ot her wi se i ndi cat ed on t he dr awi ngs.

See Sect i on 35 30 00 BEACH FI LL.

b. I n addi t i on t o t he above, payment wi l l be made f or i n- pl ace beach f i l l t o t he t ol er ance l i ne i ndi cat ed i n Sect i on 35 30 00 BEACH FI LL.

Payment quant i t i es wi l l be det er mi ned by t he Gover nment usi ng Di gi t al Ter r ai n Model ( DTM) sur f ace- t o- sur f ace met hod of cal cul at i on. When beach f i l l i s pl aced above t he s l ough zone t o compensat e f or wave act i on, payment wi l l be based on a cut and f i l l cal cul at i on. No payment wi l l be made f or mat er i al pl aced i n excess of t he t ol er ance t empl at e A( T) i ndi cat ed on t he dr awi ngs.

c. The Gover nment wi l l pay 95 per cent ( wi t hhol d 05 per cent ) of pr ogr ess and t ot al payment made under t hi s l i ne i t em unt i l al l access ar eas have been r est or ed as i ndi cat ed above. Thi s i s not consi der ed r et ai nage under c l ause PAYMENTS UNDER FI XED- PRI CE CONSTRUCTI ON CONTRACTS of Sect i on 00700 CONTRACT CLAUSES. Thi s i s consi der ed payment wi t hhel d f or wor k pai d f or under t hi s l i ne i t em whi ch has not been per f or med. Accept ance of r epai r s t o access r out es may be subj ect t o f i nal appr oval of l ocal per mi t t i ng aut hor i t i es.

1. 6. 1. 2 Measurement

a. The maps and/ or dr awi ngs al r eady pr epar ed ( c l ause CONTRACT DRAWI NGS, MAPS, AND SPECI FI CATI ONS of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1) ar e bel i eved t o r epr esent accur at el y t he exi st i ng condi t i ons at t he t i me t he sur veys wer e per f or med, but t he dept hs and el evat i ons shown t her eon may be ver i f i ed and cor r ect ed by el evat i ons and soundi ngs t aken bef or e commenci ng t he wor k. Once quant i t i es wi t hi n a speci f i ed r each or sect i on have been det er mi ned t hr ough t he use of i n- pl ace measur ement , t hey wi l l not be r eopened except on evi dence of col l us i on, f r aud, or obvi ous er r or .

b. Beach f i l l sat i sf act or i l y pl aced wi l l be measur ed f or payment by use of Di gi t al Ter r ai n Model ( DTM) sur f ace- t o- sur f ace di f f er ence

SECTI ON 01 22 00 Page 4 met hod. The quant i t i es wi l l be comput ed by t he Gover nment i n accor dance wi t h c l ause QUANTI TY SURVEYS of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1. Measur ement of quant i t y pl aced f or pay pur poses wi l l be based on or i gi nal and f i nal cr oss sect i ons made on t he sect i on or r each i ndi cat ed on t he dr awi ngs. The Cont r act or shal l gi ve 3 cal endar days advance not i ce, i n wr i t i ng, t o t he Cont r act i ng Of f i cer ' s Repr esent at i ve of t he need t o per f or m t he or i gi nal and f i nal sur veys.

Qual i t y Cont r ol Sur veys shal l be t he r esponsi bi l i t y of t he Cont r act or .

Mont hl y par t i al payment s wi l l be based on appr oxi mat e quant i t i es det er mi ned by measur ement of t he i n- pl ace beach f i l l and i n accor dance wi t h c l ause QUANTI TY SURVEYS of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1.

c. I n accor dance wi t h c l ause QUANTI TY SURVEYS of Sect i on 00700 CONTRACT CLAUSES i n Vol ume 1, t he Gover nment wi l l per f or m pr e- and post - const r uct i on t opogr aphi c sur vey at 100- f oot s t at i ons wi t h el evat i ons t aken at 10- f oot r ange i nt er val s f r om t he basel i ne t o t he t oe s l ope el evat i on. I n or der t o achi eve f i nal gr ade i n s l ough zone, and account f or nat ur al f enci ng pr i or t o Gover nment sur vey, t he Cont r act or shal l pl ace mat er i al t o f i nal gr ade wi t hi n t ol er ance f or t he ent i r e s l ope or may st ockpi l e beach f i l l up- sl ope of t he swash zone as l ong as t he upsl ope f i l l vol ume above t ol er ance does not exceed vol ume on t he f or eshor e s l ope bel ow t ol er ance, known her ei n as t he compensat i ng s l opes. Af t er st ockpi l ed beach f i l l i s measur e f or payment , t he Cont r act or shal l pr oduce a smoot h uni f or m sl ope t o wi t hi n t he accept abl e t ol er ances of t he f i nal gr ade f r om t he t op of s l ope t o t he wat er l i ne. Once post - const r uct i on sur vey i s per f or med, no measur ement s wi l l be r evi sed except on suspi c i on of f r aud or obvi ous error.

1. 6. 1. 3 Uni t of Measur e

Cubi c yar d.

1. 6. 2 Beach Ti l l i ng ( Li ne I t em 0002)

1. 6. 2. 1 Payment

Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o beach t i l l i ng. See Sect i ons 01 57 20 ENVI RONMENTAL PROTECTI ON and 35 30 00 BEACH

FILL.

1. 6. 2. 2 Measurement

Beach t i l l i ng wi l l be measur ed f or payment by t he act ual ar ea t i l l ed t o t he t ent h of an acr e.

1. 6. 2. 3 Uni t of Measur e

Acre.

1. 6. 3 St andby Ti me ( Li ne I t em 0005)

1. 6. 3. 1 Payment

St andby t i me, when exer ci sed by t he Cont r act i ng Of f i cer , wi l l be pai d f or each hour or par t t her eof t hat beach f i l l act i v i t i es ar e not i n oper at i on.

St andby t i me shal l be ut i l i zed when t he pr esence of a Fl or i da Depar t ment of Tr anspor t at i on ( FDOT) cont r act or i n t he i mmedi at e v i c i ni t y of t he

SECTI ON 01 22 00 Page 5 s t agi ng/ access ar ea( s) whi ch t he Cont r act or i s act i vel y usi ng pr ohi bi t s t he Cont r act or f r om del i ver i ng and pl aci ng Beach Fi l l . I t wi l l not be ut i l i zed f or del ays caused by i ncr eased t r af f i c as a r esul t of FDOT const r uct i on or any ot her condi t i ons unl ess di r ect ed by t he Cont r act i ng Of f i cer . St andby t i me i s not af f or ded f or del ays caused by adver se weat her condi t i ons or i f t he Cont r act i ng Of f i cer det er mi nes t he del ay i s caused by t he Cont r act or oper at i ng i n a negl i gent manner . Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o st andby of Beach Fi l l act i v i t i es onl y upon i mpl ement at i on of t hi s l i ne i t em. I f per f or mance of t hi s l i ne i t em i s not r equi r ed or i mpl ement ed per t he NOTES i n Sect i on 00010A LI NE I TEMS AND PRI CI NG SCHEDULE, no payment wi l l be made t o t he Cont r act or f or t hi s l i ne item.

1. 6. 3. 2 Measurement

St andby Ti me, i f r equi r ed and i mpl ement ed as descr i bed i n Payment above, wi l l be measur ed and pai d f or each hour or par t t her eof i n 1/ 6 hour i ncr ement s, or 10 mi nut e i nt er val s, t hat t he Beach Fi l l act i v i t i es ar e not i n oper at i on by r equest of t he Cont r act i ng Of f i cer .

1. 6. 3. 3 Uni t of Measur e

Hour

1. 6. 4 Beach Debr i s Removal ( Li ne I t em 0006)

1. 6. 4. 1 Payment

Payment wi l l be made f or cost s associ at ed wi t h or i nci dent al t o r emoval , t r anspor t at i on, and di sposal of beach wr ack debr i s , as def i ned i n Sect i on 35 30 00 BEACH FI LL encount er ed pr i or t o pl acement . Debr i s not consi der ed f or t hi s payment i ncl ude any gener at ed const r uct i on debr i s, wast e mat er i al s, packagi ng mat er i al and t he l i ke. The Cont r act or shal l mai nt ai n a separ at e cont ai ner f or di sposal of beach debr i s f r om t he " Debr i s Cont ai ner " as descr i bed i n Sect i on 01 50 02 TEMPORARY CONSTRUCTI ON FACI LI TI ES.