Solicitation Amendment - W912EF25QA0480001.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

calls)

Solicitation/Contract Form Continuation

CHEMICAL ANALYTICAL SERVICES FOR INDUSTRIAL HYGIENE SAMPLING/ANALYSIS

BIDDER INQUIRY:

Bidder/Offeror Solicitation Questions:

All inquiries regarding this solicitation are to be submitted via Bidder Inquiry. Telephone and email inquiries will not be accepted.

Bidder Inquiry is a website that allows bidders to post questions regarding the solicitation and view all questions by other bidders and responses by USACE. Bidder Inquiry can be accessed through ProjNet at (https://www.projnet.org)

To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of the comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

TIMING OF BIDDER INQUIRIES: Bidders are encouraged to submit their bidder inquiries promptly. The Government will make every effort to answer all bidder inquiries; however, the closer to the solicitation due date an inquiry is received, the less likely it is that a timely response can be provided.

The Bidder Inquiry Key is: CC4ZZP-U3RU5H

Specific Instructions for ProjNet Bid Inquiry Access:

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone.

Make sure to remember your Secret Question and Answer as they will be use from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Instructions for Entering Questions:

1. After you are logged in click on the "post new inquiry", it is on the left side of the window under the Word "Submit" a.) This is the window where you will enter your questions b.) Comment Classification: Click on the down arrow to the right of the words "Please select from below", select "Public".

c.) Discipline: This is where you select who this question should be directed to. Example, if the question is about an electrical drawing or specification select: "Electrical" from the pull-down list.

d.) Sheet. Enter the sheet number of the drawing you are asking about.

e.) Detail. Enter the detail name of the detail shown on the drawing that you are asking about.

f.) Specification. Enter the Specification number and paragraph number.

g.) File. Use this if you are going to attach a pdf file.

W912EF25QA0480001

https://www.projnet.org h.) Question. Enter your question here.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

For questions about the ProjNet Bidder Inquiry, please contact the Call Center help desk at Project: Public User (833) 389-1097 or 217- 367-3273, which operates from 8AM to 5PM (Central US time zone). Bidder inquiry help questions can also be emailed to the helpdesk at staff@projectnet.info

Offerors are cautioned to clearly print prices for all line items. Be especially careful placing decimal points, as a mistake in your offer may render it unresponsive. Your quote must be valid for 30 calendar days after the due date specified for receipt of quotations. Please include shipping costs in the quoted price of each item.

Registration at www.sam.gov is required. If not registered, please do so. Step-by-step help information on how to register is detailed on the website, along with frequently asked questions (FAQs). Lack of registration in the SAM database may make an offeror ineligible for award.

Effective 29 April 2018, the notarized letter process is now mandatory on all CURRENT registrants at SAM who have a requirement to update data on their SAM record. The notarized letter is mandatory and is required for the GSA Federal Service Desk (FSD, https://www.fsd.gov) to activate the entity's registration. Both Federal Assistance entities and all non-Federal entities must mail the original, signed copy of the notarized letter to the Federal Service Desk. Failure to do so within 30 days of activation may result in the registration no longer being active. Mail the completed, signed, notarized letter to:

FEDERAL SERVICE DESK

ATTN: SAM.GOV REGISTRATION PROCESSING

460 INDUSTRIAL BLVD

LONDON, KY 40741-7285

UNITED STATES OF AMERICA

Completion of the required FAR 52.212-3 Alt. I, Offeror Representations and Certifications - Commercial Products and Commercial Services is required. When you complete your SAM registration, the link to complete your Reps and Certs is also available. Please do not hesitate to contact me or the SAM web site if you need assistance or have questions.

In accordance with FAR 52.229-3 Federal, State, and Local Taxes, and per Title 4 of the US Code 104-107, the Government is exempt from paying local and state taxes. Exempt Tax Identification Number 91-0828090.

General Contract Information:

Delivery Date________________________________________________

Offeror's Name (Printed) _________________________________________

Offeror's Contact Telephone Number_______________________________

Offeror's Email Address___________________________________________

W912EF25QA0480001

Federal Tax Identification No. ____________________________________________

CAGE Code ________________ Unique Entity ID ______________________________

Is your company registered on-line in SAM (www.sam.gov)? YES NO

To ensure receipt of your quote, please send to the attention of Gregory Moyer at:

Email: gregory.moyer@usace.army.mil

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS - COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES

Submission of Price Quote - Contractor shall submit the following in 1 copy:

1. Signed and dated Standard Form 1449 (Solicitation / Contract / Order for Commercial Items).

2. Signed and dated Standard Form 30, if applicable, for any Amendments to the Solicitation

3. Completed schedule (pricing information) for all line items listed in the solicitation / amendments.

4. Completed Clause 52.212-3 and Alt I, "Offeror Representations and Certifications--Commercial Products and Commercial Services".

As noted above.

5. Descriptive Materials (brochures, illustrations, drawings, data sheets, etc.) must provide proof of active and current accreditation from the American Industrial Hygiene Association (AIHA(r)), or accreditation from the International Organization for Standardization's ISO/IEC 17025 standard. Additionally, the contractor is required to provide an active and current accreditation from the United States Environmental Protection Agency (USEPA).

BASIS FOR AWARD

The Government will award one contract resulting from this solicitation in accordance with FAR 13.106 to the responsible offeror meeting or exceeding all solicitation requirements and representing the best value based on price.

mailto:ruth.a.johnson@usace.army.mil

Continuation of Supplies or Services and Prices/Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

ID-215 Hexavalent Chromium, HEX-01

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

OSHA ID-214, Ozone

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7400, Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7402, Asbestos (by TEM)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 9102, Lead

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7303 Beryllium

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 1550, Stoddard Solvent

Product Service Code: R405 1 Each

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

EPA/600/R-96/116, Bulk Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

ID-215 Hexavalent Chromium, HEX-01

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

OSHA ID-214, Ozone

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7400, Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7402, Asbestos (by TEM)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 9102, Lead

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7303 Beryllium

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 1550, Stoddard Solvent

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

EPA/600/R-96/116, Bulk Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

ID-215 Hexavalent Chromium, HEX-01

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

OSHA ID-214, Ozone

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7400, Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7402, Asbestos (by TEM)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 9102, Lead

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7303 Beryllium

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 1550, Stoddard Solvent

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

EPA/600/R-96/116, Bulk Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

ID-215 Hexavalent Chromium, HEX-01

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

OSHA ID-214, Ozone

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7400, Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7402, Asbestos (by TEM)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 9102, Lead

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7303 Beryllium

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 1550, Stoddard Solvent

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

EPA/600/R-96/116, Bulk Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

ID-215 Hexavalent Chromium, HEX-01

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust)

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

OSHA ID-214, Ozone

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7400, Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

NIOSH 7402, Asbestos (by TEM)

4006 Product Service Code: R405

Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 9102, Lead

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 7303 Beryllium

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

NIOSH 1550, Stoddard Solvent

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Option Line Item

EPA/600/R-96/116, Bulk Asbestos

Product Service Code: R405 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price

1 Each

Continuation of Description

CHEMICAL ANALYTICAL SERVICES FOR INDUSTRIAL HYGIENE SAMPLING/ANALYSIS

1. : This is a non-personnel services requirement to provide laboratory analytical services and related efforts in support General of the U.S. Army Corps of Engineers (USACE), Northwestern Division, Walla Walla District (CENWW) for the chemical analysis of heavy metal, ozone, volatile organic compounds, asbestos and other industrial hygiene air, bulk, tape and wipe samples. The Government (USACE) shall not exercise any supervision or control over the contract (purchase order) service providers performing the services herein. Such contract service providers shall be accountable solely to the contractor who, in turn is responsible to the Government.

1.1. : This PWS covers requirements for the contractor to provide all personnel, equipment, Description of Services/Introduction supplies, facilities, transportation, tools, materials, supervision, and other items and non-personal services necessary to perform chemical analytical services for industrial hygiene sample analysis. The contractor shall perform to the standards of the PWS.

The contractor's laboratory shall maintain active and current American Industrial Hygiene Association (AIHA)(r)-accreditation or must meet the International Organization for Standardization/International Electrotechnical Commission (ISO/IEC) 17025 international standard to ensure the results reported have been generated by a laboratory with a known and certified quality system. If analytical services are subcontracted by the contractor, the subcontractor must maintain active and current American Industrial Hygiene Association (AIHA)(r)-accreditation or must meet the International Organization for Standardization /International Electrotechnical Commission (ISO/IEC) 17025 international standard to ensure the results reported have been generated by a laboratory with a known and certified quality system.

1.2. : The CENWW performs industrial hygiene sampling for operational and construction projects that involve Background collection of primary samples, split samples and/or quality assurance samples from various industrial operations. Once these samples are collected, analysis by an accredited laboratory is necessary.

1.2.1. :Period of Performance

Base Year: 1 October 2025 to 31 May 2026

Option 1: 1 June 2026 to 31 May 2027

Option 2: 1 June 2027 to 31 May 2028

Option 3: 1 June 2028 to 31 May 2029

Option 4: 1 June 2029 to 31 May 2030

1.2.2. Preaward

1.2.3 Submittals. The Contractor shall submit the following items:

- Active and current AIHA(r)-accreditation or International Organization for ISO/IEC 17025 international standard

- Active and current USEPA-accreditation.

1.3. : The contractor shall perform laboratory analysis services, chemical analysis of heavy metals, ozone, asbestos, and Scope other industrial hygiene air samples.

Services include the following methods:

Occupational Safety and Health Administration (OSHA) ID-215 v2 with Institute of Medicine (IOM) Sampler, Hexavalent Chromium National Institute for Occupational Safety and Health (NIOSH) 7300, Welding Fumes NIOSH 7500+0600, Silica, Crystalline Quartz (with Respirable Dust) NIOSH 7400, Asbestos (A Rule) NIOSH 9102, Lead OSHA ID-214, Ozone NIOSH 7303, Beryllium NIOSH 1550, Stoddard Solvents NIOSH 7402, Asbestos (by TEM) EPA/600/R-96/116; Asbestos Bulk

The following specific information related to the activities and required services is provided:

1) The contract shall maintain active and current AIHA(r)-accreditation or shall meet the International Organization for ISO/IEC 17025 international standard to ensure the results reported have been generated by a laboratory with a known and certified quality system.

2) For bulk sample analysis for asbestos and lead-based paint, the laboratory shall maintain active and current USEPA-accreditation.

3) The contractor's laboratory personnel shall follow chain-of-custody (COC) procedures to ensure sample integrity as IH data are potentially subject to legal proceedings. Reference U.S. Army Public Health Center (APHC) Technical Guide (TG) 141 for an example of a COC record [https://phc.amedd.army.mil/organization/ls/Pages/LOD.aspx]

4) The contractor shall retain all analytical and supporting data for a minimum period of five (5) years following the date of analysis.

5) The capability of providing access to reports electronically via internet is required for all results (report access shall be controlled and prevent unauthorized access to its resources, or any confidential or sensitive information).

The following is required:

Adobe (PDF) file that is fully searchable structured complete data packages (including Quality Control (QC) and raw data).

Sampling tracking and invoice.

6) The contractor shall ship/deliver required media, calibrators, and other supplies to a location address specified by the Government prior to each sampling event. The projected estimates of samples to be collected will be used to determine the numbers and types of sample containers and shipping supplies. The contractor is responsible for coordinating shipment/delivery with the Government.

7) Potential sample matrices will include air, building material, paint and other industrial hygiene sample media.

8) The standard turnaround time will be five (5) business days. However, depending on project needs, required turnaround times may vary for different sampling events. The order laboratory should also provide percentage factor used for fourth (4th) day, third (3rd) day, 48-hour and 24-hour turnarounds.

9) Samples will be collected by Government personnel.

10) Samples and extracts shall be retained by the contractor for a period of six (6) months after date of analysis. The contractor shall provide a listing of the maximum time period for which samples and extracts can be retained for different matrices and analytical parameters.

11) Packages must be available in electronic searchable structured portable deliverable format (PDF).

12) Sample analyses for which the definitive or comprehensive data package is specified may potentially require external data validation by a third party for up to five (5) years following date of analyses. This data package must be suitable for data validation and be legally defensible. The contractor shall retain all analytical data for a period of five

(5) years following date of analysis. If external data validation is potentially required for any samples analyzed during this five (5)-year period, the Government will specify the definitive or comprehensive data package prior to sample collection.

13) The contractor shall provide the Government with a copy of all chain of custody form(s) and sample receipt form

(s) from the laboratory upon receipt of the samples at the laboratory and have the ability to post this information on the laboratory's secure internet website.

14) The ability of the laboratory to provide timely (same day) courier services such as delivery or pickup of supplies and samples shall be required on an as needed basis.

15) Invoicing and payment schedule shall be implemented on a quarterly basis

1.4. : The contractor will be notified via e-mail when services are requested. It is important that the contractor Contract Structure provide a valid e-mail address for one point of contact with your company whom you wish to receive these e-mail notifications.

If the Point of Contact (POC) changes, please notify the Contracting Officer Representative (COR) immediately. The contractor will have 24 hours to respond to the notification.

1.4.1. : Laboratory services to be ordered on an as needed basis. Payments will be made in accordance Firm-Fixed Price (FFP) with actual quantities ordered and accepted by the Government. Price Schedules shall include all costs associated with performance of the required service, to include all labor, materials, and any other direct, indirect or incidental costs necessary for performance of service. Unless the PWS is modified in writing (e.g., there is a change in the scope of services), the obligated amount will not be adjusted. However, unless otherwise authorized in writing by the Government, the services shall not be ordered more than once per year.

1.4.2. : The contract will include quantities of testing needed. The contractor shall only be paid for work Quantity Tracking directed and performed as agreed to by the Contracting Officer (KO). At no time shall the contractor exceed the Price Schedule quantities.

1.4.3. : The unit prices per test shall include all efforts needed to produce the lab test report (including review). The Unit Prices contractor's pricing shall include with each test item all costs associated with performing the tests. The contractor's pricing shall include all direct costs as well as indirect costs such as overhead, profit, bond, and workers compensation insurance. It should be noted that stand-by time will be paid only when specifically directed by the Government to compensate unanticipated delays that are outside the control of the contractor.

1.4.4. : There will be no other costs paid for under this contract, except those which are noted herein and/or shown Other Costs on the Price Schedule.

1.5. :General Requirements

1.5.1. : The Government shall evaluate the contractor's performance under this contract in accordance with the Quality Assurance Appendix 1 - Performance Requirement Summary (PRS). The contractor's performance assessment is primarily focused on what the Government must do to ensure that the contractor has performed in accordance with the PRS. The performance threshold in the PRS describes the minimum acceptable level of service required for each requirement. These thresholds are critical to mission success.

1.5.2. : The contractor is not required to perform services on federal holidays.Recognized Holidays

New Year's Day Labor Day

Martin Luther King Jr.'s Birthday Columbus Day

President's Day Veteran's Day

Memorial Day Thanksgiving Day

Juneteenth National Independence Day Christmas Day

Independence Day

1.5.3. : The work shall be performed at the contractor facility.Place of Performance

1.5.3.1. : Sampling Media Delivery The sampling media shall be delivered as follows:

COR: Name Disclosed After Award

U.S. Army Corps of Engineers

Walla Walla District

201 North 3rd Ave

Walla Walla, WA 99362-1876

1.5.4. : The contractor shall be responsible for safeguarding all Government equipment, information, and Physical Security property provided for contractor use.

1.5.5. Post Award Conference/Periodic Progress Meetings: The KO, COR, and other Government personnel, as appropriate, may meet periodically with the contractor to review the contractor's performance. At these meetings the KO will apprise the contractor of how the Government views the contractor's performance, and the contractor will apprise the Government of problems, if any, being experienced. Appropriate action shall be taken to resolve outstanding issues. These meetings shall be at no additional cost to the Government.

1.5.6. ): The COR will be identified by separate letter. The COR monitors all technical Contracting Officer Representative (COR aspects of the purchase order and assists in contract administration. The COR is authorized to perform the following functions:

Assure that the contractor performs the technical requirements of the order.

Perform inspections necessary in connection with order performance: maintain written and oral communications with the contractor concerning technical aspects of the purchase order.

Monitor contractor's performance and notifies both the KO and contractor of any deficiencies.

Provide site entry of contractor personnel.

A letter of designation issued to the COR, a copy of which is sent to the contractor, states the responsibilities and limitations of the COR, especially with regard to changes in cost or price, estimates or changes in delivery dates. The COR is not authorized to change any of the terms and conditions of the resulting contract.

1.5.7. Authorized Individuals (AI): The AI will be identified by separate letter. The AI is the technical expert and has the authority to perform the following functions:

- Discuss, via phone or email, technical aspects of Industrial Hygiene methods, results, turnaround times, scheduling, analysis, media and other items related to implementation of the contract.

- Request media, equipment and shipping methods for requested items

- Request analysis of samples via Laboratory's Chain of Custody/Analysis Request forms.

1.5.8. : All contract personnel attending meetings, answering Government telephones, Identification of Contractor Employees and working in other situations where their contractor status is not obvious to third parties are required to identify themselves as such to avoid creating an impression in the minds of members of the public that they are Government officials. The contractor shall ensure that all documents or reports produced by contractors are suitably marked as contractor products or that contractor participation is appropriately disclosed.

2. Definitions and Acronyms:

2.1. Definitions

2.1.1. CONTRACTOR. A supplier or vendor awarded an order to provide specific supplies or service to the government. The term used in this PURCHASE order refers to the prime.

2.1.2. CONTRACTING OFFICER (KO). A person with authority to enter into, administer, and or terminate the PURCHASE order, and make related determinations and findings on behalf of the Government. Note: The only individual who can legally bind the Government.

2.1.3. CONTRACTING OFFICER'S REPRESENTATIVE (COR). An employee of the U.S. Government appointed by the contracting officer to administer the contract. Such appointment shall be in writing and shall state the scope of authority and limitations. This individual has authority to provide technical direction to the contractor as long as that direction is within the scope of the contract, does not constitute a change, and has no funding implications. This individual does NOT have authority to change the terms and conditions of the contract.

2.1.4. DEFECTIVE SERVICE. A service output that does not meet the standard of performance associated with the PWS.

2.1.5. DELIVERABLE. Items that can be physically delivered, but may include non-manufactured things such as meeting minutes or reports.

2.1.6. KEY PERSONNEL. Contractor personnel that are evaluated in a source selection process and that may be required to be used in the performance of a contract by the Key Personnel listed in the PWS. When key personnel are used as an evaluation factor in best value procurement, an offer can be rejected if it does not have a firm commitment from the persons that are listed in the proposal.

2.1.7. PHYSICAL SECURITY. Actions that prevent the loss or damage of Government property.

2.1.8. QUALITY ASSURANCE. The Government procedures to verify that services being performed by the Contractor are performed according to acceptable standards.

2.2. ACRONYMS

AR Army Regulation

COR Contracting Officer Representative

IOM Institute of Medicine

KO Contracting Officer

POC Point of Contact

PRS Performance Requirements Summary

PWS Performance Work Statement

QA Quality Assurance

TEM Transmission Electron Microscopy

3. :CONTRACTOR-FURNISHED ITEMS AND RESPONSIBILITIES

3.1. General. The contractor shall furnish all supplies, equipment, facilities and services required to perform work under the contract that are not listed under section 3 of the PWS.

3.2. Materials. The contractor shall provide filters, tubes, passive monitors, solutions and other, supplies, and equipment necessary to meet the requirements under the PWS. The contractor is responsible for coordinating shipment/delivery with the Government.

3.3. Equipment. The contractor shall provide industrial hygiene sampling pumps and calibrators, IAQ equipment, aerosol and particle counters, stack emission equipment and other sampling instruments for a nominal fee, as needed. The contractor is responsible for coordinating shipment/delivery with the Government.

Performance Requirements Summary

The contractor service requirements are summarized into performance objectives that relate directly to mission essential items.

The performance threshold briefly describes the minimum acceptable levels of service required for each requirement. These thresholds are critical to mission success.

PWS

Paragraph

Performance Objective Standard Performance Threshold

Method of Surveillance

1.1.

The contractor shall maintain active and current American Industrial Hygiene Association (AIHA)(r)-accreditation or must meet the International Organization for Standardization /International Electrotechnical Commission (ISO/IEC) 17025 international standard to ensure the results reported have been generated by a laboratory with a known and certified quality system.

Meet certifications, licenses, and training requirements and are up to date.

All certifications, licenses, and training are current 100% of the time.

Receive a copy of current certification

1.3.

The contractor shall perform laboratory analysis services, chemical analysis of heavy metals, ozone, asbestos, and other industrial hygiene air samples.

The standard turnaround time will be five (5) business days.

However, depending on project needs, required turnaround times may vary for different sampling events. The order laboratory should be able to

The standard turnaround time will be five (5) business days on laboratory analysis services.

Meet minimum standard 90% of the time.

Track through email activity provide a turnaround time frame within 24-hour of being notified.

1.4.1

The contractor will be notified via e-mail when services are requested. The contractor will have 24 hours to respond to the notification.

24 hours response to notification

95% Track through email activity

Requirements

CHEMICAL ANALYTICAL SERVICES FOR INDUSTRIAL HYGIENE SAMPLING/ANALYSIS

Continuation of Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

1004 Both

Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

2003 Both

Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

3002 Both

Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

4001 Both

Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Inspection and Acceptance Location

4010 Both

Destination Instructions: The work shall be performed at the contractor facility.

DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD AVE.

WALLA WALLA, WA 99362-1876

UNITED STATES

Continuation of Deliveries or Performance

Delivery Period From 01 Oct 2025 to 31 May 2026

Line Item Delivery Schedule Quantity Address and POC

Delivery Period From 01 Oct 2025 to 31 May

1 Each Place of Performance DoDAAC: 960505 CountryCode: USA

ARMY CORPS OF ENGINEERS CIVIL WORKS

WALLA WALLA DIST LOGISTICS MGMT OFC, 201 N 3RD

AVE.

WAL…