A22_Solicitation_W912EE22B0007_Amendment_0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Reference Solicitation No. W912EE22B0007 for 12 Mile Bayou, Shreveport, Louisiana, P.L. 84-99 Emergency Bank Stabilization, West Agurs Levee Sta. 196+90 & 427+10.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 12-Aug-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EE22B0007

X 9B. DATED (SEE ITEM 11)

22-Jul-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

12-Aug-2022

CODE

VICKSBURG CONTRACTING OFFICE

4155 CLAY ST

VICKSBURG MS 39183-3435

W912EE 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EE22B0007

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

SPECIFICATIONS: Page 5 of 107 is revised and replaced.

Specifications revised by this amendment have the notation "Revised by Amendment 0001" at the bottom of the page. Text added by this amendment is shown as underlined. Text deleted by this amendment is shown as overstruck.

Contractors are advised to review current navigation bulletins regarding a scheduled lock outage at Old River Lock on the Mississippi River. The outage is currently scheduled to be a continuous closure commencing on approximately 30 August 2022 and continuing through approximately 12 November 2022. Dates are subject to change. Contractors should monitor for updates to the associated navigation bulletins. Old River Lock closures could delay stone supply under this contract. The duration of the Old River Lock closure will be considered an excusable delay to the extent it impacts delivery of materials under this contract but will not be grounds for any change in contract pricing or claim against the government. Issuance of the Notice to Proceed for work under this contract will be coordinated with the contractor after contract award. At the contractor's option, the Notice to Proceed can be issued immediately after receipt and verification of bonds as noted, or delayed up until, but no later than, completion of the Old River Lock closure.

W912EE22B0007

COMPLETED SECTION 00600, A COMPLETE HARD COPY OF THEIR ONLINE REPRESENTATIONS

AND CERTIFICATIONS APPLICATIONS (ORCA) REGISTRATION. SEE FAR CLAUSES 52.204-7 AND

52.204-8 FOR REQUIREMENT INFORMATION. THE WEBSITE FOR ORCA IS WWW.SAM.GOV.

(J) THE NOTICE TO PROCEED (NTP): THE SUCCESSFUL BIDDER IS ADVISED THAT

PERFORMANCE AND PAYMENT BONDS SHALL BE SUBMITTED IN ACCORDANCE WITH THE TIME

FRAME IN BLOCK 12B OF SF1442. THE NTP WILL BE ISSUED IMMEDIATELY AFTER VERIFICATION

OF ACCEPTABLE PERFORMANCE AND PAYMENT BONDS. WITHIN TEN (10) CALENDAR DAYS

AFTER ISSUANCE OF THE NTP, THE CONTRACTOR SHALL INITIATE A MEETING TO DISCUSS THE

SUBMITTAL PROCESS WITH THE AREA OR RESIDENT ENGINEER OR HIS AUTHORIZED

REPRESENTATIVE. PHYSICAL WORK CANNOT START UNTIL THE ACCIDENT PREVENTION PLAN,

CONTRACTOR QUALITY CONTROL PLAN, AND OTHER SUBMITTALS WHICH MAY BE REQUIRED,

HAVE BEEN SUBMITTED AND APPROVED AND ALL PRELIMINARY MEETINGS CALLED FOR

UNDER THE CONTRACT, HAVE BEEN CONDUCTED.

(K) CONTRACTORS ARE ADVISED TO REVIEW CURRENT NAVIGATION BULLETINS REGARDING A

SCHEDULED LOCK OUTAGE AT OLD RIVER LOCK ON THE MISSISSIPPI RIVER. THE OUTAGE IS

CURRENTLY SCHEDULED TO BE A CONTINUOUS CLOSURE COMMENCING ON APPROXIMATELY

30 AUGUST 2022 AND CONTINUING THROUGH APPROXIMATELY 12 NOVEMBER 2022. DATES ARE

SUBJECT TO CHANGE. CONTRACTORS SHOULD MONITOR FOR UPDATES TO THE ASSOCIATED

NAVIGATION BULLETINS. OLD RIVER LOCK CLOSURES COULD DELAY STONE SUPPLY UNDER

THIS CONTRACT. THE DURATION OF THE OLD RIVER LOCK CLOSURE WILL BE CONSIDERED AN

EXCUSABLE DELAY TO THE EXTENT IT IMPACTS DELIVERY OF MATERIALS UNDER THIS

CONTRACT, BUT WILL NOT BE GROUNDS FOR ANY CHANGE IN CONTRACT PRICING OR CLAIM

AGAINST THE GOVERNMENT. ISSUANCE OF THE NOTICE TO PROCEED FOR WORK UNDER THIS

CONTRACT WILL BE COORDINATED WITH THE CONTRACTOR AFTER CONTRACT AWARD. AT

THE CONTRACTOR'S OPTION, THE NOTICE TO PROCEED CAN BE ISSUED IMMEDIATELY AFTER

RECEIPT AND VERIFICATION OF BONDS AS NOTED, OR DELAYED UP UNTIL, BUT NO LATER

THAN, COMPLETION OF THE OLD RIVER LOCK CLOSURE.

(L) ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH

THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS

MANUAL", DATED NOVEMBER 2014.

(M) THE GOVERNMENT RESERVES THE RIGHT, AS THE INTERESTS OF THE GOVERNMENT MAY

REQUIRE, TO POSTPONE OR DELAY THE DATE AND/OR TIME SET FOR OPENING BIDS.

REVISIONS OR AMENDMENTS TO THE BID OPENING DATE AND/OR TIME, IF ANY, WILL BE

ANNOUNCED BY AMENDMENT OR AMENDMENTS TO THIS INVITATION FOR BIDS.

Revised By Amendment 0001