specs.pdf

SOLICITATION No. W912EE18B0017

DATE: 20 JULY 2018

REQUEST FOR PROPOSAL

FOR

TALLAHATCHIE RIVER BASIN, TALLAHATCHIE

RIVER UPPER YAZOO PROJECTS, ITEM 7D CHANNEL

IMPROVEMENT, BANK STABILIZATION

THIS PROCUREMENT IS TOTAL SMALL

BUSINESS SET ASIDE.

♦Building Strong® ♦Serving the Army ♦Serving the Nation

VICKSBURG DISTRICT

4155 CLAY STREET

VICKSBURG, MS 39183-3435 CEMVK-EC-TC

INQUIRIES

REGARDING THIS SOLICITATION SHOULD

BE MADE TO THE FOLLOWING:

http://www.projnet.org/projnet

Plans and specifications will be available on the Federal Business Opportunities (FBO) Web Page at: http://www.fedbizopps.gov/ http://www.projnet.org/projnet http://www.fedbizopps.gov/

SOLICITATION NUMBER: W912EE18B0017

TECHNICAL INQUIRIES AND QUESTIONS

ALL QUESTIONS MUST BE SUBMITTED VIA PROJNET.

TECHNICAL INQUIRIES AND QUESTIONS RELATING TO THIS SOLICITATION ARE TO BE

SUBMITTED VIA BIDDER INQUIRY IN PROJNET AT (HTTPS://WWW.PROJNET.ORG) .

BIDDERS ARE ENCOURAGED TO SUBMIT QUESTIONS 5 DAYS PRIOR TO BID OPENING

IN ORDER TO ENSURE ADEQUATE TIME IS ALLOTTED TO FORM AN APPROPRIATE

RESPONSE AND AMEND THE SOLICITATION, IF NECESSARY. TO SUBMIT AND REVIEW

INQUIRY ITEMS, PROSPECTIVE VENDORS WILL NEED TO USE THE BIDDER INQUIRY

KEY PRESENTED BELOW AND FOLLOW THE INSTRUCTIONS LISTED BELOW THE KEY

FOR ACCESS. A PROSPECTIVE VENDOR WHO SUBMITS A COMMENT /QUESTION WILL

RECEIVE AN ACKNOWLEDGEMENT OF THEIR COMMENT/QUESTION VIA EMAIL,

FOLLOWED BY AN ANSWER TO THE COMMENT/QUESTION AFTER IT HAS BEEN

PROCESSED BY OUR TECHNICAL TEAM.

ALL TIMELY QUESTIONS AND APPROVED ANSWERS WILL BE MADE AVAILABLE

THROUGH PROJNET. APPROVED ANSWERS TO ALL TIMELY QUESTIONS WILL ALSO BE

POSTED ON THE FEDBIZOPS IN THE FORM OF A REPORT GENERATED FROM PROJNET

AS SOON AS THE COMMENT/QUESTION ENTERING PERIOD IS OVER AND ALL

ANSWERS ARE ALL FINALIZED.

THE SOLICITATION NUMBER IS: W912EE18B0017

THE BIDDER INQUIRY KEY IS: U55JY5-AFX4T3

SPECIFIC INSTRUCTIONS FOR PROJNET BID INQUIRY ACCESS:

1. FROM THE PROJNET HOME PAGE LINKED ABOVE, CLICK ON QUICK ADD ON THE

UPPER RIGHT SIDE OF THE SCREEN.

2. IDENTIFY THE AGENCY. THIS SHOULD BE MARKED AS USACE.

3. KEY. ENTER THE BIDDER INQUIRY KEY LISTED ABOVE.

4. EMAIL. ENTER THE EMAIL ADDRESS YOU WOULD LIKE TO USE FOR

COMMUNICATION.

5. CLICK CONTINUE. A PAGE WILL THEN OPEN SAYING THAT A USER ACCOUNT

WAS NOT FOUND AND WILL ASK YOU TO CREATE ONE USING THE PROVIDED

FORM.

6. ENTER YOUR FIRST NAME, LAST NAME, COMPANY, CITY, STATE, PHONE,

EMAIL, SECRET QUESTION, SECRET ANSWER, AND TIME ZONE. MAKE SURE TO

REMEMBER YOUR SECRET QUESTION AND ANSWER AS THEY WILL BE USED

FROM THIS POINT ON TO ACCESS THE PROJNET SYSTEM.

7. CLICK ADD USER. ONCE THIS IS COMPLETED YOU ARE NOW REGISTERED

WITHIN PROJNET AND ARE CURRENTLY LOGGED INTO THE SYSTEM.

SPECIFIC INSTRUCTIONS FOR FUTURE PROJNET BID INQUIRY ACCESS:

1. FOR FUTURE ACCESS TO PROJNET, YOU WILL NOT BE EMAILED ANY TYPE OF

PASSWORD. YOU WILL UTILIZE YOUR SECRET QUESTION AND SECRET ANSWER

TO LOG IN.

2. FROM THE PROJNET HOME PAGE LINKED ABOVE, CLICK ON QUICK ADD ON THE

UPPER RIGHT SIDE OF THE SCREEN.

3. IDENTIFY THE AGENCY. THIS SHOULD BE MARKED AS USACE.

4. KEY. ENTER THE BIDDER INQUIRY KEY LISTED ABOVE.

5. EMAIL. ENTER THE EMAIL ADDRESS YOU USED TO REGISTER PREVIOUSLY IN

PROJNET.

6. CLICK CONTINUE. A PAGE WILL THEN OPEN ASKING YOU TO ENTER THE

ANSWER TO YOUR SECRET QUESTION.

7. ENTER YOUR SECRET ANSWER AND CLICK LOGIN. ONCE THIS IS COMPLETED

YOU ARE NOW LOGGED INTO THE SYSTEM.

W912EE-18-B-0017

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SOLICITATION, OFFER, AND AWARD (SF1442)

00010 BIDDING SCHEDULE

00100 INSTRUCTIONS TO BIDDERS

00600 REPRESENTATIONS AND CERTIFICATIONS

00700 CONTRACT CLAUSES

00 80 00.00 09 SPECIAL CONTRACT REQUIREMENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00.00 09 GENERAL CONTRACT REQUIREMENTS

01 22 00.00 09 MEASUREMENT AND PAYMENT

01 33 00 SUBMITTAL PROCEDURES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 09 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 04.00 09 CONTRACTOR QUALITY CONTROL

01 57 20.00 09 ENVIRONMENTAL PROTECTION

01 57 23.00 09 STORM WATER POLLUTION PREVENTION PLAN

DIVISION 31 - EARTHWORK

31 01 00.00 09 GENERAL SITEWORK

31 11 00.00 09 CLEARING AND GRUBBING

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 92 04.00 09 EROSION CONTROL

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 31 19.00 09 STONE

-- End of Project Table of Contents –

PROJECT TABLE OF CONTENTS Page 1

W807PM81991057

TALLAHATCHIE RIVER BASIN, TALLAHATCHIE RIVER UPPER YAZOO PROJECTS, ITEM 7D

CHANNEL IMPROVEMENT, BANK STABILIZATION

DESCRIPTION OF WORK: The work consists of furnishing all plant, labor, materials and equipment, and constructing the bank stabilization and associated work on the Tallahatchie River in Tallahatchie County, Mississippi. The principal features of work include clearing and grubbing, debris removal, excavation, backfill, R200 riprap, erosion control, storm water prevention and environmental protection.

The estimated value of the proposed work is between $1,000,000 and $5,000,000.

DUSTIN G. CANNADA (601)631-7546

NOTE: In this request for proposal, "bid" and "bidder" mean "offer" and "offeror".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

20 July 2018

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

SEE SPECIAL NOTICES TO BIDDERS

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by

GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within 10 calendar days and complete it within 161 calendar days after receiving award, X Notice to proceed. This performance period is X mandatory, negotiable. ( See Section 00 80 00.00 09

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X

YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original to perform the work required are due at the place specified in Item 8 BY 21 August 2018 @ 02:30 p.m.

If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

VICKSBURG CONTRACTING OFC

4155 CLAY ST

VICKSBURG MS 39183-3435

W912EE

PAGE

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

(601)631-7261 FAX: TEL: TEL: FAX:

W912EE18B0017

X

20B. SIGNATURE

(REV. 4-85) STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) Page 2 (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

SEE SCHEDULE

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY: 964145

US ARMY CORPS OF ENGRS FINANCE CENTER

5722 INTEGRITY DRIVE

MILLINGTON TN 38054-5005

26. ADMINISTERED BY

VICKSBURG CONTRACTING OFFICE

4155 CLAY STREET

VICKSBURG, MS 39183-3435

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror) OFFER

Section 00010 - Solicitation Contract Form

BID SCHEDULE

TALLAHATCHIE RIVER BASIN, TALLAHATCHIE RIVER

UPPER YAZOO PROJECTS, ITEM 7D CHANNEL IMPROVEMENT, BANK STABILIZATION

ITEM DESCRIPTION

EST

QTY U/M UNIT PRICE AMOUNT

MOBILIZATION AND

DEMOBILIZATION 1 JOB FOR $

0002 CLEARING AND GRUBBING 1 JOB FOR $

EXCAVATION AND

BACKFILL FOR

TRANSVERSE STONE DIKES

AND/OR STONE TIEBACKS

0003AA FIRST 15 DIKES 15 EACH $ $

0003AB OVER 15 DIKES 12 EACH $ $

0004 R200 RIPRAP

0004AA FIRST 11,700 TONS 11,700 TONS $ $

0004AB OVER 11,700 TONS 5,000 TONS $ $

ENVIRONMENTAL

PROTECTION FEATURES 1 JOB FOR $

TOTAL $

NOTES:

(a) THIS PROCUREMENT IS TOTAL SMALL BUSINESS SET-ASIDE.

(b) All technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in Project at http://www.projnet.org/project. See SNTB Page entitle “TECHNICAL INQUIRIES AND QUESTIONS”

(c) Bidders shall furnish unit prices for all items listed on the schedule of bid items which require unit prices. If the bidder fails to insert a unit price in the appropriate blank for required items, but does furnish an extended total or an estimated amount for such items, the Government will deem his unit price to be the quotient obtained by dividing the extended estimated amount for that line item by the quantity. IF THE BIDDER OMITS BOTH THE UNIT

PRICE AND THE EXTENDED ESTIMATED AMOUNT FOR ANY ITEM, HIS BID WILL BE DECLARED

NONRESPONSIVE.

(d) All quantities shown on the BIDDING SCHEDULE are estimated quantities except when the unit of measure is shown as "lump sum", "job" or "each".

(e) If a bid or modification to a bid based on unit price is submitted which provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment to the unit price in the schedule must be stated. If it is not stated, the bidder agrees that the lump sum adjustment shall be applied on a pro rata basis to the unit price in the Bid Schedule.

(f) Item Nos. 0003 and 0004 have been subdivided into sub-items. A bid for the work shall include a bid for each of these sub-items. Bidders should refer to Section 00 80 00.00 09 SPECIAL CONTRACT REQUIREMENTS, paragraph entitled “VARIATIONS IN ESTIMATED QUANTITIES-SUBDIVIDED ITEMS” before preparing their bids for these items.

(g) All extensions of the unit price shown will be subject to verification by the Government. In case of variation between the unit price and the extension, the unit price will be considered to be the bid.

(h) Award will be made as a whole to the lowest responsive, responsible bidder as may be in the best interest of the Government.

(i) Lack of registration in the SAM database will make an offeror ineligible for award. SEE CONTRACT CLAUSE

52.204-7 ENTITLED, "SYSTEM FOR AWARD MANAGEMENT".

(j)The SF1442, Bidding Schedule, and Section 00600 (Representations and Certifications) must be accurately completed and returned with your bid or it may be rejected as nonresponsive. An offeror may also submit, in lieu of the completed section 00600, a complete hard copy of their Online Representations and Certifications Applications (ORCA) registration. See FAR Clauses 52.204-7 and 52.204-8 for requirement information. The website for ORCA is www.sam.gov.

(k) The notice to proceed with construction will be issued after receipt and Government verification of the required performance and payment bonds. The contract also requires submission of various pre-work plans and Government approval of those plans as well as various preconstruction meetings prior to commencement of physical work at the site. Notice to proceed will not be delayed to await receipt of these plans. The contract performance time includes adequate time for submission and Government review of the required pre-work plans and all required preconstruction meetings to be conducted after notice to proceed.

http://www.projnet.org/project

(l) ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH THE

PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS

MANUAL", DATED NOVEMBER 2014.

(m)

Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veterans Affairs–VOW to Hire Heros Act http://benefits.va.gov/vow/ Army Wounded Warrior Program – http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation–Hiring Our Heros http://www.hiringourheroes.org/ Guide to Hiring Veterans – Reference Material http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_- _guide_to_hiring_veterans_0.pdf http://www.fedshirevets.gov/index.aspx http://www.dol.gov/vets/ http://benefits.va.gov/vow/ http://wtc.army.mil/modules/employers/index.html http://www.hiringourheroes.org/ http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_-

Section 00100 - Bidding Schedule/Instructions to Bidders

SPECIAL NOTICES

FOR: : TALLAHATCHIE RIVER BASIN, TALLAHATCHIE RIVER UPPER YAZOO

PROJECTS,ITEM 7D CHANNEL IMPROVEMENT, BANK STABILIZATION

BID OPENING MAY BE ATTENDED IN PERSON OR VIEWED ONLINE

AT http://155.76.244.230/bids/bids.htm

1. SEALED BIDS FOR THE WORK DESCRIBED HEREIN WILL BE

RECEIVED UNTIL DATE AND TIME OF BID OPENING.

2. THIS PROCUREMENT IS A TOTAL SMALL BUSINESS SET-ASIDE.

3. YOUR ATTENTION IS DIRECTED TO SECTION 00100-BID

SCHEDULE/INSTRUCTIONS TO BIDDERS CLAUSE ENTITLED “SUBMISSION

OF BIDS”. IT IS THE BIDDER’S RESPONSIBILITY TO ENSURE THAT

BIDS SENT BY COMMERCIAL CARRIER ARE CLEARLY IDENTIFIED AS

CONTAINING A SEALED BID ON THE OUTERMOST ENVELOPE. THIS

INCLUDES, BUT IS NOT LIMITED TO, BIDS SENT VIA: FEDERAL

EXPRESS, AIRBORNE EXPRESS, EXPRESS COURIER SERVICES, INC.,

EXPRESS MAIL - U.S. POSTAL SERVICE, UNITED PARCEL SERVICE AND

PUROLATOR.

4. NOTE THE AFFIRMATIVE ACTION REQUIREMENT OF THE EQUAL

OPPORTUNITY CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING

FROM THIS SOLICITATION.

5. NOTE THE AFFIRMATIVE ACTION REQUIREMENT OF THE CONTRACT

CLAUSE ENTITLED, “AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS

FOR CONSTRUCTION”, WHICH WILL APPLY TO THE CONTRACT RESULTING

FROM THIS SOLICITATION.

6. SEE SECTION 00 80 00.00 09, SPECIAL CONTRACT

REQUIREMENTS, CLAUSE ENTITLED “COMMENCEMENT, PROSECUTION,

AND COMPLETION OF WORK”.

7. SEE SECTION 01 00 00.00 09, GENERAL CONTRACT REQUIREMENTS

CLAUSE, ENTITLED, “PAYMENT INVOICES” WHICH WILL APPLY TO THE

CONTRACT RESULTING FROM THIS SOLICITATION. THE FEDERAL

ACQUISITION REGULATION REQUIRES THAT THE “REMIT TO” ADDRESS OF

THE INVOICE MATCH THE “REMIT TO” ADDRESS ON THE CONTRACT OR A

PROPER NOTICE OF ASSIGNMENT.

http://155.76.244.230/bids/bids.htm

8. MAIL BIDS TO THE VICKSBURG DISTRICT HEADQUARTERS

BUILDING, ROOM 120, 4155 CLAY STREET, VICKSBURG, MISSISSIPPI

39183-3435. BIDS SENT BY COMMERCIAL CARRIER SHALL BE CLEARLY

MARKED ON THE OUTER ENVELOPE AS CONTAINING A “SEALED BID”.

BIDS MUST BE RECEIVED PRIOR TO THE EXACT TIME SET FOR BID

OPENING.

9. HAND CARRIED BIDS MUST BE DELIVERED TO THE CONTRACTING

OFFICE, ROOM 120, IN THE VICKSBURG DISTRICT HEADQUARTERS

BUILDING, 4155 CLAY STREET, VICKSBURG, MISSISSIPPI 39183-3435.

ALL BIDS MUST BE RECEIVED PRIOR TO THE EXACT TIME SET FOR BID

OPENING. NOTE: BIDS DELIVERED LATER THAN 15 MINUTES PRIOR TO

THE TIME SET FOR THE BID OPENING SHALL BE DELIVERED DIRECTLY

TO ROOM 103, BID OPENING ROOM, RATHER THAN ROOM 120, THE PLANS

AND SPECIFICATIONS ROOM.

10. BIDS WILL NOT BE ACCEPTED NOR SHALL BIDS BE WITHDRAWN

TELEGRAPHICALLY OR BY ELECTRONIC COMMERCE.

11. VENDORS CAN BE FOUND ON THE WEB SITE: http://www.cpars.navy.mil/.

IF THE CONTRACTOR WISHES TO PARTICIPATE IN THE PERFORMANCE

EVALUATION PROCESS, ACCESS TO CCASS AND PKI CERTIFICATION IS THE

SOLE RESPONSIBILITY OF THE CONTRACTOR.

12. ELECTRONIC FUNDS TRANSFER (EFT)

PURSUANT TO FAR 52.232-5 AND 52.232-33, ALL PAYMENTS UNDER

THIS CONTRACT WILL BE MADE BY ELECTRONIC FUNDS TRANSFER (EFT).

CONTRACTORS ARE REQUIRED TO COMPLETE FORM:

UFC-DISB-4.

THE FORM AND COMPLETION INSTRUCTIONS MAY BE DOWNLOADED FROM

THE U. S. ARMY CORPS OF ENGINEERS FINANCE CENTER AT:

HTTP://WWW.FC.USACE.ARMY.MIL (CLICK ON "DIRECTORATES" AT THE

TOP OF THE PAGE, THEN CLICK ON "DIRECTORATE OF ACCOUNTING

OPERATIONS" AND THEN “EFT DIRECT DEPOSIT FORM”)

THE “INSTALLATION EROC” FOR THE VICKSBURG CONSOLIDATED

CONTRACTING OFFICE IS “B4."

13. BID PACKAGE ATTACHMENTS, REPRESENTATIONS AND CERTIFICATIONS

ARE TO BE COMPLETED AND INCLUDED IN THE BID PACKAGE SUBMITTED BY

THE OFFEROR.

http://www.cpars.navy.mil/ http://www.fc.usace.army.mil/

14. PRIOR TO BID OPENING, IN ACCORDANCE WITH FEDERAL

ACQUISITION REGULATION PART 14.303 (b) MODIFICATION OR

WITHDRAWAL OF BIDS, “A BID MAY BE WITHDRAWN IN PERSON BY A

BIDDER OR ITS AUTHORIZED REPRESENTATIVE IF, BEFORE THE EXACT

TIME SET FOR OPENING OF BIDS, THE IDENTITY OF THE PERSONS

REQUESTING WITHDRAWAL IS ESTABLISHED AND THAT PERSON SIGNS A

RECEIPT FOR THE BID."

THE FOLLOWING STEPS WILL BE REQUIRED BY THE VICKSBURG

CONTRACTING OFFICE:

1) CONTRACTOR MUST PRESENT A LETTER VERIFYING THEY ARE A

REPRESENTATIVE OF THE COMPANY.

2) CONTRACTOR MUST SHOW VALID PICTURE ID.

3) VICKSBURG DISTRICT CONTRACTING OFFICE WILL HAVE THE

REPRESENTATIVE SIGN A RECEIPT FOR BID.

GENERAL NOTICES

1. AUTHORITY & APPROPRIATION INFORMATION PROGRAM DATA

AUTHORITY: Flood Control Acts of 1936, Sec. 4 and 8a; 1941, Sec.

3b and 3g; 1946, Sec. 3, 10f, and 10q; and 1965, Sec. 2045

APPROPRIATION: Consolidated Appropriations Act, 2018 PL 115-14

FUNDING CITATION: 96X3112

2. NEGOTIATIONS AFTER SEALED BIDDING.

The Government has the option to reject all bids received in response to the sealed bid advertisement and initiate negotiation. Negotiations will include soliciting offers from each responsible bidder that submits a bid in response to the Invitation for Bids. If, after bid opening, the Contracting Officer determines that negotiations are in the best interest of the Government, the following steps will be followed:

(a) An amendment to the sealed bid advertisement will be issued to each responsible bidder changing the Invitation for Bids Number to Request for Proposals Number. The amendment will also make any necessary changes to the scope of the work.

(b) A cover letter signed by the negotiator will accompany the amendment explaining the procedures to be followed during negotiations.

3. BID, PERFORMANCE AND PAYMENT BONDS.

A bid bond is required with the bid package and is to be executed on Standard Form SF24. Performance and payment bonds will be required after award. See Section 00700, Contract Clauses 52.228-1, BID GUARANTEE and 52.228-15, PERFORMANCE AND

PAYMENT BONDS -- CONSTRUCTION

4. AMENDMENTS PRIOR TO DATE SET FOR OPENING BIDS.

The right is reserved, as the interest of the Government may require, to revise or amend the specifications and/or drawings prior to the date set for opening bids. Such revisions or amendments, if any, will be announced by amendment or amendments to this Invitation for Bids. Copies of such amendments as may be issued will be furnished to all prospective bidders. If the revision or amendments are of a nature which require material changes in quantities or prices bid or both, the date set for opening bids may be postponed by such number of days as in the opinion of the District Engineer will enable bidders to revise their bids. In such case, the amendments will include an announcement of the new date for opening bids.

5. BUSINESS INTEGRITY.

The apparent successful bidder as a condition for award of any contract resulting from this solicitation may be required to execute a certificate related to Business Integrity.

6. CONDITIONS AFFECTING THE WORK.

Bidders should visit the site and take such other steps as may be reasonably necessary to ascertain the nature and location of the work, and the general and local conditions which can affect the work or the cost thereof. Failure to do so will not relieve bidders from responsibility for estimating properly the difficulty or cost of successfully performing the work. The Government will assume no responsibility for any understanding or representations concerning conditions made by any of its officers or agents prior to the execution of the contract, unless included in the Invitation for Bids, the specifications, or related documents.

7. BIDDER'S QUALIFICATIONS.

A determination of contractor responsibility will be made. A determination of non-responsibility may be cause for the rejection of a prospective contractor's bid. In accordance with FAR 9.104-1 - General Standards, before a bid is considered for award, the bidder shall be requested by the Government to submit a statement regarding their previous experience in performing comparable work, their business and technical organization, financial resources, the plant available to be used in performing the work and/or other information necessary to make the determination of contractor responsibility.

8. SITE OF THE WORK.

Bidders are advised that for purpose of applicability of the Davis-Bacon Act and other contract labor standard provisions, "the site of the work" under the contract to be awarded pursuant to this Invitation may not be limited to the physical place(s) where the construction called for in the contract will remain when work on it has been completed. The "site of the work" may include other adjacent or nearby property used by the Contractor or Subcontractors during such construction. For example, fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., will be considered part of the site of the work provided they are dedicated exclusively or nearly so to performance on the contract and are so located in proximity to the actual construction location that it would be reasonable to include them.

9. INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE,

AND BONDS.

a. Specifications, Invitation No. W912EE18B0017, Bidding Schedule, Pre-award Information/Description of Work/Bid Evaluation, Equipment Schedule, Construction Contract Clauses, and Wage Determination Decisions No. MS180001 01/05/2018 MS1 of the Secretary of Labor, are parts of this Invitation.

b. (1) An offeror (bidder) electing to use individual sureties for either bid guarantees or performance and payment bonds must submit, concurrently with the bonds and required affidavits, a statement of both the business and personal names of the persons and/or brokerages firms through whom the bonds or the guarantees were obtained, together with the address and telephone number of the persons and/or brokerage firms.

(2) Offerors or bidders should note that some individual sureties and brokers of individual sureties have been debarred or suspended from offering themselves or others as sureties to the Government. Offerors or bidders are responsible for ascertaining the current status of their sureties and brokers.

(3) Failure to provide the required information or the submission of bid guarantees obtained from debarred or suspended sureties or brokers may cause rejection of the offer

(bid).

10. DEFINITIONS

(a) The term "head of the agency" or "Secretary" as used herein means the Secretary of the Army; and the term "his duly authorized representative" means the Chief of Engineers, Department of the Army, or an individual or board designated by him.

(b) "Contracting Officer" means a person with the authority to enter into, administer, and/or terminate contracts and make related determinations and findings. The term includes certain authorized representatives of the Contracting Officer acting within the limits of their authority as delegated by the Contracting Officer.

(c) The agency board of contract appeals having jurisdiction over all appeals from final decisions of the Contracting Officer under the Contract Disputes Act of l978 is the Armed Services Board of Contract Appeals, addressed as follows:Recorder, Armed Services Board of Contract Appeals, Skyline 6, 7th Floor, 5109 Leesburg Pike, Falls Church, Virginia 22041-3208.

(d) "Small business concern" means a concern including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria and size standards in 13 CFR 121.

(1) Size Standards for Construction and Special Trades.

(a) Construction. A concern is small if its average annual receipts for its preceding 3 fiscal years did not exceed $36.5 million.

(b) Dredging. A concern is small if (1) its average annual receipts for its preceding 3 fiscal years did not exceed $27.5 million, and (2) at least 40 percent of the yardage in the contract's plans and specifications is dredged with equipment owned by the concern or obtained from another small business dredging concern.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

CLAUSES INCORPORATED BY FULL TEXT

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

(End of provison)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Economic Area

Goals for Minority Participation for Each Trade

Goals for Female Participation for Each Trade

Memphis, Tennessee, Non-SMSA(Non-Standard Metropolitan Statistical Area) Counties

26.5%

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Memphis, Tennessee, Non-SMSA Counties, which includes Tallahatchie County, Mississippi.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Contracting Officer U.S. Army Corps of Engineers Vicksburg District 4155 Clay Street Vicksburg, Mississippi 39183-3435

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Mr. Jason Overstreet, Project Engineer, Greenwood Area Office, 100 Moore Street, Greenwood, MS 38930-4512 Telephone (662) 453-5531

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

http://farsite.hill.af.mil/

Section 00600 - Representations & Certifications

52.209-7 Information Regarding Responsibility Matters JUL 2013 252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $36,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) (d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment.