R0002.pdf

W68MD953213418

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

W912DW-16-B-0005 - Libby Pow erhouse Oil Storage Room Water Mist Fire Protection System, Libby, MT

(See Continuation page)

1. CONTRACT ID CODE PAGE OF PAGES

1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 19-Feb-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912DW-16-B-0005

X 9B. DATED (SEE ITEM 11)

27-Jan-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

19-Feb-2016

CODE

USA ENGINEER DISTRICT, SEATTLE

ATTN: CECT-NWS

4735 EAST MARGINAL WAY SOUTH, BLDG. 1202

SEATTLE WA 98134-2388

W912DW 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912DW-16-B-0005

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

(End of Summary of Changes)

The following items are applicable to this modification:

AMENDMENT NOTES

1. This amendment two (0002) provides for the following:

a. Section 00 73 00 revising contract duration from 180 to 330 days.

b. Attachment 00 73 00-A added revisions by notation to delete the words "HIGH

PRESSURE" from General Note 1 on sheet M-001

c. Section 01 11 10 revision to 1.1.b clarifying time period requirement for temporary fire protection as well as 24/7 fire watch or approved equivalent.

2. The date and time of bid opening, February 26, 2016 at 1:00:00 PM LOCAL TIME remains the same.

3. The attached revised sections are to be replaced in their entirety. Specifications changes are generally identified, for convenience, either by strikeout for deletions, and double underlining of text for additions or a single dark line in the margin. All portions of the revised sections shall apply whether or not changes have been indicated.

4. NOTICE TO BIDDERS: Bidders must acknowledge receipt of this amendment by number and date on bid. Please mark outside of envelope in which your bid is enclosed to show amendment received.

Encl:

00 73 00 (revised) 00 73 00-A (revised) 01 11 10 (revised)

Libby Dam Oil Storage Room Water Mist Fire Protection System 16007 Kootenai River, MT

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 73 00

SPECIAL CLAUSES

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEP 2000) (FAR 52.211-12)

1.3 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)(FAR

52.228-5)

1.3.1 REQUIRED INSURANCE IN ACCORDANCE WITH FAR 28.307-2

1.4 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984) (FAR 52.236-1)

1.5 PHYSICAL DATA (APR 1984)(FAR 52.236 4)

1.6 LAYOUT OF WORK (APR 1984) (FAR 52.236 17)

1.7 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995)-(UAI

31.105-101)

1.8 PAYMENT FOR MATERIALS DELIVERED OFF-SITE (MAR 1995) - (UAI

52.232-5000)

1.9 FIELD OFFICE OVERHEAD

1.10 FIELD OFFICE OVERHEAD - PER DIEM RATE

1.11 FIELD OFFICE OVERHEAD - PERCENTAGE MARKUP

1.12 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)(DOD FAR SUPP

252.236-7001)

1.13 EPA ENERGY STAR

1.14 RECOVERED MATERIALS

1.15 PROPRIETARY REFERENCES

1.16 PERFORMANCE EVALUATIONS

1.17 PARTNERING )

1.18 KEY PERSONNEL, SUBCONTRACTORS AND OUTSIDE ASSOCIATES OR

CONSULTANTS (MAY 2006)

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

-- End of Section Table of Contents --

DOCUMENT 00 73 00 Page 1

W912DW-16-B-0005 R0002

SECTION 00 73 00

SPECIAL CLAUSES

PART 1 GENERAL

1.1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (FAR

52.211-10)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the one hundred eighty (180) three hundred thirty (330) calendar days after date of receipt by Contractor of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

1.2 LIQUIDATED DAMAGES - CONSTRUCTION (SEP 2000) (FAR 52.211-12)

a. If the Contractor fails to complete the work within the time specified in the Contract, or any extension, the Contractor shall pay to the Government as liquidated damages, the sum of $1,052 for each day of delay until the work is completed or accepted.

b. If the Government terminates the Contractor's right to proceed, the resulting damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess cost of repurchase under the Termination clause of the CONTRACT CLAUSES.

1.3 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)(FAR 52.228-5)

a. The Contractor shall, at its own expense, provide and maintain during the entire performance period of this Contract at least the kinds and minimum amounts of insurance required in the Insurance Liability Schedule or elsewhere in the Contract.

b. Before commencing work under this Contract, the Contractor shall certify to the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective:

1. For such period as the laws of the State in which this Contract is to be performed prescribe; or

2. Until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

c. The Contractor shall insert the substance of this clause, including this paragraph, in subcontracts under this Contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the Contract. The Contractor shall maintain a copy of

DOCUMENT 00 73 00 Page 2 all subcontractors' proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

1.3.1 REQUIRED INSURANCE IN ACCORDANCE WITH FAR 28.307-2

a. Workers' compensation and employer's liability: Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when Contract operations are so commingled with a Contractor's commercial operation that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 shall be required, except in states with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers.

b. General Liability:

1. The Contracting Officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000 per occurrence.

2. Property damage liability insurance shall be required only in special circumstances as determined by the agency.

c. Automobile liability: The Contracting Officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the Contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

d. Aircraft public and passenger liability: When aircraft are used in connection with performing the Contract, the Contracting Officer shall require aircraft public and passenger liability insurance. Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger liability, and $200,000 per occurrence for property damage. Coverage for passenger liability bodily injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

e. Environmental Liability: If this contract includes the transport, treatment, storage, or disposal of hazardous material waste the following coverage is required.

The Contractor shall ensure the transporter and disposal facility have liability insurance if effect for claims arising out of the death or bodily injury and property damage from hazardous material/waste transport, treatment, storage and disposal, including vehicle liability and legal defense costs in the amount of $1,000,000.00 as evidenced by a certificate of insurance for General, Automobile, and Environmental Liability Coverage. Proof of this insurance shall be provided to the Contracting Officer.

DOCUMENT 00 73 00 Page 3

1.4 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984) (FAR 52.236-1)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifteen percent (15%) of the total amount of work to be performed under the Contract. The percentage may be reduced by a supplemental agreement to this Contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

1.5 PHYSICAL DATA (APR 1984)(FAR 52.236 4)

Data and information furnished or referred to below is for the Contractor's information. The Government will not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

a. Physical Conditions: The indications of physical conditions on the drawings and in the specifications are the result of site investigations by test holes shown on the drawings.

b. Weather Conditions: Each bidder shall be satisfied before submitting his bid as to the hazards likely to arise from weather conditions.

Complete weather records and reports may be obtained from any National Weather Service Office.

c. Transportation Facilities: Each bidder, before submitting his bid, shall make an investigation of the conditions of existing public and private roads and of clearances, restrictions, bridge load limits, and other limitations affecting transportation and ingress and egress at the jobsite. The unavailability of transportation facilities or limitations thereon shall not become a basis for claims for damages or extension of time for completion of the work.

d. Right-of-Way: The right-of-way for the work covered by these specifications will be furnished by the Government, except that the Contractor shall provide right-of-way for ingress and egress across private property where necessary to gain access to the jobsite. The Contractor may use such portions of the land within the right-of-way not otherwise occupied as may be designated by the Contracting Officer.

The Contractor shall, without expense to the Government, and at any time during the progress of the work when space is needed within the right-of-way for any other purposes, promptly vacate and clean up any part of the grounds that have been allotted to, or have been in use by, him when directed to do so by the Contracting Officer. The Contractor shall keep the buildings and grounds in use by him at the site of the work in an orderly and sanitary condition. Should the Contractor require additional working space or lands for material yards, job offices, or other purposes, he shall obtain such additional lands or easements at his expense.

1.6 LAYOUT OF WORK (APR 1984) (FAR 52.236 17)

The Contractor shall lay out its work from Government established base lines and benchmarks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and

DOCUMENT 00 73 00 Page 4 grades that may be established or indicated by the Contracting Officer.

The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due, or to become due, to the Contractor.

1.7 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995)-(UAI

31.105-101)

a. This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals and FAR Part 49.

b. Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region VIII.

Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

c. Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

d. When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

1.8 PAYMENT FOR MATERIALS DELIVERED OFF-SITE (MAR 1995) - (UAI 52.232-5000)

a. Pursuant to FAR clause 52.232-5, Payments Under Fixed Priced Construction Contracts, materials delivered to the contractor at locations other than the site of the work may be taken into consideration in making payments if included in payment estimates and if all the conditions of the General Provisions are fulfilled.

Payment for items delivered to locations other than the work site will be limited to:

DOCUMENT 00 73 00 Page 5

1. materials required by the technical provisions; or

2. materials that have been fabricated to the point where they are identifiable to an item of work required under this contract.

b. Such payment will be made only after receipt of paid or receipted invoices or invoices with canceled check showing title to the items in the prime contractor and including the value of material and labor incorporated into the item. In addition to petroleum products, payment for materials delivered off-site is limited to the following items: Any other construction material stored offsite may be considered in determining the amount of a progress payment.

1.9 FIELD OFFICE OVERHEAD

Notice to Offerors: You must declare below the accounting practice that you apply to contracts to calculate field office overhead for all change orders, modifications, and requests for equitable adjustment. Pursuant to Federal Acquisition Regulation (FAR) Parts 31.105(d)(3) and 31.203(d)(1), an accounting practice that varies from modification to modification is not allowable. Select one of the following:

a. If you use Time Distribution Base for Per Diem Rate practice, see Special Contract Requirement "Field Office Overhead - Per Diem Rate".

b. If you use Direct Cost Distribution Base for a Percentage Mark-up practice, see Special Contract Requirement "Field Office Overhead - Percentage Markup".

c. If you choose Other Accounting Practice That is Allowed Under the FAR and That Uses a Single Distribution Base, you must describe the accounting practice in sufficient detail below to allow the Contracting Officer to determine what accounting practice is being utilized by your company and that it complies with the criteria for acceptable accounting practices as set out in FAR Parts 31.105(d)(3) and 31.203(d)(1).

1.10 FIELD OFFICE OVERHEAD - PER DIEM RATE

The Contracting Officer shall make an equitable adjustment and modify the contract in writing for any change to the contract, issued pursuant to the Changes clause or otherwise, for which the Government is responsible, and which causes either an increase or decrease in the Contractor's costs as to time or performance under the contract. Under such an equitable adjustment, the Contractor's field office overhead shall be an allowable cost, in accordance with the Contractor's accounting practice as identified by the Contractor.

The Contractor shall declare which standard form of accounting practice it applies to field overhead costs: if a contractor indicates that it follows a per diem basis, no overhead percentage markup rate for office overhead costs shall be allowed.

Under such an equitable adjustment, the Contractor shall be reimbursed for field office overhead on a per diem basis when the completion of the contract is extended by reason of the change issued under any clause, except the Default clause, subject to the Contractor substantiating the variable expense by providing a detailed breakdown of its proposed increase or decrease of costs as required by the Contract Clause DFARS

DOCUMENT 00 73 00 Page 6

252.236-7001 MODIFICATION OF PROPOSALS - PRICE BREAKDOWN. No payment of field office overhead on a per diem basis shall be allowed for any change when the completion of the contract is not extended by reason of the change.

1.11 FIELD OFFICE OVERHEAD - PERCENTAGE MARKUP

The Contracting Officer shall make an equitable adjustment and modify the contract in writing for any change to the contract, issued pursuant to the Changes clause or otherwise, for which the Government is responsible, and which causes either an increase or decrease in the Contractor's costs as to time or performance under the contract. Under such an equitable adjustment, the Contractor's field office overhead shall be an allowable cost, in accordance with the Contractor's accounting practice as identified by the Contractor.

The Contractor shall declare which standard form of accounting practice it applies to field overhead costs: if a contractor indicates that it follows a percentage basis, no per diem rate for office overhead costs shall be allowed.

Under such an equitable adjustment, payment of office overhead costs shall be allowed for any change on a percentage markup basis regardless of whether the completion of the contract is, or, is not, extended by reason of the change, except for modifications issued pursuant to the Default Clause. The Contractor shall provide a detailed breakdown of its proposed increase or decrease of costs as required by Contract Clause DFARS

252.236-7001 MODIFICATION PROPOSALS - PRICE BREAKDOWN.

1.12 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)(DOD FAR SUPP

252.236-7001)

a. The Government will provide to the Contractor, without charge, one set of drawings files and contract specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

b. The Contractor shall:

1. Check all drawings files furnished immediately upon receipt.

2. Compare all drawings and verify the figures before laying out the work.

3. Promptly notify the Contracting Officer of any discrepancies.

4. Be responsible for any errors which might have been avoided by complying with this paragraph (b); and

5. Reproduce and print drawings and contract specifications as needed.

c. In general:

1. Large scale drawings shall govern small scale drawings; and

2. The Contractor shall follow figures marked on drawings in preference to scale measurements.

d. Omissions from the drawings files or specifications or the

DOCUMENT 00 73 00 Page 7 misdescription of details of work which are manifestly necessary to carry out the intent of the specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

e. The work shall conform to the specifications and the contract drawings identified in the index of drawings attached at the end of the Special Clauses.

1.13 EPA ENERGY STAR

The Government requires that certain equipment be Energy Star compliant.

Initially, the sole Energy Star requirement shall be the self-certification by the bidder that the specified equipment is Energy Star compliant. Within 3 months of the availability of an EPA sanctioned test for Energy Star compliance, the Contractor shall submit all equipment upgrades and additions for testing and provide proof of compliance to the Government upon completion of testing. Testing shall be at the Contractor's expense.

1.14 RECOVERED MATERIALS

The Corps of Engineers encourages all bidders to utilize recovered materials to the maximum extent practicable. The attached APPENDIX R contains procurement guidelines for products containing recovered materials.

1.15 PROPRIETARY REFERENCES

All items specified on a brand name basis are to indicate the general type desired based on level of quality, and are not intended to restrict selection to products of any particular manufacturer.

1.16 PERFORMANCE EVALUATIONS

In accordance with the provisions of FAR 42.1502(e), construction contractor's performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $700,000.00, the USACE will evaluate contractor's performance and prepare a performance report using the Contractor Performance Appraisal Reporting System (CPARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days.

Access is granted by a network of government Focal Points. Typically there are many Focal Points assigned to the agency. If you require assistance with identifying your Focal Point, please email the CPARS helpdesk (webptsmh@navy.mil) with the contract/order number you are trying to access and they will provide you with the Focal Point name and contact information.

1.17 PARTNERING )

In order to most effectively accomplish this contract, the Government

DOCUMENT 00 73 00 Page 8 proposes to form a partnership with the Contractor to develop a cohesive building team. It is anticipated that this partnership would involve the Corps of Engineers, the Contractor, primary subcontractors and the designers. This partnership would strive to develop a cooperative management team drawing on the strengths of each team member in an effort to achieve a quality project within budget and on schedule. This partnership would be bilateral in membership and participation will be totally voluntary. The Contractor and Government shall be responsible for their own labor and travel costs.

1.18 KEY PERSONNEL, SUBCONTRACTORS AND OUTSIDE ASSOCIATES OR CONSULTANTS

(MAY 2006)

In connection with this contract, any in-house personnel, subcontractors, and outside associates or consultants will be limited to individuals or firms that were specifically identified in the Contractor's accepted proposal. The Contractor shall obtain the Contracting Officer's written consent before making any substitution for these designated in-house personnel, subcontractors, associates, or consultants. If the Contractor proposes a substitution, it shall submit the same type of information that was submitted in the accepted proposal to the Contracting Officer for evaluation and approval. The level of qualifications and experience submitted in the accepted proposal or that required by the Solicitation, whichever is greater, is the minimum standard for any substitution.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

DOCUMENT 00 73 00 Page 9

APPENDIX R

PART 247 - COMPREHENSIVE PROCUREMENT GUIDELINE FOR PRODUCTS CONTAINING

RECOVERED MATERIALS

40 CFR Ch. 1

Subpart B-Item Designations

§ 247.10 Paper and Paper Products

Paper and paper products, excluding building and construction paper grades

§ 247.11 Vehicular Products

a. Lubricating oils containing re-refined oil, including engine lubricating oils, hydraulic fluids, and gear oils, excluding marine and aviation oils.

b. Tires, excluding airplane tires.

c. Reclaimed engine coolants, excluding coolants used in non-vehicular applications.

d. Rebuilt vehicular parts.

(60 FR 21381, May 1, 1995, as amended at 69 FR 24038, Apr. 30, 2004)

§ 247.12 Construction Products

a. Building insulation products, including the following items:

1. Loose-fill insulation, including but not limited to cellulose fiber, mineral fibers (fiberglass and rock wool), vermiculite, and perlite;

2. Blanket and batt insulation, including but not limited to mineral fibers (fiberglass and rock wool);

3. Board (sheathing, roof decking, wall panel) insulation, including but not limited to structural fiberboard and laminated paperboard products, perlite composite board, polyurethane, polyisocyanurate, polystyrene, phenolics, and composites; and

4. Spray-in-place insulation, including but not limited to foam-in-place polyurethane and polyisocyanurate, and spray-on cellulose.

b. Structural fiberboard and laminated paperboard products for applications other than building insulation, including building board, sheathing, shingle backer, sound deadening board, roof insulating board, insulating wallboard, acoustical and non-acoustical ceiling tile, acoustical and non-acoustical lay-in panels, floor underlayments, and roof overlay (coverboard).

c. Cement and concrete, including concrete products such as pipe and block containing:

DOCUMENT 00 73 00 Page 10

1. Coal fly ash;

2. Ground granulated blast furnace slag (GGBF);

3. Cenospheres; or

4. Silica fume from silicon and ferrosilicon metal production.

d. Carpet made from polyester fiber made from recovered materials for use in moderate-wear applications such as single-family housing and similar wear applications.

e. Floor tiles and patio blocks containing recovered rubber or plastic.

f. Shower and restroom dividers/partitions containing recovered plastic or steel.

g. Consolidated latex paint used for covering graffiti; and reprocessed latex paint used for interior and exterior architectural applications such as wallboard, ceilings, and trim; gutter boards; and concrete, stucco, masonry, wood, and metal surfaces.

h. Carpet cushion made from bonded polyurethane, jute, synthetic fibers, or rubber containing recovered materials.

i. Flowable fill containing coal fly ash and/or ferrous foundry sands.

j. Railroad grade crossing surfaces made from cement and concrete containing fly ask, recovered rubber, recovered steel, recovered wood, or recovered plastic.

k. Modular threshold ramps containing recovered steel, rubber, or aluminum.

l. Nonpressure pipe containing recovered steel, plastic, or cement.

m. Roofing materials containing recovered steel, aluminum, fiber, rubber, plastic or plastic composites, or cement.

(60 FR 21381, May 1, 1995, as amended at 62 FR 60974, Nov. 13, 1997; 65 FR 3081, Jan. 19, 2000; 69 FR 24038, Apr. 30, 2004)

§ 247.13 Transportation Products

a. Traffic barricades and traffic cones used in controlling or restricting vehicular traffic.

b. Parking stops made from concrete or containing recovered plastic or rubber.

c. Channelizers containing recovered plastic or rubber.

d. Delineators containing recovered plastic, rubber, or steel.

e. Flexible delineators containing recovered plastic.

(60 FR 21381, May 1, 1995, as amended at 62 FR 60974, Nov. 13, 1997; 65 FR 3081, Jan. 19, 2000)

DOCUMENT 00 73 00 Page 11

§ 247.15 Landscaping Products

a. Hydraulic mulch products containing recovered paper or recovered wood used for hydroseeding and as an over-spray for straw mulch in landscaping, erosion control, and soil reclamation.

b. Compost made from yard trimmings, leaves, grass clippings, and/or food waste for use in landscaping, seeding of grass or other plants on roadsides and embankments, as a nutritious mulch under trees and shrubs, and in erosion control and soil reclamation.

c. Garden and soaker hoses containing recovered plastic or rubber.

d. Lawn and garden edging containing recovered plastic or rubber.

e. Plastic lumber landscaping timbers and posts containing recovered materials.

(60 FR 21381, May 1, 1995, as amended at 62 FR 60974, Nov. 13, 1997; 65 FR 3081, Jan. 19, 2000)

§ 247.16 Non-paper Office Product

a. Office recycling containers and office waste receptacles.

b. Plastic desktop accessories.

c. Toner cartridges.

d. Plastic-covered binders containing recovered plastic; chipboard and pressboard binders containing recovered paper; and solid plastic binders containing recovered plastic.

e. Plastic trash bags.

f. Printer ribbons.

g. Plastic envelopes.

h. Plastic clipboards containing recovered plastic.

i. Plastic file folders containing recovered plastic.

j. Plastic clip portfolios containing recovered plastic.

k. Plastic presentation folders containing recovered plastic.

l. Office furniture containing recovered steel, aluminum, wood, agricultural fiber, or plastic.

(60 FR 21381, May 1, 1995, as amended at 62 FR 60974, Nov. 13, 1997; 65 FR 3081, Jan. 19, 2000; 69 FR 24038, Apr. 30, 2004)

§ 247.17 Miscellaneous Products

a. Pallets containing recovered wood, plastic, or paperboard.

b. Sorbents containing recovered materials for use in oil and solvent clean-ups and as animal bedding.

DOCUMENT 00 73 00 Page 12

c. Industrial drums containing recovered steel, plastic, or paper.

d. Awards and plaques containing recovered glass, wood, paper, or plastic.

e. Mats containing recovered rubber and/or plastic.

f. Non-road signs containing recovered plastic or aluminum and road signs containing recovered aluminum, and sign supports and posts containing recovered plastic or steel.

g. Manual-grade strapping containing recovered steel or plastic.

h. Bike racks containing recovered steel or plastic.

i. Blasting grit containing recovered steel, coal and metal slag, bottom ash, glass, plastic, fused alumina oxide, or walnut shells.

(62 FR 60974, Nov. 13, 1997, as amended at 65 FR 3081, Jan. 19, 2000; 69 FR 24038, Apr. 30, 2004)

-- End of Section --

DOCUMENT 00 73 00 Page 13

This page intentionally blank

00 73 00-A - 1

ATTACHMENT 00 73 00-A

INDEX OF DRAWINGS

DRAWING NO. LDP-1.21, DATED 19 MAR 15

SHEET

NUMBER

PLATE

NUMBER

TITLE REVISION

NUMBER

DATE

1 G-001 PROJECT LOCATION AND MAP

2 G-002 DRAWING INDEX, GENERAL NOTES, AND

LEGEND

3 G-003 CONTRACTOR WORKING AREA AND ACCESS

4 G-004 CO2 SYSTEM DEMOLITION 1 - GENERAL C02

DEMO

5 G-005 C02 SYSTEM DEMOLITION 2 - HVAC, MISC.

6 G-006 WATER MIST SYSTEM SIGNAGE

7 S-001 WATER MIST SYSTEM - CURB DETAILS

8 M-001 WATER MIST SYSTEM - NOTES

9 M-002 WATER MIST SYSTEM - PLANS

10 M-003 WATER MIST SYSTEM - PIPE ROUTING

ELEVATION

11 M-004 WATER MIST SYSTEM - ELEMENTARY

SCHEMATIC

12 E-001 WATER MIST SYSTEM ELECTRICAL

ELEMENTARY SCHEMATIC

13 E-002 WATER MIST SYSTEM POWER SUPPLY AND

CABLE ROUTING

14 E-003 WATER MIST SYSTEM ELECTRICAL

INSTALLATION DETAILS, SHEET 1

15 E-004 WATER MIST SYSTEM ELECTRICAL

INSTALLATION DETAILS, SHEET 2

16 E-005 WATER MIST SYSTEM ELECTRICAL

INSTALLATION DETAILS, SHEET 3

00 73 00-A - 2

REFERENCE DRAWINGS

Reference drawings provided show conditions at time of construction. These drawings are furnished for information only and the Government does not warrant that conditions will be exactly as shown. Minor deviations can be anticipated and shall not be the basis for a claim for extra compensation.

The list of reference drawings set out in the index on the drawings, Sheet No. S-001 is hereby incorporated by reference into these specifications.

SHEET

NUMBER

PLATE

NUMBER

TITLE

1 LDP-1-3-7/1 HEATING & VENTILATING - VENTILATION DIAGRAM

2 LDP-1-6-0-0/4 ARRANGEMENT PLAN EL. 2131.5 - BAYS 1-4

3 LDP-3-6-9A24/14 SCHEMATIC DIAGRAM MAIN UNIT ANNUNICATOR

4 LDP-1-3-7/10 HEATING & VENTILATING - ERECTION BAY EL. 2100 & 2114

5 LDP-1-3-7/12 HEATING & VENTILATING - TYPICAL DETAILS SHEET 2

6 LDP-1-3-7/7 HEATING & VENTILATING CENTRAL SYSTEM - EB, BAYS 1 & 2

7 LDP-1-3-8/4 ERECTION BAY - EMBEDDED PIPING EL. 2131.5

8 LDP-1-3-8/5 ERECTION BAY - EMBEDDED PIPING EL. 2114

9 LDP-1-3-9/3 GOVERNOR & LUBRICATING OIL SYSTEMS

10 LDP-1-3-9/7 PIPING DIAGRAM - POTABLE WATER AND SANITARY SYSTEMS

11 LDP-1-3-9/18 ALL BAYS EXPOSED PIPING - TRANS OIL SHEET 1

12 LDP-1-4-3/1 ERECTION BAY - CONCRETE OUTLINE TRANSVERSE SECTION

13 LDP-1-3-9/19 ALL BAYS EXPOSED PIPING - TRANS OIL SHEET 2

14 LDP-1-3-9/20

ALL BAYS EXPOSED PIPING - GOVERNOR OIL & LUBE OIL SHEET

15 LDP-1-3-9/21

ALL BAYS EXPOSED PIPING - GOVERNOR OIL & LUBE OIL SHEET

16 LDP-1-4-3/5 ERECTION BAY - CONCRETE OUTLINE PLAN EL. 2131.5

17 LDP-1-3-9/23 ALL BAYS EXPOSED PIPING - COMPRESSED AIR SHEET 2

18 LDP-1-3-9/25 ALL BAYS EXPOSED PIPING - COMPRESSED AIR SHEET 4

00 73 00-A - 3

W912DW-16-B-0005 R0002

19 LDP-1-3-9/28 ALL BAYS EXPOSED PIPING - COMPRESSED AIR SHEET 7

20 LDP-1-3-9/34 POTABLE WATER & SANITARY - SHEET 1

21 LDP-1-3-9/35 POTABLE WATER & SANITARY - SHEET 2

22 LDP-1-6-1A0/2 CONDUIT AND CABLE NUMBERING SYSTEM

23 LDP-1-6-1A0/3 ONE LINE DIAGRAM CQ01 & CQ02

24 LDP-1-6-9A23/2 ONE LINE DIAGRAM CONTROL SOURCES

25 LDP-1-6-9D31/1 STATION SERVICE ANNUNCIATOR SCHEMATIC DIAGRAM

26 LDP-3-6-9A24/15 POWERHOUSE SCHEMATIC - STATION SERVICE ANNUNCIATOR

27 LDP-1-6-1A34/1 SCHEMATIC DIAGRAM CARBON DIOXIDE SYSTEMS

28 LDP-1-6-1A34/2

CARBON DIOXIDE SYSTEMS CONNECTION DIAGRAMS &

DETAILS

29 LDP-1-6-1A11/5 EQUIPMENT INSTALLATION ERECTION BAY EL. 2114

30 LDP-1-6-1A11/6 EQUIPMENT INSTALLATION ERECTION BAY EL. 2131.5

31 LDP-1-6-1D1/3 EMBEDDED CONDUIT & GROUNDING - ERECTION BAY EL. 2131.5

32 LDP-1-6-2D1/3 LIGHTING SYSTEM - ERECTION BAY EL. 2131.5

33 LDP-1-3-9D4/1 BATTERY SWITCHBOARD SB

34 E-101 ELEC. DIST. EQUIP. REPLACEMENT - OVERALL PLAN EL. 2131.5

35 E-201

ELEC. DIST. EQUIP. REPLACEMENT - 480V SUBSTATION

NAMEPLATE

36 E-202

ELEC. DIST. EQUIP. REPLACEMENT - 480V SUBSTATION SQ1 ONE-

LINE

37 E-401

ELEC. DIST. EQUIP. REPLACEMENT - DAM CABLES & FEEDERS

SHEET 1

38 E-602 ELEC. DIST. EQUIP. REPLACEMENT - ONE-LINE DIAGRAM SQ1

39 E-750 ELEC. DIST. EQUIP. REPLACEMENT - CONTROL ROOM LAYOUT

00 73 00-A - 4

REVISIONS TO DRAWINGS BY NOTATIONS

M-001 General Note 1: Delete “HIGH PRESSURE” from note.

Revise to “THE CONTRACTOR SHALL PROVIDE A COMPLETE AND OPERATIONAL ELECTRIC

DRIVEN WATER MIST SYSTEM IN ACCORDANCE WITH NFPA 750.”

End of Attachment 00 73 00-A

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 10

SUMMARY OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

1.3 CHANGES IN SPECIFICATIONS AND DRAWINGS

1.4 DEFINITIONS

PART 2 - PRODUCTS - NOT USED

PART 3 - PRODUCTS - NOT USED

-- End of Section Table of Contents --

SECTION 01 11 10 Page 1

SECTION 01 11 10

SUMMARY OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

This section covers the technical specifications to perform all work required to install a new water mist fire protection system in the oil storage room and oil purification room at Libby Dam. This section is a general summary of the required and optional work and is not all-inclusive. The work described within these specifications shall include, but not necessarily be limited to the following:

a. Removal of the existing CO2 system in the oil purification room and oil storage room at Libby Dam. This includes but is not limited to the mechanical piping and the electrical features as well as the CO2 bottles themselves. The bottles (i.e. cylinders or tanks) and firing heads, however, shall remain the property of the Government.

b. Provision of temporary suitable manual fire protection, as well as a 24/7 fire watch or approved equivalent, during time period from when CO2 system is disabled until the new water mist system is operable and accepted.

c. Detailed design, provision, and installation of a fine water mist fire protection system for the oil purification room and oil storage room at Libby Dam. The oil purification room and oil storage room together are to be considered one zone; if water mist is triggered in either room, it is triggered in both rooms.

d. Testing, demonstration, and training for fine water mist fire protection system, as well as cleanup of any water or oily water in the powerhouse resulting from testing, demonstrations, or training.

e. Detailed design, provision, and installation of electrical system needed to meet the requirements of the fire suppression system being provided.

f. Detailed design, provision, and installation of 3-hour-rated fire doors and frames, including but not limited to field-verification of all dimensions and details. Install fire doors and frames in three locations as shown, at the door between the oil storage room and the oil purification room, at the door out of the oil storage room, and at the door out of the oil purification room.

f. Appurtenant concrete work, seismic restraint, and firestopping.

h. Detailed design, provision, and installation of a concrete curb around the water tanks, with a water removal pump and discharge/drainage piping, as well as a notch to direct any spilled water towards the hallway to the west of the tank location.

i. Detailed design, provision, and installation of a spray-barrier, to prevent any spray from the pumps or pressurized piping of the water skid from reaching the existing electrical equipment in case of

SECTION 01 11 10 Page 2 rupture or leak.

1.3 CHANGES IN SPECIFICATIONS AND DRAWINGS

The Government reserves the right to revise or amend the specifications and/or drawings prior to the date set for opening bids. Copies of such amendments will be furnished to all prospective bidders. If the revisions and amendments require material changes in quantities or prices bid, or both, the date set for bid opening may be extended to enable bidders the opportunity to revise their bids. The amendment will include an announcement of the new date for opening bids.

1.4 DEFINITIONS

a. Wherever in the specifications, or upon the drawings, the words "directed", "required", "ordered", "designated", "prescribed", or words of like import are used, it shall be understood that the "direction", "requirement", "order", "designation", or "prescription" of the Contracting Officer is intended, and similarly the words "approved", "acceptable", "satisfactory", or words of like import shall mean "approved by" or "acceptable to" or "satisfactory to" the Contracting Officer unless otherwise expressly stated.

b. Where "as shown", "as indicated", "as detailed", or words of like import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word "provided" as used herein shall be understood to mean "provided complete in place", that is, "furnished and installed". (FAR 52.236.21(b) and (c)).

c. Wherever in these specifications or upon the drawings, the words "Contracting Officer" (CO) or "Contracting Officer's Representative" (COR) are used, it shall be understood to also mean "Government" unless otherwise expressly stated.

d. Wherever in these specifications the acronym "GQAR" is used, it shall be understood to mean "Government Quality Assurance Representative", unless otherwise expressly stated.

e. Wherever in these specifications the work "weekend(s)" is used, it shall be understood to mean "Friday, Saturday, Sunday, and Federal Holidays", unless otherwise expressly stated.

f. Whenever in these specifications the word "Project" is used, it shall be understood to mean The Libby Powerhouse.

PART 2 - PRODUCTS - NOT USED

PART 3 - PRODUCTS - NOT USED

-- End of Section --

SECTION 01 11 10 Page 3