W912DS-15-B-0008-0001.pdf

W16ROE51053555

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment 0001 is to:

1. Update Block 10 the description to read from: 26,000 CY to: 20,000 CY.

2. Change Section 00 73 00 Para 1.2 COMMENCEMENT, PROSECUTION, & COMPLETION OF WORK (1965 APRIL OCE) to read from: " Esopus Creek Dredge Area" to: "Saugerties Harbor Dregde Area"

The bid opening date remains the same 17 Aug 2015 at 2:00 P.M.

NOTE: Bidders must acknow ledge receipt of this amendment by the date specified in the bid (or as amended) by one of the follow ing methods: In the space provided on the SF 1442, by separate letter, or by signing block 15 below . FAILURE TO ACKNOWLEDGE AMENDMENT BY THE DATE AND TIME SPECIFIED MAY RESULT IN REJECTION OF YOUR BID IN ACCORDANCE WITH THE LATE BID, LATE

MODIFICATION OF BID, OR LATE WITHDRAWAL OF BID (FAR 14.304).

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 17-Jul-2015

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912DS-15-B-0008

X 9B. DATED (SEE ITEM 11)

14-Jul-2015

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

17-Jul-2015

CODE

US ARMY CORPS OF ENGINEERS, NEW YORK

26 FEDERAL PLAZA, RM 1843

NEW YORK NY 10278-0090

W912DS 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912DS-15-B-0008

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

AMENDMENT 0001

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION/CONTRACT FORM

The required performance has changed from Project: Maintenance Dredging, Saugerties Harbor, Esopus Creek, NYDescription: The work involves maintenance dredging of approximately 26,000 cubic yards of material from the shallow draft (12 feet MLLW) entrance reach of the Saugerties Harbor Federal Navigation Project Channel located at the confluence of the Esopus Creek and Hudson River; with upland placement of the dredged material in the federally owned Houghtaling Island dredged material placement site (DMPS). This solicitation is a 100% Small Business Set-AsideNAICS Code 237990, Size Standard: $27,500,000.00Submit Bids no later than 2:00 PM EST on 17 Aug 2015 to:U.S. Army Corps of Engineers Contracting Division 26 Federal Plaza, RM 1843New York, NY 10278-0090Due to heightened security at U.S. Government installations, all offerors are instructed to allow ample time to get through the security check in order to have their bids delivered before 2 PM to the address above. to Project: Maintenance Dredging, Saugerties Harbor, Esopus Creek, NYDescription: The work involves maintenance dredging of approximately 20,000 cubic yards of material from the shallow draft (12 feet MLLW) entrance reach of the Saugerties Harbor Federal Navigation Project Channel located at the confluence of the Esopus Creek and Hudson River; with upland placement of the dredged material in the federally owned Houghtaling Island dredged material placement site (DMPS). This solicitation is a 100% Small Business Set-AsideNAICS Code 237990, Size Standard: $27,500,000.00Submit Bids no later than 2:00 PM EST on 17 Aug 2015 to:U.S. Army Corps of Engineers Contracting Division 26 Federal Plaza, RM 1843New York, NY 10278-0090Due to heightened security at U.S.

Government installations, all offerors are instructed to allow ample time to get through the security check in order to have their bids delivered before 2 PM to the address above..

SECTION 00 73 00 - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

SPECIAL CONTRACT REQUIREMENTS

1.2 COMMENCEMENT, PROSECUTION, & COMPLETION OF WORK (1965 APRIL OCE)

The Contractor will be required to (a) commence work under this contract within five (5) calendar days after the date the date the Contractor receives the notice to proceed, (b) to prosecute said work diligently, (c) to substantially complete the work, to include dredging and interim stabilization of the disposal area within 60 calendar days after receipt of the notice to proceed; subject to the conditions in paragraphs 1.8.a(4) “Ice, Flood and Freshet Conditions”, and 1.53 “Monthly Anticipated Adverse Weather Delay”. The time stated for completion shall include the final clean-up. In addition, the Contractor shall be required to complete in-water dredging in the Saugerties Harbor Dredge Area no later than September 30, 2015 unless the Contractor submits and receives approval from the Contracting Officer for an extension of the in-water dredging period. Any Contracting Officer approved extension of the in-water dredging period shall not allow in-water dredging later than October 15, 2015. In no case will an extension be granted for delays caused by the Contractor’s action except those excusable delays found

W912DS-15-B-0008

in FAR 52.249-10. Should the total quantity of material to be paid for and actually removed under the contract exceed the limit established in the clause entitled “Variations in Estimated Quantities”, additional time will be allowed at the rate of one (1) calendar day for each 2,250 cubic yards in excess of the established limit. However, this shall not relieve the Contractor from the requirement to complete all in-water dredging work within the period noted above.