W912CH24R0043 Solicitation AMD 0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. Contract ID Code Page Of

2. Amendment/Modification No.

3. Effective Date

4. Requisition/Purchase Req No.

5. Project No. (If applicable)

6. Issued By Code 7. Administered By (If other than Item 6) Code

8. Name And Address Of Contractor (No., Street, City, County, State and Zip Code)

9A. Amendment Of Solicitation No.

9B. Dated (See Item 11)

10A. Modification Of Contract/Order No.

10B. Dated (See Item 13) Code Facility Code

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing items 8 and 15, and returning ____________ copies of the amendments: (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. Accounting And Appropriation Data (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATIONS OF CONTRACTS/ORDERS

It Modifies The Contract/Order No. As Described In Item 14.

A. This Change Order is Issued Pursuant To: The Changes Set Forth In Item 14 Are Made In

The Contract/Order No. In Item 10A.

B. The Above Numbered Contract/Order Is Modified To Reflect The Administrative Changes (such as changes in paying office, appropriation data, etc.) Set

Forth In Item 14, Pursuant To The Authority of FAR 43.103(b).

C. This Supplemental Agreement Is Entered Into Pursuant To Authority Of:

D. Other (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______________ copies to the Issuing Office.

14. Description Of Amendment/Modification (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. Name And Title Of Signer (Type or print)

16A. Name And Title Of Contracting Officer (Type or print)

15B. Contractor/Offeror 15C. Date Signed 16B. United States Of America 16C. Date Signed

By (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITIONS UNUSABLE

30-105-02 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

SEE SCHEDULE

X

Firm Fixed Price

0003 2024SEP10

W912CH

ACC-DTA

6501 E. 11 MILE RD.

DETROIT ARSENAL, MI 48397-5000

HEATHER R. MIERENDORF

EMAIL: HEATHER.R.MIERENDORF.CIV@ARMY.MIL

W912CH-24-R-0043

2024JUL12

X

X

/SIGNED/

2 signed

SEE SECOND PAGE FOR DESCRIPTION

1 4

CONTINUATION SHEET

Reference No. of Document Being Continued Page of

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION A - SUPPLEMENTAL INFORMATION

Buyer Name: HEATHER R. MIERENDORF

Buyer Office Symbol/Telephone Number: CCTA-APN-A/(517)644-4388

Type of Contract 1: Firm Fixed Price

Kind of Contract: Supply Contracts and Priced Orders

Weapon System: TANK,ABRAMS,M1A2 FAMILY OF VEHICLES(FOV)

*** End of Narrative A0000 ***

1. The purpose of Amendment 0003 is to update Solicitation W912CH-24-R-0043 with the following:

Section E:__________

a) Narrative E.3 Supplemental Requirements To First Article Approval (Contractor Testing) has been deleted.

2. All other terms and conditions of the solicitation remain unchanged and in full force and effort.

*** END OF NARRATIVE A0004 ***

2 4

W912CH-24-R-0043

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

SECTION E - INSPECTION AND ACCEPTANCE

E.1 INSPECTION AND ACCEPTANCE POINTS: ORIGIN____________________________________________

The Government's inspection and acceptance of the supplies offered under this contract/purchase order shall take place at ORIGIN.

Offeror must specify below the exact name, address, and CAGE of the facility where supplies to be furnished under this contract/purchase order will be available for inspection/acceptance.

INSPECTION POINT: __________________________________________

(Name) (CAGE)

(Address) (City) (State) (Zip)

ACCEPTANCE POINT: __________________________________________

(Name) (CAGE)

(Address) (City) (State) (Zip)

E.2 DRAWINGS FOR INSPECTION___________________________

E.2.1 When requested, the Contractor shall make available to the Government Inspector, the drawings, specifications and any applicable

Engineering Exceptions associated to the drawings, to which the product was manufactured. Upon completion of product inspection and acceptance by the Government Inspector, all drawings, specifications and Engineering Exceptions, will be returned to the Contractor.

E.2.2 If the contractor is not the actual manufacturer of the item being procured (i.e. dealer, distributor, etc.) the contractor shall ensure that subcontractor drawings are available for review to support the Government's inspection requirements.

E.3 SUPPLEMENTAL REQUIREMENTS TO FIRST ARTICLE APPROVAL (CONTRACTOR TESTING)____________________________________________________________________________

*** Deleted ***

E.4_NOTICE REGARDING FIRST ARTICLE TEST SAMPLE______________________________________________

E.4.1 The approved first article items, as described elsewhere in this contract, consist of a quantity of 2 that will be consumed or destroyed in testing. Any items consumed or destroyed in testing shall not be delivered as part of the contractually required quantity as set forth in the schedule. The cost of any items that are consumed or destroyed shall be included in the overall offer or contract price. A quantity of 0 that successfully passes all specified tests, less the destructive tests, if any, 0 serve as a manufacturing standard for the remainder of the contract.

E.4.2 A manufacturing standard is an item, which conforms to all technical performance requirements. A manufacturing standard will serve as 1) an aid in identifying configuration changes not controlled by the contractual design. 2) an aid in identifying any process changes, or 3) the approved workmanship sample, when required, unless alternate samples are submitted for specific characteristics by the Contractor and approved by the Government.

E.4.3 The manufacturing standard will only be used to supplement contractual acceptance/rejection criteria for those process characteristics that require approved workmanship samples. For other characteristics, if configuration or process changes are identified in production units, the contractor will notify the contracting officer for disposition. Manufacturing items that serve as a manufacturing standard may be delivered as part of the contractual quantity with the last shipment made under this contract provided it meets all contractual requirements existing at time of delivery.

E.5 USE OF MIL-STD 1916_______________________

E.5.1 The Government will not accept lots whose samples submitted for acceptance contain non-conformances unless appropriately documented and approved by the contracting officer. The contractor shall use MIL-STD 1916, DOD Preferred Methods of Acceptance of

Product. The Verification Level (VL) shall be VL for major characteristics and II for minor characteristics.

E.5.2 MIL-STD HDBK-1916 provides guidance on the use of MIL-STD 1916. This handbook is not contractually binding.

E.6 NOTICE REGARDING FIRST ARTICLE__________________________________

3 4

Name of Offeror or Contractor:

PIIN/SIIN MOD/AMD

E.6.1 Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.

E.6.2 When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.

E.6.3 Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule.

*** END OF NARRATIVE E0001 ***

4 4