W912BV21Q00730002RevisedSOW.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to:

1. Incorporate Summary of Work, Revised 20 July 2021, as specified in Section 01 11 00 SOW. All changes are highlighted in yellow .

2. The POC for this action is Linda Tow nsel at linda.d.tow nsel@usace.army.mil.

SEE SUMMARY OF CHANGES.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 20-Jul-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912BV21Q0073

X 9B. DATED (SEE ITEM 11)

13-Jul-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

20-Jul-2021

CODE

CONTRACTING DIV

US ARMY CORPS OF ENGINEERS, TULSA DISTRICT

2488 E. 81ST STREET

TULSA OK 74137-4290

W912BV 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

X 1

W912BV21Q0073

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 01 00 00 - GENERAL REQUIREMENTS

The following have been added by full text:

01 11 00 REVISED SOW

SECTION 01 11 00

SUMMARY OF WORK

Revised 20 July 2021

PART 1 GENERAL

1.1 SCOPE OF WORK

In general, this Scope of Work consists of Demolition and Disposal activities of Erected Radio Tower and Appurtenances located at the Council Grove Lake Project Office. This solicitation also includes option award items for expanding the overall performance to include Radio Tower Demolition, Deconstruction, and Disposal activities at various project sites in Southeast Kansas.

This project will be a total turn-key contract with all work being performed by the Contractor unless otherwise stated. The Contractor shall provide all plant, materials, equipment, labor, instruments, tools, Sub- Contractors, supervision, management, per diem, and travel necessary to complete all work in accordance with the statement of work (SOW), attached drawings, specifications, and all other contract documents and requirements. Where contract documents and criteria appear to be in conflict, the Contractor shall consult the Contracting Officer (KO) or the Contracting Officer's Representative (COR), as applicable, for clarification before beginning any work.

1.2 BID ITEMS:

BASE BID: COUNCIL GROVE LAKE, Radio Tower Demolition and Disposal.

Located at Council Grove Lake, Morris County Kansas. (Reference Supporting Documents for Specific Performance).

Option Bid Item 1: BIG HILL LAKE, Radio Tower Demolition and Disposal.

This option award item shall expand upon the awarded base option and if awarded, this work will be performed at the Big Hill Lake Project Office, Labette County Kansas. (Reference Supporting Documents for Specific Performance).

Option Bid Item 2: FALL RIVER LAKE, Radio Tower Demolition and Disposal.

This option award item shall expand upon the awarded base option and if awarded, this work will be performed at the Fall River Lake Project Office, Greenwood County Kansas. (Reference Supporting Documents for Specific Performance).

Option Bid Item 3: Teeterville, Radio Tower Demolition and Disposal.

This option award item shall expand upon the awarded base option and if awarded, this work will be performed at the Teeterville Repeater Project Site, Greenwood County Kansas. (Reference Supporting Documents for Specific Performance).

Option Bid Item 4: Marion Reservoir, Radio Tower Demolition and Disposal.

This option award item shall expand upon the awarded base option and if awarded, this work will be performed at the Marion Reservoir Project Office, Marion County Kansas. (Reference Supporting Documents for Specific Performance).

Option Bid Item 5: John Redmond Reservoir, Radio Tower Demolition and Disposal.

This option award item shall expand upon the awarded base option and if awarded, this work will be performed at the John Redmond Reservoir Project Office, Coffey County Kansas. (Reference Supporting Documents for Specific Performance).

1.3 BASIS FOR PAYMENT

Payment will be made in a lump sum upon completion of work. The basis for payment under this contract is completion of the total prescribed work according to each line item bid option. The contract price shall be full compensation for furnishing all materials, equipment, labor, and incidentals necessary to complete the work as specified. The Government shall make a final inspection and acceptance of the work before payment is authorized.

1.4 WORK HOURS

Regular work hours will be from 7:00 am- 4:30 pm Monday through Friday, excluding federal holidays. Any proposed changes to the work hours must be approved by the Contracting Officer's Representative (COR).

1.5 COMPLETION TIME

Work shall be completed in 180 calendar days after award. The Notice To Proceed (NTP) shall be issued upon Award however the Contractor will not be granted access to the jobsite until required submittals have been approved, reviewed, or received.

1.6 SAFETY REQUIREMENTS

The Contractor shall comply with the Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1 dated 30 November 2014 in addition to all applicable Federal, State, and Local safety codes and practices. It is the Contractor's responsibility to ensure public safety during the entire duration of the contract. Necessary signs, barriers, warning devices, etc.

shall be operated and maintained by the Contractor at Contractor expense.

Contractor employees shall comply with the minimum dress requirements as stated in Chapter 5 of EM 385-1-1.

1.7 EQUIPMENT

All equipment used to perform work under this contract shall be in good operating and mechanical condition and shall comply with EM 385-1-1. All equipment shall be inspected by the Contractor and the inspection reports shall be submitted to the Contracting Officer's Representative prior to utilization of such equipment to accomplish work on this contract.

Equipment designated for use on the water must be inspected with Government Representative on site. Equipment with fluid leaks such as gasoline, oil, and hydraulic fluid are NOT authorized for use and equipment needing repairs must be removed from Government Property for servicing.

1.8 WEATHER LIMITATIONS

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORKDAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 4 4 5 5 4 4 4 4 3 4 4

1.9 SUBMITTALS

The Contractor will be required to furnish certain submittals. These submittals will include progress reports, certifications of materials, safety plans, drawings, training certifications, work plans, etc. These will be specifically listed and shall be furnished to the Contracting Officer's Representative electronically via Adobe (.PDF) or Microsoft Word (.docx) unless other formatting is requested by the COR or alternative formatting has been an approved by the COR prior to submission.

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. FIO (For Information Only) submittals do not require Government approval. In addition to submittals referenced throughout the specifications, the Contractor shall furnish:

Contracting Company's Health and Safety Program; G

Personnel Training; G

For all personnel accessing the jobsite (including sub-Contractors):

a. Anti-Terrorism Level 1 Awareness; G, COR

b. Operational Security (OPSEC); G, COR

c. Proof of E-verify; G, COR

1.10 PREWORK CONFERENCE

A pre-work conference will be held with the Contracting Officer's Representative (COR) and the Contractor prior to the commencement of any work. The Contractor's responsible person and necessary administrative staff will be required to attend this meeting. Procedures for proper invoicing and payment, schedule, etc., will be covered at this time.

1.11 VERIFICATION OF SITE CONDITIONS

The Contractor shall obtain all required information, measurements, dimensions, etc. necessary to field verify all existing conditions and dimensions and provide the specified Detailed Work Plan, Traffic Control Plan, and all other necessary submittal information. If there are existing conditions that appear to affect the proposed construction, the Contractor shall inform the COR in writing before proceeding with any manufacturing or construction processes, including ordering of materials. Before beginning any demolition or deconstruction work, survey the site and examine the drawings and specifications to determine the extent of the work. To protect both the Government's and Contractor's interests, detailed documentation of existing conditions shall be recorded by the Contractor before beginning any work. Record existing conditions in the presence of the Contracting Officer showing the condition of structures, pavement, and other facilities adjacent to construction areas. Digital photographs each with 5-megapixel minimum resolution shall be provided (thumb drive or DVD/CD format) by the Contractor as a record of existing conditions. Also, 5"x7" color hard copies of each photograph shall be provided on photograph quality paper by the Contractor to the Contracting Officer's Representative. Include in the record possible conflicting electrical service and conduits, plumbing lines, alarms systems, the location and extent of existing cracks and other damage and description of surface conditions that exist prior to starting work.

Submit survey results as specified.

1.12 SITE VISIT

An authorized Contractor Representative in conjunction with the Contracting Officer's Representative and Technical Representatives shall conduct a site visit at the proposed construction site. The purpose of the site visit will be to allow the Contractor the opportunity to further examine the project site conditions with the on-site Government personnel.

1.13 PUBLIC SAFETY

The Contractor's work plan, traffic control plan, and construction methods shall be developed and executed with the understanding that public safety will not be compromised. The Contractor shall plan and execute the work to maintain public safety during both active work times and non- work times.

The Contractor shall leave the work area daily in such a manner that public safety is maintained during non-work hours.

1.14 TRAFFIC CONTROL

If the Contractor's performance creates a disturbance that causes a potential hazard or in requires the public in general to alter their behavior and normal interactions with regards to traffic ability of public roads, then a traffic control plan shall be required. It is the Contractors responsibility to prepare, execute, and notify all responsible parties of their traffic control plan prior to starting work. The Contractor shall submit a traffic control plan for Government review and approval before distributing to other governmental officials. The traffic control plan shall be in accordance with all requirements of this contract and the Manual on Uniform Traffic Control Devices (MUTCD), 2009 Edition and all revisions.

1.15 CONTRACTOR STAGING AREA

The Government will identify an area for the Contractor's use for staging, storage, and other contract activities. The Contractor shall provide all necessary facilities (gates, fences, gravel, office trailers, storage buildings, fuel tanks, etc.) and utilities. The Government will provide no facilities. The Contractor shall obliterate all facilities and return the area to its pre-contract state (including grading and turfing) before the contract is deemed to be complete by the Government. Payment may be withheld pending acceptable obliteration of these facilities.

1.16 ENVIRONMENTAL CLEANUP

The Contractor shall maintain a clean work area at all times. The Contractor shall be responsible for the protection and preservation of the environment and will be required to restore all damages/disturbances subject to the approval of the Contracting Officer. The Contractor shall remove and dispose of all debris off Government property in a state approved disposal site unless specified otherwise. The Contractor will be required to comply with all Federal and State environmental requirements.

1.17 COORDINATION OF WORK

The Contractor shall coordinate all work with the Contracting Officer's Representative, maintain communications with lake office personnel and efficiently raise awareness to the effected public. The Contractor shall be required to complete the work without impacting the day to day operations.

The Government point of contact (POC) for this work will be Gary Kepley at 620-767-5195. The Contractor must also allow government representatives access to Contractor facilities with 24-hour notice.

1.18 ANTITERRORISM AND OPERATIONS SECURITY REQUIREMENTS

The Contractor shall be responsible for ensuring all personnel, to include sub-contractor personnel, comply with the training requirements and procedures identified on the document titled "Antiterrorism/Operations Security Requirements" in Section H, Special Contract Requirements. When items for which training is identified, the Contractor shall ensure that all personnel complete acknowledgement for the specified training; the

Contractor is responsible for ensuring all training acknowledgments, when applicable, are submitted to the COR or Contracting Officer within 10 calendar days of contract award (or NTP for construction contracts). In no event shall any Contractor or sub-Contractor personnel be onsite prior to completion of any applicable training and submission of training verification. Training materials and verification forms will be provided by the Contracting Officer upon written request. Pre? screen candidates using E-Verify Program. The Contractor must pre-screen candidates using the E- Verify Program (http://www.dhs.gov/E?Verify) website to meet the established employment eligibility requirements. The Contractor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E? verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

1.19 CONTRACTOR PERSONNEL

Persons hired by the Contractor shall be fully qualified to perform the work in a professional manner and in industry installation standards. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

The Contractor is responsible for providing the Contracting Officer's Representative with a copy all required licenses, certifications, and other documents pertaining to the contracted personnel.

1.20 QUALIFICATIONS

The Contractor shall furnish proof of at least 5 years of work experience with regards to performing masonry repair, concrete mortar installation, ferrous and non-ferrous metal welding as applicable to field installation and modifications of steel frame installation as outlined in this SOW.

1.21 LIQUIDATED DAMAGES

Liquidated damages of $243.17 per day shall be incurred by the Contractor for every day beyond the end of the performance period in which the contract is not completed.

1.22 REGULATORY REQUIREMENTS

The Contractor must comply with Kansas Laws and Regulations for sanitizing equipment that has made contact with bodies of water to mitigate invasive species at no additional cost to the Federal Government. Reference Kansas Department of Health and Environment for methods and procedures pertaining to the mitigation and prevention of aquatic nuisance species.

1.23 DELIVERY, STORAGE, AND HANDLING

Reference Specifications for Instructions.

1.24 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.25 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation and comply with Installation requirements for locating and marking underground utilities.

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Scan the construction site with Ground Penetrating Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered.

Verify the elevations of existing piping, utilities, and any type of underground or encased obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed.

Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.25.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.26 GOVERNMENT-FURNISHED MATERIAL AND EQUIPMENT

NONE

1.27 DELIVERY SCHEDULE

Notify the Contracting Officer in writing at least 5 calendar days in advance of the date on which the materials and equipment are required.

PART 2 PRODUCTS

2.1 PRODUCTS

The Contractor is responsible for acquiring all products as outlined in the specifications unless otherwise instructed by the Contracting Officer.

PART 3 EXECUTION

3.1 GENERAL

The existing Radio Towers identified for demolition have surpassed their utilization expectancy and it is the intention of this scope of performance to fully remove them and restore ground conditions at the performance site.

Reference supporting documentation and map locations for further information.

The acceptance of work performed will be determined by the Contracting Officer's Representative in reference to the pre-negotiated performance standards outlined in this Scope of Work and Specifications. All negotiations shall be performed by the Contracting Officer and any modifications or changes to the contract will be reflected in the Contracting Officer's Representative's assessment of contract compliance and performance.

3.1.1 BASE BID: COUNCIL GROVE LAKE, Radio Tower Demolition and Disposal.

EQUIPMENT:

Tower: 150 Ft. Guyed Tower

Site Coordinates: 38°40'34.10"N 96°30'34.31"W

Antenna 1: Elevation 152 Ft., No Label (Brand, Dipole (Type)

The Contractor will remove The Antenna and Transmission Line, Deconstruct the Tower, Remove the Anchors, Remove the Guy Wires, Remove the Handrails around the Anchors, and Remove any Grounding System in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

The Primary Tower Base is in close proximity to the Office Building and will remain in place.

The Western Anchor is in close proximity to known underground utilities and the ground must not be disturbed. The Contractor will cut the anchor flush with surface grade.

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible manner consistent with all applicable Local, County, State, and Federal Laws.

3.1.2 Option Bid Item 1: Big Hill Lake, Radio Tower Demolition and

Tower: 150 Ft. Monopole

Site Coordinates: 37°16'30.95"N 95°28'22.58"W

Antenna 1: Elevation 150 Ft., No Label (Brand), Dipole (Type) the Tower and Remove any Grounding System in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

The Tower Base is encased with concrete and must be saw cut or chipped no less than 3 inches below grade and patched with a concrete repair mortar as approved by the Contracting Officer.

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible

3.1.3 Option Bid Item 2: FALL RIVER LAKE, Radio Tower Demolition and

Tower: 303 Ft. Guyed Tower

Site Coordinates: 37°38'50.32"N 96° 4'46.17"W

Antenna 1: Elevation 286 Ft., No Label (Brand, Dipole (Type) the Tower, Remove the Anchors, Remove the Tower Base, Remove the Guy Wires, Remove the Handrails around the Anchors, and Remove any Grounding System in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible

3.1.4 Option Bid Item 3: Teeterville, Radio Tower Demolition and Disposal.

Tower: 300 Ft. Guyed Tower

Site Coordinates: 38° 2'22.56"N 96°25'23.91"W

Antenna 1: Elevation 270 Ft., No Label (Brand), Dipole (Type)

Antenna 2: Elevation 300 Ft., No Label (Brand), Dipole (Type)

Remove the Handrails around the Anchors, and Remove any Grounding System in addition to, the Fence, Generator Building, and Concrete Foundation in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

The Contractor will disconnect all utilities including the Emergency Generator.

The Contractor is responsible for disconnecting, deconstructing, removing, and delivering the following items to the Government.

a. Emergency Generator with Exhaust, Air Intake, and Electrical Panel.

b. Propane Tank.

c. Communication Equipment Inside of Building.

d. Ductless Air Conditioner.

e. Lock Set on Door.

f. Signage from the Fence.

All items are in working condition and must remain undamaged and operable at time of delivery to the following address:

Fall River Lake Project Office 2453 Lake Rd.

Fall River, KS 67047

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible

3.1.5 Option Bid Item 4: Marion Reservoir, Radio Tower Demolition and

FCC ID: N/A

Site Coordinates: 38°22'42.26"N 97° 4'32.07"W

Antenna 1: Elevation 150 Ft., No Label (Brand), Dipole (Type)

Remove the Handrails around the Anchors, and Remove any Grounding System in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible

3.1.6 Option Bid Item 5: John Redmond Reservoir, Radio Tower Demolition and

FCC ID: N/A

Site Coordinates: 38°15'18.32"N 95°44'58.14"W

Dish: Elevation 45 Ft., No Label (Brand), Raydome (Type)

Antenna 1: Elevation 80 Ft., No Label (Brand) Dipole (Type)

Antenna 2: Elevation 128 Ft., No Label (Brand) Dipole (Type)

Remove the Handrails around the Anchors, and Remove any Grounding System in accordance with the specifications and drawings unless otherwise directed by the Contracting Officer.

One of the Anchor's is encased with concrete and must be saw cut or chipped no less than 3 inches below grade and patched with a concrete repair mortar as approved by the Contracting Officer.

The Tower is painted with lead-based paint, which does not require removal prior to disposal. However, any disposal plan needs to include language addressing the paint. Disposal shall be in an environmentally responsible

3.2 ACCOMPLISHMENT OF WORK

The selected contractor shall furnish all labor, materials, services, trained personnel, bonds, insurance, security, instrumentation, and equipment to ensure the entire project is completed in accordance with the specifications. The objective of these tasks are to fully remediate, demolish, and dispose of the existing government equipment in full compliance with federal, state, and any other applicable laws and to remediate site ground conditions as specified.

-- End of Section --

(End of Summary of Changes)