Amendment 0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912BU24B0014

X 9B. DATED (SEE ITEM 11)

22-May-2024

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Amendment 0002 is hereby issued to provides answers for additional RFIs.

Please indicate receipt of this amendment on Standard Form 1442 (SOLICITATION, OFFER AND AWARD) as Amendment No. 0002. Failure to acknowledge all amendments may be cause for rejection of the bid.

**********************************THIS AMENDMENT DOES NOT EXTEND THE BID OPENING DATE*****************************

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Jul-2024

CODE

U.S. ARMY CORPS AND ENGINEERS - PHILA

1650 ARCH STREET

PHILADELPHIA PA 19103

W912BU 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

1. Expectation of completion of either, or both of the, site locations? 180 days is enough time to complete the scope but with bids not due to 6/26 and award within maybe a month, we are looking at the earliest starting the project in late August-Early Sept in Pittsburgh, which shortens suitable paint season for 2024.

Please provided and estimated or expected completion.

Expected completion is 180 days from Notice to Proceed. Period of Performance for this contract will not be changed. A no cost time extension may be issued if weather delays occur.

2. On SF 1442 it states the project magnitude to be $1-5M however in the specifications (para 1.6e) it states a magnitude of $100-250K. Please clarify to which magnitude USACE has determined.

Project magnitude is between $1M and $5M.

3. This project has a service NAICS code of 562910 Remediation Services, can this be changed to the construction NAICS code of 238320 Painting and Wallcovering?

The contract is primarily a remediation contract, the NAICS is 562910 and will not be changed.

4. Would email submission be considered for this IFB?

Email submission is not allowed for this IFB.

5. Please confirm that the schedule as per spec section 01 32 01 must be cost loaded.

Schedules should be cost loaded as required in the specifications.

6. Please confirm that the superintendent cannot serve as either the SSHO or QCM.

The superintendent can not sever as the SSHO or QCM

7. Please confirm that the QCM cannot also serve as the SSH The QCM can not serve as the SSHO

W912BU24B0014

(End of Summary of Changes)

SECTION SF 30 BLOCK 14 CONTINUATION PAGE SUMMARY OF CHANGES