W912BU-18-B-0005_Specs-AM1.pdf

W25PHS80864704

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

THIS AMENDMENT DOES NOT EXTEND THE BID OPENING DATE OF 26 JUNE 2018 AT 11:00 AM (EST)

(continued)

1. CONTRACT ID CODE PAGE OF PAGES

J 1 1

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912BU18B0005

X 9B. DATED (SEE ITEM 11)

23-May-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

A0001

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Jun-2018

CODE

CONTR DIV-CONTRACTS BR

USACE, PHILA DISTRICT

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

W912BU 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

This page was intentionally left blank for duplex printing.

Amendment No. 0001

IFB W912BU-18-B-0005

14. DESCRIPTION OF AMENDMENT (continued)

a. BIDDING INQUIRIES AND RESPONSES: Bidding inquiries with responses, annotated Amendment No. 0001, attached hereto.

b. BIDDING SCHEDULE, SECTION 00 10 00 SOLITICITATION: Delete Section 00 10 00 Page 3 containing the BIDDING SCHEDULE and substitute revised Section 00 10 00 Page 3 annotated Amendment No. 0001, attached hereto.

c. SECTION 00 70 00 CONTRACT CLAUSES: Delete Contract Clause 52.211-10 in its entirety and substitute revised Contract Clause 52.211-10, attached hereto.

d. SECTION 00 73 46 WAGE RATES: Delete NJ46 of Section 00 73 46 WAGE RATES in its entirety and substitute updated NJ46 of Section 00 73 46 WAGE RATES annotated Amendment No. 0001, attached hereto.

e. SECTION 01 30 00 ADMINISTRATIVE REQUIREMENTS: Delete Section 01 30 00, page 1 in its entirety and substitute revised Section 01 30 00, page 1 annotated Amendment No. 0001, attached hereto.

f. SECTION 35 20 23 DREDGING: Delete Section 35 20 23, page 14 in its entirety and substitute revised Section 35 20 23, page 14 annotated Amendment No. 0001, attached hereto.

g. CONTRACT DRAWINGS: Please delete Drawings C-102, C-103, C-301, C-302 and C-401 in their entirety and substitute revised Drawings C-102, C-103, C-301, C-302 and C-401 with the latest revision date of 06 June 2018, attached hereto.

h. Please indicate receipt of this amendment on Standard Form 1442

(SOLICITATION, OFFER, AND AWARD) as Amendment No. 0001. Failure to acknowledge all amendments may be cause for rejection of the bid.

Response to Bidding Inquiries

Bidding Inquiry Responses for Solicitation No. W912BU-18-B-0005 Inquiry

Section/ Drawing

Inquiry Response

1 What is the historical nature for removal of material in this area?

This project has been maintained utilizing large hydraulic pipeline dredge plants.

2 Is this project specifically made for hydraulic dredging?

Dredging work to be performed by hydraulic pipeline dredge only. Due to the light density of the very fine silts that settle within the contract work limits the only viable method to clear the fluid, soft silts is to utilize large suction pipeline dredges with significant horsepower.

3 We would plan on mechanical removal with a clamshell bucket into dump scows and transited to the disposal site for hydraulic removal.

Is this a viable method?

No. See above.

4 Is there language for debris encountering?

Not applicable. No mechanical dredging and hydraulic unloaders will be permitted for this contract work.

Material typically dredged in the past consists of dark grey, very soft silt. See Appendix B-40 Abstract of Bottom Samples.

5 Note #2 indicates that the information depicted on the contract map represents the results of surveys made on December 20, 2016. These surveys are no longer representative of the current condition of the project. Please provide an updated bathymetric survey in electronic or xyz format.

The soundings and cross sections on sheets C-102, C-103, C-301 and C-302 have been updated with the most recent survey data available and are included in the AM0001 drawings.

6 Please provide an updated topographic survey of the Pedricktown North Disposal Area.

Sheet C-401 has been updated with the most recent survey data available and is included in the AM0001 drawings. Please see notes 11-14 on sheet C-401.

Response to Bidding Inquiries

Bidding Inquiry Responses for Solicitation No. W912BU-18-B-0005 Inquiry

Section/ Drawing

Inquiry Response

7 Please clarify the fill capacity of the Pedricktown Disposal Area.

Please refer to sheet C-401, notes 11-14.

8 The Contractor shall be required to … (b) commence actual dredging within 15 days after the date of the notice to proceed, … (d) complete the entire work and ready for use not later than 40 days after the date of the notice to proceed.

The government –furnished disposal area to be used is the Pedricktown North Disposal Area and would require approximately 40,000 linear feet of pipeline. The pipeline setup of this length will require approximately 50 days to its complete installation. The required dredging start of 15 days is not realistic.

Adding dredging and demobilization days would increase the needed days threefold. We suggest that the government change the 15 day startup requirement to 75 days and the 40 day completion requirement to 180 days.

See Amendment No. 0001.

9 The estimated $1,000,000 and $5,000,000 magnitude for the Contract Work is not realistic and needs to be updated to meet the realistic scope of works and requirements for this project.

The bid range will remain the same.

10 Is there a closer disposal area to the dredge site available?

No there is not a closer disposal area ready to accept dredged material at this time.

Section 00 10 00 Page 3

BIDDING SCHEDULE

(To be attached to SF 1442)

Item Estimated Unit Estimated No. Description Quantity Unit Price Amount_____

1. Mobilization & Demobilization 1 JOB L.S. $___________

2. Removal and Satisfactory

Disposal of Material 430,284 CY $_________ $___________

TOTAL ESTIMATED AMOUNT $______________

NOTE: Bidders must bid on all items.

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR

1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after receiving the notice to proceed, (b) commence actual dredging under this contract within 30 calendar days after the date of notice to proceed, (c) prosecute the work diligently, and

(d) complete the entire work ready for use not later than 90 calendar days after the date of the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

General Decision Number: NJ180046 06/01/2018 NJ46

Superseded General Decision Number: NJ20170046

State: New Jersey

Construction Type: Heavy

County: Atlantic County in New Jersey.

HEAVY CONSTRUCTION PROJECTS

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually.

Please note that this EO applies to the above mentioned types of contracts entered into by the federal government that are subject to the Davis Bacon Act itself, but it does not apply to contracts subject only to the Davis Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2) (60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/05/2018 1 02/09/2018 2 06/01/2018

CARP0006 013 11/01/2017

Rates Fringes

CARPENTER (Including Form Work)............................$ 47.92 57%

The first sixty feet at the regular rate, 10% per hour additional for each additional fifty feet thereafter.

Amendment No. 0001

Section 00 73 46 Page 12

CARP0454 009 05/01/2016

Rates Fringes

PILEDRIVERMAN....................$ 43.95 31.32

PAID HOLIDAYS:

New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day; provided that the worker works any of the three days in the five day work week preceding the holiday and the first work day after the holiday.

* CARP0715 007 05/01/2018

Rates Fringes

Millwright.....................$ 48.80 58%+0.20

Work of erection and dismantling of elevators and towers, such as concrete conveyors and temporary material elevators, scaffolding or other structures to be used as scaffolding inside or outside of buildings: the first sixty feet at the regular rate, 10% per hour additional for each additional fifty feet thereafter.

ELEC0351 011 10/02/2017

Rates Fringes

Electricians:

Cable splicer on lead cable.$ 46.51 72.54% + .65 Electrician and cable splicer.....................$ 46.55 77.03%+.65

ENGI0825 019 01/01/2018

Rates Fringes

Power equipment operators:

GROUP 1.....................$ 47.70 30.30

GROUP 2.....................$ 46.05 30.30

GROUP 3.....................$ 43.91 30.30

GROUP 4.....................$ 42.41 30.30

GROUP 5.....................$ 40.69 30.30

Amendment No. 0001

Section 00 73 46 Page 13

Hazardous waste removal work:

Work on a state or federally designated hazardous waste site, where the worker is in direct contact with hazardous material, and when personal protective equipment is required for respiratory, skin and eye protection: 20% per hour additional.

PAID HOLIDAYS:

New Year's Day, Washington's Birthday observed, Memorial Day, Independence Day, Labor Day, Presidential Election Day, Veteran's Day, Thanksgiving Day and Christmas Day; provided

1) that the worker works three of the preceding five work days before the holiday; or, the work day before the holiday and the work day after the holiday; and, 2) that the worker works the work day before and the work day after the holiday.

DEFINITION OF GROUPS:

GROUP 1:

Backhoe, Including Backhoe Track; Boom; Concrete Paving Machine; Crane (all types, including overhead and straddle traveling type); Drill (down the hole drill, rotary drill, self propelled hydraulic drill, self powered drill);

Elevating Grader; Excavator; Front End Loader (5 cu. yd.

and over); Piledriver (length of boom, including length of leads, shall determine premium rate applicable)

GROUP 2:

Concrete Pumper; Grader/Blade (Finish); Hoist; Hydraulic Crane, 10 Tons and under; Front End Loader (2 cu. yd. but less than 5 cu. yd.); Scraper; Side Boom

GROUP 3:

Asphalt Spreader; Bulldozer; Compressor(2 or 3) (in Battery) (within 100 ft.); Crusher; Forklift; Front End Loader (1

cu. yd. and over but less than 2 cu. yd.); Lull; Mechanic;

Paver, Asphalt; Roller, Blacktop; Tractor;

GROUP 4:

Broom; Compressor (Single); Farm Tractor; Front End Loader (under 1 cu. yd.); Roller, Grade; Pump

GROUP 5:

Oiler

Amendment No. 0001

Section 00 73 46 Page 14

IRON0350 006 07/01/2016

Ironworkers:

Reinforcing.................$ 47.02 37.75 Structural and Ornamental...$ 48.02 37.75

LABO0172 007 03/01/2017

Rates Fringes

Laborers:

Landsacpe Laborer, Power Tool Operator...............$ 38.75 28.60 Pipelayer...................$ 39.45 28.60

Hazardous waste removal work:

Work on a state or federally designated hazardous waste site, where the worker is required to wear Level A, B or C personal protection: $3.00 per hour additional.

Work on a state or federally designated hazardous waste site, where the worker is not required to wear Level A, B, or C personal protection: $1.00 per hour additional.

PAID HOLIDAYS:

New Year's Day, President's Day, Memorial Day, Independence Day, Labor Day, Presidential Election Day, Veteran's Day, Thanksgiving Day and Christmas Day; provided that the worker works three days for the same employer within a period of ten working days consisting of five working days before and five working days after the day upon which the holiday falls or is observed.

LABO0222 013 07/01/2012

Rates Fringes

LABORER

MASON TENDER:

Cement/Concrete.............$ 29.35 23.07

PAIN0711 023 05/01/2017

Amendment No. 0001

Section 00 73 46 Page 15

Painters:

Work on bridges (Major Bridges Designed for Commercial Navigation)......$ 54.13 27.12

PAIN0711 024 05/01/2017

Rates Fringes

Painters:

New Construction Brush and roller...........$ 40.19 22.72

Repaint work, on projects on which no major alterations occur.

Brush and roller...........$ 29.05 18.91

* PLAS0592 036 05/01/2018

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 42.09 32.82

* PLUM0322 010 05/01/2018

Rates Fringes

PIPEFITTER.......................$ 46.17 40.34

TEAM0331 003 05/01/2017

Rates Fringes

Truck drivers:

Dump Truck, Pickup Truck....$ 36.53 19.44 Off the Road Truck, Flatbed Truck...............$ 36.88 19.44

Hazardous waste removal work:

Work on a state or federally designated hazardous waste site, where the worker is in direct contact with hazardous material, and when personal protective equipment is required for respiratory, skin and eye protection: $3.00 per hour additional.

Work on a state or federally designated hazardous waste site

Amendment No. 0001

Section 00 73 46 Page 16 where the worker is not working in a zone requiring Level A, B or C personal protection: $1.00 per hour additional.

PAID HOLIDAYS:

New Year's Day, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Presidential Election Day, Veteran's Day, Thanksgiving Day and Christmas Day.

BEREAVEMENT LEAVE:

Any worker having a death in his or her immediate family (parent, spouse, child, brother or sister, mother in law or father in law) shall be given three days time off with pay at the time of death upon furnishing proof of said death.

This provision shall also apply to grandparents, when living with the worker.

SUNJ2004 022 01/02/2009

Rates Fringes

LABORER: Common or General......$ 25.30 11.92

OPERATOR: Backhoe Loader Combo............................$ 31.28 20.79

WELDERS Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic

Amendment No. 0001

Section 00 73 46 Page 17 violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198 005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that

Amendment No. 0001

Section 00 73 46 Page 18 classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non union rates. Example: SULA2012 007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG OH 0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour

Amendment No. 0001

Section 00 73 46 Page 19

Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

Amendment No. 0001

Section 00 73 46 Page 20

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

33 CFR 88 Pilot Rules

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Notice To Mariners

Movement Of Navigation Aids

Evidence Of Insurance

Placing Submerged Pipelines Across The Channel

SD-11 Closeout Submittals

1.3 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

In addition to FAR 52.211-10 of Section 00 70 00 CONTRACT CLAUSES:

a. The Contractor shall:

(1) commence actual dredging under this contract within 30 calendar days after the date of receipt by him of notice to proceed, and

(2) complete the entire work for use not later than 90 calendar days after the date the Contractor receives the notice to proceed.

1.4 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

The liquidated damages amount for FAR 52.211-12 in Section 00 70 00

Section 01 30 00 Page 1

CONTRACT CLAUSES, is $2000.00.

1.5 SUPERVISION

1.5.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.5.2 Superintendent Qualifications

The project superintendent must have a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

1.5.2.1 Duties

The project superintendent is primarily responsible for managing and coordinating day-to-day production and schedule adherence on the project.

The superintendent is required to attend partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.5.3 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to insure timely completion. Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.6 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule of prices or earned value report, shop drawings, and other submittals, scheduling programming, prosecution of the work, and clear expectations of the "Interim DD Form 1354" Submittal. Major subcontractors who will engage in the work must also attend.

1.7 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's

Section 01 30 00 Page 2

3.4.3 Continuing Effluent Control

Upon completion and acceptance of a work assignment, provide continuing, intermittent labor to assure that effluent control is continued beyond the completion of dredged discharge into the disposal area. Control, including the removal of flashboards, shall be continued until water impoundment is reduced to that which existed prior to the commencement of disposal into this area. The time required for effluent control beyond completion and acceptance of the work assignment shall not be considered part of the completion time for the contract.

3.5 OVERDEPTH AND SIDE SLOPES

3.5.1 Overdepth

a. Dredging is required to a depth of 35 feet MLLW (DATUM) plus 1 foot allowable overdepth, limited by a vertical plane through the required depth contour, within the contract work limits from Station 0+000 to Station 1+650.

b. Dredging is required to a depth of 38 feet MLLW (DATUM) plus 1 foot allowable overdepth, limited by a vertical plane through the required depth contour, within the contract work limits from Station 1+650 to Station 6+236.

3.5.2 Side and End Slopes

No side or end slopes are specified for this contract (box cut).

Computation of payment quantities will be to the specified depth within the channel edges for all areas requiring dredging, with the following exceptions: Dredging will be required to a distance of 25 feet outside the North Channel edge, north turning basin edges, and entrance widening (flare), when required dredging depths exist inside the channel and basin, along the perimeter of the north edge.

3.5.3 Excessive Dredging

Material taken from beyond the limits specified in the Paragraphs entitled:

"Overdepth" and "Side and End Slopes" will be deducted from the total amount dredged as excessive dredging, for which payment will not be made.

Nothing herein shall be construed to prevent payment for the removal of shoals performed in accordance with the applicable provisions of paragraph "FINAL EXAMINATION AND ACCEPTANCE" and Section 01 30 00 "SHOALING".

3.6 ESTIMATED QUANTITIES

The total estimated quantity of material necessary to be removed within the specified limits as shown on the Contract Drawings, including allowable overdepth, areas outside the channel and turning basin limits as previously specified, and anticipated shoaling, is as follows:

ACCEPTANCE

SECTION

STATION TO

STATION

TO PROJECT

DEPTH

35' MLLW

ALLOWABLE

OVERDEPTH

TO 36' MLLW

TOTALS

AS-1 0+000 to 1+650

27,028 15,387 42,415

Section 35 20 23 Page 13

( ) ( )ACCEPTANCE

SECTION

STATION TO

STATION

TO PROJECT

DEPTH

38' MLLW

ALLOWABLE

OVERDEPTH

TO 39' MLLW

TOTALS

AS-2 1+650 to 3+600

114,665 42,304 156,969

AS-3 3+600 to 4+600

13,103 9,766 22,869

AS-4 4+600 to 6+236

6,328 6,015 12,343

SUBTOTAL AS-2,3 AND 4 134,096 58,085 192,181

SURVEY TOTALS 161,124 73,472 234,596

ESTIMATED SHOALING 164,160 31,528 195,688

TOTALS 325,284 105,000 430,284

TOTAL ESTIMATED BID QUANTITY 430,284

3.7 LIMIT OF DREDGING

3.7.1 General

The area to be dredged is within the limits indicated on the Contract Drawings and specified in paragraph "FINAL EXAMINATION AND ACCEPTANCE", as defined by dredging prism indicated in the Paragraphs entitled: "OVERDEPTH AND SIDE SLOPES" and "MEASUREMENT AND PAYMENT", of this section.

3.7.2 Quantity Acceptance

Complete all dredging requirements for each acceptance section prior to its acceptance by the Government. In any portion of an acceptance section, when the before dredging survey indicates dredging is required, remove material found to be remaining above the required depth by the after dredging survey, by dredging, unless such dredging is waived by the Contracting Officer. Dragging of a bar or other device will not be allowed. All material removed from within the dredging prism, whether accomplished by initial dredging or redredging, will be paid for at the contract unit price and as determined by the quantity calculation resulting from the difference between the before dredging survey and the final after dredging survey. In any portion of an acceptance section, when the after dredging survey indicates dredging is required that was not indicated by the before dredging survey, remove such material to the required depth, unless waived by the Contracting Officer. Such work will be paid for at the contract unit price and an additional quantity calculation will be made based on the after dredging survey, provided that the material is not determined by the Contracting Officer to be misplaced material.

Section 35 20 23 Page 14