W912BU-17-B-0007_Specs-AM0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

FLOOD CONTROL & COASTAL EMER (FCCE) REPAIR, GREAT EGG HARBOR INLET & PECK BEACH, OCEAN CITY, NJ

THIS AMENDMENT DOES NOT EXTEND THE BID OPENING DATE OF 15 AUGUST 2017 AT 3:00 P.M.

CONTINUED ON NEXT PAGE

USAED, PHILADELPHIA

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PA 19107-3390

USAED, PHILADELPHIA

ATTN: MICHAEL HUGHES

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PA 19107-3390

W912BU17B0007

07/24/2017

07/14/2017

This page was intentionally left blank for duplex printing.

Amendment No. 0001

IFB W912BU-17-B-0007

14. DESCRIPTION OF AMENDMENT (continued)

a. BIDDING SCHEDULE: Please delete the Bidding Schedule in its entirety, and substitute the revised Bidding Schedule, annotated Amendment No. 0001, attached hereto.

b. SECTION 00 70 00 – CONTRACT CLAUSES: Please delete page 00 70 00-29 in its entirety and substitute revised page 00 70 00-29, annotated Amendment No.

0001, attached hereto.

c. CONTRACT DRAWINGS: Please delete the following drawings in their entirety and substitute the revised drawings, of the same numbers, with the latest revision date of 19 July 2017, attached hereto:

C-103 C-301 C-104 C-302 C-105 C-303 C-106

d. Please indicate receipt of this amendment on Standard Form 1442 (SOLICITATION, OFFER, AND AWARD) as Amendment No. 0001. Failure to acknowledge all amendments may be cause for rejection of the bid.

Amendment No. 0001

IFB W912BU-17-B-0007

00 10 00-3

BIDDING SCHEDULE

(To be attached to SF 1442)

Item Estimated Unit Estimated No. Description Quantity Unit Price Amount

BASE BID

1. Mobilization and Demobilization 1 JOB LS $__________

2. MEC Modifications and Monitoring 1 JOB LS $__________

3. Beachfill 930,000 CY $________ $__________

TOTAL ESTIMATED BASE BID AMOUNT $_________________

OPTIONS

4. Option 1 - Beachfill 50,000 CY $________ $__________

5. Option 2 - Beachfill 150,000 CY $________ $__________

6. Option 3 - Beachfill 250,000 CY $________ $__________

7. Option 4 - Option Stockpile 5,000 CY $________ $__________

8. DELETED

TOTAL ESTIMATED BASE BID AND ALL OPTIONS AMOUNT $_________________

NOTES:

1. Bidders must bid on all items.

Amendment Number 0001 W912BU-17-B-0007 Section 00-70-00 29 of 155

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

"The Contractor shall be required to commence work under this contract within 10 calendar days after the date the Contractor receives the Notice To Proceed (NTP), and complete the entire Base Bid work within 120 calendar days after the date of receipt of NTP. The Options, if exercised, will provide the following additional calendar days to the period of performance of the Base Bid: Option 1 - 5 days; Option 2 - 10 days; Option 3 - 15 days; Option 4 - 0.

The Contracting Officer has the right to exercise any or all of the options within 14 calendar days after the approval by the Government of the Pre-Condition Surveys.

The time stated for completion shall include final cleanup of the premises."

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $4,700.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the

W912BU-17-B-0007 Section 00-70-00 30 of 155 delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

52.214-26 AUDIT AND RECORDS--SEALED BIDDING (OCT 2010)

(a) As used in this clause, records includes books, documents, accounting procedures and practices, and other data, regardless of type and regardless of whether such items are in written form, in the form of computer data, or in any other form.

(b) Certified cost or pricing data. If the Contractor has been required to submit certified cost or pricing data in connection with the pricing of any modification to this contract, the Contracting Officer, or an authorized representative of the Contracting Officer, in order to evaluate the accuracy, completeness, and currency of the certified cost or pricing data, shall have the right to examine and audit all of the Contractor's records, including computations and projections, related to--

(1) The proposal for the modification;

(2) The discussions conducted on the proposal(s), including those related to negotiating;

(3) Pricing of the modification; or

(4) Performance of the modification.

(c) Comptroller General. In the case of pricing any modification, the Comptroller General of the United States, or an authorized representative, shall have the same rights as specified in paragraph (b) of this clause and also the right to interview any current employee regarding such transactions.

(d) Availability. The Contractor shall make available at its office at all reasonable times the materials described in reproduction, until 3 years after final payment under this contract, or for any other period specified in Subpart 4.7 of the Federal Acquisition Regulation (FAR). FAR Subpart 4.7, Contractor Records Retention, in effect on the data of this contract, is incorporated by reference in its entirety and made a part of this contract.

(1) If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement.

(2) Records pertaining to appeals under the Disputes clause or to litigation or the settlement of claims arising under or relating to the performance of this contract shall be made available until disposition of such appeals, litigation, or claims.

(e) The Contractor shall insert a clause containing all the provisions of this clause, including this paragraph (e), in all subcontracts expected to exceed the threshold in FAR 15.403-4(a)(1) for submission of certified cost or pricing data.

52.214-27 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA -

MODIFICATIONS - SEALED BIDDING. (AUG 2011)

(a) This clause shall become operative only for any modification to this contract involving aggregate increases and/or decreases in costs, plus applicable profits, expected to exceed the threshold for the submission of certified cost or pricing data at FAR 15.403-4(a)(1), except that this clause does not apply to a modification if an exception