W912BU-15-B-0006-AM1.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

W912BU

Maintenance Dredging, New Jersey Intracoastal Waterway and Adjacent New Jersey Waterways

THIS AMENDMENT HEREBY EXTENDS THE BID OPENING DATE TO 7 JULY 2015 AT 11:00 A.M.

(Continued)

E5CTCSGF

US ARMY ENGINEER DISTRICT, PHILADELPHIA

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PENNSYLVANIA 19107-3390

US ARMY ENGINEER DISTRICT, PHILADELPHIA

POC: SANDI FLETCHER

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PENNSYLVANIA 19107-3390

W912BU-15-B-0006

06/16/2015

05/22/2015

This page was intentionally left blank for duplex printing.

Amendment No. 0001

IFB W912BU-15-B-0006

14. DESCRIPTION OF AMENDMENT (continued)

a. REQUESTS FOR INFORMATION (RFI) WITH RESPONSES: RFI’s with responses, annotated Amendment No. 0001, are attached to this amendment.

b. SECTION 00 73 00 SPECIAL CLAUSES: Please delete Section 00 73 00 in its entirety and substitute revised Section 00 73 00, annotated Amendment No. 0001, attached hereto.

c. SECTION 00 73 15 WAGE RATES: Please delete Section 00 73 15 in its entirety and substitute revised Section 00 73 15, annotated Amendment No. 0001, attached hereto.

d. TECHNICAL SPECIFICATIONS:

(1) Section 35 20 23 – DREDGING: Please delete pages 35 20 23-1 through 35 20 23-17 in their entirety and substitute revised pages 35 20 23-1 through 35 20 23-17, annotated Amendment No. 0001, attached hereto.

e. Please indicate receipt of this amendment on Standard Form 1442 (SOLICITATION, OFFER, AND AWARD) as Amendment No. 0001. Failure to acknowledge all amendments may be cause for rejection of the bid.

This page was intentionally left blank for duplex printing.

RFI #

Dwg Sheet/Spec Section Question Response

Bidding Schedule

Under the items that have a unit price of days, how many hours is considered a day?

Per Section 35 20 23, Paragraphs 3.5.4, 3.5.5, and 3.5.6, 8 hours is considered a work day.

Bidding Schedule

How can the contractor accurately price their mobilization and demobilization cost without knowing the exact location to the projects start and end points? Please give the contractor a place to mobilize into as well as the projects end location.

The starting and ending locations for dredging are yet to be determined. See Amendment 0001 for the starting location for disposal area work.

3 35 20 23

The contractor needs to be compensated for this time. I would recommend adding a bid item which would include stringing the pipeline ready for use as well as breaking it back down. The contractor will have cost in not only setting up their pipeline but also tearing it back down to move to another location. Please provide a bid item that will allow payment to the contractor for Onsite Job Setup and Teardown. This pay item would not qualify for the contractor’s original mobilization or demobilization, but would count for any subsequent dredging locations in-between. See Amendment 0001.

4 35 20 23

Most small business contractors do not have a tug in their fleet. A tug will normally be hired in order for them to light boat to the location where they will make up with our equipment and tow to the required destination depending on the distance. At that point the tug will begin their light boat back home.

This pay item causes several issues. The first issue being that we don’t know the exact locations of the required project areas; or how many times a towing company will be needed during the duration of the project. Secondly, the way the pay item is laid out, the contractor wouldn’t be allowed payment for the tow subs light boating.

Please find an expectable solution that is fair to both the Contractor and Owner. Bid as shown.

5 35 20 23

Instead of a drag line, would a long reach excavator or long reach marsh excavator be acceptable?

No. A long reach excavator or long reach marsh excavator will not be allowed. Bid as shown.

6 35 20 23

Each sluice weir is completely different depending on location, existing condition, accessibility, are walkways required and if so to what degree, materials being used, sizing, etc. It simply is not feasible to give a lump sum price per sluice weir by just going off a typical drawing. Please give the contractors the exact scope of work for the sluice weirs being replaced with plan drawings as well the locations the work is being performed.

Walkways shall be constructed to provide safe access to the sluice and timber flashboards. See Amendment 0001.

7 35 20 23

Being paid by the linear foot without details of where the coir logs are going and is difficult to price. Are the coir logs being placed on dry land? Are they being placed in the water and if so, to what depth? Please provide the Contractors with more details about the placement of the coir logs.

Coir logs will be placed where needed on marsh areas. Coir logs will not be placed in water. Bid as shown.

REQUESTS FOR INFORMATION with RESPONSES Solicitation No. W912BU-15-B-0006

8 35 20 23

To what degree does the owner foresee the work needing to be done on the Government-furnished disposal/placement areas?

The Contractor is payed by the rate as specified on the Bid Schedule. All of the disposal/placement areas are not known at this time and therefore work needed to be completed is also not known.

9 35 20 23

The contractor will need the location of these areas in order to examine them. Please provide a plan drawing depicting these locations.

All of the work areas are not known at this time. See Amendment 0001.

10 35 20 23 Would floating rubbers be acceptable for this application?

No, floating rubbers will not be acceptable. Bid as shown.

11 35 20 23

Will the contractor be required to work on Sunday at any point during the contract? If so, this needs to be addressed prior to bidding so the contractor can make the necessary adjustments for overtime and per diem.

No, the Contractor will not be required to work on Sundays.

12 35 20 23

Please provide the locations that the trestles will need to be used as well as the specifications which should include sizing, length, plan drawings, etc.

All disposal/placement areas are not known at this time. See Amendment 0001.

13 35 20 23

Can you please give us more information regarding the application for the brush cutter? Does this need to be a riding brush cutter? Does it need to be a weed eater type machine? What size are the fields that need to be cleared? Bid as shown.

14 35 20 23

Would it be possible to change this project from an hourly project to a per cubic yard project? No. Bid as shown.

15 35 20 23

Please send out plan drawings of the projected dredging areas for the Contractors review.

The projected dredging areas are not known at this time. Bid as shown.

16 35 20 23

How does the Contractor now what the sufficient shore crew will be without knowing the specifics of the site location? You are asking the Contractor to bid on items blindly without having any knowledge what so ever on the site of work. What you are asking here would be for the contractor to provide sufficient crew to assemble pipeline which would require workboats towing the pipeline to location, an excavator barge and land equipment to handle the pipeline, in hopes that the area is even accessible to the contractor in order to provide efficient work all while still maintaining a sufficient crew and equipment to continue dredging operations. See Amendment 0001.

17 35 20 23

Will the contractor have the required amount of pipeline at all times during ongoing dredging operations in order to also run shore pipe at a separate location? Yes.

SECTION 00 73 00

SPECIAL CLAUSES

INDEX

PARA TITLE

SC-1 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

SC-2 LIQUIDATED DAMAGES - CONSTRUCTION

SC-3 CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS

SC-4 PHYSICAL DATA

SC-5 LAYOUT OF WORK

SC-6 LIMITATION ON SUBCONTRACTING

SC-7 ENVIRONMENTAL LITIGATION

SC-8 SIGNAL LIGHTS

SC-9 INSPECTION

SC-10 ACCOMMODATIONS AND MEALS FOR GOVERNMENT INSPECTORS

SC-11 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

SC-12 PERFORMANCE EVALUATION OF CONTRACTOR

SC-13 INSURANCE REQUIREMENTS

Section 00 73 00 Page 1

SPECIAL CLAUSES

SC-1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

There will be 2 Notices to Proceed used for this contract.

The Contractor shall be required to (a) start work and start actual dredging with the 12"-14" dredge under this contract within 10 calendar days after the date of receipt by him of the 1st notice to proceed, which will be issued approximately 4 August 2015; (b) start actual dredging with the 10" dredge within 10 calendar days after the 2nd notice to proceed, which will be issued approximately 17 September 2015; (c) prosecute the said work diligently; and (d) complete all dredging work by 31 December 2015 and complete the entire work ready for use not later than 21 January 2016.

The time stated for completion shall include final cleanup of the premises.

(FAR 52.211-10)

SC-2 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

a. If the Contractor fails to complete the work within the time fixed for the contract, or any extensions thereof, the Contractor shall pay to the Government as liquidated damages the sum of $1450.00 for each day of delay.

b. If the Government terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned the Government in completing the work.

c. If the Government does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damages until the work is completed or accepted. (FAR 52.211-12)

SC-3 CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS (AUG 2000)

a. The Government will provide to the Contractor, without charge, one set of contract drawings (sketches) and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

b. The Contractor shall—

(1) Check all drawings (sketches) furnished immediately upon receipt;

(2) Compare all drawings (sketches) and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

c. In general--

(1) Large-scale drawings (sketches) shall govern small-scale drawings (sketches); and

Section 00 73 00 Page 2

(2) The Contractor shall follow figures marked on drawings (sketches) in preference to scale measurements.

d. Omissions from the drawings (sketches) or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings (sketches) and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

e. The work shall conform to the specifications and the contract drawings (sketches) identified in Section 00 73 30 WORK AREAS.(DFARS 252.236-7001)

SC-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor. (FAR 52.236-4)

a. The indications of physical conditions on the sketches and in the specifications are the result of site investigations by surveys.

b. Tide and Datum Data. Tidal and Datum information was derived from the 2001 epoch. Full tide range for a given area is approximately double the difference between Mean Lower Low Water (MLLW) and North American Datum of 1988 (NAVD88) as described below. All needed tide gauges must be approved by Survey POC. Coordination is required with USACE survey point of contact to establish or verify any system or gauge being used for tide measurements.

NJIWW

NORTH MARKER To SOUTH MARKER Delta from MLLW to NAVD88

MANASQUAN INLET SOUTHERN END OF

POINT PLEASANT

CANAL

2.42

2 47 0.24

47 51 0.32

51 54 0.4

54 68 0.56

68 74 0.77

74 78 0.94

78 101 1.08

101 109 1.19

Section 00 73 00 Page 3

NORTH MARKER To SOUTH MARKER Delta from MLLW to NAVD88

109 115 1.43

115 145 1.69

145 163 1.85

163 AB JUNCTION 2.0

AB JUNCTION 215 2.39

215 243 2.35

243 252 2.27

252 282 2.1

282 383 2.35

383 431 2.41

431 443 2.5

443 463 2.63

463 END (CSI) 2.73

c. Weather Conditions. The site of the work is sheltered from storms, except for open areas of the waterway adjacent to some of the inlets. It is believed that work can be performed during all seasons of the year except during winter months when ice conditions may interfere with dredging operations. Complete weather records and reports may be obtained from the local U.S. Weather Bureau Office nearest to the work site. The Contractor shall satisfy himself as to the hazards likely to arise from weather conditions during the dredging period.

d. Channel Traffic. Traffic in the work area consists of commercial and sport fishing vessels and pleasure craft. This traffic may interfere with dredging operations.

e. Obstruction of Channel. The Government will not undertake to keep the channel free from vessels or other obstructions, except to the extent of such regulations if any, as may be prescribed by the Secretary of the Army, in accordance with the provisions of Section 7 of the River and Harbor Act approved 8 August 1917. The Contractor will be required to conduct the work in such manner as to obstruct navigation as little as possible, and in case the Contractor's plant so obstructs the channel as to make difficult or endanger the passage of vessels, said plant shall be promptly moved on the approach of any vessel to such an extent as may be necessary to afford a practicable passage. The Contractor shall request the U.S. Coast Guard to issue a Notice to Mariners for each work assignment advising navigation interests that the Contractor's dredging plant will be operating in the Harbor. The Contractor shall submit each such request to the U.S. Coast

Section 00 73 00 Page 4

Guard, MSO/Group Philadelphia, 1 Washington Avenue, Philadelphia, PA 19147-4395. The Contractor shall furnish a copy of each request to the Contracting Officer not less than five days prior to the start of dredging.

Each request shall contain the approximate time required for completion of dredging. Upon completion of dredging, the Contractor shall promptly remove his plant, including ranges, buoys, piles and other marks placed by him under the contract in navigable waters and on shore.

f. Navigation Aids. The Contractor shall not relocate or move any aids to navigation that have been established by the U.S. Coast Guard. If it becomes necessary to have any aid to navigation moved in order to complete dredging operations under this contract, the Contractor shall notify the U.S. Coast Guard at least 21 working days (Sundays and holidays excluded) prior to the desired date for movement of the aid. All requests shall be made in writing to: Commander (OAN), Fifth Coast Guard District, 431 Crawford Street, Portsmouth, VA 23704. A copy of each request shall be furnished to the Contracting Officer.

g. Location. The work assignments issued as part of this contract will be for dredging at various locations along the New Jersey Intracoastal Waterway and additional waterways connecting to deep waters adjacent to the New Jersey Intracoastal Waterway, as shown on the sketch included in Section 00 73 30 of this specification.

h. Bridge and Utility Crossings:

(1) Bridges: The following bridges cross the New Jersey Intracoastal Waterway between Manasquan, New Jersey and the Delaware Bay. The location, type, horizontal clearance, and vertical clearance in feet above mean high water for each bridge are as follows:

NEW JERSEY INTRACOASTAL WATERWAY BRIDGES

Clearance Statute Miles from Location Type Hor. Vert. Manasquan Inlet

Brielle - Pt. Pleasant (RR) Bascule 48 3 0.9 Brielle - Pt. Pleasant (Hwy) Bascule 90 30 1.1 Bay Head - Manasquan Canal:

West Pt. Pleasant (Hwy) Bascule 47 10 3.0 West Pt. Pleasant (Hwy) Vertical Lift 80 30 4.0 Barnegat Bay:

Mantoloking (Hwy) Bascule 51 14 6.3 Island Heights (Hwy) Bascule 80 30 14.1 Route 37 (Hwy) Fixed 80 60 14.1 Manahawkin Bay:

Route 72(Hwy) Fixed 100 60 37.4 Beach Thorofare:

Atlantic City (Hwy) Bascule 60 20 67.2 Atlantic City (RR) Swing 50 5 68.9 Atlantic City (Hwy) Fixed 80 35 69.0 Inside Thorofare:

Atlantic City (Hwy) Bascule 50 10 70.0 Ventnor City (Hwy) Bascule 50 9 71.2 Beach Thorofare:

Section 00 73 00 Page 5

Margate City (Hwy) Bascule 60 14 74.0 Broad Thorofare:

Somer Point (Hwy) Bascule 49 9 77.8

Beach Thorofare:

Ocean City (Hwy) Bascule 70 14 80.4 Crook Horn Thorofare:

Ocean City - 34th St. (Hwy) Fixed 80 35 84.3 Ocean City (RR) Swing 59 2 86.6 Ludlam Thorofare:

Sea Isle City (Hwy) Fixed 80 35 93.4 Ingram Thorofare:

Avalon (Hwy) Fixed 80 35 98.2 Great Channel:

Stone Harbor (Hwy) Bascule 50 11 102.0 Grassy Sound Channel:

North Wildwood (Hwy) Bascule 25 8 105.2 Wildwood (RR) Bascule 50 6 107.5 Wildwood (Hwy) Bascule 57 25 108.9 Middle Thorofare:

Wildwood Crest (Hwy) Bascule 50 23 112.2 Cape May Canal:

Cape May - U.S. Rt. 9 (Hwy) Fixed 80 55 114.3 Cape May (RR) Swing 50 4 115.1 Seashore Rd. (Hwy) Fixed 80 55 115.5

Effective on August 30, 2001, the Coast Guard is changing regulations governing the operation of the Cape May Canal Railroad Bridge at the New Jersey Intracoastal Waterway, mile 115.1, across Cape May Canal, in Cape May, New Jersey. The regulation maintains the bridge in the open position, except that it would close for the crossing of trains and the maintenance of the bridge. This change will provide for the reasonable needs of navigation.

(2) Utility Crossings. The following pipelines, telephone and power lines cross the New Jersey Intracoastal Waterway between Manasquan, New Jersey, and Delaware Bay. The location and type are as follows:

NEW JERSEY INTRACOASTAL WATERWAY UTILITY CROSSINGS

Statute Miles from Manasquan Inlet Location Description

2.0 Manasquan Inlet, Manasquan, NJ Submarine Cable

(U.S. Coast Guard)

2.0 Easterly side of New York Long Submarine Cable

Branch Railroad drawbridge between (U.S. Coast Guard) Brielle and Pt. Pleasant, NJ

2.0 Easterly side of New York Long Submarine Cable

Branch Railroad drawbridge between (Western Cable) Brielle and Pt. Pleasant, NJ

2.0 Easterly side of New York Long Submarine Cable

Branch Railroad drawbridge between (NY & LBRR Co.)

Brielle and Pt. Pleasant, NJ

Section 00 73 00 Page 6

2.0 Westerly side of New York Long Four Submarine

Branch Railroad drawbridge between Cables Brielle and Pt. Pleasant, NJ (NY & LBRR Co.)

2.0 Westerly side of New York Long Two Submarine

Branch Railroad drawbridge between Cables Brielle and Pt. Pleasant, NJ (NJ Bell Tel. Co.)

2.0 Easterly side of State Highway Three Submarine

drawbridge along Route 35, between Cables Brielle, Monmouth Co. and Pt. (NJ Bell Tel. Co.)

Pleasant Beach, Ocean Co., NJ

2.0 Easterly side of State Highway Submarine Cables

drawbridge along Route 35, between (NJ Highway Dept.)

Brielle, Monmouth Co. and Pt.

Pleasant Beach, Ocean Co., NJ

2.0 Easterly side of State Highway Submarine

drawbridge along Route 35, between (NJ Natural Brielle, Monmouth Co. and Pt. Gas Co.)

Pleasant Beach, Ocean Co., NJ

2.1 Westerly side of State Highway Aerial Power Wires

drawbridge along Route 35, between (Jersey Central Brielle, Monmouth Co. and Pt. Power & Light Co.)

Pleasant Beach, Ocean Co., NJ

2.2 Westerly side of State Highway Two Submarine

drawbridge along Route 35, between Gas Pipelines Brielle, Monmouth Co. and Pt. (NJ Natural Pleasant Beach, Ocean Co., NJ Gas Co.)

2.8 North side of Pine Bluff Ave. Two Submarine

(Pt. Pleasant Canal) Cables (NJ Bell Tel. Co.)

2.8 North side of Pine Bluff Ave. 18-inch

(Pt. Pleasant Canal) Pipe Outfall (Ocean County)

2.8 South side of Pine Bluff Ave. Submarine

(Pt. Pleasant Canal) Force Main, (Pt. Pleasant Hospital)

2.8 Front Street (Pt. Pleasant Canal) Submarine Water

Main (Borough of Pt. Pleasant)

3.0 North side of N.J. Route 88 Submarine Cables

(Pt. Pleasant Canal) (NJ Bell Tel. Co.)

3.0 North side of Route 88 Aerial Cable

(Pt. Pleasant Canal) (Crosswicks Industries)

3.0 South side of Route 88 Bridge Aerial Wires

(Pt. Pleasant Canal) (Jersey Central

Section 00 73 00 Page 7

Power & Light Co.)

3.0 South side of Route 88 Bridge Bridge Oper.

(Pt. Pleasant Canal) Cables (NJ State Highway Dept.)

3.0 Burnt Tavern Road 12-inch Water Main

(Pt. Pleasant Canal) (Boro of Pt.

Pleasant) and 6-inch Gas Main (NJ Natural Gas Co.)

3.1 Pt. Pleasant Canal Bridge St. Bridge 8 Submarine Sewer

in the Borough of Pt. Pleasant, the Pipelines Ocean Borough of Bay Head, Brick Two.,and Crossings, Outfall Borough of Mantoloking, NJ Pipeline, and the 2 Temporary Piers (Ocean Co. Sewer Authority)

4.0 South side of Lovelandtown Bridge Submarine Cables

(Bridge Ave. Pt. Pleasant Canal) (NJ Bell Telephone Co.)

4.2 Rue Mirador Submarine Cables

(Pt. Pleasant Canal) (NJ Bell Telephone Co.)

4.3 775 Feet southerly of Marine Submarine Water Farkway, Pt. Pleasant, NJ Main (Boro of (Pt. Pleasant Canal) Pt. Pleasant)

6.3 Southerly side of County highway Submarine

bridge along Route 528, Mantoloking, Telephone Cable NJ (NJ Bell Telephone Co.)

6.3 Southerly side of County highway Submarine Water

bridge along Route 528, Mantoloking, Main (Ocean Co.

NJ Board of Chosen Freeholders)

6.3 Northerly side of County highway Submarine Power

bridge along Route 528, Mantoloking, Cable (Ocean Co.

NJ Board of Chosen Freeholders)

6.3 Northerly side of County highway Submarine Gas Main

bridge along Route 528, Mantoloking, (NJ Natural Gas NJ Co.)

12.8 Between Bay Ave. on the westerly Submarine

side of the Bay and 2nd Ave., Ortley Pipeline (Toms Beach, Dover Township, Ocean Co., NJ River Chemical Corp.)

13.5 Between Beachview Dr. on the westerly Submarine

side of the Bay and 8th Ave., Ortley Pipeline (Dover Beach, Dover Township, Ocean Co., NJ Sewage Authority)

Section 00 73 00 Page 8

14.0 Approx. 150 feet northerly from the Lay a submarine

Centerline of the fixed bridge along Cable (Jersey NJ Route 37, Ocean Co., NJ Central P&L Co.)

14.3 Southerly side of highway bridge Submarine

along Rt 37, Island Heights, NJ Telephone Cable (NJ Bell Tel Co.)

16.8 Approximately 2 miles southerly of Two Submarine

highway bridge along Rt 37, Island Power Cables Heights, NJ (Jersey Central P&L Co.)

34.0 Between Bergen Avenue, Harvey Cedars3 Submarine Cables

and a point opposite in Stafford (American Township, Ocean Co., NJ Telephone & Telegraph)

36.5 Between Main Point Meadows, Submarine Power

Stafford Township, and 2nd St. Cable (A.C. Elec.

Surf City, NJ Co.)

37.4 Northerly side of State highway Submarine Gas Main

bridge along Rt 72, Ship Bottom, NJ (NJ Natural Gas Co.)

37.4 Northerly side of State highway Submarine Power

bridge along Rt 72, Ship Bottom, NJ Cable (A.C. Elec.

Co.)

37.4 Northerly side of State highway Submarine Cable

bridge along Rt 72, Ship Bottom, NJ (NJ Bell Tele.

Co.)

42.4 Between West Creek Landing Rd., Submarine Power

Eagleswood Township and South Cable (A.C.

Caroline Ave., Beach Haven, Long Elec. Co.)

Beach Township, Ocean Co. NJ

44.8 Between Taylor Ave. Beach Haven and Submarine Cables

a point opposite in Little Egg (Amer. Telephone Harbor Township, Ocean Co. NJ and Telegraph Co.)

46.1 Between Leeward Ave. Beach Haven and Submarine Cables

a point just south of Thompson (Amer. Telephone Creek, Little Egg Harbor Township, and Telegraph Co.)

Ocean Co., NJ

46.1 Between Long Beach and Foxoboro Submarine Cables

Point and Big and Little Sheeps- (U.S. Coast Guard) Head Creeks

49.3 Between Long Beach and Foxoboro Submarine Cables

Point and Big and Little Sheeps- (U.S. Coast Guard) Head Creeks

49.3 Between Long Beach and south bank of Submarine tower

Big Sheepshead Creek, Ocean Co., NJ Cable (A.O. Elec

Section 00 73 00 Page 9

Co.)

52.5 Between Little Egg Harbor Coast Submarine Cables

Guard Station and Island Beach, (U.S. Coast Guard) Atlantic County, NJ

67.2 Northeasterly side of State highway Submarine Cable

bridge along Rt 30, Absecon Blvd., (A.C. Elec Co.)

Atlantic City, NJ

67.2 Northeasterly side of State highway Submarine pipeline

bridge along Rt 30, Absecon Blvd., (Sun Oil Co.)

Atlantic City, NJ

67.2 Southerly side of State highway Submarine Bridge

bridge along Rt 30, Absecon Blvd., Operating Cables, Atlantic City, NJ (NJ State Hwy, Dept.)

67.2 Southerly side of State highway 2-inch Submarine

bridge along Rt 30, Absecon Blvd., Water Main (Brown Atlantic City, NJ Const. Co.)

67.2 Southwesterly side of State highway 8-inch Submarine

bridge along Rt 30, Absecon Blvd., Gas Pipeline (So.

Atlantic City, NJ Jersey Gas Co.)

67.2 Southwesterly side of State highway Submarine Cable

bridge along Rt 30, Absecon Blvd., (NJ Bell Telephone Atlantic City, NJ Co.)

68.4 Approx. at end of Kuehnle Ave. 2 Submarine Cables

(Venice Lagoon) Atlantic City, NJ (U.S. Coast Guard)

68.6 End of Ontario Ave., Submarine Cable

Atlantic City, NJ

68.6 End of Ontario Ave., 4 Submarine

Atlantic City, NJ Plastic Pipes (A.C. Elec. Co.)

68.8 Southerly side of Ontario Ave., Aerial Wires (A.C.

Atlantic City, NJ Electric Co.)

68.9 Approx. 430 feet northerly of the Submarine Cable

Pennsylvania-Reading Seashore Lines (A.C. Elec. Co.)

RR Bridge, Atlantic City, NJ

68.9 Northerly side of the Pennsylvania- 2 Submarine Cables

Reading Seashore Lines RR Bridge, (A.C. Elec. Co.)

Atlantic City, NJ

68.9 Northerly side of the Pennsylvania- 3 Submarine Cables

Reading Seashore Lines RR Bridge, (A.C. Elec. Co.)

Atlantic City, NJ

68.9 Northerly side of the Pennsylvania- Submarine Cable

Reading Seashore Lines RR Bridge, (PA-Reading Atlantic City, NJ Seashore Lines)

Section 00 73 00 Page 10

68.9 Northerly side of the Pennsylvania- Submarine 2-inch

Reading Seashore Lines RR Bridge, Airline Atlantic City, NJ (PA-Reading Seashore Lines)

68.9 Northerly side of the Pennsylvania- Submarine Cable

Reading Seashore Lines RR Bridge, (Atlantic City RR Atlantic City, NJ Co.)

68.9 Northerly side of the Pennsylvania- 48-inch Submarine

Reading Seashore Lines RR Bridge, Water Main Atlantic City, NJ (A.C. City Water Dept.)

68.9 Southerly side of the Pennsylvania- 4 Submarine Cables

Reading Seashore Lines RR Bridge, (Atlantic City Atlantic City, NJ Transportation Co.)

68.9 Southerly side of the Pennsylvania- Submarine Cable

Reading Seashore Lines RR Bridge, (PA-Reading Atlantic City, NJ Seashore Lines)

69.9 Approx. 300 feet northerly of the 2 Submarine Cables

State highway bridge along Albany (A.C. Elec. Co.)

Ave., Atlantic City, NJ

70.0 Approx. 150 feet northerly of the 12-inch Submarine

State highway bridge along Albany Gas Pipeline (So.

Ave., Atlantic City, NJ Jersey Gas Co.)

70.0 Approx. 150 feet northerly of the Submarine Cables

State highway bridge along Albany (NJ Bell Telephone Ave., Atlantic City, NJ Co.)

70.0 Northerly side of the State highway Two 12-inch Gas

bridge along Albany Ave., Atlantic Pipelines (A.C.

City, NJ Gas Co.)

70.0 Northerly side of the State highway Two 36-inch

bridge along Albany Ave., Atlantic Submarine Water City, NJ Mains (A.C.

Water Dept.)

70.0 Southerly side of the State highway Submarine Cable

bridge along Albany Ave., Atlantic (A.C. Elec. Co.)

City, NJ

70.1 Annapolis Ave., Atlantic City, NJ 12-inch Water Main

(A.C. Water Dept.)

70.2 Richmond Ave., Atlantic City, NJ Submarine Cable

(A.C. Elec Co.)

70.2 Richmond Ave., Atlantic City, NJ 12-inch Submarine

Force Main (A.C.

Sewerage Co.)

Section 00 73 00 Page 11

70.2 Richmond Ave., Atlantic City, NJ Submarine Cable

(Atlantic Coast TV Cable Co.)

70.3 Inside Thorofare near Richmond Ave.,48-inch Force Main

Atlantic City, NJ (Atlantic County Sewerage Auth.)

70.7 Baton Rouge Ave., Ventnor, NJ Submarine Cables

(A.C. Elec. Co.)

71.0 Suffolk Place, Ventnor, NJ 14-inch Submarine

Water Main (City of Ventnor)

71.2 Dudley Ave., Ventnor, NJ Submarine Cable

(A.C. Elec. Co.)

71.2 Southerly side of Dorset Ave., Submarine Cable

Ventnor, NJ (City of Ventnor)

71.2 Southerly side of Dorset Ave., Submarine Cables

Ventnor, NJ (NJ Bell Tele.

Co.)

71.4 Dudley Avenue Submarine Cable

Ventnor, NJ (A.C. Elec. Co.)

71.5 Wellington Avenue Submarine Cable

Ventnor, NJ (A.C. Elec. Co.)

71.56 Between Wellington & Harvard Ave. Submarine Cable

Ventnor, NJ (A.C. Elec. Co.)

71.6 Harvard Ave., Ventnor 8-inch Submarine

Water Main (City of Ventnor)

71.6 Harvard Ave., Ventnor Submarine Cable

(So. Jersey TV Cable Co.)

71.7 Diagonally across from Fulton & Submarine Cables

Canal to Fulton & Harvard in (A.C. Elec. Co.)

Ventnor, NJ

71.9 Fulton Avenue, Ventnor, NJ Submarine Cables

(A.C. Elec. Co.)

71.9 Fulton Avenue, Ventnor, NJ 6-inch Submarine

Gas Pipeline (So.

Jersey Gas Co.)

72.0 Wellington Ave., Ventnor, NJ Submarine Cables

(U.S. Coast Guard)

72.0 Wellington Ave., Ventnor, NJ Submarine Cables

(A.C. Elec. Co.)

Section 00 73 00 Page 12

72.4 Melbourne Ave., Ventnor, NJ Submarine Cables

(NJ Bell Tel Co.)

72.5 West Canal, near Melbourne Ave., 30-inch Force Main

Ventnor, NJ (Atlantic County Sewer Authority)

72.8 Baltimore Ave., Ventnor, NJ Submarine Cables

(A.C. Elec. Co.)

73.0 Swarthmore & Washington Ave., Submarine

Ventnor, NJ Discharge Pipeline (City of Ventnor)

77.8 Northerly side of drawbridge along Submarine Cables

Somers Point - Longport Blvd., Ocean(NJ Bell Tel. Co.)

City, NJ

77.8 Southerly side of drawbridge along Submarine Cables

Somers Point - Longport Blvd., Ocean (A.C. Elec. Co.)) City, NJ

80.3 400 feet westerly of highway Submarine Cable drawbridge at State Rt. 52, Ocean (NJ Bell Tel. Co.)

City, NJ

80.4 Alongside of the highway drawbridge Submarine Cables

at State Rt. 52, Ocean City, NJ (A.C. Elec. Co.)

80.4 Westerly side of the highway Submarine Cable

drawbridge at State Rt. 52, Ocean (NJ Bell Tel. Co.)

City, NJ

80.9 Approx. 2300 feet southerly of Submarine Cable

highway drawbridge Rt. 52, Ocean (A.C. Elec. Co.)

City between Beesley Point and 13th St., Ocean City, NJ

82.0 Between Shooting Island and Submarine Cables

Tennessee Ave., Ocean City, NJ (A.C. Elec. Co.)

84.3 Northerly side of the Co. highway Submarine Cables

bridge along 34th St. Ocean City, NJ (NJ Bell Tel Co.)

84.3 Southerly side of the Co. highway Submarine Cables

bridge along 34th St. Ocean City, NJ (NJ Bell Tel Co.)

84.3 Southerly side of the Co. highway Aerial Wires

bridge along 34th St. Ocean City, NJ (A.G. Elec. Co.)

86.6 Northerly side of PA-Reading Seashore Submarine Cables

Lines RR Bridge, Ocean City, NJ

93.4 Sea Isle City Blvd. Between Dennis Submarine Cable

Township & Sea Isle City, NJ (NJ Bell Tel. Co.)

93.45 Along the southerly side of Sea Isle Submarine Cable

Blvd. (41st St.), Sea Isle City, NJ (NJ Bell Tel. Co.)

Section 00 73 00 Page 13

93.5 Southerly side of 41st St., Sea Isle Submarine Cable

City, NJ (A.C. Elec. Co.)

93.6 Northerly side of 44st St., Sea IsleSubmarine Pipeline

City, NJ (Sun Oil Co.)

93.6 Northerly side of 44st St., Sea Isle Aerial Wires

City, NJ (A.C. Elec. Co.)

93.6 At 44th St., Sea Isle City, NJ 8-inch Submarine

Gas Pipeline (NJ Natural Gas Co.)

93.6 Southerly side of 44th St., Sea Isle Submarine Cables

City, NJ (NJ Bell Tel. Co.)

93.7 Approx. 200 feet southerly from 44th Submarine Cables

Street, Sea Isle City, NJ (A.C. Elec. Co.)

97.8 Northerly side of the former Co. Submarine Cable

highway drawbridge at Avalon, NJ (Garden State TV Co.)

97.8 Northerly side of the former Co. Submarine Cables

highway drawbridge at Avalon, NJ (NJ Bell Tel. Co.)

97.8 At the former Co. highway drawbridge Submarine Cable

Avalon, NJ (Co. of Cape May)

98.2 Northerly side of County highway Submarine Cable

fixed bridge at Avalon, NJ (A.C. Elec. Co.)

102.0 Northerly side of Co. highway Submarine Cables

drawbridge at Stone Harbor, NJ (A.C. Elec. Co.)

102.0 Northerly side of Co. highway 8-inch Submarine

drawbridge at Stone Harbor, NJ Gas Pipe (NJ Natural Gas Co.)

102.0 Northerly side of Co. highway Submarine Cable

drawbridge at Stone Harbor, NJ (Garden State TV Co.)

102.0 At Co. highway drawbridge, Stone Submarine Cable

Harbor, NJ (Co. of Cape May)

102.0 Southerly side of Co. highway Submarine Cable

drawbridge at Stone Harbor, NJ (NJ Bell Tel. Co.)

105.2 Northerly side of Co. highway Submarine Cable

drawbridge at North Wildwood, NJ (A.C. Elec. Co.)

105.2 At Co. highway drawbridge, North Submarine Cable

Wildwood, NJ (Co. of Cape May)

105.2 Southerly side of Co. highway 6-inch Submarine

drawbridge at North Wildwood, NJ Gas Pipeline (NJ Natural Gas Co.)

Section 00 73 00 Page 14

105.2 Southerly side of Co. highway Submarine Cables

drawbridge at North Wildwood, NJ (NJ Bell Tel. Co.)

108.9 Approx. 100 feet southerly of State Submarine Cables

highway bridge along Rt. 47, (NJ Bell Tel. Co.)

Wildwood, NJ

108.9 Approx. 100 feet southerly of State Submarine Cable

highway bridge along Rt. 47, (So. Jersey TV) Wildwood, NJ Cable Co.)

108.9 On the westerly side of the PA- 3 Submarine Cables

Reading Seashore Line RR Bridge, (A.C. Elec. Co.)

Middle Twp., Cape May County, NJ

108.9 Approx. 475 feet northerly of the Submarine Water

drawbridge along NJ Rt. 47, between Main (City of Wildwood, NJ and Middle Twp., Wildwood) Cape May Co., NJ (Grassy Sound)

109.0 Approx. 200 feet southerly of State 16-inch Water Main

highway bridge along Rt. 47, (City of Wildwood) Wildwood, NJ

109.0 Approx. 300 feet southerly of State 24-inch Water Main

highway bridge along Rt. 47, (City of Wildwood) Wildwood, NJ

109.0 Approx. 380 feet southerly of State 20-inch Water Main

highway bridge along Rt. 47, (City of Wildwood) Wildwood, NJ

112.2 Northerly side of County highway Submarine Cable

bridge along Rt. 585, Wildwood (NJ Bell Tel. Co.)

Crest, NJ

112.2 At Co. highway bridge along Rt. 585, Submarine Cable

Wildwood Crest, NJ (Cape May Co.

Bridge Commission)

112.2 Southerly side of County highway 14-inch Sewage

bridge along Rt. 585, Wildwood Pipeline (Twp. of Crest, NJ Lower Municipal Utils. Authority)

114.3 Easterly side of State highway bridge Submarine Cables

along U.S. Rt. 9, Cape May Canal (NJ Bell Tel. Co.)

114.3 Approx. 200 feet westerly of State Aerial Power Wires

highway bridge along U.S. Rt. 9, (A.C. Elec. Co.)

Cape May Canal

114.3 Approx. 275 feet westerly of State 2 Submarine Cables

highway bridge along U.S. Rt. 9, (NJ Bell Tel. Co.)

Cape May Canal

114.3 At the site of the former drawbridge 2 Submarine Power

along U.S. Rt. 9, Cape May Canal Cables (NJ State Highway Dept.)

Section 00 73 00 Page 15

114.3 At the site of the former drawbridge 6-inch Submarine

along U.S. Rt. 9, Cape May Canal Gas Pipeline (NJ Natural Gas Co.)

115.1 Easterly side of PA-Reading SeashoreAerial Power Wires

Lines drawbridge, Cape May Canal (A.G. Elec. Co.)

115.1 At the PA-Reading Seashore Lines 2 Bridge Operating

drawbridge, Cape May Canal Cables (PA-Reading Seashore Lines)

115.1 Westerly side of PA-Reading Seashore Aerial PowerWires

Lines drawbridge, Cape May Canal (A.G. Elec. Co.)

115.1 Approx. 150 feet westerly of 12-inch Water Main

PA-Reading Seashore Lines (Twp. of Lower drawbridge, Cape May Canal Municipal Utils.

Authority)

115.5 Easterly side of highway drawbridge 2 Submarine Cables

at Seashore Rd., Cape May Canal (NJ Bell Tel. Co.)

115.5 At the highway drawbridge at Bridge Operating

Seashore Road, Cape May Canal Cable (NJ State Highway Dept.)

115.5 Westerly side of highway drawbridge 6-inch Submarine

at Seashore Rd., Cape May Canal Gas Pipeline (NJ Natural Gas Co.)

115.5 Approx. 120 feet westerly of highway Aerial Wires

drawbridge at Seashore Rd., Cape May(S. Jersey TV Co.)

Canal

115.5 Approx. 450 feet westerly of highway 8-inch Water Main

drawbridge at Seashore Rd., Cape May (Twp. of Lower Canal Municipal Utils.

Authority)

115.5 On the westerly side of Bayshore Rd., Submarine Cable

Lower Twp, Cape May Co., NJ (NJ Bell Tel. Co.)

115.5 On the westerly side of the fixed Submarine Cable

bridge along Seashore Rd., Lower (NJ Bell Tel. Co.)

Twp., Cape May Co., NJ

116.4 Easterly side of Bayshore Rd., Cape Submarine Cable

May Canal (NJ Bell Tel. Co.)

117.6 Approx. 2,000 feet easterly from the Submarine Cable

Delaware Bay entrance to Cape May (U.S. Coast Guard) Canal

The Contractor shall take all necessary precautions to prevent damage to these utilities. The Contractor shall cause timely notice of the dredging to be given to the owners and, when in the opinion of the Contractor such action is necessary, he shall request that the Government require said owner or owners to mark the pipelines or move the cables so as to avoid

Section 00 73 00 Page 16 interference with the dredging operations. Any request made by the Contractor shall be within 30 days following his receipt of the Notice to Proceed.

Disclaimer: The above information may not be complete and it is the Contractor's responsibility to investigate all crossings.

i. Laying of Submerged Pipelines and Obstruction of Channel. Should it become necessary in the performance of this contract to use a submerged pipeline, the Contractor shall notify the Contracting Officer in advance of the schedule for placement of the pipeline. If the submerged line is to be placed across a navigable channel, the Contractor shall submit a request for approval at least 21 working days (Sundays and holidays excluded) prior to the desired closure date, to the U.S. Coast Guard, MSO/Group Philadelphia, 1 Washington Avenue, Philadelphia, PA 19147-4395. A copy of each request shall be furnished to the Contracting Officer. This request shall contain the following information:

(1) Location (Channel Centerline Stationing) and depth (over the top of the pipeline) at which the submerged line will be placed;

(2) The desired length of time the channel is to be closed;

(3) The date and hour placement or removal will commence;

(4) The date and hour of anticipated completion; and

(5) The name and telephone number of the person to be contacted for information and response to any emergency condition.

The Coast Guard has indicated that the requirements of navigation may make it necessary to establish times other then those requested. IT SHALL BE THE

CONTRACTOR'S RESPONSIBILITY TO COORDINATE HIS PLANS WITH THE COAST GUARD

SUFFICIENTLY IN ADVANCE OF THE PLANNED CLOSING TO PREVENT DELAY TO THE

DREDGING OPERATIONS AND COMPLY WITH THE COAST GUARD REQUIREMENTS.

j. Bridge to Bridge Radio Telephone Equipment. In order that radio telephone communication may be made with passing vessels, all dredges engaged in work under the contract shall be equipped with and operate bridge-to-bridge radio telephone equipment. The radio telephone equipment shall operate on VHF Channel 13 (156.65 MHz) with low power output having a communication range of approximately ten miles. The frequency has been approved by the Federal Communication Commission.

k. The most recent dredging of NJIWW, Wills Hole Thorofare, Toms River and adjacent New Jersey Waterways was completed under Contract W912BU-13-C-0011 by Barnegat Bay Dredging Company during calendar years 2013-2015.

l. Disposal Areas: Government-furnished disposal areas will be available under this contract. Their locations will be along the New Jersey Intracoastal Waterway and Cape May Canal. The Government-furnished Cape May Canal Confined Disposal Facility will be used for placement of material dredged from the adjacent Cape May Lewes ferry channel portion of the New Jersey Intracoastal Waterway. Additional placement areas along the New Jersey Intracoastal Waterway will be provided by the Government as dredging assignments are given and may include marsh restoration to the west of Avalon, NJ and in the vicinity of Mordecai Island, NJ.

m. A Water Quality Certificate from the State of New Jersey

Section 00 73 00 Page 17 for the New Jersey Intracoastal Waterway portion of this work is on file in the Office of the Chief, Operations Division,Philadelphia District.

n. Magnitude of the Contract Work. The estimated value of the contract is between $1,000,000 and $5,000,000.

SC-5 LAYOUT OF WORK (DEC 1996)

The Contractor shall lay out its work from Government-provided channel coordinates, furnished as part of each work assignment. The Contractor shall furnish, at its own expense, such stakes, templates, platforms, equipment, range markers and labor as may be required in laying out any part of the work, from the channel coordinates furnished by the Government.

The Contractor shall be responsible for executing the work to such lines and grades. The Contractor must have real time differential GPS positioning in accordance with the Corps survey manual, class 1 survey requirements for dredge positioning. The Contractor shall provide real time positioning on a computer screen during dredging, and have the capability of playback in 15 minute intervals. The position must be recorded on disk every 15 minutes and submitted to the Contracting Officer on a daily basis. This requirement can be achieved with daily reports from an Automatic Identification System (AIS). Reports need to include at a minimum, time, date, latitude, and longitude.(CENAP)

SC-6 LIMITATIONS ON SUBCONTRACTING (NOV 2011)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside or reserved for small business concerns or 8(a) concerns;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) concerns; and

(3) Orders set aside for small business or 8(a) concerns under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).

(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for --

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

Section 00 73 00 Page 18

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees. (FAR 52.219-14)

SC-7 ENVIRONMENTAL LITIGATION (1974 NOV OCE)

a. If the performance of all or any part of the work is suspended, delayed, or interrupted due to an order of a court of competent jurisdiction as a result of environmental litigation, as defined below, the Contracting Officer, at the request of the Contractor, shall determine whether the order is due in any part to the acts or omissions of the Contractor or a Subcontractor at any tier not required by the terms of the contract. If it is determined that the order is not due in any part to acts or omissions of the Contractor or a Subcontractor at any tier other than as required by the terms of this contract, such suspension, delay, or interruption shall be considered as if ordered by the Contracting Officer in the administration of this contract under the terms of the SUSPENSION OF WORK clause of this contract. The period of such suspension, delay, or interruption shall be considered unreasonable, and an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) as provided in that clause, subject to all the provisions thereof.

b. The term "environmental litigation", as used herein, means a lawsuit alleging that the work will have an adverse effect on the environment or that the Government has not duly considered, either substantively or procedurally, the effect of the work on the environment. (CENAP)

SC-8 SIGNAL LIGHTS

The Contractor shall display signal lights and conduct his operations in accordance with the General Regulations of the Coast Guard governing lights and day signals to be displayed by towing vessels with tows on which no signals can be displayed, vessels working on wrecks, dredges, and vessels engaged in laying cables or pipe or in submarine or bank protection operations, lights to be displayed on dredge pipe lines, and day signals to be displayed by vessels of more than 65 feet in length moored or anchored in a fairway or channel, and the passing by other vessels of floating plant working navigable channels, as approved by the Commandant, U.S. Coast Guard with respect to vessels in inland waters (33 CFR 88), as applicable. (CENAP)

SC-9 INSPECTION (DEC 1996)

The presence of the inspector shall not relieve the Contractor of responsibility for the proper execution of the work in accordance with the specifications. The Contractor will be required:

a. To furnish, on the request of the Contracting Officer or any inspector, the use of such boats, boatmen, laborers, a part of the ordinary and usual equipment and crew of the dredging plant as may be reasonably necessary in inspecting and supervising the work.

b. To furnish, on the request of the Contracting Officer or any inspector, suitable transportation from all points on shore designated by the Contracting Officer to and from the various pieces of plant and to and from the disposal areas.

Section 00 73 00 Page 19

Should the Contractor refuse, neglect, or delay compliance with these requirements, the specific facilities may be furnished and maintained by the Contracting officer, and the cost thereof will be deducted from any amounts due or to become due the Contractor. (CENAP)

SC-10 ACCOMMODATIONS AND MEALS FOR GOVERNMENT INSPECTORS (DEC 1996)

a. The Contractor shall furnish regularly to Government inspectors on board the dredge a suitable separate area for an office. A separate trailer on the dredge may be supplied in lieu of a room. The trailer must be securely lashed to the dredge and enclosed by railings. The room or trailer shall be fully equipped and maintained to the satisfaction of the Contracting Officer; it shall be properly heated, ventilated, lighted and insulated from noise, and shall have a desk which can be locked, a chair for each inspector, and washing conveniences. The entire cost to the Contractor for furnishing, equipping and maintaining the foregoing accommodations shall be included in the cost of all bid items. If the Contractor fails to meet these requirements, the facilities referred to above will be secured by the Contracting Officer, and the cost thereof will be deducted from payments to the Contractor.

b. If the Contractor maintains on this work an establishment for the subsistence of his own employees, he shall, when requested, furnish to inspectors employed on the work, and to all Government agents who may visit the work on official business, meals of a quality satisfactory to the Contracting Officer. The meals furnished will be paid for by the Government agents at a rate of $5.00 per person for each meal. (CENAP)

SC-11 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995)

a. This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals, and FAR Part 49.

b. Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by the Contractor or sub-contractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial or series for which the Government can determine both ownership and…