W9128F24R0045_2_Fort Peck - Outdoor Station Service Transformer specs 2 of 4.pdf

SPECIFICATIONS

(For Construction Contract)

Solicitation Number W9128F24R0045

Ft Peck Outdoor Station Service Transformer Replacement

December 2023

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

Outdoor Station Svc XFMR B Install, Ft Peck Dam, MT FP67

PROJECT TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 11 10.00 26 STATEMENT OF WORK

01 12 00 CONSTRUCTION GENERAL

01 22 00.00 26 MEASUREMENT AND PAYMENT

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 78 39.00 24 AS-BUILT DRAWINGS

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00.00 26 DEMOLITION

02 42 00.00 26 REMOVAL OF EXISTING SWITCHYARD INSULATING OIL SYSTEM PIPING

02 82 00 ASBESTOS-CONTAINING MATERIALS

02 83 00 LEAD IN CONSTRUCTION

DI VI SI ON 03 - CONCRETE

03 30 53.09 26 CAST-IN-PLACE CONCRETE AND FOUNDATIONS

03 60 00.01 26 CONCRETE DEMOLITION AND REPAIR OF CONCRETE SURFACES,

DI VI SI ON 05 - METALS

05 05 23.16 26 STRUCTURAL STEEL WELDING AND FABRICATION

05 50 04.00 26 METALS: MISCELLANEOUS, STANDARD ARTICLES, SHOP FABRICATED

ITEMS

DI VI SI ON 13 - SPECI AL CONSTRUCTI ON

13 48 00.00 26 SEISMIC RESTRAINT FOR MECHANICAL AND ELECTRICAL EQUIPMENT

DI VI SI ON 26 - ELECTRI CAL

26 00 00.00 26 ELECTRICAL EQUIPMENT AND WORK

26 05 13.00 26 MEDIUM-VOLTAGE CABLE

26 05 19.00 26 INSULATED WIRE AND CABLE

26 05 26.00 26 GROUNDING AND GROUND TESTING

26 08 01.00 26 SYSTEMS TESTING AND COMMISSIONING

26 13 13.00 26 METAL-CLAD SWITCHGEAR

DI VI SI ON 31 - EARTHWORK

31 00 00.09 26 EARTHWORK

DI VI SI ON 32 - EXTERI OR I MPROVEMENTS

32 11 23.01 26 CRUSHED ROCK SURFACING AND QUENCH ROCK

DI VI SI ON 33 - UTI LI TI ES

33 00 00.01 26 SWITCHYARD CIVIL STRUCTURES

PROJECT TABLE OF CONTENTS Page 1

33 40 00.00 26 STORM DRAINAGE UTILITIES

DI VI SI ON 44 - POLLUTI ON AND WASTE CONTROL EQUI PMENT

44 42 52.01 26 OIL-STORM WATER PROCESSING

DI VI SI ON 48 - ELECTRI CAL POWER GENERATI ON

48 20 00.04 26 TRANSFORMER MOVEMENT AND TESTING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 10.00 26

STATEMENT OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section Table of Contents --

SECTION 01 11 10.00 26 Page 1

SECTION 01 11 10.00 26

STATEMENT OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

The scope of work consists of the Contractor furnishing all supervision, engineering, labor, materials, and equipment to perform the following work in strict accordance with the detailed requirements of this contract:

a. Remove and dispose of existing station service transformer A located in Switchyard 1.

b. Remove and dispose of existing station service transformer B and oil.

c. Remove existing containment curbing and fence

d. Remove and dispose of existing 15kV and 5kV cables to station service transformer B.

e. Remove and dispose of existing conduit and power, control, and annunciation cables from transformer B to Powerhouse 2.

f. Remove and dispose of existing 5kV switchgear in Powerhouse 2

g. Remove and dispose of existing 5kV feeder cables from station service switchgear in Powerhouse 2 to the loads and to the 5kV switchgear in Powerhouse 1.

h. Remove and dispose of all power, control, and annunciation cables for the 5kV switchgear

i. Remove and dispose of existing 5kV switchgear meters located on the unit control board in Powerhouse 2 and instrument board in the control room.

j. Furnish and install oil containment and transformer pad for the Government furnished station service transformer B in switchyard 2.

k. Install Government furnished station service transformer B

l. Furnish and install new 15kV and 5kV cables, conduit and duct bank from the powerhouse to the new transformer B location in switchyard 2.

m. Furnish and install new power, control, and annunciation cables to the new transformer

n. Furnish and install new 5kV switchgear in powerhouse 2.

o. Furnish and install new 5kV feeder cables from the station service switchgear to the loads and to the 5kV switchgear in powerhouse 1

p. Furnish and install new power, control, and annunciation cables for

SECTION 01 11 10.00 26 Page 2 the 5kV switchgear.

q. Install Government furnished Shark meters.

r. Test and commission equipment installed.

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section --

SECTION 01 11 10.00 26 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.3.1 Interruption of Electric Power

1.4 CARE OF WATER

1.5 Project Survey and Layout

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

1.7.2 Joint Use of Transportation Facilities

1.8 PUBLIC ROADS

1.8.1 Lane Closure

1.8.2 Traffic Control Devices

1.8.3 Temporary Traffic Control (TTC)

1.8.4 Operations

1.8.4.1 Flaggers

1.8.5 Road Closure

1.8.6 State and Local Public Roads

1.8.7 City Streets

1.8.8 Utility Lines

1.9 COOPERATION WITH OTHER CONTRACTORS

1.10 AREA USE SCHEDULE

1.11 COORDINATION AND OUTAGES

1.12 SUBMITTALS

1.13 PROJECT SIGN

1.14 WARRANTY OF CONSTRUCTION (MAR 1994)

1.15 TELEPHONE/INTERNET

1.16 USE OF GOVERNMENT EQUIPMENT

1.16.1 Powerhouse Bridge Crane Operation

1.16.2 Working Hours

1.16.3 Hours of Use and Overtime Payment

1.17 TOILET FACILITIES AND PORTABLE TOILETS

1.18 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for use in the prosecution of work under this contract, subject to the SECTION 00 72 00, GENERAL CONDITIONS (CONTRACT CLAUSES) clause entitled "Operations and Storage Areas."

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.3.1 Interruption of Electric Power

If it is necessary to cut off power in transmission lines that pass through construction areas, it shall be the Contractor's responsibility to make the necessary arrangements with the owner of the powerline, and the Contractor shall pay all costs therefore.

SECTION 01 12 00 Page 2

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make the needed investigations and determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

1.5 Project Survey and Layout

In addition to the requirements of FAR 52.236-17 Layout of Work, the Contractor shall provide a licensed land surveyor to check initial project control, and to provide and set hubs for project construction. The Contractor shall use (and reference in all as-built data) project stationing as described on the contract drawings. In addition, a licensed land surveyor shall provide final project embankment survey (i.e. to include major breakpoints, riverward toe, profile, top of levee at riverward/landward and landward toe) prior to placement of surfacing for government review and approval. If applicable a licensed land surveyor shall also provide, set and verify as built condition of major flood control structures/features; i.e. flood wall control. These surveys shall provide and verify both horizontal and vertical project control. This survey shall be used for final as-built embankment profile and cross section, and major flood control structure records, and recorded on the as-built condition in accordance with Section, As-Built Drawings.

The Contractor may utilize their own quality control personnel to provide interim surveys for quantity determination for payment in accordance with paragraph entitled Quantity Surveys (Apr 1984).

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation.

SECTION 01 12 00 Page 3

1.7.2 Joint Use of Transportation Facilities

The Contractor may use jointly with Contractors and others, existing access and haul roads constructed by the Government or by others. Unless otherwise specifically authorized in writing, the Contractor will not be granted exclusive use of any access or haul road whether it be an existing road or one constructed by the Contractor. However, the use by others of roads constructed by or assigned to the Contractor primarily for the Contractor's use will be limited by the Contracting Officer to the minimum considered consistent with efficient prosecution of the work under this and other contracts in force. Maintenance of jointly used facilities shall be shared in proportion to use. In the event of a disagreement between this Contractor and others as to the use of any road, the decision of the Contracting Officer shall be final. The Contractor shall not obstruct any existing road on the land controlled by the Government.

1.8 PUBLIC ROADS

1.8.1 Lane Closure

One lane of the road must remain open at all times. The Contractor shall determine an appropriate method for the specific Temporary Traffic Control (TTC) zone one-lane, two-ways traffic control method in accordance with MUTCD requirements. The Contractor shall furnish all necessary personnel and traffic control devices, perform routine day and night inspections of TTC elements, and maintain all furnished traffic control devices to provide safety for motorists, bicyclists, pedestrians, workers, enforcement/emergency officials, and equipment as required by MUTCD The Contractor is required to coordinate the road/lane closure with the MDT and USACE.

1.8.2 Traffic Control Devices

All traffic control devices (signs, arrow boards, barricades, lighting etc) by the Contractor, must conform with the U.S. Department of Transportation, Federal Highway Administration, Manual on Uniform Traffic Control Devices.

1.8.3 Temporary Traffic Control (TTC)

The Contractor shall be responsible for the safe control of traffic on all haul and access roads used primarily for the work under these specifications and at their crossings with roads used by others. The Contractor shall, at the Contractor's own expense, furnish all personnel, and traffic control devices necessary for the safe movement of all road users through or around Temporary Traffic Control zone. Traffic control plans, including a listing of equipment and its employment, shall be submitted for review and approval prior to construction.

1.8.4 Operations

When operations are being conducted near a U. S. or State Highway or when construction equipment is being used on or adjacent to such highway, the Contractor shall furnish all necessary traffic control devices and personnel to provide safe and effective movement of all road users through or around Temporary Traffic Control zone as required by MUTCD All required state and/or local permits shall be obtained at the Contractor's expense in advance and shall be provided to the COR. The highways and streets shall be kept open at all times.

SECTION 01 12 00 Page 4

1.8.4.1 Flaggers

The Contractor shall provide flaggers when:

a) Construction equipment and/or vehicles are blocking the roadway making it difficult for vehicles to pass or see or due to terrain.

b) One-way traffic is required thru a construction zone.

c) Trucks are pulling onto and/or off of a roadway or operating at a reduced speed causing a hazardous situation for drivers.

d) Anytime the Contractor feels that road users are at risk due to Construction activity.

Flagger shall have all qualifications, high-visibility safety apparel, and appropriate hand-signaling devices in accordance with MUTCD requirements.

The flagger shall be properly trained as required by the state. The Contractor shall furnish all necessary traffic control devices to establish appropriate TTC zone when the Flagger Control is utilized.

1.8.5 Road Closure

At each location designated by the Contracting Officer and where safe operation requires the closing of roads, streets or other travel arteries leading to the work under this contract, the Contractor shall furnish all appropriate traffic control devices to provide safety for motorists, bicyclists, pedestrians, workers, enforcement/emergency officials, and equipment during construction as required by MUTCD. Arrangements for closure of roads, streets or other travel arteries shall be made by the Contractor with local State, County or City officials. The Contractor shall notify the appropriate official in writing at least ten (10) days in advance of the date desired to close a road to traffic and shall furnish a copy of the agreement and approved Temporary Traffic Control plans to the Contracting Officer prior to closure.

1.8.6 State and Local Public Roads

(a) Load Limits:

The Montana Department of Transportation and local County Road Commissions restrict the load weights of haul vehicles using highways and county roads during the spring thaw period. The load restrictions are usually imposed from 1 April through June depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.8.7 City Streets

Where the Contractor intends to cross or to use city streets for haul roads the Contractor shall enter into an agreement with the City and shall comply with any restrictions the City may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these highways. A copy of all such agreements shall be furnished the Contracting Officer before the Contractor begins hauling in city

SECTION 01 12 00 Page 5 streets.

1.8.8 Utility Lines

It shall be the responsibility and obligation of the Contractor to make all arrangements with the affected companies for the necessary moving and alterations of utility lines and the continuation of service during construction as covered by the plans and specifications.

1.9 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of others working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits.

The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.10 AREA USE SCHEDULE

(a) General:

The purpose of this paragraph is to supplement and expand the information and requirements as shown on the Area Use Plan drawing. Other Contractors have been assigned adjacent areas and the Contractor shall be responsible for investigating the site to determine the existing areas and conditions. Close cooperation by all Contractors will be required in all joint-use areas and of the common boundaries of areas to facilitate the orderly and timely construction of all contracts.

1.11 COORDINATION AND OUTAGES

The Contractor's employees shall not open, close or tamper with switches, valves or control devices for existing installed equipment. Only Government operating personnel will be authorized to open or close existing switches, valves and control devices to enable the Contractor to make connections or modifications to existing equipment. Work shall be coordinated and scheduled to reduce the "Outage" time of operating equipment or systems to a minimum. Work in the proximity of exposed energized equipment such as in the switchyard or work involving connections to existing energized or operating equipment or systems shall perform only under the Safe Clearance Procedures. The Contractor will be instructed by the Contracting Officer in the proper procedure for requesting clearances. Only qualified supervisory personnel will be permitted to request clearances. Request for "Outage" shall be made by the Contractor to the Contracting Officer in each instance and in sufficient time to permit adjusting power plant operations, and to coordinate outages with the dispatching agency. Scheduling of "Outage" will be subject to the approval of the Contracting Officer.

1.12 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SECTION 01 12 00 Page 6

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-AO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

(Agreements for hauling on roads)

Temporary Traffic Control (TTC); G, AO

SD-02 Shop Drawings

Care of Water; G-AO

SD-11 Closeout Submittals

Warranty of Construction

(List of warranties with copy of each)

1.13 PROJECT SIGN

The Contractor shall provide a new project sign constructed in accordance with Standard Sign Detail bound herein. The sign shall be erected at the project site by the Contractor at the location determined by the Contracting Officer. The project sign shall remain the property of the Contractor and upon completion of the contract, work shall be removed from the premises by the Contractor. No separate payment will be made for the sign.

1.14 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

SECTION 01 12 00 Page 7

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.15 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.16 USE OF GOVERNMENT EQUIPMENT

1.16.1 Powerhouse Bridge Crane Operation

Government personnel only will operate the powerhouse bridge crane. The Contractor will be responsible for furnishing and performing all rigging for all lifts. The Government must inspect and approve all rigging prior to performing the lift. The Contractor will be responsible for all off-loading, movement, and loading of required construction equipment. .

SECTION 01 12 00 Page 8

1.16.2 Working Hours

The Contractor shall properly prepare and plan all lifts such that Government operators are required for a minimum number of occasions. Use of the crane will only be during normal Government working hours. A crane operator will not be furnished on a standby basis. The Contractor shall coordinate with the Contracting Officer, in writing 24 hours in advance, the need for a crane operator. The Government will operate the crane during the normal daytime working hours of 7:00 am to 4:30 pm Monday thru Thursday. {If operation after hours is required, the Contractor shall make arrangements for payment to the Government (see paragraph below).}

1.16.3 Hours of Use and Overtime Payment

The Contractor is required to pay the Government, at the existing overtime wage rates for the Government personnel involved, for all work performed by Government personnel during other than normal working periods at the request of the Contractor. Overtime rates may be obtained from the Project Engineer's office.

1.17 TOILET FACILITIES AND PORTABLE TOILETS

The Contractor will be allowed to use the powerhouse restroom facilities designated for their use. The Contractor shall negotiate with the existing janitorial contractor a monthly fee for additional cleaning and supplies to maintain these facilities during their use. This fee in the past as ranged from $100-200 per month to be paid directly to the janitorial Contractor.

The Contractor and his staff are expected to be respectful of the restroom privileges. Should the restroom privileges be abused, the Contractor will be required to bring portable toilets for his staff.

The Contractor may provide and maintain portable toilets for use by the Contractor's staff. Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.18 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. The Contractor shall plan all work accordingly. These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October

SECTION 01 12 00 Page 9

Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 10

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00.00 26

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 GENERAL INFORMATION

1.2 MEASUREMENT

1.3 PAYMENT

1.4 RETAINAGE OF PAYMENT

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 22 00.00 26 Page 1

SECTION 01 22 00.00 26

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 GENERAL INFORMATION

In each instance, the contract price for a contract line item number (CLIN) will constitute full compensation as herein specified, as shown, or as otherwise approved. The contract price and payment will also constitute full compensation for all work incidental to completion of the CLIN, unless such work is otherwise specifically mentioned for separate payment under another CLIN. In the event any work is required by the specification sections or by the drawings and not specifically mentioned in the measurement and payment paragraphs separate or direct payment will not be made. All costs are therefore incidental to, and included in, the contract prices and payment for all CLINs listed in the price schedule.

1.2 MEASUREMENT

CLINs measured as a per job will be measured for payment as a complete job in the locations indicated. This measurement includes all incidental work and materials such as fasteners, electrical materials, and O&M manuals that are necessary to make a complete job. Unless the CLIN paragraph makes a specific exception of any item, incidental items will not be measured under any other CLIN, even though there is another listing for the work or material.

1.3 PAYMENT

Payment for all work specified, shown, or incidental to complete the work will be made as follows:

CLIN 0001 Mobilization and Demobilization

Payment will be made on a per job basis under CLIN 0001. Payment shall be made for all costs incurred prior to arriving onsite (mobilization) or immediately after departing the work site (demobilization). These costs include, but are not limited to, all preparatory work at the contractors shop, labor costs associated with travel to and from the work site, and transportation costs.

CLIN 0002 Remove and Dispose of Existing Station Service Transformer A and Associated Components

Payment will be made on a per job basis under CLIN 0002. Payment shall be made for all materials, labor, and equipment needed to remove and dispose of the existing transformer,and associated components.

CLIN 0003 Remove and Dispose of Existing Station Service Transformer B and Associated Components,Including Oil

Payment will be made on a per job basis under CLIN 0003. Payment shall be made for all materials, labor, and equipment needed to remove and dispose of the existing transformer, associated

SECTION 01 22 00.00 26 Page 2 components, and oil.

CLIN 0004 Remove and Dispose of Existing 15kV and 5kV Cables and Associated Components, Including Power, Control, and Annunciation Conduit and Cable.

Payment will be made on a per job basis under CLIN 0004. Payment shall be made for all materials, labor, and equipment needed to remove and dispose of the existing 15kV and 5kV cables, and the power, control and annunciation cables from the transformer to the powerhouse equipment, including conduit and supports and all other associated components.

CLIN 0005 Remove and Dispose of Existing 5kV Switchgear

Payment will be made on a per job basis under CLIN 0005.

Payment shall constitute full compensation for all materials, labor, and equipment necessary to remove and dispose of existing 5kV switchgear and associated components, including the meters located on the unit control board in powerhouse 2 and instrument board in the control room.

CLIN 0006 Remove and dispose of Existing Switchgear Feeder cables and Power, Control and Anunciation Cable

Payment will be made on a per job basis under CLIN 0006.

Payment shall be made for all materials, labor, and equipment needed to remove and dispose of the existing 5kV feeder cables from the switchgear to the fist point of termination, and for for removing the power, control and annunciation cables from the switchgrear to the powerhouse equipment.

CLIN 0007 Furnish and Install Oil Containment and Transformer Pad

Payment will be made on a per job basis under CLIN 0007. Payment shall be made for all materials, labor, and equipment needed to install the oil containment and transformer pad. This includes concrete containment, foundations within containment, quenching stone, piping, valves, along with incidental components.

CLIN 0008 Install Government Furnished Station Service Transformer B

Payment will be made on a per job basis under CLIN 0008.

Payment shall be made for all materials, labor, and equipment needed to move the Government furnished transformer from the long term storage in switchyard 2 to the permanent location in the switchyard, placing it on the pad and perform all connections, including transformer weld anchoring and paint repair.

CLIN 0009 Furnish and Install 15kV and 5kV Cables for Station Service transformer B and Power, Control and Annunciation Cables and Conduit.

Payment will be made on a per job basis under CLIN 0009.

Payment shall be made for all materials, labor, and equipment needed to furnish and install the new 15kV and 5kV cables, and the the power, control and annunciation cables from the transformer to the equipment in the powerhouse, including duct

SECTION 01 22 00.00 26 Page 3 system, conduit and all other associated components.

CLIN 00010 Furnish and Install 5kV Switchgear and Associated Equipment

Payment will be made on a per job basis under CLIN 00010. Payment shall be made for all materials, labor, and equipment needed to furnish and install the new 5kV switchgear and associated components, including the installation of the the Government furnished Shark meters, as shown on the contract drawings. This includes the modifications to main control boards.

CLIN 0011 Furnish and Install New Switchgear Feeder cables and New Power, Control and Annunciation Cables for 5kV Switchgear

Payment will be made on a per job basis under CLIN 0011. Payment shall be made for all materials, labor, and equipment needed to furnish and install the new switchgear 5kV feeder cables, and the the power, control and annunciation cables from the new switchgear to the equipment in the powerhouse.

CLIN 0012 Commissioning Services and Training Payment will be made on a per job basis under CLIN 0012. Payment shall be made for all materials, labor, and equipment needed to perform commissioning of installed equipment and training of project personnel.

1.4 RETAINAGE OF PAYMENT

Retainage in the amount of 10% of original contract amount will be withheld until the final submittals for Operation and Maintenance Data, Final Approved Version of Contractor Prepared Drawings and AS-BUILT CONTRACT DRAWINGS AND FIO DRAWINGS have been approved by the Government.

PART 2 PRODUCTS

(NOT USED)

PART 3 EXECUTION

(NOT USED)

SECTION 01 22 00.00 26 Page 4

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.3 CONTRACTOR PERFORMANCE EVALUATIONS

1.4 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.5 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

1.6 CONTRACT DRAWINGS AND SPECIFICATIONS

1.6.1 SETS FURNISHED

1.6.2 DISTRIBUTION

1.6.3 NOTIFICATION OF DISCREPANCIES

1.6.4 OMISSIONS

1.7 SUBMITTALS

1.8 PAYMENT

1.8.1 PROMPT PAYMENT ACT

1.8.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.9 AVAILABILITY AND USE OF UTILITY SERVICES

1.10 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.11 INSURANCE REQUIRED

1.12 CONTRACTOR QUALITY CONTROL (CQC)

1.13 NONDOMESTIC CONSTRUCTION MATERIALS

1.14 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.15 AS-BUILT DRAWINGS

1.16 ASBESTOS AND LEAD

1.17 PARTNERING

1.17.1 Team-Led (Informal) Partnering

1.18 PROFIT

1.19 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.20 DRAWING SCALES

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

Attachments:

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.publications.usace.army.mil/USACE-Publications/Engineer-Pamphlets/ on pages 10 and 11 of 13.

1.2 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.3 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.

For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS).

After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide

SECTION 01 30 00.24 Page 2 security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site: https://www.cpars.gov .

1.4 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. Gener al secur i t y r equi r ement s and gui dance:

The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts.

The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations.

Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures.

The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures-this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

2. Ant i t er r or i sm ( AT) Level I t r ai ni ng:

All contract personnel requiring routine access to Army installations, facilities, and controlled access areas, or requiring network access shall complete initial and annual refresher AT Level I awareness training.

Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

3. Physi cal secur i t y and access cont r ol r equi r ement s: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency

SECTION 01 30 00.24 Page 3

Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

3.1 Submit a complete, updated and signed, list of all Contractor and subcontractor personnel, including their titles and intended working hours, who will be working on site prior to start of work. This listing shall be revised and resubmitted when personnel changes occur. (SUBMITTAL

FIO)

3.2 Personnel Risk Assessment

A minimum of seven days prior to engaging in work submit, to the COR or Project POC, a Personnel Risk Assessment (PRA) for each employee requiring authorized unescorted access to the Jobsite. The Contractor employee will only be allowed authorized unescorted physical access after the PRA is shown to and approved by the Government.

3.3 Authorized Unescorted Access Requirements

Perform a PRA on all Contractor personnel that require authorized unescorted access to the Jobsite. Costs associated with the execution of the PRA shall be at the expense of the Contractor. The content of the PRA is defined by the requirements as follows: (SUBMITTAL PRA)

a. Criminal Check - Obtain a criminal background check, completed within the last seven years (assuming continuous employment, otherwise a new one must be accomplished), on all Contractor personnel that require authorized unescorted access to the Jobsite. A minimum of a 7-year criminal background check with the state patrol office shall be performed from all states of residence and employment, for the past seven years. The Project Security Officer through the Contracting Officer will approve, disapprove, or revoke authorized unescorted access to the Jobsite as a result of the seven-year background check.

b. Identity Verification - Contractor employees shall provide positive verification of individual identity prior to authorized unescorted access to the Jobsite. Acceptable forms of identity verification are documents issued by a federal Government agency that include: the individual's photograph, name, and date of birth, such as a passport or military identification (ID) card. Additionally, a state issued driver's license or ID card is acceptable for identity verification.

c. The Criminal Check and Identity Verification shall be updated at least every seven years for each employee requiring authorized unescorted access to the Jobsite.

d. Escort Requirements - Contractor personnel not cleared for authorized access to the Jobsite may be escorted by Government or Contractor personnel that have authorized unescorted access to the Jobsite. All costs related to the escorting of non-cleared personnel shall be at the expense of the Contractor. Additional burden shall not be placed

SECTION 01 30 00.24 Page 4 upon the Government to provide these escorts. Prior to access, coordination with the Project Security Officer is required, including but not limited to:

(1) Verification of identity with photo identification

(2) Name of escorting individual and verification of unescorted status

(3) Time of entry into the Jobsite

(4) Time exiting the Jobsite.

4. Not Used

5. Not Used

6. Suspi c i ous Act i v i t y Repor t i ng t r ai ni ng ( e. g. i WATCH, Cor psWat ch, or See Somet hi ng, Say Somet hi ng) :

All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

This training shall be completed within 10 days prior to mobilization and within 30 calendar days of new employees commencing performance with the results reported to the COR. (submittal: iWATCH and/or CorpsWatch Training Sign In Sheets).

http://www.myarmyonesource.com/cmsresources/Army%20OneSource/Media/Videos/ Family%20Programs%20and%20Services/iWatch_Program/iWATCH%2060_4streaming.wmv

7. Not Used

8. Not Used

9. Not Used

10. Not Used

11. Not Used

12. Not Used

13. Escor t i ng i n c l assi f i ed and/ or sensi t i ve ar eas: In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas. There is no classified information or operations associated with this contract.

14. Pr e- scr een candi dat es usi ng E- Ver i f y Pr ogr am: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to

SECTION 01 30 00.24 Page 5 the Contracting Officer to become part of the official contract file.

15. Not Used

16. Not Used

1.5 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

No work will be required at the construction site during the period 30 November through 01 April inclusive. The days in this period have been included in computing the calendar days for completion of the work. The Contractor may perform work at the site during all or any part of this period upon giving prior written notice to the Contracting Officer.

Working during this non-work period requires approval by the Contracting Officer. No time extensions will be granted for delays during this period.

1.6 CONTRACT DRAWINGS AND SPECIFICATIONS

1.6.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.6.2 DISTRIBUTION

The Government will provide the Contractor with a CD-ROM or DVD-ROM or sent electronically containing Adobe Acrobat.pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS). Prepare final record or as-built drawings as defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.6.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in…