A.07.24 Amendment 0001- Bridge Crane Replacement, NFPH.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment 0001 provides Government responses to requests for information and additional project photos; extends the period of performance to 550 calendar days; and extends the proposal due to date to May 12, 2020.

1. CONTRACT ID CODE PAGE OF PAGES

1 59

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 22-Apr-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W9127S20R0001

X 9B. DATED (SEE ITEM 11)

17-Mar-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

22-Apr-2020

CODE

CONTRACTING DIVISION

USACE, LITTLE ROCK (W9127S)

700 W. CAPITOL AVE, RM 7315

LITTLE ROCK AR 72201-3225

W9127S 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9127S20R0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 28-Apr-2020 01:00 PM to 12-May-2020 01:00 PM.

The contractor period of performance end date has increased by 130 days from 420 days to 550 days.

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

FOB: Destination

96721H

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0002 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0003 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0004 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0005 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

550 dys. ADC 1 NORFORK POWERHOUSE

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0006 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0007 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0008 has been changed from:

420 dys. ADC 1 NORFORK POWERHOUSE

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0009 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0010 has been changed from:

CAGE

420 dys. ADC 1 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

550 dys. ADC 1 NORFORK POWERHOUSE

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0011 has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0012 has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0013 has been changed from:

420 dys. ADC 50 NORFORK POWERHOUSE

SALESVILLE AR 72653

CAGE

550 dys. ADC 50 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0014 has been changed from:

CAGE

420 dys. ADC 50 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 50 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0015 has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

550 dys. ADC 10 NORFORK POWERHOUSE

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0016 has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0017 has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for SUBCLIN 0018AA has been changed from:

420 dys. ADC 10 NORFORK POWERHOUSE

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for SUBCLIN 0018AB has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

The following Delivery Schedule item for SUBCLIN 0018AC has been changed from:

CAGE

420 dys. ADC 10 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

550 dys. ADC 10 NORFORK POWERHOUSE

SALESVILLE AR 72653

The following Delivery Schedule item for CLIN 0019 has been changed from:

CAGE

420 dys. ADC 4 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

CAGE

550 dys. ADC 4 NORFORK POWERHOUSE

1487 HIGHWAY 177

SALESVILLE AR 72653

SECTION 00 30 00 - AVAILABLE INFORMATION

The following have been added by full text:

PICTURES

RFI RESPONSE

UNCLASSIFIED\\FOR OFFICIAL USE ONLY

Bid Inquiry Contractor Report All Inquiries

Project: Norfork Bridge Crane Replacement Review: RFI Review (00001) (sorted by CommentID ) Displaying 1 inquiry.

Id Discipline Sheet Detail Spec 8485768 Contracting Page 4 SF1442

Comment Classification: UNCLASSIFIED (U)

The 420 day POP for this contract is extremely tight especially in view of current events. Would the Government consider amending the solicitation to 550 days to allow sufficient time to design, have HDC review and approve the design, procure, fabricate, assemble, wire and test, ship and install / remove the cranes?

Thank you.

On: Apr 01 2020.

Government Response. . Period of performance will be revised to allow for 550 calendar days On: Apr

20 2020 Current Request Status: Request Closed

Information for this report is procurement sensitive.

Report Complete

UNCLASSIFIED\\FOR OFFICIAL USE ONLY

Patent 11/892,984 ProjNet property of ERDC since 2004.

SECTION 00 72 00 - GENERAL CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 550 calendar days after receipt of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,354.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)